2008 Addendum 1.pdf

-1-

May 19, 2020

Bid #2008 Kenosha County Victim Witness, Juvenile Intake, and District Attorney Relocation and Partial Remodel Project

ADDENDUM #1

BIDS DUE: THURSDAY, MAY 28, 2020 BY 3:00PM Local Time to: County of Kenosha Clerk of the Courts - Attn: Rebecca Matoska-Menting located at the Kenosha County Courthouse, Room 204 912 56th Street Kenosha, WI 53140. At that time Bids will be opened publicly for consideration by the Owner.

To all Contract Bidders of record.

This Addendum is issued to modify, explain or correct the original Drawings and Specifications as noted below, and is hereby made a part of the Contract documents. Please attach this Addendum to the Specifications in your possession. Acknowledge receipt of this Addendum in the space provided on the Bid Form. Failure to do so may subject Bidder to disqualification.

This Addendum consists of (5) written pages, (1) sign in sheets, and (8) Attachments

APPROVED MANUFACTURERS

All the following Acceptable Manufacturer's products below must meet or exceed written specifications:

1. SECTION – 08 56 71 – BULLET RESISTANT HOLLOW METAL WINDOWS

a. Chicago Bullet Proof Window Systems, Inc.

- CBP Model STW BR HM window with Speak-Thru and Non- Ricochet Dip Tray

2. SECTION – 08 14 29 – WOOD DOORS (PRE-FINISHED)

a. Chicago Bullet Proof Window Systems, Inc.

- CBP Model WH BR Wood Haven Door and Frame.

QUESTIONS AND ANSWERS

1. How many phases are necessary to complete this project?

a. There are (4) phases to the project in (3) different areas. Phase 1 is the remodeling of the small conference room in the Courthouse basement. Phase 2 is the new Juvenile Intake office remodel in the Courthouse basement. Phase 3 will be the DA remodel area on the first floor of the Molinaro Building and Phase 4 will be the enclosure of the existing relocated reception on the first floor of the Molinaro Building. All areas are indicated on sheet A001. The GC will be responsible for coordinating the schedule of moving in/out of these areas in accordance with the indicated phases.

2. Where will the dumpster and construction staging area be located for the project?

a. The dumpster will be located on the northside of the Molinaro Building parking lot for all phases of the project. Coordinate location with County.

3. Per sheet 2IT200, will there be a TV location indicated in conference 2111?

a. There is to be a TV location rough-in included for a future TV location on the East wall.

Rough in will include blocking in the wall for a wall mount TV, (1) duplex outlet, and an HDMI run to the base of the wall. In addition, all TV locations are to receive (2) CAT 6 cables. All headend equipment will be provided by the owner. All final TV locations to be coordinated with the Architect before installation.

-2-

4. Per sheet 1IT200, will there be a TV location indicated in conference 1101?

a. There is to be a TV location rough-in included for a TV on the North wall. Rough in will include (1) duplex outlet, (1) Coax. In addition, all TV locations are to receive (2) CAT 6 cables. All headend equipment will be provided by the owner. All final TV locations to be coordinated with the Architect before installation. Coax cable for area 01 to be reused from Area 02. General contractor to be responsible for the cable function during the relocation process.

5. Drawing on sheet A002 only shows door Types LNL with Glass, However, page 1A201 notes type FG Door on the Door Schedule. Does this door have glass? If so, will it be ¼” Clear Tempered?

a. Door 1101A will be a FG style door. Please see attached sheet A002 for FG door style standards. Per Glazing specifications (08 80 00) the glazing will be ¼” clear tempered for door 1101A.

6. Sheet 2A201 notes a Type HG Door on Door Schedule. Is this door Half Glass? It also has a X on glass. Is this ¼” Clear Tempered?

a. Yes, this door will be half glass. See updated sheet A002 for HG door standards. In addition, see attached sheet 2A201 for updated door schedule.

7. I am confused on finding the specifications for the new ductwork to be added. Where are the requirements?

a. There will be no specification included with the project for HVAC. The scope of work is shown on sheets 2M200 for area 02 and attached sheet 3M200 for Area 03. See the General Mechanical Notes on Sheet 2M200 & 3M200.

8. Do you have an estimated start and completion date?

a. The desired start and completion dates are listed on the Bid Offer Form. Per the Bid offer, desired start will be June 2020 and substantial completion on September 15th, 2020. If these dates cannot be met, please fill out your possible completion schedule per the form request.

9. Drawing Page A002 calls for Type B Frame to have a sidelite. I don’t see this frame called out on any of the door schedules. Should this be excluded?

a. All sidelites have been eliminated from the project. Please see attached updates sheet

A002 - WALL TYPES & TYPICAL DETAILS.

10. Drawing sheet 3A201 – Door Schedule for type 3100A calls for type F door (which has no glass on page A002) but in the remarks states to be bullet proof glazing. Please confirm.

a. Door 3100A is to be solid door with no glazing. Remark for door 3100A should read, “Solid core construction wood veneer faces, bullet-resistant composite core and solid 3/8 inch thick wood stile and rail edges of same species as veneer”.

11. Drawing Page 2A201, on the Room Schedule, 2100 West and 2101 East list GL-3.

Please confirm what is GL-3?

a. GL-3 refers to bullet resistant glazing, Level III. However, all bullet resistant glazing and wall panel is to be removed from Area 02. There is no bullet proofing in Areas 01 & 02.

Area 03 is the only area to receive Level III bullet resistant construction.

12. Drawing Page 2A201, the Room Schedule also states GL-1 on some rooms. Please confirm what that is?

a. GL-1 refers to 1/4” Tempered Glass. See the Material Key on sheet A002 – WALL

TYPES AND TYPICAL DETAILS. The only rooms with GL-1 in Area 02, will be the west wall of Waiting 2100 and the East wall of Reception 2101. All GL-1 referenced in Office

-3-

2107, Multi-purpose Office 2108, Office 2109, Office 2110, and Conference 2111 to be excluded from the project.

13. Drawing Spec Section 088000 – Glazing – notes several different types of glass. Under

Part 2 – Products & 2.3 – Fabrication - it notes 3/8” clear or gray? Is this included?

Tinted Glass?

a. There will be no 3/8” thick glass required for this project. All non Bullet-Resistant glass to be ¼” Clear tempered unless noted otherwise. Per sheet 2A201 frosted glass will be required at door 2100A. See updated sheet 2A201.

14. On Sheet 2A300 for Area 02 at detail 05, the reception (2) hollow metal frames they are wanting just ¼” clear tempered and not Level 3 bullet resistant. Is that correct? Also, I cannot find in the specs what is the type of speak hole cover they require?

a. The glazing in this area will be GL-1, 1/4” clear tempered glass. Area 02 will have no

Bullet Resistant construction. The speak hole in this area will be just a 4” diameter hole cut in the glass with a speak hole frame. Basis of design for the speak hole frame: CRL Aluminum Plastic Speak-Thru Hole Frame. Center of speak hole to be cut at 2’-0” off counter height as shown on sheet 2A300 detail 04. All holes in glazing even capped punctures to be polished finish.

15. Sheet 2A300 details 04 & 05 list a Voice Port and refers to specification section 08 80

00. Nothing is listed in the spec for this item.

a. For the voice port in Area 02, refer to question #13 for basis of design.

16. Sheet 2A300 details 04 & 05 list a Pass Thru Tray and refers to specification section

08 80 00. Nothing is listed in the spec for this item.

a. The pass thru tray in this area per elevations 04 & 05 will be an open section of the glass window. Hollow metal frame trim around the opening is to be provided. Minimum opening dimension to be 4”(H) x 14”(W).

17. Sheet 3A300 details 02 & 03 list a Voice Port, Level III rated, spec section 08 56 71.

Nothing listed in the spec for this item.

a. The basis of design for the voice port in Area 03 is the Armortex ANVS6 cast stainless steel speaker. Description reads; “Natural voice Speak Thru provide voice transmission along with security. SSBRS models will fit into 4″ to 6″ diameter hole. 7″ Stainless Steel face plates are secured form the safe side to avoid tampering from the exterior. For ballistic levels 1 thru 3 UL listed laminated polycarbonate offsets face plates”.

Specification section 08 56 71 is a performance-based specification and equal manufacturers meeting the UL level and design intent will be accepted after review by the architect.

18. Sheet 3A300 details 02 & 03 list a Pass Thru Tray, Level III rated, specification section

08 56 71. Nothing listed in the spec for this item.

a. The basis of design for the voice port in Area 03 is the Armortex Deal Tray Non-Ricochet

RMDT-1016. Description reads; Transaction Deal Trays are rolled and formed from 16ga stainless steel with a #3 satin brushed finish and can be lined with HI-Hard ballistic steel to meet ballistic protection requirements. Recessed trays “RMDT” are designed to install into a cut out of 2″ high counters with a capped glazing cap running across top middle”.

Counter top is provided by 06 61 00 and coordinated with recessed deal tray. Deal tray total dimension to be 10” x 16”. Specification section 08 56 71 is a performance-based specification and equal manufacturers meeting the UL level and design intent will be accepted after review by the architect.

-4-

19. Sheet 3A300 details 02 & 03 list Armortex Bullet Resistant Hollow Metal Window System UL Rated Level III rated spec section 08 56 71. Nothing listed in the spec for this item.

a. Specification section 08 56 71 – BULLET RESISTANT HOLLOW METAL WINDOWS

Parts 2 – PRODUCTS provides the intent of design for the Bullet Resistant Hollow Metal Windows. Specification section 08 56 71 is a performance-based specification and equal manufacturers meeting the UL level and design intent will be accepted after review by the architect. See plans and elevations for window sizes.

20. What is the deck height for each area of work?

a. The deck height for Areas 01 & 02 is approximately 10’-2”. The deck height in Area 03 is approximately 9’-10” to the bottom of the concrete tee and 10’-10” at the top of the concrete tee. General Contractor to field verify all existing deck heights.

21. What are the available work hours for this project?

a. Building access will be available form 6AM – 5PM. 5PM the building closes and all work must be completed by this time. All loud work that could potentially interfere with the county court must be done prior to 8AM.

22. Who will be responsible for permit fees?

a. General contractors and sub-contractors will be responsible for all required city permit fees.

23. The drawings call for data to the TV locations, so just one data jack, no coax?

a. TV location in Area 01 to include (1) duplex outlet, (1) Coax. TV locations in Area 02 & 03 to include (1) duplex outlet, (1) HDMI. In addition, all TV locations are to receive (2) CAT 6 cables. All headend equipment will be provided by the owner.

24. Will the Card Reader at door 2100A remain or be removed?

a. Existing Card Reader at door 2100A is to be relocated to door 2100B. There will be no card reader at door 2100A. General Contractor responsible for the relocation of the existing card reader.

25. Who is responsible for the removal of the existing cubicles in Area 03?

a. The General Contractor will not be responsible for cubicle removal. Cubicle removal by owner. General contractor responsible to coordinate with moving schedule.

26. Per sheet 3IT200, will there be a TV location indicated in conference 3112?

a. There is to be rough included for a future TV location on the East wall. Rough in will include blocking in wall for wall mount TV, (1) duplex outlet, (1) Coax and an HDMI run to the base of the wall. In addition, all TV locations are to receive (2) CAT 6 cables. All headend equipment will be provided by the owner. All final TV locations to be coordinated with the Architect before installation.

27. Per sheet 2IT200, there is a dedicated 20 amp outlet and (2) cat 6 lines shown for a copy print area, will this be required in Area 03 as well? If so, what is the location?

a. There will be a copy print station on the West wall, North of Existing Conference 3112.

This location will include a 20 amp dedicated outlet and (2) cat 6 lines for a copy/print area. Final location to be coordinated with the Architect before installation.

28. There are some C2 locations on the print but no description in the Keynote Legend of what they get, one voice and one data?

a. The type of line in this case doesn’t matter. Each C2 location is indicating (2) cat 6 lines.

-5-

REVISED DRAWINGS

• 01 - TITLE SHEET

• A002 – WALL TYPES & TYPICAL DETAILS

• 2A201 – AREA 02 – PROPOSED FLOOR PLAN

• 2IT200 - AREA 02 – TECHNOLOGY AND ELECTRICAL PLANS

• 3A300 – SECTIONS AND DETAILS

• 3A400 – AREA 03 – CEILING PLANS

• 3IT200 – AREA 03 – TECHNOLOGY AND ELECTRICAL PLANS

• 3M200 – AREA 03 – HVAC PLAN

01KUENY ARCHITECTS, LLC

10505 CORPORATE DRIVE - SUITE 100 PLEASANT PRAIRIE, WI 53158 PHONE (262) 857-8101 FAX (262) 857 8103

SITE MAP GENERAL NOTES

1. All concrete to test 4000 psi in 28 days.

2. Verify all dimensions, access, utilities and working conditions in the field.

3. Conform to all applicable codes, ordinances and safety standards.

4. Obtain and pay for all required permits and fees.

5. Notify Architect immediately if work cannot proceed as shown on Drawings or as described in the

Specifications.

6. No concrete to be poured without Architect's prior review.

7. All Contractor's to co-operate with all trades, Owner's and Architect's representatives.

8. Leave site clean, neat and free of debris at all times.

9. Each Prime and Sub-contractor is responsible for having read each page of the Specifications, Drawings, Addenda and Change Orders.

10. Guard against interfering with Owner's operations.

11. These Drawings contain no provisions or procedures for on-site safety. Each Contractor and their employees are responsible to follow all laws and ordinances and provide their own engineering to provide a safe work place.

12. The locations of existing underground utilities, shown on these Drawings, are shown in an approximate way only and have not been independently verified by the Owner or its representatives. The Contractor shall determine the exact location of all existing utilities before commencing work, and agrees to be fully responsible for any and all damages which might be occassioned by the Contractor's failure to exactly locate and preserve any and all underground utilities.

13. Services perform for this project have been conducted in a manner consistent with the level of care and skill ordinarily exercised by members of the profession currently practicing in this area under similar budget and time constraints. No warranty, expressed or implied, is made.

MATERIAL INDICATIONS DRAWING LEGEND

New or Required Point Elevation

Existing Point Elevation

Existing Contours

New or Required Contours

A Grid Lines

3.1

Building Section

Wall Section

Room/Space Number

Door Number

SHEET INDEX

Earth Backfill

Rigid Insulation

Concrete Block

Aluminum

Lumber (Rough)

Steel

Sand Fill

Concrete

Finished Wood

Stone Fill

Plywoo d Batt Insulation

4.1

Room Name

101A Interior Elevation

Detail Section1 5.1

7.1

5.1

Detail Number Page Number

Exterior Elevation

2.1

# Wall Tag

+ 100.0

+ 100.0

+ 100.0

+ 100.0

CONSULTANTS

OH Door NumberOH 101A

Kenosha County

Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project

912 56th St, Kenosha, WI 53140

April 24, 2020

Kenosha County Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project

TITLE SHEET

01 Title Sheet

GENERAL ARCHITECTURE

A001 Work Area and Phasing Key Plan A002 Wall Types & Typical Details

ARCHITECTURAL

1A200 Area 01 - Existing and Demo 1A201 Area 01 - Plans and Details 1A202 Area 01 - Ceiling & Finish Plans 1IT200 Area 01 - Technology & Electrical Plan 2A200 Area 02 - Existing and Demo Plans 2A201 Area 02 - Proposed Floor Plan 2A202 Area 02 - Finish Plans 2A300 Area 02 - Sections and Details 2A400 Area 02 - Ceiling Plans 2IT200 Area 02 - Technology & Electrical Plans 2M200 Area 02 - HVAC Plan 3A200 Area 03 - Existing and Demo Plan 3A201 Area 03 - Proposed Plan 3A202 Area 03 - Finish Plans 3A300 Area 03 - Sections and Details 3A400 Area 03 - Ceiling Plans 3IT200 Area 03 - Technology & Electrical Plans 3M200 Area 03 - HVAC Plan

ARCHITECT Kueny Architects 10505 Corporate Drive, Suite 100

(262) 857-8101 Pleasant Prairie, Wisconsin

53158 Architect of Record - Jon P. Wallenkamp Project Contact - Lee Anderson (262) 945-7709

PROJECT

LOCATION

BID SET DRAWINGS

WALL BASE PER ROOM FINISH SCHEDULE

FLOOR FINISH PER SCHEDULES AND

DETAILS

CONTINUOUS STEEL STUD

RUNNER; ANCHOR TO FLOOR STRUCTURE

5/8" GYPSUM BOARD; EACH SIDE

ACOUSTICAL BATT INSULATION; TYPICAL

AT ACOUSTICAL PARTITIONS

FINISH CEILING PER SCHEDULES AND

WALL SECTIONS

UNDERSIDE OF STRUCTURE

EXTEND TO UNDERSIDE OF STRUCTURE

AND SEAL PER SCHEDULES AND DETAILS

W

AL

L

HE

IG

HT

P

ER

S

CH

ED

UL

ES

WALL EXTENDED PAST FINISH CEILING;

SEE BRACING DETAIL

A STEEL STUD PARTITION

A1 3-5/8" STEEL STUD; 16" 0.C. / WALL EXTENSION 6" PAST FINISH CEILING

A2 3-5/8" STEEL STUD; 16" 0.C. / WALL EXTENSION TO STRUCTURE

WALL BASE PER ROOM FINISH SCHEDULE

FLOOR FINISH PER SCHEDULES AND

DETAILS

CONTINUOUS STEEL STUD

RUNNER; ANCHOR TO FLOOR STRUCTURE

5/8" GYPSUM BOARD; ONE SIDE

ACOUSTICAL BATT INSULATION; TYPICAL

AT ACOUSTICAL PARTITIONS

FINISH CEILING PER SCHEDULES AND

WALL SECTIONS

UNDERSIDE OF STRUCTURE

EXTEND TO UNDERSIDE OF STRUCTURE

AND SEAL PER SCHEDULES AND DETAILS

W

AL

L

HE

IG

HT

P

ER

S

CH

ED

UL

ES

WALL EXTENDED PAST FINISH CEILING;

SEE BRACING DETAIL

B STEEL STUD PARTITION

B1 3-5/8" STEEL STUD; 16" 0.C. / WALL EXTENSION 6" PAST FINISH CEILING

B2 3-5/8" STEEL STUD; 16" 0.C. / WALL EXTENSION TO STRUCTURE

B3 2-1/2" STEEL STUD; 16" 0.C. / WALL EXTENSION 6" PAST FINISH CEILING

B4 2-1/2" STEEL STUD; 16" 0.C. / WALL EXTENSION TO STRUCTURE

FINISHED CEILING PER SCHEDULES

AND DETAILS

METAL STUD KICKERS @ 36" O.C.

TO STRUCTURE; SAME GA AS

WALL

WALL TYPE PER SCHEDULES AND

FLOOR PLANS

WALL PER PLAN; SEE FLOOR

PLAN FOR WALL TYPE

SEAL EDGE WITH CLEAR

SILICON

1/4" CLEAR TEMPERED GLASS;

OFFSET GLAZING TO ONE SIDE

OF WALL

EXTERIOR GLAZING PER PLANS

AND SCHEDULES

WINDOW BLINDS PER PLANS

ALUMINUM CAP; SEE PLAN

FOR WALL THICKNESS

LEVEL PER PLANS

0'-0"

CE

IL

IN

G

H

EI

G

HT

P

ER

P

LA

NS

HE

IG

HT

P

ER

P

LA

NS

4"

WIDTH PER PLANS 1"

M

IN

I M

UM

1' -8

HE

IG

HT

P

ER

P

LA

NS

WALL BASE PER

ROOM

PVC EDGING TYPICAL ON ALL

DOORS AND DRAWERS

ADJUSTABLE SHELVES; SEMI

EXPOSED SURFACES TO BE

MELAMINE

DRAWER PER ELEVATIONS

COUNTER TOP MATERIAL

PER INTERIOR ELEVATIONS

WOOD BLOCKING AS NEEDED

WALL CABINETS IF APPLICABLE

TO PROJECT PER INTERIOR

ELEVATIONS

CONSTRUCTION SIMILAR

TO BASE CABINETS

CEILING PER PLANS AND

SCHEDULES

STUD WALL PER

WIDTH

PER PLANS

3-5/8" METAL STUD

RUNNER WRAPPED

DOUBLE

METAL STUD; STUD TYPICAL

MINERAL WOOL INSULATION;

FULL FRAME WIDTH AND

HOLLOW METAL DOOR

FRAME;

5/8" GYPSUM BOARD PER

WALL TYPE SCHEDULE

WOOD OR HOLLOW METAL

DOOR;

3-5/8" METAL STUD

DOUBLE METAL STUDS; SAME

AS WALL CONSTRUCTION

MINERAL WOOL INSULATION;

FULL FRAME WIDTH AND

HOLLOW METAL DOOR

FRAME;

5/8" GYPSUM BOARD PER

WALL TYPE SCHEDULE

WOOD OR HOLLOW METAL

DOOR;

ANCHOR METAL STUD WALL

TO ACOUSTICAL CEILING TILE

SYSTEM

METAL STUD WALL;

THICKNESS

ACOUSTICAL CEILING SYSTEM;

SEE ROOM FINISH SCHEDULE

AND CEILING PLANS

PAINT WALL PER FINISH

SCHEDULES

(TYPICAL PER REMODEL AREA 01 ONLY)

LEVER STOREROOM LOCK

Outside lever fixed, unlocked by key. Inside lever always unlocked.

LEVER CLASSROOM LOCK

Outside lever locked and unlocked by key. Inside lever always unlocked.

SINGLE CYLINDER CLASSROOM LOCK

Deadbolt locked or unlocked by key from outside. Deadbolt unlocked by thumbturn only from inside.

LEVER OFFICE LOCK

Push-button locking. Pushing button locks outside lever until unlocked by key outside or by turning inside lever.

LEVER ENTRANCE LOCK

Turn/Push-button locking. Pushing and turning button locks outside lever requiring use of key until button in manually unlocked.

Push-button locking. Push button locks outside lever until locked by outside key or by turning inside lever.

DOOR WIDTH

DO

O

R

HE

IG

HT

DOOR WIDTH

DO

O

R

HE

IG

HT

F LNL

6" 1'

-6

2'-0" 6"

FG

6" 2'-0" 6"

DOOR WIDTH

5' -8

6"

6" 2'-0" 6"

DOOR WIDTH

3' -1

0" 2'

-8

6"

HG

DO

O

R

HE

IG

HT

DO

O

R

HE

IG

HT

7' -0

2"

3'-0"

A

WALL BASE PER ROOM FINISH SCHEDULE

FLOOR FINISH PER SCHEDULES AND

DETAILS

CONTINUOUS STEEL STUD

RUNNER; ANCHOR TO FLOOR STRUCTURE

5/8" GYPSUM BOARD; BOTH SIDES

ACOUSTICAL BATT INSULATION; TYPICAL

AT ACOUSTICAL PARTITIONS

FINISH CEILING PER SCHEDULES AND

WALL SECTIONS

UNDERSIDE OF STRUCTURE

EXTEND TO UNDERSIDE OF STRUCTURE

AND SEAL PER SCHEDULES AND DETAILS

W

AL

L

HE

IG

HT

P

ER

S

CH

ED

UL

ES

WALL EXTENDED PAST FINISH CEILING;

SEE BRACING DETAIL

U UL RATED - BULLET RES.

U1 3-5/8" STEEL STUD; UL LEVEL III RATING / WALL TO STRUCTURE

BULLET RESISTANT FIBERGLASS PANEL;

UL RATING PER PLANS AND SPECS; PANEL

AT SECURE SIDE OF CONSTRUCTION

4" WIDE BATTEN STRIP AT EACH PANEL

SEAM; SEE SPECIFICATIONS

*ALL INSTALLATION TO BE COMPLETED IN ACCORDANCE WITH

MANUFACTURER'S SPECIFICATIONS

01 ADDENDUM #1 MAY 19, 2020

REV. / DESCRIPTION DATE

kuenyarch.com ©2020 Kueny Architects L.L.C. - All Rights Reserved SCALE: As indicated

A002Kenosha County - Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project

April 24, 2020

Wall Types & Typical Details

912 56th St, Kenosha, WI 53140

3" = 1'-0"2 Typical Kicker Detail

3" = 1'-0"5 Typical Sound Stop

1/2" = 1'-0"6 Typical Millwork Section

3" = 1'-0"4 3-5/8" Metal Stud Head 3" = 1'-0"3 3-5/8" Metal Stud Jamb

3" = 1'-0"1 Partition Wall @ Ceiling

MATERIAL KEY

CODE DESCRIPTION

CEILING TYPE

ACT-1 2x2 Acoustical Ceiling Panels

FLOOR TYPE

CPT-1 2x2 Carpet Tile VB 4" Vinyl Base

PAINT SCHEDULE KEY

EPOXY Epoxy Paint LATEX-E Latex Wall Paint - Enamel LATEX-S Latex Wall Paint - Satin Finish

WALL TYPE

GL-1 1/4" Tempered Glass GL-2 1" Insulated Glass GL-3 Bullet Resisitant Glazing - Level III GWB1 5/8" G.W.B. Taped and Finished on Stud Framing per Wall Type GWB2 5/8" Moisture & Mold Resistant Gypsum Wallboard

Taped & Finished on Stud Framing per Wall Type

LOCKSET TYPESDOOR PANEL TYPES DOOR FRAME

CR

existing IT office conference waiting 2100reception clst.

existing RR

ex. chase office 01 existing file storage room

7' -1

7/

8" 9'

-7

8' -1

5/ multi purpose office

FI

EL

D

VE

RI

F Y

D

IM

EN

SI

O

NS

'-4

/1

6"

'-8

8'-9 1/2"

20'-0"

'-0

'-9

/8

'-1

7/

8"

'-9

7' -5 office 03

3' -3

/2

6'

-0

2A300 5

2A300

B

2101A

4"

2107A

2108A

2111A

2109A

2110A

'-1

'-6

E2103 clst.

A

2A300 7

02 05 00.C5 hall

7'-9 5/8" 8'-0"

15'-9 5/8"

14'-8 5/8"

6'-6 5/8"

9'-7"

2A300

4' -3

/8

2A300

1'-4"

2A3006

5' -3

/8

E2106

E2105

E2104

A1 A1

A1 A002

Sim

A002

Sim

B1

B1

B3

B3

B3

A1 A1

A1

A1

A1 existing hall

A1

A1

A1

A1

A1

2A3004

02 05 00.C6

2A300

1. REMOVE LOOSE PAINT AND

MISCELLANEOUS HANGING OBJECTS

FROM WALLS AND CEILINGS AT ALL

AREAS TO RECEIVE NEW FINISHES.

2. PATCH AND REPAIR ALL EXISTING

FLOOR SLABS AND WALL SURFACES

DAMAGED FROM DEMOLITION OR

PRIOR USE.

3. PATCH ALL AREAS OF ELECTRICAL

AND MECHANICAL DEMOLITION THAT

WILL NOT BE REUSED.

4. CONTRACTOR TO FIELD VERIFY ALL

EXISTING DIMENSIONS AND

CONDITIONS. IN THE EVENT OF A

DISCREPANCY BETWEEN THE

DRAWINGS AND THE EXISTING

CONDITIONS, NOTIFY THE ARCHITECT

BEFORE PROCEEDING.

5. DO NOT REMOVE ANY ITEMS WHICH

JEOPARDIZE THE STRUCTURAL

INTEGRITY OF THE BUILDING. IF

HIDDEN ELEMENTS OR DETERIORATED

ELEMENTS ARE ENCOUNTERED,

NOTIFY THE ARCHITECT IMMEDIATELY.

6. PROTECT ALL ADJACENT AREAS AND

ITEMS "TO REMAIN" DURING

DEMOLITION/CONSTRUCTION.

REPAIR/REPLACE ALL ITEMS DAMAGED

DURING CONSTRUCTION.

7. EXISTING BUILDING CONDITIONS

SHOWN ON THESE DRAWINGS ARE

DERIVED FROM DRAWINGS OF THE

ORIGINAL BUILDING AND FROM LIMITED

FIELD OBSERVATION.

8. THE CONTRACTOR SHALL PROVIDE

AND MAINTAIN ADDITIONAL MEANS OF

EGRESS AS NEEDED AS A RESULT OF

CONSTRUCTION SEQUENCING AND/OR

REGULATORY REQUIREMENTS.

GENERAL PROJECT NOTES

01 ADDENDUM #1 MAY 19, 2020

REV. / DESCRIPTION DATE

kuenyarch.com ©2020 Kueny Architects L.L.C. - All Rights Reserved

PLAN NORTH

KEYNOTE LEGEND

SCALE: As indicated

2A201Kenosha County - Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project

April 24, 2020

Area 02 - Proposed Floor Plan

912 56th St, Kenosha, WI 53140

Spec. # Description

02 05 00.C5 EXISTING CONCRETE COLUMN TO REMAIN; FIELD VERIFY

LOCATION

02 05 00.C6 EXISTING STEEL COLUMN TO REMAIN; PAINT PER ROOM

FINISH SCHEDULE

ROOM SCHEDULE - AREA 02

NUMBER NAME FLOOR TYPE BASE

WALL FINISH CEILING

REMARKSNORTH SOUTH EAST WEST TYPE HEIGHT

2100 waiting CPT-1 TL-1 GWB1 Existing Existing GWB1/GL-1 ACT-1 7'-11" 2101 reception CPT-1 VB Existing Existing GWB1/GL-1 Existing ACT-1 7'-11" 2102 hall CPT-1 VB Existing GWB1 Existing/GWB1 Existing/GWB1 ACT-1 7'-11" 2103 existing RR Existing Existing Existing Existing Existing Existing ACT-1 Existing 2104 ex. chase Existing Existing Existing Existing Existing Existing Existing Existing 2105 clst. CPT-1 Existing Existing Existing Existing Existing Existing Existing 2106 clst. CPT-1 Existing Existing Existing Existing Existing Existing Existing 2107 office 01 CPT-1 VB GWB1 Existing/GWB1 Existing GWB1 ACT-1 7'-11" 2108 multi purpose office 02 CPT-1 VB GWB1 GWB1 Existing/GWB1 GWB1 ACT-1 7'-11" 2109 office 03 CPT-1 VB Existing/GWB1 GWB1 Existing/GWB1 GWB1 ACT-1 7'-11" 2110 office CPT-1 VB Existing/GWB1 GWB1 Existing/GWB1 Existing ACT-1 7'-11" 2111 conference CPT-1 VB GWB1 Existing/GWB1 GWB1 Existing/GWB1 ACT-1 7'-11" 2112 existing IT Existing Existing Existing Existing Existing Existing Existing Existing

DOOR SCHEDULE - AREA 02

MARK

FROM ROOM TO ROOM

LABEL

DOOR FRAME

REMARKSNUM NAME NUM NAME TYPE MATERIAL SWING WIDTH HEIGHT THICKNESS LOUVER GLASS TYPE MATERIAL GLASS 2100A - existing hall 2100 waiting - HG Wood RH 3' - 0" 7' - 0" 1 3/4" - X A HM - Door glazing to be 1/4" tempered frosted glass 2100B 2100 waiting 2102 hall - LNL Wood LHR 3' - 0" 7' - 0" 1 3/4" - X A HM - Contractor to provide door frame acceptable for new card reader and electric strike 2101A 2102 hall 2101 reception - HG Wood RH 3' - 0" 7' - 0" 1 3/4" - X A HM - Contractor to provide door frame acceptable for new card reader and electric strike 2107A 2102 hall 2107 office 01 - LNL Wood LH 3' - 0" 7' - 0" 1 3/4" - X A HM - - 2108A 2102 hall 2108 multi purpose office 02 - LNL Wood RH 3' - 0" 7' - 0" 1 3/4" - X A HM - - 2109A 2102 hall 2109 office 03 - LNL Wood RH 3' - 0" 7' - 0" 1 3/4" - X A HM - - 2110A 2102 hall 2110 office - LNL Wood LH 3' - 0" 7' - 0" 1 3/4" - X A HM - - 2111A 2102 hall 2111 conference - HG Wood LH 3' - 0" 7' - 0" 1 3/4" - X A HM - -

HARDWARE SCHEDULE

MARK LOCKSET PUSH-PULL HOLD OPEN CLOSER HINGE DOOR STOP THRESHOLD WEATHERSTRIP KICKPLATE SOUNDSTOP NAMEPLATE NOTES 2100A By Owner - - X X - X - - X - Lockset Provided by Owner; Installed by G.C.

2100B By Owner - - X X X - - - X - Lockset Provided by Owner; Installed by G.C.

2101A By Owner - - X X X - - - X - Lockset Provided by Owner; Installed by G.C.

2107A By Owner - - - X X - - - X - Lockset Provided by Owner; Installed by G.C.

2108A By Owner - - - X X - - - X - Lockset Provided by Owner; Installed by G.C.

2109A By Owner - - - X X - - - X - Lockset Provided by Owner; Installed by G.C.

2110A By Owner - - - X X - - - X - Lockset Provided by Owner; Installed by G.C.

2111A By Owner - - - X X - - - X - Lockset Provided by Owner; Installed by G.C.

PAINT SCHEDULE

ROOM

FLOOR

WALLS

CEILING METAL WOOD REMARKSNUM NAME NORTH SOUTH EAST WEST

2100 waiting - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2101 reception - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2102 hall - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2103 existing RR - - - - - - - - 2104 ex. chase - - - - - - - - 2105 clst. - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2106 clst. - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2107 office 01 - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2108 multi purpose office 02 - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2109 office 03 - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2110 office - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2111 conference - Latex-S Latex-S Latex-S Latex-S - Enamel Varnish 2112 existing IT - - - - - - - -

C4

C4

C4

C4

CR

CR

existing IT office conference waiting reception clst.

existing RR

ex. chase office 01 existing file storage room multi purpose office office 03 clst.

hall

26 05 00.01

DEDICATED

20A

26 05 00.0326 05 00.03

26 05 00.0326 05 00.03

3'-4" A.F.F

MICROWAVE

FRIDGE

26 05 00.05

C2

C

C

C

27 00 00.01

27 00 00.02

3'-4" A.F.F

26 05 00.08

27 00 00.06

C2

C

TV

06 10 00.B1

01 ADDENDUM #1 MAY 19, 2020

REV. / DESCRIPTION DATE

kuenyarch.com ©2020 Kueny Architects L.L.C. - All Rights Reserved

PLAN NORTH

KEYNOTE LEGEND

SCALE: As indicated

2IT200Kenosha County - Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project

April 24, 2020

Area 02 - Technology & Electrical Plans

912 56th St, Kenosha, WI 53140

Spec. # Description

06 10 00.B1 PROVIDE ALL REQUIRED BLOCKING FOR ACCESSORIES;

GRAB BARS, CABINETS AND MECHANICAL FIXTURES

26 05 00.01 RELOCATE LIGHT SWITCH LOCATION; NEW LOCATION PER

PLAN

26 05 00.03 FIELD VERIFY EXISTING OUTLET LOCATIONS; MINIMUM (01)

OUTLETS REQUIRED IN ADDITION TO OUTLET LOCATIONS

SHOWN ON PLAN; BASED ON EXISTING CONDITIONS

COORDINATE LOCATION WITH OWNER

26 05 00.05 EXISTING ELECTRICAL PANEL

26 05 00.08 NEW CIRCUITS FOR AREA 02 TO EXISTING ELECTRICAL

PANEL; COORDINATE CIRCUIT AVAILABILITY WITH COUNTY

27 00 00.01 NEW CARD READER LOCATION; CONTRACTOR TO PROVIDE

CABLE PULL AND CARD READER ROUGH IN

27 00 00.02 ALL REMODEL AREA 02 NEW DATA LOCATIONS TO ROUTE

BACK TO EXISTING IT 2112; COORDINATE WITH COUNTY IT;

CONTRACTOR TO PROVIDE ALL DATA PULL

27 00 00.06 RELOCATE EXISTING CARD TO NEW LOCATION; GENERAL

CONTRACTOR TO PROVIDE ALL NEW CABLE PULL AND

ROUGH IN; NEW LOCATION PER PLANS

2"

8' -6

8'-4 1/4"

BR PANEL

1'-6"

BR PANEL

6'-10 1/4"

3A300

First Floor 0'-0"

EXISTING ACOUSTICAL

CEILING TO REMAIN; SEE

REFLECTED CEILING PLANS

(09 29 00) 5/8" GYPSUM BOARD

FINISH (09 91 00) PAINT PER ROOM

FINISH SCHEDULE

(08 14 29) WOOD DOOR; BULLET

RESISTANT UL RATED LEVEL III;

SEE SPECIFICATIONS

3100A waiting

(09 29 00) BULLET REISITANT WALL

SYSTEML UL RATED LEVEL III; SEE

SPECIFICATIONS

(09 65 00) WALL BASE PER ROOM

FINISH SCHEDULE

(08 56 71) ARMORTEX BULLET

RESISTANT HOLLOW METAL

WINDOW SYSTEM - UL RATED

LEVEL III; SEE SPECIFICATIONS

(06 61 00) SOLID SURFACE

COUNTER TOP

(08 56 71) VOICE PORT; LEVEL III

RATED SYSTEM

(08 56 71) PASS THRU TRAY;

LEVEL III RATED SYSTEM

(09 91 00) PAINT PER ROOM

FINISH SCHEDULE

reception waiting

8' -6

2' -6

1'-6"2'-0"

(09 51 00) ACOUSTICAL CEILING SYTEMS;

SEE REFELCTED CEILING PLANS

(09 29 00) GYPSUM BOARD WALL FINISH;

PAINT PER ROOM FINISH SCHEDULE

(08 56 71) BULLET RESISTANT HOLLOW

METAL WINDOW SYSTEM; SEE

SPECIFICATIONS

(08 56 71) VOICE PORT; SEE

SPECIFICATIONS

(08 56 71) PASS THRU TRAY; SEE

SPECIFICATIONS

(06 61 00) SOLID SURFACE

COUNTER TOP

(09 29 00) BALLISTIC GRADE FIBER GLASS

PANEL; UL RATING LEVEL III

(09 29 00) GYPSUM BOARD WALL FINISH;

PAINT PER ROOM FINISH SCHEDULE

(06 61 00) SOLID SURFACE COUNTER

TOP SUPPORT BRACKET

KC Basement 0'-0"

FI

EL

D

VE

RI

FY

E

XI

ST

IN

G C

EI

LI

NG

H

EI

G

HT

7'

-1 0"8'

-1 0"

(09 51 00.01) ACOUSTICAL CEILING

SYSTEM; SEE ROOM FINISH

SCHEDULES AND CEILING PLAN

1' -0

FI

EL

D

VE

RI

F Y

E

XI

ST

IN

G F

LO

O

R

ST

R U

CT

UR

E

HE

IG

H T

'-1

/8

(09 29 00.07) 3-5/8" METAL STUD

WALL

(09 29 00.C4) ANCHOR METAL STUD

WALL TO EXISTING FLOOR

(09 29 00.08) BRACE METAL STUD

WALL TO EXISTING FLOOR

STRUCTURE

(09 29 00.01) 5/8" GYPSUM WALL

BOARD; PAINT PER SCHEDULE

(09 65 00.02) 4" VINYL WALL BASE

PER ROOM FINISH SCHEDULE

(07 21 00.B1) BATT INSULATION

3'-0" 2'-1" 3'-0"

8'-1"

3' -0

UNDER

COUNETR

FRIDGE

BY OWNER

(06 10 00) PROVIDE ALL REQUIRED

BLOCKING FOR ACCESSORIES;

GRAB BARS, CABINETS AND

MECHANICAL FIXTURES

(09 51 00) ACOUSTICAL CEILING

SYSTEM; SEE SPECIFICATIONS

(06 61 00) SOLID SURFACE COUNTER

TOP; SEE SPECIFICATIONSSINK FAUCET; PROVIDED BY

OWNER - INSTALLED BY G.C.

(06 40 00) BASE CABINET;

SIZE PER ELEVATIONS AND

DETAILS

(09 29 00) 5/8" GYPSUM BOARD

FINISH; (09 91 00) PAINT PER ROOM

FINISH SCHEDULE

(09 65 00) WALL BASE PER ROOM

FINISH SCHEDULE2'

-1 0"

3102A

5'-8" 3'-4" 4 7/8"2'-10" 10'-6 7/16" hall

8' -6

First Floor 0'-0"

3A300

(09 51 00) EXISTING ACOUSTICAL

CEILING; SEE REFLECTED CEILING

PLANS

(09 29 00) 5/8" GYPSUM BOARD

FINISH (09 91 00) PAINT PER ROOM

FINISH SCHEDULE

(08 14 29) WOOD DOOR; BULLET

RESISTANT UL REATED LEVEL III;

SEE SPECIFICATIONS

(09 29 00) BULLET RESISTANT WALL

SYSTEM UL RATED LEVEL III; SEE

SPECIFICATIONS

(09 65 00) WALL BASE PER ROOM

FINISH SCHEDULE

(08 56 71) ARMORTEX BULLET

RESISTANT HOLLOW METAL

WINDOW SYSTEM - UL RATED

LEVEL III; SEE SPECIFICATIONS

(06 61 00) SOLID SURFACE

COUNTER TOP

(08 56 71) VOICE PORT; LEVEL III

RATED SYSTEM

(08 56 71) PASS THRU TRAY;

LEVEL III RATED SYSTEM

(09 91 00) PAINT PER ROOM

FINISH SCHEDULE

3100A

1'-6" 3'-0" 10 1/4" 3'-0" 1'-6"

9'-10 1/4"4'-1 3/4" 5 5/16"

2' -6

2' -1

0" 5'

-8

3111A3110A3109A

8' -6

7' -2 hall

FIELD VERIFY EXISTING DIMENSION

18'-11 1/8"

(09 51 00) ACOUSTICAL CEILING

SYSTEM; SEE SPECIFICATIONS

(09 29 00) 5/8" GYPSUM BOARD

FINISH; (09 91 00) PAINT PER ROOM

FINISH SCHEDULE

(09 65 00) WALL BASE PER ROOM

FINISH SCHEDULE

(08 11 00) HOLLOW METAL DOOR

FRAME

3107A

13'-3 1/2"7'-2 7/8"3'-0"

6"

(09 51 00) ACOUSTICAL CEILING

SYSTEM; SEE SPECIFICATIONS

(09 29 00) 5/8" GYPSUM BOARD

FINISH; (09 91 00) PAINT PER ROOM

FINISH SCHEDULE

(09 65 00) WALL BASE PER ROOM

FINISH SCHEDULE

(08 11 00) HOLLOW METAL DOOR

FRAME

hall

01 ADDENDUM #1 MAY 19, 2020

REV. / DESCRIPTION DATE

kuenyarch.com ©2020 Kueny Architects L.L.C. - All Rights Reserved SCALE: As indicated

3A300Kenosha County - Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project

April 24, 2020

Area 03 - Sections and Details

912 56th St, Kenosha, WI 53140

3/8" = 1'-0"3 Waiting 301 - East

3/4" = 1'-0"7 Bullet Resistant Counter - Reception 302 1/2" = 1'-0"8 Typical 3-5/8" Stud Wall - Area 03

3/8" = 1'-0"22 Hall 3104 - West Kitchenette

3/8" = 1'-0"1 Hall 3103 - North 3/8" = 1'-0"2 Reception 3101 - West

3/8" = 1'-0"5 Hall 3108 - East 3/8" = 1'-0"4 Hall 3108 - North

3A300

EXISTING CEILING

TO REMAIN

EXISTING CEILING

TO REMAIN

02 05 00.L202 05 00.L2

02 05 00.L2 02 05 00.L2

02 05 00.L2 02 05 00.L2

02 05 00.L2

02 05 00.L2

02 05 00.L2

02 05 00.L202 05 00.L2

02 05 00.L2

02 05 00.L2

A.F.F.

EXISTING 2X2 ACT

8' - 6"

A.F.F.

EXISTING 2X2 ACT

8' - 6"

A.F.F.

2X2 ACT

8' - 6"

A.F.F.

EXISTING 2X2 ACT

8' - 6"

A.F.F.

2X2 ACT

8' - 6"

A.F.F.

EXISTING 2X2 ACT

8' - 6"

A.F.F.

EXISTING 2X2 ACT

8' - 6"

A.F.F.

EXISTING 2X2 ACT

8' - 6"

A.F.F.

2X2 ACT

8' - 6"

A.F.F.

EXISTING 2X2 ACT

8' - 6"

A.F.F.

EXISTING 2X2 ACT

8' - 6"

A.F.F.

2X2 ACT

8' - 6"

*SEE 3M200 FOR NEW SUPPLY AND RETURN AIR LOCATION. ALL DUCT WORK TO BE

COORDINATED AROUND LIUGHT FIXTURES

EXISTING CEILING SCHEDULE - REMODEL AREA 03

DESCRIPTION EXISTING TOTAL

EXISTING 2X4 TROFFER LIGHT FIXTURE

RELOCATED

(PER PLAN) DEMOLISHED

EXISTING 2X2 TROFFER LIGHT FIXTURE

41 EA.

EXISTING TO

REMAIN

31 EA. 10 EA. 0 EA.

4 EA. 0 EA. 3 EA. 1 EA.

ALTERNATE #2 - UPGRADE ALL LIGHT FIXTURES TO LED - COUNTY TO PURCHASE

LIGHT FIXTURES - G.C. TO INSTALL

EXISTING CEILING

TO REMAIN

EXISTING CEILING

TO REMAIN

*SEE PROPOSED CEILING PLAN FOR CEILING TYPES; ALTERNATE #2

TO BE THE UPGRADING OF ALL LIGHT FIXTURES IN THE AREA OF WORK

TO 2X2 LED FIXTURES SUPPLIED BY THE COUNTY AND INSTALLED BY THE G.C.

WORK INCLUDED IN ALTERNATE #3 WILL BE THE REPLACMENT OF ACT TILES

AND PATCHING OF CEILING GRID FOR NEW DESIGN.

09 51 00.03

*SEE 3M200 FOR NEW SUPPLY AND RETURN AIR LOCATION. ALL DUCT WORK TO BE

COORDINATED AROUND LIUGHT FIXTURES

1. REMOVE LOOSE PAINT AND

MISCELLANEOUS HANGING OBJECTS

FROM WALLS AND CEILINGS AT ALL

AREAS TO RECEIVE NEW FINISHES.

2. PATCH AND REPAIR ALL EXISTING

FLOOR SLABS AND WALL SURFACES

DAMAGED FROM DEMOLITION OR

PRIOR USE.

3. PATCH ALL AREAS OF ELECTRICAL

AND MECHANICAL DEMOLITION THAT

WILL NOT BE REUSED.

4. CONTRACTOR TO FIELD VERIFY ALL

EXISTING DIMENSIONS AND

CONDITIONS. IN THE EVENT OF A

DISCREPANCY BETWEEN THE

DRAWINGS AND THE EXISTING

CONDITIONS, NOTIFY THE ARCHITECT

BEFORE PROCEEDING.

5. DO NOT REMOVE ANY ITEMS WHICH

JEOPARDIZE THE STRUCTURAL

INTEGRITY OF THE BUILDING. IF

HIDDEN ELEMENTS OR DETERIORATED

ELEMENTS ARE ENCOUNTERED,

NOTIFY THE ARCHITECT IMMEDIATELY.

6. PROTECT ALL ADJACENT AREAS AND

ITEMS "TO REMAIN" DURING

DEMOLITION/CONSTRUCTION.

REPAIR/REPLACE ALL ITEMS DAMAGED

DURING CONSTRUCTION.

7. EXISTING BUILDING CONDITIONS

SHOWN ON THESE DRAWINGS ARE

DERIVED FROM DRAWINGS OF THE

ORIGINAL BUILDING AND FROM LIMITED

FIELD OBSERVATION.

8. THE CONTRACTOR SHALL PROVIDE

AND MAINTAIN ADDITIONAL MEANS OF

EGRESS AS NEEDED AS A RESULT OF

CONSTRUCTION SEQUENCING AND/OR

REGULATORY REQUIREMENTS.

GENERAL PROJECT NOTES

01 ADDENDUM #1 MAY 19, 2020

REV. / DESCRIPTION DATE

kuenyarch.com ©2020 Kueny Architects L.L.C. - All Rights Reserved

PLAN NORTH

KEYNOTE LEGEND

SCALE: As indicated

3A400Kenosha County - Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project

April 24, 2020

Area 03 - Ceiling Plans

912 56th St, Kenosha, WI 53140

1/4" = 1'-0"1 Area 03 - Ceiling Plan - Proposed

Spec. # Description

02 05 00.L2 RELOCATED EXISTING LIGHT FIXTURE; ACT CEILING TO BE

PATCHED AND REPLACED AS NEEDED FOR NEW LIGHTING

DESIGN

09 51 00.03 NEW 2X2 LIGHT FIXTURE; FIXTURE PROVIDED BY OWNER AND

INSTALLED BY G.C.

1/8" = 1'-0"2 Alternate #2 - Area 03 - Ceiling Plan

C R

C R waiting reception office hall existing office existing office office office office hall existing conference storage

27 00 00.01

27 00 00.04

27 00 00.05

C

C 2 C

C

C2

C2

C2

C2

C

FRIDGE OUTLET

MICROWAVE OUTLET

3'-4" A.F.F.

3'-4" A.F.F.

existing electrical room

26 05 00.09

20 AMP

DEDICATED COPY/PRINT

C

C

TV

27 00 00.06

01 ADDENDUM #1 MAY 19, 2020

REV. / DESCRIPTION DATE

kuenyarch.com ©2020 Kueny Architects L.L.C. - All Rights Reserved

PLAN NORTH

KEYNOTE LEGEND

SCALE: As indicated

3IT200Kenosha County - Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project

April 24, 2020

Area 03 - Technology & Electrical Plans

912 56th St, Kenosha, WI 53140

Spec. # Description

26 05 00.09 NEW CIRCUITS FOR AREA 03 TO EXISTING ELECTRICAL PANEL;

COORDINATE CIRCUIT AVAILABILITY WITH COUNTY

27 00 00.01 NEW CARD READER LOCATION; CONTRACTOR TO PROVIDE

CABLE PULL AND CARD READER ROUGH IN

27 00 00.04 RELOCATE EXISTING UNDER COUNTER DOOR OPEN SYSTEM

TO NEW LOCATION; PROPOSED LOCATION

27 00 00.05 RELOCATE EXISTING UNDER COUNTER DOOR OPEN SYSTEM

TO NEW LOCATION; EXISTING LOCATION

27 00 00.06 RELOCATE EXISTING CARD TO NEW LOCATION; GENERAL

CONTRACTOR TO PROVIDE ALL NEW CABLE PULL AND

ROUGH IN; NEW LOCATION PER PLANS

EX

F

C-

EX

F

C-

EX

F

C-

EX FC-9EX FC-7

EX

F

C-

X

8" DIAMETER

230 CFM

12 X 8

8" DIAMETER

230 CFM

8" DIAMETER

120 CFM

8" DIAMETER

120 CFM

8" DIAMETER

120 CFM

X

8" DIAMETER

200 CFM

6" DIAMETER

80 CFM

20 X 8

8" DIAMETER

125 CFM

10" DIAMETER

320 CFM

10" DIAMETER

320 CFM

8" DIAMETER

135 CFM

16 X 8

X

X

8" DIAMETER

190 CFM

8" DIAMETER

150 CFM

EXISTING TO

REMAIN

EXISTING TO

REMAIN

EXISTING

TO

REMAIN

EXISTING

TO

REMAIN

EXISTING TO

REMAIN

EXISTING TO

REMAIN

EXISTING TO

REMAIN

23 05 00.06

23 05 00.07 existing reception existing waiting existing conference existing stair existing office existing office existing office existing storage existing office existing electrical existing hall existing vestibule existing vestibule existing office existing reception

23 05 00.06

23 05 00.07

23 05 00.06

23 05 00.07

23 05 00.06

23 05 00.07

23 05 00.07

23 05 00.07

23 05 00.07

23 05 00.0923 05 00.09

8 X 6

X

T

23 05 00.10

23 05 00.11

23 05 00.06

23 05 00.12

T 23 05 00.12

T

FC-7

FC-8

FC-9

23 05 00.11

EX

F

C-

EX

F

C-

EX

F

C-

EX FC-9EX FC-7

EX

F

C-

DUCTOWRK TO BE COORDINATED AROUND ALL LIGHT

FIXTURES. SEE CEILING PLANS

X8

12 x 8

X

20 X 8

16 X 8

X

X

23 05 00.08

23 05 00.08

23 05 00.05

23 05 00.08

23 05 00.08 reception waiting office hall existing office existing office office hall office office existing conference

23 05 00.03

23 05 00.05

23 05 00.07

23 05 00.06

23 05 00.06

23 05 00.07

23 05 00.02

23 05 00.07

23 05 00.0623 05 00.06

23 05 00.07

T

T

T

FC-7

FC-8

FC-9

23 05 00.13

23 05 00.03

1. ALL DUCTWORK IS DIAGRAMMATIC

AND COORDINATEDTO THE BEST

AVAILABLE INFORMATION.

CONTRACTOR SHALL VERIFY

STRUCTURE AND LOCATION OF OTHER

TRADES PRIOR TO FABRICATION

2. LIMIT FIXTURE RUNS TO A MAXIMUM OF

5'-0" AND ROUTE AS STRAIGHT AS

POSSIBLE.

3. SYSTEM SHALL BE BALANCED BY THE

INSTALLING CONTRACTOR. BALANCE

AIR FLOWS FOR GRILLES AND

EQUIPMENT TO +/- 10% OF SCHEDULED

AIRFLOWS. INCLUDE SYSTEM

MANUFACTURER, MODEL, SERIAL

NUMBER, RPM, HORSEPOWER,

VOLTAGE, AMPERAGE, ETC. IN

REPORTS. SUBMIT THE BALANCING

REPORTS TO THE DESIGN

PROFESSIONAL BEFORE A

COMPLIANCE STATEMENT CAN BE

SUBMITTED.

4. MECHANICAL LOW VOLTAGE WIRING

SHALL BE BY THE HVAC CONTRACTOR.

5. COORDINATE DIFFUSER LAYOUT WITH

LIGHTING LAYOUT.

6. THE CONTRACTOR SHALL PROVIDE

THE OWNER WITH WRITTEN

INSTRUCTION FOR THE OPERATION

AND MAINTENANCE OF THE SYSTEM

AND EQUIPMENT.

7. THERMOSTAT LOCATIONS SHALL BE

REVIEWED BY THE OWNER, TENANT

AND CONTRACTOR BEFORE

INSTALLATION. CONTROLS SHALL BE

LOCATED 48" ABOVE FINISH FLOOR

8. PROVIDE VOLUME DAMPER AT ALL

LOCATION WHERE NEW DUCT LEAVES

MAIN TRUCK DUCT.

GENERAL MECHANICAL NOTES

01 ADDENDUM #1 MAY 19, 2020

REV. / DESCRIPTION DATE

kuenyarch.com ©2020 Kueny Architects L.L.C. - All Rights Reserved

PLAN NORTH

KEYNOTE LEGEND

SCALE: As indicated

3M200Kenosha County - Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project

April 24, 2020

Area 03 - HVAC Plan

912 56th St, Kenosha, WI 53140

3/16" = 1'-0"1 Area 03 - HVAC Plan - Existing

3/16" = 1'-0"2 Area 03 - HVAC Plan - Proposed

Spec. # Description

23 05 00.02 RELOCATED SUPPLY AIR

23 05 00.03 RELOCATED RETURN AIR

23 05 00.05 NEW RETURN AIR

23 05 00.06 EXISTING RETURN AIR TO REMAIN

23 05 00.07 EXISTING SUPPLY AIR TO REMAIN; MECHANICAL

CONTRACTOR TO FIELD VERIFY LOCATION AND DUCT

DIAMETER - TYPICAL AT ALL SUPPLY AIR LOCATIONS

23 05 00.08 NEW FLEX DUCT TO RELOCATED AIR SUPPLY; BALANCE PER

MECHANICAL CONTRACTOR DESIGN

23 05 00.09 RELOCATE EXISTING SUPPLY AIR TO NEW LOCATION; SEE

PROPOSED HVAC PLAN

23 05 00.10 EXISTING DUCT TO REMAIN

23 05 00.11 RELOCATE EXISTING AIR RETURN; SEE PROPOSED PLAN FOR

NEW LOCATION

23 05 00.12 EXISTING THERMOSTAT TO REMAIN; MECHANICAL

CONTRACTOR TO FIELD VERIFY ALL LOCATIONS

23 05 00.13 RELOCATE THERMOSTAT LOCATION FOR FC-9

Pre-Bid Sign in Sheet

May 7, 2020

COMPANY NAME PERSON NAME E-MAIL PHONE BIDDING DIVISION

PETER SCHWABE, INC TIM CRAWLEY TCRAWLEY@PSHWABE.COM 262.765.9688 GENERAL CONTRACTOR

KPH CONSTRUCTION CORP. BRYAN HENNE ESTIMATING@KPHBUILDS.COM 414.647.1530 GENERAL CONTRACTOR

STUCKEY CONST. COMPANY ED STUCKEY ESTUCKEY@STUCKEYCONSTRUCTION.COM 847.336.8575 GENERAL CONTRACTOR

ABSOLUTE CONSTRUCTION MIKE WIEDENBECK MWIEDENBECK@ABSOLUTECONSTRUCTION.COM 262.456.6802 GENERAL CONTRACTOR

JUST MECHANICAL CHRIS WITT CHRISW@JUSTSERVICEINC.COM 262.364.9385 HVAC

VALIANT ELECTRIC JEFF HUBER JEFF@VALIANTELECTRIC.COM 262.657.7070 ELECTRICAL / LOW VOLTAGE

RASCH CONSTRUCTION STEVE RASCH STEVE@RASCHCONSTRUCTION.COM 262.657.6542 GENERAL CONTRACTOR

ELECTRICAL SYSTEMS SEAN MEEHAN SEANMEEHAN@ESSELECTRIC.COM 262.818.1768 ELECTRICAL / LOW VOLTAGE

MJ RUSSELL CONSTRUCTION MARK RUSSELL MJRUSSELLBUILDERS@GMAIL.COM 815.289.3282 GENERAL CONTRACTOR

Kenosha County – Victim Witness, Juvenile Intake and District Attorney Relocation and Partial Remodel Project – Kenosha County Courthouse and Molinaro Building

KCJIDA_Sign in Sheet - Attendance