240161_FTA_Terms_and_Conditions.pdf

FEDERAL TRANSIT ADMINISTRATION

TERMS, CONDITIONS, AND CERTIFICATIONS

***RFQ 240161***

FEDERAL TRANSIT ADMINISTRATION

TERMS, CONDITIONS AND CERTIFICATIONS

Requirements/Conditions For All FTA Assisted Contracts:

Federal Disclaimer to Third Parties Program Fraud and False or Fraudulent Statements and Related Acts

Access to Third Party Contract Records Prohibitions Against Exclusionary or Discriminatory Specifications Changes to Federal Requirements Termination Provisons (Contracts exceeding $10,000) Civil Rights Requirements Requirements for Disadvantaged Business Enterprises (DBEs) Incorporation of FTA Terms

Requirements for Contracts Exceeding $25,000 Threshold:

Debarment and Suspension Requirements

Requirements for Contracts Exceeding Small Purchase Threshold ($100,000):

Report, record retention, and access provisions Buy America requirements Provisions For Resolution Of Disputes, Breaches, Defaults Or Other Litigation Lobbying Requirements Bonding Requirements for Construction Activities; (may be imposed for nonconstruction activities) Clean Water Requirements Clean Air Requirements

Non Construction Activities

Non Construction Employee Protection Requirements (Except for supplies/raw materials) (for all turnkey, rolling stock and operiational contracts (excluding transportation services) in excess of $100,000

Planning, Research, Development and Demonstration Projects Patent Rights Requirements Rights in data and copyrights requirements

Miscellaneous Special Requirements Environmental Protection Energy Conservation Requirements Metric System Requirements

National ITS Architecture Requirements for Recycled Products (for items designated by EPA)

Seat Belt Use Text Messaging While Driving

Certifications Buy America Lobbying

Protest Procedures For Federal Transit Administration Funded Projects

City Of Tucson Protest Procedures For Federal Transit Administration (FTA) Funded Projects

Requirements/Conditions For All FTA Assisted Contracts

This Contract is Subject to Federal Financial Assistance/Application of Provisions and Clauses

This contract is funded in part by grants from the Federal Transit Administration (FTA) of the United States

Department of Transportation. The award of any contract is subject to the requirements of financial assistance contracts between the City of Tucson and the U.S. Department of Transportation.

The Contractor is required to comply with all terms and conditions prescribed for third-party contracts by the

U.S. Department of Transportation, Federal Transit Administration (FTA). If FTA requires any change to this

Contract to comply with its requirements, both parties agree to amend the Contract as required by FTA. If such changes cause an increase or decrease in the work to be performed by the Contractor or the time for such performance, then the compensation to be paid the Contractor and time of performance shall be equitably adjusted.

The required contract clauses, which are identified below as applicable to this solicitation, will be incorporated by reference in any contract resulting from this solicitation issued by the City Of Tucson. These solicitation provisions and required contract clauses are in addition to other General Specifications, Special and Technical

Specifications, Bidding or Proposal Procedures, and Bid or Proposal Forms set forth in other sections of this solicitation which may also be incorporated by reference in any resulting contract. If there is any discrepancy in the language between this document and the General Specifications, Special and Technical Specifications, Bidding or Proposal Procedures and Bid or Proposal Forms set forth in other sections of this solicitation, the stricter of two shall govern.

Some provisions and clauses require the bidder/proposer to execute and submit certain required certifications with the bid or proposal, which are included herein. Failure to execute and submit required certifications with the bid or proposal documents may render a bid or proposal non-responsive.

Federal Disclaimer to Third Parties

1. The Purchaser and Contractor acknowledge and agree that, notwithstanding any concurrence by the

Federal Government in or approval of the solicitation or award of the underlying contract, absent the express written consent by the Federal Government, the Federal Government is not a party to this contract and shall not be subject to any obligations or liabilities to the Purchaser, Contractor, or any other party (whether or not a party to that contract) pertaining to any matter resulting from the underlying contract.

2. The Contractor agrees to include the above clause in each subcontract financed in whole or in part with

Federal assistance provided by FTA. It is further agreed that the clause shall not be modified, except to identify the subcontractor who will be subject to its provisions.

Program Fraud and False or Fraudulent Statements and Related Acts - 31 U.S.C. § 3801 et seq., 49 CFR Part 31, 18 U.S.C. § 1001, 49 U.S.C. 5307

1. The Contractor acknowledges that the provisions of the Program Fraud Civil Remedies Act of 1986, as amended, 31 U.S.C. § 3801 et seq. and U.S. DOT regulations, "Program Fraud Civil Remedies," 49

C.F.R. Part 31, apply to its actions pertaining to this Project. Upon execution of the underlying contract, the Contractor certifies or affirms the truthfulness and accuracy of any statement it has made, it makes, it may make, or causes to be made, pertaining to the underlying contract or the FTA assisted project for which this contract work is being performed. In addition to other penalties that may be applicable, the

Contractor further acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification, the Federal Government reserves the right to impose the penalties of the Program Fraud Civil Remedies Act of 1986 on the Contractor to the extent the Federal

Government deems appropriate.

2. The Contractor also acknowledges that if it makes, or causes to be made, a false, fictitious, or fraudulent claim, statement, submission, or certification to the Federal Government under a contract connected with a project that is financed in whole or in part with Federal assistance originally awarded by FTA under the authority of 49 U.S.C. § 5307, the Government reserves the right to impose the penalties of 18 U.S.C.

§ 1001 and 49 U.S.C. § 5307(n)(1) on the Contractor, to the extent the Federal Government deems appropriate.

3. The Contractor agrees to include the above two clauses in each subcontract financed in whole or in part with Federal assistance provided by FTA. It is further agreed that the clauses shall not be modified, except to identify the subcontractor who will be subject to the provisions.

Access to Third Party Contract Records (Form FTA Master Agreement MA (18) dated October

1, 2011)

All contractors and third party subcontractors at each tier to provide to the U.S. Secretary of Transportation and the Comptroller General of the United States or their duly authorized representatives, access to all third party contract records as required by 49 U.S.C. § 5325(g). All contractors further agree to require its third party contractors and third party subcontractors, at each tier, to provide sufficient access to third party procurement records as needed for compliance with Federal laws and regulations or to assure proper Project management as determined by FTA.

Prohibitions Against Exclusionary or Discriminatory Specifications – 49 U.S.C. § 5323(h)(2)

1. Apart from inconsistent requirements imposed by Federal laws or regulations, the City of Tucson agrees that it will comply with 49 U.S.C. § 5325 (h) by not expending or otherwise using any Federal assistance

FTA has made available for the Project to support a procurement using exclusionary or discriminatory specifications.

Changes to Federal Requirements - 49 CFR Part 18

1. Contractor shall at all times comply with all applicable FTA regulations, policies, procedures and directives, including without limitation those listed directly or by reference in the Agreement (Form FTA

MA (18) dated October, 2011 between the City of Tucson and FTA), as they may be amended or promulgated from time to time during the term of this contract. Contractor's failure to so comply shall constitute a material breach of this contract. All standards or limits set forth in this Contract to be observed in the performance of the work are minimum requirements, unless modified by the FTA.

Termination Provisions - 49 U.S.C.Part 18, FTA Circular 4220.1F

1. Termination for Convenience (General Provision): The City Of Tucson may terminate this contract, in whole or in part, at any time by written notice to the Contractor when it is in the Government's best interest. The Contractor shall be paid its costs, including contract close-out costs, and profit on work performed up to the time of termination. The Contractor shall promptly submit its termination claim to the

City Of Tucson to be paid the Contractor. If the Contractor has any property in its possession belonging to the City Of Tucson, the Contractor will account for the same, and dispose of it in the manner the City

Of Tucson directs.

2. Termination for Default [Breach or Cause] (General Provision): If the Contractor does not deliver supplies in accordance with the contract delivery schedule, or, if the contract is for services, the

Contractor fails to perform in the manner called for in the contract, or if the Contractor fails to comply with any other provisions of the contract, the City Of Tucson may terminate this contract for default.

Termination shall be effected by serving a notice of termination on the contractor setting forth the manner in which the Contractor is in default. The contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner of performance set forth in the contract.

If it is later determined by the City Of Tucson that the Contractor had an excusable reason for not performing, such as a strike, fire, or flood, events which are not the fault of or are beyond the control of the Contractor, the City Of Tucson, after setting up a new delivery of performance schedule, may allow the Contractor to continue work, or treat the termination as a termination for convenience.

3. Opportunity to Cure (General Provision): The City Of Tucson in its sole discretion may, in the case of a termination for breach or default, allow the Contractor to cure the defect. In such case, the notice of termination will state the time period in which cure is permitted and other appropriate conditions

If Contractor fails to remedy to the City Of Tucson’s satisfaction the breach or default or any of the terms, covenants, or conditions of this Contract after receipt of written notice from the City of Tucson setting forth the nature of said breach or default, the City of Tucson shall have the right to terminate the Contract without any further obligation to Contractor. Any such termination for default shall not in any way operate to preclude the City of Tucson from also pursuing all available remedies against Contractor and its sureties for said breach or default.

4. Waiver of Remedies for any Breach: In the event that the City of Tucson elects to waive its remedies for any breach by Contractor of any covenant, term or condition of this Contract, such waiver by the City of Tucson shall not limit the City of Tucson's remedies for any succeeding breach of that or of any other term, covenant, or condition of this Contract.

5. Termination for Convenience (Professional or Transit Service Contracts): The City of Tucson, by written notice, may terminate this contract, in whole or in part, when it is in the Government's interest. If this contract is terminated, the City of Tucson shall be liable only for payment under the payment provisions of this contract for services rendered before the effective date of termination.

6. Termination for Default (Supplies and Service): If the Contractor fails to deliver supplies or to perform the services within the time specified in this contract or any extension or if the Contractor fails to comply with any other provisions of this contract, the City of Tucson may terminate this contract for default. The

City of Tucson shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. The Contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner or performance set forth in this contract.

If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the City of Tucson.

7. Termination for Default (Transportation Services): If the Contractor fails to pick up the commodities or to perform the services, including delivery services, within the time specified in this contract or any extension or if the Contractor fails to comply with any other provisions of this contract, the City of Tucson may terminate this contract for default. The City of Tucson shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of default. The Contractor will only be paid the contract price for services performed in accordance with the manner of performance set forth in this contract.

If this contract is terminated while the Contractor has possession of Recipient goods, the Contractor shall, upon direction of the City of Tucson, protect and preserve the goods until surrendered to the City of Tucson or its agent. The Contractor and the City of Tucson shall agree on payment for the preservation and protection of goods. Failure to agree on an amount will be resolved under the Dispute clause.

If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued

8. Termination for Default (Construction): If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract or any extension or fails to complete the work within this time, or if the Contractor fails to comply with any other provisions of this contract, the City of Tucson may terminate this contract for default. The City of Tucson shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. In this event, the City of Tucson may take over the work and compete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the

City of Tucson resulting from the Contractor's refusal or failure to complete the work within specified time, whether or not the Contractor's right to proceed with the work is terminated. This liability includes any increased costs incurred by the City of Tucson in completing the work.

The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if-

a. the delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of the City of Tucson, acts of another Contractor in the performance of a contract with the

City of Tucson, epidemics, quarantine restrictions, strikes, freight embargoes; and

b. the contractor, within ten [10] days from the beginning of any delay, notifies the City of Tucson in writing of the causes of delay. If in the judgment of the City of Tucson, the delay is excusable, the time for completing the work shall be extended. The judgment of the City of Tucson shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses.

If, after termination of the Contractor's right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the City of Tucson.

9. Termination for Convenience or Default (Architect and Engineering): The City of Tucson may terminate this contract in whole or in part, for the City of Tucson's convenience or because of the failure of the Contractor to fulfill the contract obligations. The City of Tucson shall terminate by delivering to the

Contractor a Notice of Termination specifying the nature, extent, and effective date of the termination.

Upon receipt of the notice, the Contractor shall (1) immediately discontinue all services affected (unless the notice directs otherwise), and (2) deliver to the Contracting Officer all data, drawings, specifications, reports, estimates, summaries, and other information and materials accumulated in performing this contract, whether completed or in process.

If the termination is for the convenience of the City of Tucson, the Contracting Officer shall make an equitable adjustment in the contract price but shall allow no anticipated profit on unperformed services.

If the termination is for failure of the Contractor to fulfill the contract obligations, the City of Tucson may complete the work by contact or otherwise and the Contractor shall be liable for any additional cost incurred by the City of Tucson.

If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued

10. Termination for Convenience or Default (Cost-Type Contracts): The City of Tucson may terminate this contract, or any portion of it, by serving a notice or termination on the Contractor. The notice shall state whether the termination is for convenience of the City of Tucson or for the default of the Contractor.

If the termination is for default, the notice shall state the manner in which the contractor has failed to perform the requirements of the contract. The Contractor shall account for any property in its possession paid for from funds received from the City of Tucson, or property supplied to the Contractor by the City of Tucson. If the termination is for default, the City of Tucson may fix the fee, if the contract provides for a fee, to be paid the contractor in proportion to the value, if any, of work performed up to the time of termination. The Contractor shall promptly submit its termination claim to the City of Tucson and the parties shall negotiate the termination settlement to be paid the Contractor.

If the termination is for the convenience of the City of Tucson, the Contractor shall be paid its contract close-out costs, and a fee, if the contract provided for payment of a fee, in proportion to the work performed up to the time of termination.

If, after serving a notice of termination for default, the City of Tucson determines that the Contractor has an excusable reason for not performing, such as strike, fire, flood, events which are not the fault of and are beyond the control of the contractor, the City of Tucson, after setting up a new work schedule, may allow the Contractor to continue work, or treat the termination as a termination for convenience.

Civil Rights Requirements - 29 U.S.C. § 623, 42 U.S.C. § 2000, 42 U.S.C. § 6102, 42 U.S.C. § 12112, 42 U.S.C. § 12132, 49 U.S.C. § 5332, 29 CFR Part 1630, 41 CFR Parts 60 et seq.

1. Nondiscrimination - In accordance with Title VI of the Civil Rights Act, as amended, 42

U.S.C. § 2000d, section 303 of the Age Discrimination Act of 1975, as amended, 42 U.S.C.

§ 6102, section 202 of the Americans with Disabilities Act of 1990, 42 U.S.C. § 12132, and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees that it will not discriminate against any employee or applicant for employment because of race, color, creed, national origin, sex, age, or disability. In addition, the Contractor agrees to comply with applicable Federal implementing regulations and other implementing requirements FTA may issue.

2. Equal Employment Opportunity - The following equal employment opportunity requirements apply to the underlying contract:

a. Race, Color, Creed, National Origin, Sex - In accordance with Title VII of the Civil

Rights Act, as amended, 42 U.S.C. § 2000e, and Federal transit laws at 49 U.S.C.

§ 5332, the Contractor agrees to comply with all applicable equal employment opportunity requirements of U.S. Department of Labor (U.S. DOL) regulations, "Office of Federal Contract Compliance Programs, Equal Employment Opportunity, Department of Labor," 41 C.F.R. Parts 60 et seq ., (which implement Executive Order No. 11246, "Equal Employment Opportunity," as amended by Executive Order No. 11375, "Amending Executive Order 11246 Relating to Equal Employment Opportunity," 42 U.S.C. § 2000e note), and with any applicable Federal statutes, executive orders, regulations, and Federal policies that may in the future affect construction activities undertaken in the course of the Project. The Contractor agrees to take affirmative action to ensure that applicants are employed, and that employees are treated during employment, without regard to their race, color, creed, national origin, sex, or age. Such action shall include, but not be limited to, the following: employment, upgrading, demotion or transfer, recruitment or recruitment advertising, layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue.

b. Age - In accordance with section 4 of the Age Discrimination in Employment Act of 1967, as amended, 29 U.S.C. § § 623 and Federal transit law at 49 U.S.C. § 5332, the Contractor agrees to refrain from discrimination against present and prospective employees for reason of age. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue.

c. Disabilities - In accordance with section 102 of the Americans with Disabilities Act, as amended, 42 U.S.C. § 12112, the Contractor agrees that it will comply with the requirements of U.S. Equal Employment Opportunity Commission, "Regulations to Implement the Equal Employment Provisions of the Americans with Disabilities Act," 29 C.F.R. Part 1630, pertaining to employment of persons with disabilities. In addition, the Contractor agrees to comply with any implementing requirements FTA may issue.

3. The Contractor also agrees to include these requirements in each subcontract financed in whole or in part with Federal assistance provided by FTA, modified only if necessary to identify the affected parties.

Requirements for Disadvantaged Business Enterprises (DBE’s) - 49 CFR Part 26

1. The Federal Fiscal Year goal has been set by the City Of Tucson in an attempt to match projected procurements with available qualified disadvantaged businesses. The City Of

Tucson goals for budgeted service contracts, bus parts, and other material and supplies for

Disadvantaged Business Enterprises have been established by the City Of Tucson as set forth by the Department of Transportation Regulations 49 C.F.R. Part 26, March 31, 1980, and amended by Section 106(c) of the Surface Transportation Assistance Act of 1987, and is considered pertinent to any contract resulting from this request for proposal.

If a specific DBE goal is assigned to this contract, it will be clearly stated in the Legal

Documents and Specifications, and if the contractor is found to have failed to exert sufficient, reasonable, and good faith efforts to involve DBE's in the work provided, the City Of Tucson may declare the Contractor noncompliant and in breach of contract. If a goal is not stated in the Special Specifications, it will be understood that no specific goal is assigned to this contract.

a. Policy - It is the policy of the Department of Transportation and the City Of Tucson that

Disadvantaged Business Enterprises, as defined in 49 CFR Part 26, and as amended in Section 106(c) of the Surface Transportation and Uniform Relocation Assistance Act of 1987, shall have the maximum opportunity to participate in the performance of

Contract financed in whole or in part with federal funds under this Agreement.

Consequently, the DBE requirements of 49 CFR Part 26 and Section 106(c) of the

STURAA of 1987, apply to this Contract.

The Contractor agrees to ensure that DBEs as defined in 49 CFR Part 26 and Section

106(c) of the STURAA of 1987 have the maximum opportunity to participate in the whole or in part with federal funds provided under this Agreement. In this regard, the Contractor shall take all necessary and reasonable steps in accordance with the regulations to ensure that DBEs have the maximum opportunity to compete for and perform subcontracts. The Contractor shall not discriminate on the basis of race, color, national origin, religion, sex, age or physical handicap in the award and performance of subcontracts. Failure by the contractor to carry out these requirements is a material breach of this contract, which may result in the termination of this contract or any such other remedy as the recipient deems appropriate.

It is further the policy of the City Of Tucson to promote the development and increase the participation of businesses owned and controlled by disadvantaged. DBE involvement in all phases of the City Of Tucson procurement activities are encouraged.

b. DBE obligation - The Contractor and its subcontractors agree to ensure that disadvantaged businesses have the maximum opportunity to participate in the performance of contracts and subcontracts financed in whole or in part with federal funds provided under the Agreement. In that regard, all Contractors and subcontractors shall take all necessary and reasonable steps in accordance with 49 CFR Part 26 as amended, to ensure that minority business enterprises have the maximum opportunity to compete for and perform contracts.

c. Where the Contractor is found to have failed to exert sufficient reasonable and good faith efforts to involve DBE's in the work provided, the City Of Tucson may declare the contractor noncompliant and in breach of contract.

d. The Contractor will keep records and documents for a reasonable time following performance of this contract to indicate compliance with the City Of Tucson DBE program. These records and documents will be made available at reasonable times and places for inspection by any authorized representative of the City Of Tucson and will be submitted to the City Of Tucson upon request.

e. The City Of Tucson will provide affirmative assistance as may be reasonable and necessary to assist the prime contractor in implementing their programs for DBE participation. The assistance may include the following upon request:

* Identification of qualified DBE

* Available listing of Minority Assistance Agencies

* Holding bid conferences to emphasize requirements

2. DBE Program Definitions, as used in the contract:

a. Disadvantaged business "means a small business concern":

i. Which is at least 51 percent owned by one or more socially and economically disadvantaged individuals, or, in the case of any publicly owned business, at least

51 percent of the stock of which is owned by one or more socially and economically disadvantaged individuals; and

ii. Whose management and daily business operations are controlled by one or more of the socially and economically disadvantaged individuals who own it.

or

iii. Which is at least 51 percent owned by one or more women individuals, or in the case of any publicly owned business, at least 51% of the stock of which is owned by one or more women individuals; and

iv. Whose management and daily business operations are controlled by one or more women individuals who own it.

b. "Small business concern" means a small business as defined by Section 3 of the Small

Business Act and Appendix B - (Section 106(c)) Determinations of Business Size.

c. “Socially and economically disadvantaged individuals" means those individuals who are citizens of the United States (or lawfully admitted permanent residents and who are black

Americans, Hispanic Americans, Native Americans, Asian-Pacific Americans, Asian-

Indian Americans, or women, and any other minorities or individuals found to be disadvantaged by the Small Business Administration pursuant to section 8(a) of the

Small Business Act.

i. "Black Americans", which includes persons having origins in any of the Black racial groups of Africa;

ii. "Hispanic Americans", which includes persons of Mexican, Puerto Rican, Cuba, Central or South American, or other Spanish or Portuguese culture or origin, regardless of race;

iii. "Native Americans”, which includes persons who are American Indians, Eskimos, Aleuts, or Native Hawaiians;

iv. "Asian-Pacific Americans", which includes persons whose origins are from Japan, China, Taiwan, Korea, Vietnam, Laos, Cambodia, the Philippines, Samoa, Guam, the U.S. Trust Territories of Pacific, and the Northern Marianas;

v. "Asian-Indian Americans", which includes persons whose origins are from India, Pakistan, and Bangladesh.

3. Prime contractors are required to pay subcontractors for satisfactory performance of their contracts no later than 30 days from receipt of each payment made by the City of Tucson to the prime contractor. If applicable, the Prime contractor is to pay all retainage owed to the DBE subcontractor within 30 days of satisfactory completion of the contracted work. For the purposes of this section, a subcontractor's work is satisfactorily completed when all the tasks called for in the subcontract have been accomplished and documented by the prime contractor as required by the City of Tucson. The City of Tucson will continue to hold full retainage as provided for under the Arizona Revised Statutes. Prime contractors must provide notice to DBE firms that complaints of violations of the prompt payment provision may be submitted in writing to the City of Tucson Office of Equal Opportunity Programs Director, 201 N. Stone Ave., 3rd Floor NW, Tucson Arizona 85701. The complaint shall set forth the facts and identify the prime contractor and the project.

Incorporation Of Federal Transit Administration (FTA) Terms - FTA Circular 4220.1F

Incorporation of Federal Transit Administration (FTA) Terms - The preceding provisions include, in part, certain Standard Terms and Conditions required by DOT, whether or not expressly set forth in the preceding contract provisions. All contractual provisions required by DOT, as set forth in FTA

Circular 4220.1F, are hereby incorporated by reference. Anything to the contrary herein notwithstanding, all FTA mandated terms shall be deemed to control in the event of a conflict with other provisions contained in this Agreement. The Contractor shall not perform any act, fail to perform any act, or refuse to comply with any of the City Of Tucson’s requests which would cause the City

Of Tucson to be in violation of the FTA terms and conditions.

Requirements for Contracts Exceeding $25,000

Debarment and Suspension Requirements - 49 CFR Part 29, Executive Order 12549

Debarment, Suspension, and Other Responsibility Matters - (Third Party Contracts over $25,000).

The Recipient agrees to comply, and assures the compliance of each subrecipient, lessee, third party contractor, or other participant at any tier of the Project, with Executive Orders Nos. 12549 and 12689, “Debarment and Suspension,” 31 U.S.C. § 6101 note, and U.S. DOT regulations, “Nonprocurement Suspension and Debarment,” 2 C.F.R. Part 1200, which adopts and supplements the provisions of U.S.

Office of Management FTA Master Agreement MA(16), 10-1-2009 17 and Budget (U.S. OMB) “Guidelines to Agencies on Governmentwide Debarment and Suspension (Nonprocurement),” 2 C.F.R. Part 180. The Recipient agrees to, and assures that its subrecipients, lessees, third party contractors, and other participants at any tier of the Project will, review the “Excluded Parties Listing System” at http://epls.gov/ before entering into any subagreement, lease, third party contract, or other arrangement in connection with the Project.

Requirements for Contracts Exceeding $100,000

Access To Records And Reports - 49 U.S.C. 5325, 18 CFR 18.36 (i), 49 CFR 633.17

Record Retention

During the course of the Project and for three years thereafter from the date of transmission of the final expenditure report, the Recipient agrees to maintain intact and readily accessible all data, documents, reports, records, subagreements, leases, third party contracts, and supporting materials related to the Project as the Federal Government may require.

Access to Records of Recipients and Subrecipients

The Recipient agrees to permit, and require its subrecipients to permit, the U.S. Secretary of Transportation, the Comptroller General of the United States, and, to the extent appropriate, the State, or their authorized representatives, upon their request to inspect all Project work, materials, payrolls, and other data, and to audit the books, records, and accounts of the Recipient and its subrecipients pertaining to the Project, as required by 49 U.S.C. § 5325(g), 18 CFR 18.36(i), 49 CFR 633.17

Buy America Requirements - 49 U.S.C. 5323(j), 49 CFR Part 661

Buy America Provision: Steel and Manufactured Products Other than Buses, Rolling Stock and Associated Equipment

The contractor agrees to comply with 49 U.S.C. 5323(j) and 49 CFR Part 661, which provide that Federal funds may not be obligated unless steel, iron, and manufactured products used in FTA-funded projects are produced in the United States, unless a waiver has been granted by FTA or the product is subject to a general waiver.

General waivers are listed in 49 CFR 661.7, and include final assembly in the United States for 15 passenger vans and 15 passenger wagons produced by Chrysler Corporation, microcomputer equipment, software, and small purchases (currently less than $100,000) made with capital, operating, or planning funds. Separate requirements for rolling stock are set out at 5323(j)(2)(C) and 49 CFR 661.11. Rolling stock not subject to a general waiver must be manufactured in the United States and have a 60 percent domestic content.

A bidder or offeror must submit to the FTA recipient the appropriate Buy America certification (see Certification section) with all bids on FTA-funded contracts, of $100,000 and above, except those subject to a general waiver. Bids or offers that are not accompanied by a completed Buy America certification must be rejected as nonresponsive. This requirement does not apply to lower tier subcontractors.

Provisions For Resolution Of Disputes, Breaches, Defaults Or Other Litigation - 49 CFR Part 18, FTA Circular 4220.1F

Disputes

Disputes arising in the performance of this Contract which are not resolved by agreement of the parties shall be decided in writing by the authorized representative of the City Of Tucson. This decision shall be final and conclusive unless within ten (10) days from the date of receipt of its copy, the Contractor mails or otherwise furnishes a written appeal to the authorized representative of the City Of Tucson. In connection with any such appeal, the Contractor shall be afforded an opportunity to be heard and to offer evidence in support of its position. The decision of the authorized representative of the City Of Tucson shall be binding upon the

Contractor and the Contractor shall abide be the decision.

Performance During Dispute

Unless otherwise directed by the City Of Tucson, Contractor shall continue performance under this Contract while matters in dispute are being resolved.

Claims for Damages

Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the party or of any of his employees, agents or others for whose acts he is legally liable, a claim for damages therefor shall be made in writing to such other party within a reasonable time after the first observance of such injury of damage.

Remedies

Unless this contract provides otherwise, all claims, counterclaims, disputes and other matters in question between the City Of Tucson and the Contractor arising out of or relating to this agreement or its breach will be decided by arbitration if the parties mutually agree, or in a court of competent jurisdiction within the State in which the City Of Tucson is located.

Rights and Remedies

The duties and obligations imposed by the Contract Documents and the rights and remedies available thereunder shall be in addition to and not a limitation of any duties, obligations, rights and remedies otherwise imposed or available by law. No action or failure to act by the City Of Tucson, Architect or Contractor shall constitute a waiver of any right or duty afforded any of them under the Contract, nor shall any such action or failure to act constitute an approval of or acquiescence in any breach thereunder, except as may be specifically agreed in writing.

Lobbying Requirements - 31 U.S.C. 1352, 49 CFR Part 19, 49 CFR Part 20

Contractors who apply or bid for an award of $100,000 or more shall file the certification required by 49 CFR part 20, "New Restrictions on Lobbying." Each tier certifies to the tier above that it will not and has not used

Federal appropriated funds to pay any person or organization for influencing or attempting to influence an officer or employee of any agency, a member of Congress, officer or employee of Congress, or an employee of a member of Congress in connection with obtaining any Federal contract, grant or any other award covered by 31 U.S.C. 1352. Each tier shall also disclose the name of any registrant under the Lobbying Disclosure Act of 1995 who has made lobbying contacts on its behalf with non-Federal funds with respect to that Federal contract, grant or award covered by 31 U.S.C. 1352. Such disclosures are forwarded from tier to tier up to the

City Of Tucson.

Bonding Requirements for Construction Activities; may be imposed for non-construction activities

Refer to the Special Terms & Conditions of this Solicitation for

Bid Bond Requirements (Construction ) Performance and Payment Bonding Requirements (Construction) Performance and Payment Bonding Requirements (Non-Construction) Advance Payment Bonding Requirements Patent Infringement Bonding Requirements (Patent Indemnity) Warranty of the Work and Maintenance Bonds

Clean Water Requirements - 33 U.S.C. 1251

1. The Contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Federal Water Pollution Control Act, as amended, 33 U.S.C. 1251 et seq . The Contractor agrees to report each violation to the Purchaser and understands and agrees that the Purchaser will, in turn, report each violation as required to assure notification to FTA and the appropriate EPA Regional Office.

2. The Contractor also agrees to include these requirements in each subcontract exceeding $100,000 financed in whole or in part with Federal assistance provided by FTA

Clean Air Requirements - 42 U.S.C. 7401 et seq., 40 CFR 15.61, 49 CFR Part 18

1. The Contractor agrees to comply with all applicable standards, orders or regulations issued pursuant to the Clean Air Act, as amended, 42 U.S.C. §§ 7401 et seq . The Contractor agrees to report each violation to the Purchaser and understands and agrees that the Purchaser will, in turn, report each violation as required to assure notification to FTA and the appropriate EPA Regional Office.

2. The Contractor also agrees to include these requirements in each subcontract exceeding $100,000 financed in whole or in part with Federal assistance provided by FTA

Requirements for Recycled Products - 42 U.S.C. 6962, 40 CFR Part 247, Executive Order 12873

The contractor agrees to comply with all the requirements of Section 6002 of the Resource Conservation and

Recovery Act (RCRA), as amended (42 U.S.C. 6962), including but not limited to the regulatory provisions of

40 CFR Part 247, and Executive Order 12873, as they apply to the procurement of the items designated in

Subpart B of 40 CFR Part 247.

Non Construction Activities

Non Construction Employee Protection Requirements (Except for supplies/raw materials)

The Contractor agrees to comply with and assures compliance by other Project participants with any applicable employee protection requirements for nonconstruction employees of the Contract Work Hours and Safety

Standards Act, as amended, 40 U.S.C. §§ 3701 et seq., in particular with the wage and hour requirements of section 102 of that Act at 40 U.S.C. § 3702, and with implementing U.S. DOL regulations, “Labor Standards

Provisions Applicable to Contracts Governing Federally Financed and Assisted Construction (also Labor

Standards Provisions Applicable to Nonconstruction Contracts Subject to the Contract Work Hours and Safety

Standards Act),” 29 C.F.R. Part 5.

Planning, Research, Development and Demonstration Projects

Patent And Rights In Data - 37 CFR Part 401, 49 CFR Parts 18 and 19

CONTRACTS INVOLVING EXPERIMENTAL, DEVELOPMENTAL, OR RESEARCH WORK.

A. Rights in Data - This following requirements apply to each contract involving experimental, developmental or research work:

1. The term "subject data" used in this clause means recorded information, whether or not copyrighted, that is delivered or specified to be delivered under the contract. The term includes graphic or pictorial delineation in media such as drawings or photographs; text in specifications or related performance or design-type documents; machine forms such as punched cards, magnetic tape, or computer memory printouts; and information retained in computer memory.

Examples include, but are not limited to: computer software, engineering drawings and associated lists, specifications, standards, process sheets, manuals, technical reports, catalog item identifications, and related information. The term "subject data" does not include financial reports, cost analyses, and similar information incidental to contract administration.

2. The following restrictions apply to all subject data first produced in the performance of the contract to which this Attachment has been added:

a. Except for its own internal use, the Purchaser or Contractor may not publish or reproduce subject data in whole or in part, or in any manner or form, nor may the Purchaser or

Contractor authorize others to do so, without the written consent of the Federal

Government, until such time as the Federal Government may have either released or approved the release of such data to the public; this restriction on publication, however, does not apply to any contract with an academic institution.

b. In accordance with 49 C.F.R. § 18.34 and 49 C.F.R. § 19.36, the Federal Government reserves a royalty-free, non-exclusive and irrevocable license to reproduce, publish, or otherwise use, and to authorize others to use, for "Federal Government purposes," any subject data or copyright described in subsections (2)(b)1 and (2)(b)2 of this clause below.

As used in the previous sentence, "for Federal Government purposes," means use only for the direct purposes of the Federal Government. Without the copyright owner's consent, the Federal Government may not extend its Federal license to any other party.

1. Any subject data developed under that contract, whether or not a copyright has been obtained; and

2. Any rights of copyright purchased by the Purchaser or Contractor using Federal assistance in whole or in part provided by FTA.

c. When FTA awards Federal assistance for experimental, developmental, or research work, it is FTA's general intention to increase transportation knowledge available to the public, rather than to restrict the benefits resulting from the work to participants in that work.

Therefore, unless FTA determines otherwise, the Purchaser and the Contractor performing experimental, developmental, or research work required by the underlying contract to which this Attachment is added agrees to permit FTA to make available to the public, either

FTA's license in the copyright to any subject data developed in the course of that contract, or a copy of the subject data first produced under the contract for which a copyright has not been obtained. If the experimental, developmental, or research work, which is the subject of the underlying contract, is not completed for any reason whatsoever, all data developed under that contract shall become subject data as defined in subsection (a) of this clause and shall be delivered as the Federal Government may direct. This subsection

(c) , however, does not apply to adaptations of automatic data processing equipment or programs for the Purchaser or Contractor's use whose costs are financed in whole or in part with Federal assistance provided by FTA for transportation capital projects.

d. Unless prohibited by state law, upon request by the Federal Government, the Purchaser and the Contractor agree to indemnify, save, and hold harmless the Federal Government, its officers, agents, and employees acting within the scope of their official duties against any liability, including costs and expenses, resulting from any willful or intentional violation by the Purchaser or Contractor of proprietary rights, copyrights, or right of privacy, arising out of the publication, translation, reproduction, delivery, use, or disposition of any data furnished under that contract. Neither the Purchaser nor the Contractor shall be required to indemnify the Federal Government for any such liability arising out of the wrongful act of any employee, official, or agents of the Federal Government.

e. Nothing contained in this clause on rights in data shall imply a license to the Federal

Government under any patent or be construed as affecting the scope of any license or other right otherwise granted to the Federal Government under any patent.

f. Data developed by the Purchaser or Contractor and financed entirely without using Federal assistance provided by the Federal Government that has been incorporated into work required by the underlying contract to which this Attachment has been added is exempt from the requirements of subsections (b), (c), and (d) of this clause , provided that the

Purchaser or Contractor identifies that data in writing at the time of delivery of the contract work.

g. Unless FTA determines otherwise, the Contractor agrees to include these requirements in each subcontract for experimental, developmental, or research work financed in whole or in part with Federal assistance provided by FTA.

3. Unless the Federal Government later makes a contrary determination in writing, irrespective of the Contractor's status (i.e., a large business, small business, state government or state instrumentality, local government, nonprofit organization, institution of higher education, individual, etc.), the Purchaser and the Contractor agree to take the necessary actions to provide, through FTA, those rights in that invention due the Federal Government as described in U.S.

Department of Commerce regulations, "Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements,"

37 C.F.R. Part 401.

4. The Contractor also agrees to include these requirements in each subcontract for experimental, developmental, or research work financed in whole or in part with Federal assistance provided by

FTA.

B. Patent Rights - This following requirements apply to each contract involving experimental, developmental, or research work:

1. General - If any invention, improvement, or discovery is conceived or first actually reduced to practice in the course of or under the contract to which this Attachment has been added, and that invention, improvement, or discovery is patentable under the laws of the United States of America or any foreign country, the Purchaser and Contractor agree to take actions necessary to provide immediate notice and a detailed report to the party at a higher tier until FTA is ultimately notified.

2. Unless the Federal Government later makes a contrary determination in writing, irrespective of the Contractor's status (a large business, small business, state government or state instrumentality, local government, nonprofit organization, institution of higher education, individual), the Purchaser and the Contractor agree to take the necessary actions to provide, through FTA, those rights in that invention due the Federal Government as described in U.S.

Department of Commerce regulations, "Rights to Inventions Made by Nonprofit Organizations and Small Business Firms Under Government Grants, Contracts and Cooperative Agreements,"

3. The Contractor also agrees to include the requirements of this clause in each subcontract for experimental, developmental, or research work financed in whole or in part with Federal assistance provided by FTA.

Miscellaneous Special Requirements

Environmental Protection 42 U.S.C. 4321 et seq., 49 U.S.C. 5324(b) et seq., 40 CFR Part 1500 et seq., 23 CFR Part 771, 49 CFR Part 622 The Contractor agrees to comply with all applicable requirements of the National Environmental Policy Act of

1969, as amended, 42 U.S.C. §§ 4321 et seq. consistent with Executive Order No. 11514, as amended, "Protection and Enhancement of Environmental Quality," 42 U.S.C. § 4321 note; FTA statutory requirements on environmental matters at 49 U.S.C. § 5324(b); Council on Environmental Quality regulations on compliance with the National Environmental Policy Act of 1969, as amended, 40 C.F.R. Part 1500 et seq.; and joint

FHWA/FTA regulations, "Environmental Impact and Related Procedures," 23 C.F.R. Part 771 and 49 C.F.R.

Part 622

Energy Conservation…