UPDATED_Solicitation No. 191N3025Q0004-Fire Engine for AC_ALL CHANGES IN BOLD AND HIGHLIGHTED YELLOW.pdf

Solicitation No. 191N3025Q0004

Enclosure:

Solicitation # 191N3025Q0004

Scope of Work

TABLE OF CONTENTS

A. SF-18: COVER SHEET

B. PRICING

C. STATEMENT OF WORK

D. PACKAGING AND MARKING

E. INSPECTION AND ACCEPTANCE

F. DELIVERIES AND PERFORMANCE

G. CONTRACT ADMINISTRATION DATA

H. SPECIAL TERMS AND CONDITIONS

I. CLAUSES

J. INSTRUCTIONS ON HOW TO SUBMIT A QUOTATION

K. EVALUATION CRITERIA

L. REPRESENTATIONS, CERTIFICATIONS AND OTHER STATEMENTS

SECTION A - PRICING

A. PRICE

The Contractor shall complete all work, including furnishing all labor, material, equipment, and services required under this purchase order for the following firm fixed price and within the time specified. This price shall include all labor, materials, all insurances, overhead and profit.

Total Price (including all labor, materials, overhead and profit)

A.1 GOODS AND SERVICES TAX (GST).

The Contractor shall include GST as a separate line item in the quotation and charge as a separate line item on the invoices.

A.2 LINE ITEMS

The Contractor shall complete all work, including furnishing all labor, material, equipment and services required under this purchase order for the following firm fixed price and within the time specified herein.

This price shall include all labor, materials, overhead and profit.

Line

Item

Description QTY Unit price

(INR)

GST Total

(INR)

001 Supply of equipment and materials for replacement of Engine Driven Fire Pump at the American Center Kolkata, 38A, Jawaharlal Nehru Road, Kolkata – 700 071

(India).

Cost of equipment/materials only:

Pricing breakdown to be provided separately.

Yield – 750 GPM

Horizontal Centrifugal Pumps

1 Lot

002 Installation, testing and commissioning of

Fire Pump.

Cost of labor including overhead and profit.

Pricing breakdown to be provided separately.

1 Job

SECTION B - STATEMENT OF WORK

SEE THE ATTACHED SCOPE OF WORK

SECTION C - PACKAGING AND MARKING

Mark materials delivered to the site as follows:

C.1 The Contractor shall follow the below instructions for import of materials, if applicable:

In case the offeror needs to import any equipment/materials from overseas to India, the Consulate will work with the concerned ministry of the local government to obtain the prior permission for duty-free import before the consignment is shipped. The contractor shall wait until a green signal is given for shipment by the Consulate. The contractor shall provide an Invoice-cum-Packing List that reflects the item description (with brochure, if available), model, quantity, and value, to obtain clearance from the

Ministry of External Affairs (MEA).

The following information shall be mentioned on the shipment documents for the subject shipment:

Description: DIPLOMATIC CARGO-OFFICE SUPPLIES (Item description…… make, model and serial number of the cargo/item, if any)

Value: _____________ for Customs Purpose Only (NCV)

Shipper:

Shipper’s name

Shipper’s address

Consignee:

American Consulate General

5/1 Ho Chi Minh Sarani

Kolkata 700071, India

Port of shipment (by sea): Kolkata Port

Port of shipment (by Air): NSCB International Airport, Kolkata

Airport code: CCU

SECTION D - INSPECTION AND ACCEPTANCE

The COR, or his/her authorized representatives, will inspect from time to time the services being performed and the supplies furnished to determine whether work is being performed in a satisfactory manner, and that all supplies are of acceptable quality and standards.

The Contractor shall be responsible for any countermeasures or corrective action, within the scope of this contract, which may be required by the Contracting Officer as a result of such inspection.

D.1 SUBSTANTIAL COMPLETION

(a) "Substantial Completion" means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the

Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

(1) do not interfere with the intended occupancy or utilization of the work, and

(2) can be completed or corrected within the time period required for final completion.

(b) The "date of substantial completion" means the date determined by the Contracting Officer or authorized Government representative as of which substantial completion of the work has been achieved.

Use and Possession upon Substantial Completion - The Government shall have the right to take possession of and use the work upon substantial completion. Upon notice by the Contractor that the work is substantially complete (a Request for Substantial Completion) and an inspection by the Contracting

Officer or an authorized Government representative (including any required tests), the Contracting

Officer shall furnish the Contractor a Certificate of Substantial Completion. The certificate will be accompanied by a Schedule of Defects listing items of work remaining to be performed, completed, or corrected before final completion and acceptance. Failure of the Contracting Officer to list any item of work shall not relieve the Contractor of responsibility for complying with the terms of the contract. The

Government's possession or use upon substantial completion shall not be deemed an acceptance of any work under the contract.

D.2 FINAL COMPLETION AND ACCEPTANCE

D.2.1 "Final completion and acceptance" means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.

D.2.2 The "date of final completion and acceptance" means the date determined by the Contracting

Officer when final completion of the work has been achieved, as indicated by written notice to the

Contractor.

D.2.3 FINAL INSPECTION AND TESTS. The Contractor shall give the Contracting Officer at least five (5) days advance written notice of the date when the work will be fully completed and ready for final inspection and tests. Final inspection and tests will be started not later than the date specified in the notice unless the Contracting Officer determines that the work is not ready for final inspection and so informs the Contractor.

D.2.4 FINAL ACCEPTANCE. If the Contracting Officer is satisfied that the work under the contract is complete (with the exception of continuing obligations), the Contracting Officer shall issue to the

Contractor a notice of final acceptance and make final payment upon:

• Satisfactory completion of all required tests,

• A final inspection that all items by the Contracting Officer listed in the Schedule of Defects have been completed or corrected and that the work is finally complete (subject to the discovery of defects after final completion), and

• Submittal by the Contractor of all documents and other items required upon completion of the work, including a final request for payment (Request for Final Acceptance).

SECTION E - DELIVERIES AND PERFORMANCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

(APR 1984)

The Contractor shall be required to:

(a) commence work under this contract within 30 calendar (or earlier) calendar days after the date the Contractor receives the notice to proceed,

(b) prosecute the work diligently, and,

(c) complete the entire work ready for use not later than 60 calendar days after NTP.

The time stated for completion shall include final cleanup of the premises and completion of punch list items.

52.211-12 LIQUIDATED DAMAGES - CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, or any extension, the Contractor shall pay liquidated damages to the Government in the amount of $100,000.00

USD or its equivalent in local currency (INR). for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Default clause.

CONTRACTOR'S SUBMISSION OF CONSTRUCTION SCHEDULES

(a) The time for submission of the schedules referenced in FAR 52.236-15, "Schedules for

Construction Contracts", paragraph (a), is hereby modified to reflect the due date for submission as “10 calendar days after receipt of an executed contract".

(b) These schedules shall include the time by which shop drawings, product data, samples and other submittals required by the contract will be submitted for approval.

(c) The Contractor shall revise such schedules (1) to account for the actual progress of the work, (2) to reflect approved adjustments in the performance schedule, and (3) as required by the

Contracting Officer to achieve coordination with work by the Government and any separate contractors used by the Government. The Contractor shall submit a schedule, which sequences work so as to minimize disruption at the job site.

(d) All deliverables shall be in the English language and any system of dimensions (English or metric) shown shall be consistent with that used in the contract. No extension of time shall be allowed due to delay by the Government in approving such deliverables if the Contractor has failed to act promptly and responsively in submitting its deliverables. The Contractor shall identify each deliverable as required by the contract.

(e) Acceptance of Schedule: When the Government has accepted any time schedule; it shall be binding upon the Contractor. The completion date is fixed and may be extended only by a written contract modification signed by the Contracting Officer. Acceptance or approval of any schedule or revision thereof by the Government shall not:

(1) Extend the completion date or obligate the Government to do so,

(2) Constitute acceptance or approval of any delay, or

(3) Excuse the Contractor from or relieve the Contractor of its obligation to maintain the progress of the work and achieve final completion by the established completion date.

NOTICE OF DELAY

If the Contractor receives a notice of any change in the work, or if any other conditions arise which are likely to cause or are actually causing delays which the Contractor believes may result in late completion of the project, the Contractor shall notify the Contracting Officer. The Contractor’s notice shall state the effect, if any, of such change or other conditions upon the approved schedule, and shall state in what respects, if any, the relevant schedule, or the completion date should be revised. The Contractor shall give such notice promptly, not more than ten (10) days after the first event giving rise to the delay or prospective delay. Only the Contracting Officer may revise the approved time schedule.

NOTICE TO PROCEED

(a) After receiving and accepting any bonds or evidence of insurance, the Contracting Officer will provide the Contractor a Notice to Proceed. The Contractor must then prosecute the work, commencing and completing performance not later than the time period established in the contract.

(b) It is possible that the Contracting Officer may elect to issue the Notice to Proceed before receipt and acceptance of any bonds or evidence of insurance. Issuance of a Notice to Proceed by the

Government before receipt of the required bonds or insurance certificates or policies shall not be a waiver of the requirement to furnish these documents.

WORKING HOURS

All work shall be performed during 9:00am to 6:00pm IST Other hours, if requested by the Contractor, may be approved by the Contracting Officer's Representative (COR). The Contractor shall give 24 hours in advance to COR who will consider any deviation from the hours identified above. Changes in work hours, initiated by the Contractor, will not be a cause for a price increase.

PRECONSTRUCTION CONFERENCE

A preconstruction conference will be held within 10 days after contract award at the American Center

Kolkata to discuss the schedule, submittals, notice to proceed, mobilization and other important issues that effect construction progress. See FAR 52.236-26, Preconstruction Conference.

DELIVERABLES - The following items shall be delivered under this contract:

Description Quantity Deliver Date Deliver To

Section G. Securities/Insurance 1 10 days after award CO

Section E. Construction Schedule 1

Within 10 days after award COR

Section E. Preconstruction Conference 1

Within 10 days after award COR

Section G. Personnel Biographies 1 10 days after award COR

Section F. Payment Request 1

Last calendar day of each month COR

Section D. Request for Substantial Completion 1

15 days before inspection COR

Section D. Request for Final Acceptance 1

5 days before inspection COR

SECTION F – CONTRACT ADMINISTRATION DATA

652.242-70 CONTRACTING OFFICER'S REPRESENTATIVE (COR) (AUG 1999)

(a) The Contracting Officer may designate in writing one or more Government employees, by name or position title, to take action for the Contracting Officer under this contract. Each designee shall be identified as a Contracting Officer’s Representative (COR). Such designation(s) shall specify the scope and limitations of the authority so delegated; provided, that the designee shall not change the terms or conditions of the contract, unless the COR is a warranted Contracting Officer, and this authority is delegated in the designation.

(b) The COR for this contract is Rohit Soni – Engineer (Civil), New Delhi.

Payment: The Contractor's attention is directed to Section H, 52.232-5, "Payments Under Fixed-

Price Construction Contracts". The following elaborates on the information contained in that clause.

Requests for payment, may be made no more frequently than monthly. Payment requests shall cover the value of labor and materials completed and in place, including a prorated portion of overhead and profit.

After receipt of the Contractor's request for payment, and on the basis of an inspection of the work, the

Contracting Officer shall make a determination as to the amount, which is then due. If the Contracting

Officer does not approve payment of the full amount applied for, less the retainage allowed by in 52.232-

5, the Contracting Officer shall advise the Contractor as to the reasons.

Under the authority of 52.232-27(a), the 14 day period identified in FAR 52.232-27(a)(1)(i)(A) is hereby changed to 30 days.

The Contractor shall show Goods and Services Tax (GST) as a separate item on invoices submitted for payment.

The Contractor shall show Goods and Services Tax (GST) as a separate item on invoices submitted for payment.

SECTION G - SPECIAL TERMS AND CONDITIONS

G.1.0 PERFORMANCE/PAYMENT PROTECTION - The Contractor shall furnish some form of payment protection as described in 52.228-13 in the amount of 50% of the contract price.

G.1.1 The Contractor shall provide the information required by the paragraph above within ten (10) calendar days after award. Failure to timely submit the required security may result in rescinding or termination of the contract by the Government. If the contract is terminated, the Contractor will be liable for those costs as described in FAR 52.249-10, Default (Fixed-Price Construction), which is included in this purchase order.

G.1.2 The bonds or alternate performance security shall guarantee the Contractor's execution and completion of the work within the contract time. This security shall also guarantee the correction of any defects after completion, the payment of all wages and other amounts payable by the Contractor under its subcontracts or for labor and materials, and the satisfaction or removal of any liens or encumbrances placed on the work.

G.1.3 The required securities shall remain in effect in the full amount required until final acceptance of the project by the Government. Upon final acceptance, the penal sum of the performance security shall be reduced to 10% of the contract price. The security shall remain in effect for one year after the date of final completion and acceptance, and the Contractor shall pay any premium required for the entire period of coverage.

G.2.0 INSURANCE - The Contractor is required by FAR 52.228-5, "Insurance - Work on a

Government Installation" to provide whatever insurance is legally necessary. The Contractor shall at its own expense provide and maintain during the entire performance period the following insurance amounts:

G.2.1 GENERAL LIABILITY (includes premises/operations, collapse hazard, products, completed operations, contractual, independent contractors, broad form property damage, personal injury):

(1) Bodily injury on or off the site, stated in U.S. dollars:

Per Occurrence $10,000.00 USD

Cumulative $30,000.00 USD

(2) Property damage on or off the site, stated in U.S. dollars:

Per Occurrence $10,000.00 USD

Cumulative $30,000.00 USD

G.2.2 The foregoing types and amounts of insurance are the minimums required. The Contractor shall obtain any other types of insurance required by local law or that are ordinarily or customarily obtained in the location of the work. The limit of such insurance shall be as provided by law or sufficient to meet normal and customary claims.

G.2.3 The Contractor agrees that the Government shall not be responsible for personal injuries or for damages to any property of the Contractor, its officers, agents, servants, and employees, or any other person, arising from and incident to the Contractor's performance of this contract. The Contractor shall hold harmless and indemnify the Government from any and all claims arising therefrom, except in the instance of gross negligence on the part of the Government.

G.2.4 The Contractor shall obtain adequate insurance for damage to, or theft of, materials and equipment in insurance coverage for loose transit to the site or in storage on or off the site.

G.2.5 The general liability policy required of the Contractor shall name "the United States of America, acting by and through the Department of State", as an additional insured with respect to operations performed under this contract.

G.3.0 DOCUMENT DESCRIPTIONS

G.3.1 SUPPLEMENTAL DOCUMENTS: The Contracting Officer shall furnish from time to time such detailed drawings and other information as is considered necessary, in the opinion of the Contracting

Officer, to interpret, clarify, supplement, or correct inconsistencies, errors or omissions in the Contract documents, or to describe minor changes in the work not involving an increase in the contract price or extension of the contract time. The Contractor shall comply with the requirements of the supplemental documents, and unless prompt objection is made by the Contractor within 20 days, their issuance shall not provide for any claim for an increase in the Contract price or an extension of contract time.

G.3.1.1. RECORD DOCUMENTS. The Contractor shall maintain at the project site:

(1) a current marked set of Contract drawings and specifications indicating all interpretations and clarification, contract modifications, change orders, or any other departure from the contract requirements approved by the Contracting Officer; and,

(2) a complete set of record shop drawings, product data, samples and other submittals as approved by the Contracting Officer.

G.3.1.2 . "As-Built" Documents: After final completion of the work, but before final acceptance thereof, the Contractor shall provide:

(1) a complete set of "as-built" drawings, based upon the record set of drawings, marked to show the details of construction as actually accomplished; and,

(2) record shop drawings and other submittals, in the number and form as required by the specifications.

G.4.0 LAWS AND REGULATIONS - The Contractor shall, without additional expense to the

Government, be responsible for complying with all laws, codes, ordinances, and regulations applicable to the performance of the work, including those of the host country, and with the lawful orders of any governmental authority having jurisdiction. Host country authorities may not enter the construction site without the permission of the Contracting Officer. Unless otherwise directed by the Contracting Officer, the Contractor shall comply with the more stringent of the requirements of such laws, regulations, and orders and of the contract. In the event of a conflict between the contract and such laws, regulations and orders, the Contractor shall promptly advise the Contracting Officer of the conflict and of the Contractor's proposed course of action for resolution by the Contracting Officer.

G.4.1 The Contractor shall comply with all local labor laws, regulations, customs, and practices pertaining to labor, safety, and similar matters, to the extent that such compliance is not inconsistent with the requirements of this contract.

G.4.2 The Contractor shall give written assurance to the Contracting Officer that all subcontractors and others performing work on or for the project have obtained all requisite licenses and permits.

G.4.3 The Contractor shall submit proper documentation and evidence satisfactory to the Contracting

Officer of compliance with this clause.

G.5.0 CONSTRUCTION PERSONNEL - The Contractor shall maintain discipline at the site and at all times take all reasonable precautions to prevent any unlawful, riotous, or disorderly conduct by or among those employed at the site. The Contractor shall ensure the preservation of peace and protection of persons and property in the neighborhood of the project against such action. The Contracting Officer may require, in writing that the Contractor remove from the work any employee that the Contracting Officer deems incompetent, careless, insubordinate or otherwise objectionable, or whose continued employment on the project is deemed by the Contracting Officer to be contrary to the Government's interests.

G.5.1 If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately give notice, including all relevant information, to the Contracting Officer.

G.5.2 After award, the Contractor has ten calendar days to submit to the Contracting Officer a list of workers and supervisors assigned to this project for the Government to conduct all necessary security checks. It is anticipated that security checks will take 15-20 days to perform. For each individual, the list shall include:

Full Name

Place and Date of Birth

Current Address

Copy of Government Photo ID

Failure to provide any of the above information may be considered grounds for rejection and/or resubmittal of the application. Once the Government has completed the security screening and approved the applicants a badge will be provided to the individual for access to the site. This badge may be revoked at any time due to the falsification of data, or misconduct on site.

G.5.3 The Contractor shall provide an English speaking supervisor on site at all times. This position is considered as key personnel under this purchase order.

G.6.0 Materials and Equipment - All materials and equipment incorporated into the work shall be new and for the purpose intended, unless otherwise specified. All workmanship shall be of good quality and performed in a skillful manner that will withstand inspection by the Contracting Officer.

G.7.0 SPECIAL WARRANTIES

G.7.1 Any special warranties that may be required under the contract shall be subject to the stipulations set forth in 52.246-21, "Warranty of Construction", as long as they are not in conflict.

G.7.2 The Contractor shall obtain and furnish to the Government all information required to make any subcontractor's, manufacturer's, or supplier's guarantee or warranty legally binding and effective. The

Contractor shall submit both the information and the guarantee or warranty to the Government in sufficient time to permit the Government to meet any time limit specified in the guarantee or warranty, but not later than completion and acceptance of all work under this contract.

G.8.0 EQUITABLE ADJUSTMENTS

Any circumstance for which the contract provides an equitable adjustment that causes a change within the meaning of paragraph (a) of the "Changes" clause shall be treated as a change under that clause; provided, that the Contractor gives the Contracting Officer prompt written notice (within 20 days) stating:

(a) the date, circumstances, and applicable contract clause authorizing an equitable adjustment and

(b) that the Contractor regards the event as a changed condition for which an equitable adjustment is allowed under the contract

The Contractor shall provide written notice of a differing site condition within 10 calendar days of occurrence following FAR 52.236-2, Differing Site Conditions.

G.9.0 ZONING APPROVALS AND PERMITS

The Government shall be responsible for:

- obtaining proper zoning or other land use control approval for the project

- obtaining the approval of the Contracting Drawings and Specifications

- paying fees due for the foregoing; and,

- for obtaining and paying for the initial building permits.

SECTION H - CLAUSES SECTION H - CLAUSES

COMMERCIAL ITEMS

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This purchase order or BPA incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this address: Acquisition.gov this address is subject to change.

DOSAR clauses may be accessed at: https://acquisition.gov/dosar

FEDERAL ACQUISTION REGULATION (48 CFR CHAPTER 1) CLAUSES:

NUMBER TITLE DATE

52.204-7 SYSTEM FOR AWARD MANAGEMENT

NOV 2024

52.204-9 PERSONAL IDENTITY VERIFICATION OF

CONTRACTOR PERSONNEL

JAN 2011

52.204-13 SYSTEM FOR AWARD MANAGEMENT

MAINTENANCE

OCT 2018

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE

REPORTING

AUG 2020

52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE

MAINTENANCE

AUG 2020

52.204-25

PROHIBITION ON CONTRACTING FOR CERTAIN

TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT

NOV 2021

52.212-1 INSTRUCTIONS TO OFFERORS—COMMERCIAL

PRODUCTS AND COMMERCIAL SERVICES

MAR 2023

52.212-4 CONTRACT TERMS AND CONDITIONS—

COMMERCIAL ITEMS

NOV 2023

52.213-4 SIMPLIFIED ACQUISITIONS (OTHER THAN

COMMERCIAL PRODUCTS AND COMMERCIAL

SERVICES) (JAN 2025) (DEVIATION FEB 2025)

FEB 2025

+++52.222-6 Construction Wage Rate Requirements (AUG 2018)

(DEVIATION FEB 2025)

52.223-17

AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED

ITEMS IN SERVICE AND CONSTRUCTION

CONTRACTS

AUG 2018

-- CONTRACTOR PERSONNEL IN A DIPLOMATIC OR

CONSULAR MISSION OUTSIDE THE UNITED STATES

MAY 2020

52.227-19 COMMERCIAL COMPUTER SOFTWARE LICENSE DEC 2007

https://acquisition.gov/browse/index/far https://acquisition.gov/dosar

52.228-3 WORKERS’COMPENSATION INSURANCE JUL 2014

52.228-4 WORKERS’ COMPENSATION AND WAR-HAZARD

INSURANCE

APR 1984

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL

BUSINESS SUBCONTRACTORS

MAR 2023

52.244-6 SUBCONTRACTS FOR COMMERCIAL ITEMS

MAR 2023

52.246-26 REPORTING NONCONFORMING ITEMS

NOV 2021

52.222-9 APPRENTICES AND TRAINEES (JUL 2005)(DEVIATION

FEB 2025)

FEB 2025

52-222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014)

(DEVIATION FEB 2025

52-222-12

CONTRACT TERMINATION-DEBARMENT (MAY 2014)

(DEVIATION FEB 2025)

FEB 2025

52.244-6 SUBCONTRACTS FOR COMMERCIAL PRODUCTS AND

COMMERCIAL SERVICES (JAN 2025) (DEVIATION FEB

2025)

THE FOLLOWING CLAUSES ARE PROVIDED IN FULL TEXT:

CYBERSECURITY SUPPLY CHAIN RISK MANAGEMENT REQUIREMENTS (FEB 2023)

(a)Definitions. As used in this clause:

Covered article - The term "covered article" includes-

(1)"Information and Communications technology" which means--

(i)any equipment or interconnected system or subsystem of equipment, used in the automatic acquisition, storage, analysis, evaluation, manipulation, management, movement, control, display, switching, interchange, transmission, or reception of data or information by the executive agency, if the equipment is used by the executive agency directly or is used by a contractor under a contract with the executive agency that requires the use of that equipment, or of that equipment to a significant extent in the performance of a service or the furnishing of a product.

(ii)computers, ancillary equipment (including imaging peripherals, input, output, and storage devices necessary for security and surveillance), peripheral equipment designed to be controlled by the central processing unit of a computer, software, firmware and similar procedures, services (including support services), and related resources; however, does not include any equipment acquired by a federal contractor incidental to a federal contract.

(2)"Telecommunications Equipment", which means equipment, other than customer premises equipment, used by a carrier to provide telecommunications services, and includes software integral to such equipment (including upgrades).

(3)"Telecommunications Service", which means the offering of telecommunications for a fee directly to the public, or to such classes of users as to be effectively available directly to the public, regardless of the facilities used.

(4)“Cybersecurity Supply Chain Risk”, which means the risk that a person may sabotage, maliciously introduce unwanted function, extract data, or otherwise manipulate the design, integrity, manufacturing, production, distribution, installation, operation, maintenance, disposition, or retirement of covered articles to surveil, deny, disrupt, or otherwise manipulate the function, use, or operation of the covered articles or information stored or transmitted on the covered articles.

(b)Contractor Cybersecurity Supply Chain Risk Management Responsibilities. The Contractor shall take all prudent actions and comply with all Government direction (as identified in paragraph (c)) to regularly identify, assess, monitor, and mitigate cybersecurity supply chain risks when providing covered articles or services affecting covered articles to the Government. The Contractor shall maintain artifacts that document its compliance with this paragraph and shall provide these artifacts to the Government within

48 hours of request.

(c) Supporting Government Cybersecurity Supply Chain Risk Assessments. The Government may perform a cybersecurity supply chain risk assessment at any time during contract administration to identity, assess, and monitor the cyber risks of the Contractor’s supply chain. The Contractor agrees that the Government may, at its own discretion, perform on-site assessments to collect information for the cybersecurity supply chain risk assessment. In performing the cybersecurity supply chain risk assessment, the Government may review any information provided by the Contractor, along with any other information available to the

Government from public, unclassified, classified, or any other sources. Examples of information that the

Government may collect for the cybersecurity supply chain risk assessment includes the following:

1. Functionality and features of covered articles, including access to data and information system privileges.

2. The user environment where a covered article is used or installed.

3. The ability of a source to produce and deliver covered articles as expected.

4. Foreign control of, or influence over, a source or covered article (e.g., foreign ownership, personal and professional ties between a source and any foreign entity or legal regime of any foreign country in which a source is headquartered or conducts operations).

5. Implications to Government mission(s) or assets, national security, homeland security, or critical functions associated with use of a source or covered article.

6. Vulnerability of Federal systems, programs, or facilities.

7. Market alternatives to the covered source.

8. Potential impact or harm caused by the possible loss, damage, or compromise of a product, material, or service to an organization’s operations or mission.

9. Likelihood of a potential impact or harm, or the exploitability of a system.

10. Security standards of the supplier as demonstrated by cooperation with assessments.

11. Security, authenticity, and integrity of covered articles and their supply and compilation chain.

12. Capacity to mitigate risks identified.

13. Factors that could lead to inability of the supplier to provide security updates.

14. Factors that may reflect upon the reliability of other supply chain risk information.

15. Any other considerations that would factor into an analysis of the security, integrity, resilience, quality, trustworthiness, or authenticity of covered articles or sources.

(d) Non-Destructive and Destructive Testing. The Government may engage in non-destructive and/or destructive testing of any information system, equipment, and software to determine whether it will negatively affect the security or performance of a Department of State information system.

(e) Novation Agreement Notice. FAR 42.1203 require Government approval of novation agreements. For proposed novation agreements for this contract, the Contractor shall provide any information requested by the Government regarding the proposed successor’s identity and information regarding its supply chain.

(f) Software Bill of Materials (SBOM) Requests. For software, within 10 business days of request by a

Department of State representative, the Contractor shall submit a SBOM to a designated representative.

This request may be requested on one (1) or more occasions and shall be delivered at no increase in contract price.

(g) SBOM Sharing Notice. The Contractor consents to the sharing of its SBOM data with other contractors, such as tool solution providers, for the sole purpose of mapping against known vulnerabilities.

(h) Notification procedures for cybersecurity supply chain events. When cybersecurity supply chain events occur, the Contractor must contact the Contracting Officer or his/her designee within 12 hours of the event.

(i) Subcontracts. The Contractor shall insert the substance of this clause in all subcontracts and other contractual instruments in support of this contract.

(j) Vulnerability Exploitability eXchange (VEX). The Contractor is required to notify the Department of any discovered software vulnerabilities within 12 hours. Within three (3) days, they shall provide a report using a VEX format.

(k) Attestation following Major Version Change. Critical Software, as defined by National Institute for

Science and Technology (NIST) Guidance, that is provided by the Contractor or subcontractors and is modified during the contract’s period of performance by a major version change (e.g., using a semantic versioning schema of Major.Minor.Patch, the software version number goes from 2.5 to 3.0) requires a new self-attestation. For indefinite delivery contract vehicles, this self-attestation must be provided for all critical software available for ordering on the contract vehicle when the software is modified during the contract vehicle’s ordering period of performance by a major version change. The Contractor shall either

(i) post the new attestation in a publicly available internet location within 15 days of the major version change and provide the COR, or Contracting Officer if a COR is not appointed, with the internet link or

(ii) shall contact the COR, or Contracting Officer if a COR is not appointed, and request the agency’s current software self-attestation form and submit it to the Government within 15 days of the major version change. The self-attestation form will contain the following elements: (i) the software producer's name;

(ii) a description of which product or products the statement refers to including the number of the major version change; and (iii) a statement attesting that the software producer follows secure development practices and tasks consistent with NIST Guidance.

(End of clause)

52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES

OR EXECUTIVE ORDERS-COMMERCIAL PRODUCTS AND COMMERCIAL

SERVICES (JAN 2025)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (JAN

2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations https://www.acquisition.gov/far/part-52#FAR_52_203_19

Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab and Other Covered Entities (DEC 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance

Services or Equipment. (NOV 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (NOV 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (MAR 2023) ( 31

U.S.C. 3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (AUG 1996) ( 31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (OCT 2004) (Public Laws 108-77 and 108-

78 ( 19 U.S.C. 3805 note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the Contracting

Officer has indicated as being incorporated in this contract by reference to implement provisions of law or

Executive orders applicable to acquisitions of commercial products and commercial services:

__ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (JUN

2020), with Alternate I (NOV 2021) ( 41 U.S.C. 4704 and 10 U.S.C. 4655).

__ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (NOV 2021) ( 41 U.S.C. 3509)).

__ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of

2009 (JUN 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

__ (4) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (JUN

2020) (Pub. L. 109-282) ( 31 U.S.C. 6101 note).

__ (5) [Reserved].

__ (6) 52.204-14, Service Contract Reporting Requirements (OCT 2016) (Pub. L. 111-117, section 743 of

Div. C).

__ (7) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (OCT

2016) (Pub. L. 111-117, section 743 of Div. C).

__ (8) 52.209-6, Protecting the Government’s Interest When Subcontracting with Contractors Debarred, Suspended, or Proposed for Debarment. (JAN 2025) ( 31 U.S.C. 6101 note).

__ (9) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (OCT

2018) ( 41 U.S.C. 2313).

__ (10) [Reserved].

__ (11) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (OCT 2022) ( 15 U.S.C. 657a).

__ (12) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (OCT

2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) ( 15 U.S.C. 657a).

https://www.acquisition.gov/far/part-52#FAR_52_204_23 https://www.acquisition.gov/far/part-52#FAR_52_204_25 https://www.acquisition.gov/far/part-52#FAR_52_209_10 https://www.acquisition.gov/far/part-52#FAR_52_232_40 https://www.govinfo.gov/link/uscode/31/3903 https://www.govinfo.gov/link/uscode/31/3903 https://www.govinfo.gov/link/uscode/10/3801 https://www.acquisition.gov/far/part-52#FAR_52_233_3 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_233_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_203_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.govinfo.gov/link/uscode/10/4655 https://www.acquisition.gov/far/part-52#FAR_52_203_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_203_15 https://www.acquisition.gov/far/part-52#FAR_52_204_10 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_204_14 https://www.acquisition.gov/far/part-52#FAR_52_204_15 https://www.acquisition.gov/far/part-52#FAR_52_209_6 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title31-section6101&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_209_9 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title41-section2313&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_219_3 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title15-section637a&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_219_4 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3

__ (13) [Reserved]

__ (14) (i) 52.219-6, Notice of Total Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (MAR 2020) of 52.219-6.

__ (15)

(i) 52.219-7, Notice of Partial Small Business Set-Aside (NOV 2020) ( 15 U.S.C. 644).

__ (ii) Alternate I (MAR 2020) of 52.219-7.

__ (16) 52.219-8, Utilization of Small Business Concerns (JAN 2025) ( 15 U.S.C. 637(d)(2) and (3)).

__ (17)

(i) 52.219-9, Small Business Subcontracting Plan (JAN 2025) ( 15 U.S.C. 637(d)(4)).

__ (ii) Alternate I (NOV 2016) of 52.219-9.

__ (iii) Alternate II (NOV 2016) of 52.219-9.

__ (iv) Alternate III (JAN 2025) of 52.219-9.

__ (v) Alternate IV (JAN 2025) of 52.219-9.

__ (18)

(i) 52.219-13, Notice of Set-Aside of Orders (MAR 2020) ( 15 U.S.C. 644(r)).

__ (ii) Alternate I (MAR 2020) of 52.219-13.

__ (19) 52.219-14, Limitations on Subcontracting (OCT 2022) ( 15 U.S.C. 637s).

__ (20) 52.219-16, Liquidated Damages—Subcontracting Plan (SEP 2021) ( 15 U.S.C. 637(d)(4)(F)(i)).

__ (21) 52.219-27, Notice of Service-Disabled Veteran-Owned Small Business Set-Aside (FEB 2024)

( 15 U.S.C. 657f).

__ (22) (i) 52.219-28, Post Award Small Business Program Representation (JAN

2025)( 15 U.S.C. 632(a)(2)).

__ (ii) Alternate I (MAR 2020) of 52.219-28.

__ (23) 52.219-29, Notice of Set-Aside for, or Sole-Source Award to, Economically

Disadvantaged Women-Owned Small Business Concerns (OCT 2022) ( 15 U.S.C. 637(m)).

__ (24) 52.219-30, Notice of Set-Aside for, or Sole-Source Award to, Women-Owned Small Business

Concerns Eligible Under the Women-Owned Small Business Program (OCT 2022) ( 15 U.S.C. 637(m)).

__ (25) 52.219-32, Orders Issued Directly Under Small Business Reserves (MAR

2020) ( 15 U.S.C. 644(r)).

__ (26) 52.219-33, Nonmanufacturer Rule (SEP 2021) ( 15U.S.C. 637(a)(17)).

__ (27) 52.222-3, Convict Labor (JUN 2003) (E.O.11755).

https://www.acquisition.gov/far/part-52#FAR_52_219_6 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_6 https://www.acquisition.gov/far/part-52#FAR_52_219_7 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_7 https://www.acquisition.gov/far/part-52#FAR_52_219_8 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_9 https://www.acquisition.gov/far/part-52#FAR_52_219_13 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_13 https://www.acquisition.gov/far/part-52#FAR_52_219_14 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_16 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_27 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_28 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_28 https://www.acquisition.gov/far/part-52#FAR_52_219_29 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_30 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_219_32 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec644.htm https://www.acquisition.gov/far/part-52#FAR_52_219_33 https://www.govinfo.gov/content/pkg/USCODE-2018-title15/html/USCODE-2018-title15-chap14A-sec637.htm https://www.acquisition.gov/far/part-52#FAR_52_222_3

_X_ (28) 52.222-19, Child Labor-Cooperation with Authorities and Remedies (JAN 2025) (E.O.13126).

__ (29): [Reserved]

__ (30) [Reserved]

__ (31) (i) 52.222-35, Equal Opportunity for Veterans (JUN 2020) ( 38 U.S.C. 4212).

__ (ii) Alternate I (JUL 2014) of 52.222-35.

__ (32) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (JUN 2020) ( 29 U.S.C. 793).

__ (ii) Alternate I (JUL 2014) of 52.222-36.

__ (33) 52.222-37, Employment Reports on Veterans (JUN 2020) ( 38 U.S.C. 4212).

__ (34) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (DEC

2010) (E.O. 13496).

_X_ (35)

(i) 52.222-50, Combating Trafficking in Persons (NOV 2021) ( 22 U.S.C. chapter 78 and E.O. 13627).

__ (ii) Alternate I (MAR 2015) of 52.222-50 ( 22 U.S.C. chapter 78 and E.O. 13627).

__ (36) 52.222-54, Employment Eligibility Verification (JAN 2025) (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803.)

__ (37)

(i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA–Designated Items

(May 2008) ( 42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (ii) Alternate I (MAY 2008) of 52.223-9 ( 42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

__ (38) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential

Hydrofluorocarbons (MAY 2024) (E.O. 13693).

__ (39) 52.223-12, Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air

Conditioners (MAY 2024) (E.O. 13693).

__ (40)

(i) 52.223-13, [Reserved]

__ (41)

(i) 52.223-14. [Reserved]

__ (42) 52.223-15, [Reserved]

__ (43) https://www.acquisition.gov/far/part-52#FAR_52_222_19 https://www.acquisition.gov/far/part-52#FAR_52_222_35 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_222_35 https://www.acquisition.gov/far/part-52#FAR_52_222_36 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title29-section793&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_222_36 https://www.acquisition.gov/far/part-52#FAR_52_222_37 http://uscode.house.gov/view.xhtml?req=granuleid:USC-prelim-title38-section4212&num=0&edition=prelim https://www.acquisition.gov/far/part-52#FAR_52_222_40 https://www.acquisition.gov/far/part-52#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_50 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_222_54 https://www.acquisition.gov/far/part-22#FAR_22_1803 https://www.acquisition.gov/far/part-52#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_223_9 http://uscode.house.gov/browse.xhtml;jsessionid=114A3287C7B3359E597506A31FC855B3 https://www.acquisition.gov/far/part-52#FAR_52_223_11 https://www.acquisition.gov/far/part-52#FAR_52_223_12 https://www.acquisition.gov/far/part-52#FAR_52_223_13 https://www.acquisition.gov/far/part-52#FAR_52_223_14 https://www.acquisition.gov/far/part-52#FAR_52_223_15

(i) 52.223-16. [Reserved]

_X_ (44) 52.223-18, [Reserved]

__ (45) 52.223-20, Aerosols (MAY 2024) (E.O. 13693).

__ (46) 52.223-21, Foams (MAY 2024) (E.O. 13693).

__ (47)

(i) 52.224-3 Privacy Training (JAN 2017) (5 U.S.C. 552 a).

__ (ii) Alternate I (JAN 2017) of 52.224-3.

__ (48)

(i) 52.225-1, Buy American-Supplies (OCT 2022) ( 41 U.S.C. chapter 83).

__ (ii) Alternate I (OCT 2022) of 52.225-1.

__ (49)

(i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (NOV 2023) ( 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections

4501-4732), Public Law 103-182, 108-77, 108-78, 108-286, 108-302, 109-53, 109-169, 109-283, 110-

138, 112-41, 112-42, and 112-43.

__ (ii) Alternate I [Reserved].

__ (iii) Alternate II (JAN 2025) of 52.225-3.

__ (iv) Alternate III (FEB 2024) of 52.225-3.

__ (v) Alternate IV (Oct 2022) of 52.225-3.

__ (50) 52.225-5, Trade Agreements (NOV 2023) ( 19 U.S.C. 2501, et seq., 19 U.S.C. 3301 note).

_X_ (51) 52.225-13, Restrictions on Certain Foreign Purchases (FEB 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

__ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct

2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10

U.S.C. Subtitle A, Part V, Subpart G Note).

__ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside…