Amendment 0001.pdf

PDF 3 MB Posted Oct 3, 2025

Attached to: Replace Switchgear at FCI Estill
Solicitation number: 15BFA025B00000036
Issued by: Department of Justice Bureau of Prisons Field Acquisition Office

About this file

Written by GovTribe AI · Oct 3, 2025

This document is an Amendment (SF-30) for Solicitation 15BFA025B00000036 issued by the Federal Bureau of Prisons for a Replace Switchgear project at FCI Estill in South Carolina. Amendment 0001 extends the bid due date to November 4, 2025, at 1:00 pm CST, and incorporates two key updates: the Pre-Bid Conference Meeting Minutes and an updated Construction Wage Determination SC20250013 effective 9/19/2025.

The project involves replacing switchgear at the federal correctional institution, with a project magnitude between $1,000,000 and $5,000,000. The performance period is 430 calendar days after notice to proceed, with work hours restricted to 6:30 am and 3:30 pm Monday through Friday, excluding weekends and federal holidays. Liquidated damages are $1,482.96 per calendar day of delay after scheduled completion. Contractors must adhere to strict security protocols, including providing valid photo identification, maintaining tool accountability, and avoiding contact with inmates. The Davis-Bacon Act applies, requiring workers to be paid according to the specified wage determination.

View the file

Other files

File	Type	Posted
Amendment 0004 .pdf	PDF	Jan 12, 2026
Abstract.pdf	PDF	Nov 19, 2025
Amendment 0003.pdf	PDF	Nov 6, 2025
Amendment 0002.pdf	PDF	Oct 29, 2025
1 - Instructions to Bidders.pdf	PDF	Sep 9, 2025
7 - SF24-Bid Bond 10-2023.pdf	PDF	Sep 9, 2025
2 - Solicitation 15BFA025B00000036.pdf	PDF	Sep 9, 2025
6 - Construction Wage Determination SC20250013 03-14-2025.pdf	PDF	Sep 9, 2025
8 - Criminal History Check Form.pdf	PDF	Sep 9, 2025

On GovTribe

Work with this file

Download the original file
Contacts named in this file
Similar government files
Ask GovTribe AI about this file

Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

1 13

2. AMENDMENT/MODIFICATION NUMBER

3. EFFECTIVE DATE

10/03/2025

4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

23Z3AR1

15BFA0CODE

Federal Bureau of Prisons Field Acquisition Office U.S. Armed Forces Reserve Complex 346 Marine Forces Drive Grand Prairie, TX 75051

Julie Bergami

(O) (202) 598-6019

6. ISSUED BY 15B305CODE7. ADMINISTERED BY (If other than Item 6)

Federal Bureau of Prisons FCI Estill 100 Prison Road Estill, SC 29918

9A. AMENDMENT OF SOLICITATION NUMBER

15BFA025B00000036

CODE FACILITY CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, country, state and ZIP Code) (X)

X 9B. DATED (SEE ITEM 11)

09/09/2025

10A. MODIFICATION OF CONTRACT/ORDER

NUMBER

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods: (a) By completing items 8 and 15, and returning __1__copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

ORDER NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return _______ copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Amendment 0001 is hereby issued to incorporate the following into Invitation for Bids 15BFA025B00000036:

1) Incorporate Pre-Bid Site Visit Meeting Minutes and Sign-In Sheet (see attached);

2) Update Construction Wage Determination SC20250013, effective 9/19/2025 (see attached); and

3) Extend bid due date to November 4, 2025, no later than 1:00 pm CST.

End of Amendment 0001

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

Julie Bergami Contracting Officer

(Signature of person authorized to sign)

15B. CONTRACTOR/OFFEROR 15C. DATE SIGNED

By (Signature of Contracting Officer)

16B. UNITED STATES OF AMERICA 16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

15B30525PR000039

15BFA025B00000036/0001 Page 1 of 13 bop01431 Highlight bop01431 Typewritten Text X

PRE-BID CONFERENCE MEETING MINUTES

15BFA025B00000036 – REPLACE SWITCHGEAR

FCI ESTILL - PROJECT 23Z3AR1

1 | P a g e

DATE: Tuesday, September 23, 2025, at 9:00 am local time Place: FCI Estill Camp’s Visitation Room, 100 Prison Road, Estill, SC

ADMINISTRATIVE CONTRACTING OFFICER: Jakisha Butts

I. INTRODUCTIONS:

Round table introduction of all attendee’s.

II. PURPOSE OF MEETING:

Indicate the purpose of this meeting is to familiarize the contractor with the unique circumstances and requirements surrounding a correctional setting. This meeting is also to explain the solicitation, as issued, and not to furnish additional information.

State - nothing said here shall be interpreted as a change to the solicitation without the issuance of a formal amendment through the FAO Contracting Officer, Julie Bergami.

III. MINUTES:

Advised minutes will be recorded and distributed via System for Award Management at www.sam.gov.

IV. SITE VISIT INFORMATION:

Walk to selected site for Replace Switchgear immediately following the meeting.

V. FRONT COVER PAGE FORMS AND INSTRUCTIONS:

Note the instructions on the cover letter in the Solicitation that all bids be submitted electronically through the JEFS APP BOX per Section V. Electronic Bid Submission & Bid Opening instructions:

FEDERAL BUREAU OF PRISONS

U.S. ARMED FORCES RESERVE COMPLEX

ATTN: JULIE BERGAMI, CONTRACTING OFFICER, FAO

346 MARINE FORCES DRIVE

GRAND PRAIRIE, TX 75051

VI. TIME FRAMES AND LOCATION FOR SUBMISSION OF BIDS:

State the deadline for submission of bids for this project is October 21, 2025, by 1:00 CST. Per the above mentioned instructions.

VII. GENERAL TOPICS:

The following submission/completion items will be addressed:

15BFA025B00000036/0001 Page 2 of 13

FCI ESTILL - PROJECT 23Z3AR1

2 | P a g e

1. From the solicitation, each bidder SHALL complete and submit the following forms, clauses, and statements with his/her bid. Failure to do so may cause your bid to be considered as non-responsive:

STANDARD FORM 1442 Pages 1 & 2: Please include Unique Entity Identifier (UEI) number and Tax ID# and e-mail address where indicated in block 10 and complete blocks 14-20c. If your company has a “doing business as” name reflected in you SAM registration, include this name as well in Block 14. Ensure the address typed in block 14 matches the address in your System for Award Management (SAM) registration.

PAST PERFORMANCE SUBMISSION: Please ensure the Cover letter is reviewed and complied with its entirety. References and banking submissions must be submitted in advance to the bid opening directly to jbergami@bop.gov via email.

COMMODITY OR SERVICES SCHEDULE (PAGE 4): Complete the Unit Price (JB = job) and Amount blocks (these amounts will be the same). Note: The amounts listed in this section should be the same as the amount listed in block 17 of the SF-1442.

BID GUARANTEE: See Page 5 of the solicitation. A bid bond must be submitted in original (ink signatures) with your solicitation. The penal sum of the bond must be at least 20% of the bid price, not to exceed $3 million, whichever is less. A blank bid bond was included in the solicitation. The bid bond must be from a Government approved surety. A list of approved sureties can be located on the Department of Treasury, Bureau of the Fiscal Service website.

REPRESENTATIONS AND CERTIFICATIONS: All contractors submitting a bid must be registered in the System for Award Management (SAM) at www.sam.gov with the North American Industry Classification Standard code (NAICS) 238210 which is applicable to this acquisition.

FAR PROVISION 52.204-8: Pursuant to the section (b) (1) of this provision, provision 52.204-7 is included in this solicitation. Bidders should not mark either of the two options under section (b) (2).

Leave these options unmarked.

FAR PROVISION 52.204-24: Offerors shall complete section (d) as applicable.

FAR PROVISION 52.209-7: Offerors shall complete section (b) as applicable.

FAR PROVISION 52.209-13: Offerors should mark as applicable either (b)(1) or (b)(2). If (b)(2) is applicable, please follow additional instructions provided.

FAR PROVISION 52.229-11: Offerors shall complete section (d) as applicable.

PAST PERFORMANCE: Past performance information should be submitted prior to bid closing.

AMENDMENTS: Amendments (if any) must be acknowledged and submitted with the bid by one of the methods as described in item eleven of the Standard Form 30.

15BFA025B00000036/0001 Page 3 of 13

FCI ESTILL - PROJECT 23Z3AR1

3 | P a g e

2. Other general items to be addressed:

DAVIS BACON ACT: This contract is subject to the Davis Bacon Act. Wage Decision SC20250013 is applicable for this area. All applicable workers must be paid according to the terms of the wage decision.

LICENSING AND PERMITS: All required licensing and permits are required to be obtained by the contractor who receives contract award.

MAGNITUDE: The magnitude of the project is between $1,000,000 and $5,000,000.

WORK HOURS: Work hours within the secure perimeter shall be between 6:30 am and 3:30 pm Monday through Friday excluding weekends and federal holidays.

COR: The Contracting Officer’s Representative (COR) is Tyler McGhie, Facilities Manager at FCI Estill.

PERIOD OF PERFORMANCE: The completion period is 430 calendar days after issuance of notice to proceed.

TIME EXTENSIONS: Time extensions for inclement weather will not be granted unless the weather is unusually severe and abnormal in comparison to prior years.

LIQUIDATED DAMAGES: Liquidated damages for this project are in the amount of $1,482.96 per calendar day of delay after scheduled completion.

PRE-CONSTRUCTION CONFERENCE: A Pre-Construction conference is required after the contract is awarded and will be scheduled accordingly.

PROGRESS SCHEDULE: A copy of the progress schedule is to be provided to the Administrative

Contracting Officer and COR as soon as possible. Each time the progress schedule is changed, it must be provided to both the Administrative Contracting Officer and COR. It is suggested an updated document be provided by the Prime Contractor at the mandatory monthly progress meeting.

PROGRESS MEETINGS: Progress meetings are mandatory and will be scheduled monthly.

PAYMENT REQUESTS: Application for payments is to be submitted on AIA G702(Continuation) or the contractors own form as long as the information is similar to the G702. Contactors can get these forms from the following website www.aiabookstore.com

QUESTIONS: Oral questions asked at Site Visit of a technical nature are not acceptable due to the possibility of misunderstanding or misinterpretation. All questions shall be sent in WORD FORMAT to Julie Bergami, FAO Contracting Officer, via email at jbergami@bop.gov. In order to provide sufficient response time prior to the bid due date, the Government has established that questions be submitted no later than Friday, September 26, 2025, at 12:00 pm, CST.

15BFA025B00000036/0001 Page 4 of 13

4 | P a g e

ACCESS TO SITE/PARKING OF VEHICLES: Parking will be provided for employee vehicles and contractor work vehicles.

STORAGE OF MATERIALS: Storage of materials will be coordinated with the COR.

CONTRACTOR TEMPORARY OFFICE: No temporary office space will be provided.

INSPECTIONS: "Punch List" items generated by inspections will be corrected and discrepancy items re-inspected and approved before contract closure takes place. Should any work be covered without proper notification, the contractor shall uncover that work for inspection at his own expense.

SAFETY MANAGER (Garett Rousu):

3. SAFETY POINTS:

The contractor is responsible for providing required protective gear to all contractor workers, should it be required. Contractor will ensure that all workers have proper safety gear at all times.

Contractor is responsible for the prevention of accidents on the project site and has spill kit onsite and containment procedures. OSHA requirements will be adhered to.

The Contractor will have a Safety Representative on site at all times during the completion of this project.

Proper storage of any chemicals in lay down yard with SDS present.

CAPTAIN (Felipe Rodriguez):

4. SECURITY

ADVERSE WEATHER: Whenever adverse weather conditions or other institution emergency contingencies are in effect, contract workers will not be permitted passage into the secure institution. Should emergency conditions be implemented while contract workers are inside the secure perimeter, they will be required to secure their tools, remove vehicles and equipment, and leave the institution grounds until the emergency situation has been resolved.

Depending upon the nature of the emergency, this normally will not affect any construction outside of the secure perimeter. Contractor is reminded that fog days will be treated like rain days. The performance period of 430 days will allow adequate time to complete the job, and no consideration will be allowed for normal rain days and normal fog days. The normal rain, snow or fog days will be based on the average over the last ten (10) years for the local community.

15BFA025B00000036/0001 Page 5 of 13

5 | P a g e

SECURITY CLEARANCES: Contract workers are subject to security investigative procedures.

Please refer to the contract for details. Please refer to Page 8 of the contract.

EMPLOYEE IDENTIFICATION: Contractor personnel working on project site must bring valid photo identification to the institution each day. The identification will be surrendered upon entry to and returned upon exit from institution property.

TOOL ACCOUNTABILITY: Strict accountability and control of all contractor tools and hazardous materials must be maintained at all times. All contractor tools to be used inside the secure perimeter must be inventoried and accounted for at the conclusion of the workday Contractor tools may not be stored on-site overnight. The contractor should provide for enough time at the conclusion of the workday for the return and accounting of all tools issued during the workday.

Lost or missing tools must be reported to the COR the Captain immediately.

ILLEGAL ITEMS ON FEDERAL PROPERTY: Firearms, ammunition, knives, other weapons, drugs, narcotics, and alcoholic beverages are not permitted inside/outside the secure perimeter or anywhere else on Federal property at any time. This includes the private vehicles of contract workers. Violators will be subject to criminal prosecution. All persons, vehicles, and equipment are subject to search by institution authorities at any time.

NO CONTACT WITH INMATES: Contract workers are not to have any contact with inmates at any time. No photographs may be taken of inmates.

CONTRACTOR EMPLOYEE WORK DRESS: Green or khaki-colored clothing is not allowed, as inmates wear these colors.

PHOTOGRAPHS: The institution’s Facilities Department maintains a digital camera that will be utilized by FBOP staff to document the project work. The Contractor may request copies of these photos and may request that photos be taken for specific conditions. Cellular telephones equipped with photographic capabilities are prohibited on the project construction site.

VIII. ADDITIONAL DISCUSSION:

Any additional discussion should be added here.

Meeting minutes recorded by:

Jakisha Butts, Contract Specialist FCI Estill

JAKISHA BUTTS

Digitally signed by JAKISHA

BUTTS

Date: 2025.09.26 13:27:54 -04'00'

15BFA025B00000036/0001 Page 6 of 13

6 | P a g e

NOTICE:

MEETING MINUTES ARE PROVIDED FOR INFORMATIONAL PURPOSES ONLY. THEY ARE NOT

INTENDED TO CHANGE ANY SPECIFICATIONS, TERMS OR CONDITIONS OF THE

SOLICITATION. ANY AND ALL CHANGES TO THE SOLICITATION SHALL BE ISSUED IN

SUBSEQUENT AMENDMENTS ISSUED BY THE CONTRACTING OFFICER ON A STANDARD

FORM 30 (SF-30).

15BFA025B00000036/0001 Page 7 of 13

15BFA025B00000036/0001 Page 8 of 13

��$��0��" ��1&� ��2� �� 3��4#�

��5 ��$��"��6�� 7�$��6��.8� ��3��*��9� ��.8� ��3��*��9�:&,�� .8� ��3��*��"��

3��

��"�� 0��$ 3�� 2� �� 3��4#�

��5 ��0;��

��2� �� 3��4#�

��+��5 ��0 �� <+��&�/�1/�1&==============================================================>(0��

��>&�.8� ��3��*��9��>>�� 0��-��"��;��>��$��"��

�&��>>��7�� 8��/�&$&;��>&�! ��

��8�� 1�

3��7 �?��>>�0��-��"��;��>��@�A&A�� 7�$��>>��>�� 7�$��>>��>�� ;��0��>>��>�� $ ��1�0 ��>>��>��0

��&��>>==============================>=============================>>(0��

��7��7�� >&�.8� ��3��*��9�:��>> ��7��-��"��;��>��$��"��

��7��

��"��>>�8�� 0��-��"��>��

3��7 ��7�$��>>��>�� 7�$�� ;>>��>��0�� $ ��1�0 ��0

��.8� ��3��*��7�$��7��2��"&�(0��

3��"� 0�� .8� ��3��*�� 0�

��"�0 ��0 0�7

�� 7�$��

�0 ��6��&5�� 0

��6��7 �� .8� ��3��*��3�� 777&� 3�7 ��$

��&B ��0�

15BFA025B00000036/0001 Page 9 of 13

�(�)*+��,�)��-��(�./�$�01��2�(�./��3�4��3��5��(�./� �&1��(�./��"��-��(�./��6��7��8��(�./��6��3�.��9��6��7��8��/��3��6��0��(�.��&�� 0421.��51��&:�� 19��:2��61:�2.��1�8�5��1��4�.�5��3��91��0421.��,61�6��,1�7�3��&:��01��6��.��;�< �91��2��6��.��-��8�5��

��'	��	�/��52:3��1�0�>1�7��<��
�?#�	�+��1001��1��@��2��
�?#�	�+��'�4�2�.��#'	��#�+��?�5761��	A5�8��1��5761��<��'��	�+��?�:�6/��122��3��*4��.��'�'	��	��B��<��'
=$?	�/�	A52:3��%"��'�4��22��1��B��<��*%		��$	��
�>#�C	��D%"��(:5��22��1��#�2.E��=�C�(��"	��B

(	�*�
��5��8��4��5��&�3�91��5��9��4��91�0��14��1��1�,6�56�,�23��5�3��2�FFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFFF��>1�7��6��52��9�5��1��0�.�&��2�3��1��6��6��0��0:0�,��:�3��	A�5:��8��#�3��<�D��B�B�E�1��<��D��E��'2��6��1��6��14�19��6��,��3��0��1��91��01��91�0��1��'2��2�1��1��6��6�0��0:0�,��G:��0��19�	A�5:��8��#�3��<��1�5:��2.�&��91�5�3��1��.�51��5��1��:&51��5��1,6�56��6��19��A��/�

1:��/�1��$��44�/��52:3��6��5��/��4��.�

15BFA025B00000036/0001 Page 10 of 13

��	!�"��#��$��%��	��&&��	��	��
�'�	��(��)*�	��+	��#��,��	��	��	��,��-��	��,��

��-��/��0��1#��	��	��	��-��
��	��	��2

��&��2&��-��,�� &��3�� #�&�� !�� -��0�2&��-��2 ��&��2��

��&��	!��#��,��'
�-��)��	�
��&��	��4��#�2��-�2�2��&��,��!��#�2��-��2&��-��,��'
��)��	�
��&��	��4��#��
��#��2��#�2��-�2�2��&��,��!��#�2��-��2&��-��,��	��2��#��2��	��	��

��!��0��+��#��2��	��	��5
��2��,��!��&��	��

��&��66,,,0��0��6��	��6,��6��2��)	��	��07��	��#�	��#��,��!��	�
��,��	�&��#��	��#�	��2�-��#��,��-��&��	��	��	��
��/8%$9�303��0)))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))))):��-��#��	��,��2��	��#�	��,��#�
��&��#��-&��#�	��
	��&��	��	��-��,��2��0�:��	��#�	��&��	��
��#��	��,��&��

&&��2��	��#�	��07��9��1��#��+�#�
�)��#��,��	��	��;; 7;;��;;7+<=;;��> +>��> %>��
��,��&��#��	��#�	��

��-0��2&��"7?��8@)��3��6��6/�/A0��"7?��#��#��

��,��	��	��-��&��
��-�#��	��#�	��,��	��2&��,�

2��0��8@��

2��	��	�
�	��
2��,��&&��	��0�0��
2��"�	��8@0�:��

2��3��2&�� 2�� &�� ,��2��0�:��6��6/�/A��2&��##� ��#��2�� 07��&��,��

&��#��	��	��2��&��BC(��	��	��2��%*+��	��#�	��07��+��9��1��#��:��7+<=��#��	��&��#��	��#�	��
��D��#��&��#��	��#�	��#��	��

��0��E+?�"��7+<=) C)��6��6/�/A0�7+<=�� ,�� 0� C�� #� ��0:�� 2��2&�� 2��

15BFA025B00000036/0001 Page 11 of 13

��	��	�
�� !�	�

��#��	��#��$��	#��
	��

��		��
�	�

��	�
��"��%�	��#�&�

��	��((%�((��
��	��

�	�
��	��*��+�,-&��.��
	�

��	��#�
	�

��	�
��	��"#�

��	�
��	��

��	��#��
	�

��	��	�
��	�
��	��

��/��0�%�-1��)��23��2��%��

	��
��	��
��	��#��

��-1��

	��
��#��	�

��	�
��	�"��
��"�	��2��

��3��2��

��	�
��	�

�� 4%�4�� 5 ��6��5 � �7�� *657.��

��	�
��	��+�,-&��3�.�.�%

��	��((%�((��
��	��

��	��
��	��

�� +�,�-�&��8*�.)*�.��/��0�%�9/��8)��2��8��%��

��	�
��	��

��9/ �� 9��8��

��	�
��	��"��
��"�	��2��

��8��

��	�
��	�

��4%�4��

��	�
��	��

��)))))))))))))))))))))))))))))))))))))))))))))))))))))))))))6�!/�7/�/&9';��'<;��==/�1%�=&<,/%%�.�5��

�	4��"�0��.��	��#��	�#��
�	��

��657��

	��	��
��	��#��
��"��	��

��657�?	��
��6��%�	��#��&�>��

	�"#��
0��?	��
��6��%�	��#�

15BFA025B00000036/0001 Page 12 of 13

��	�� !��
��"�	��#��

	��
$��$	��	��$��$

	��%
��	��

&��	�'��()��
$�*�	&��	��	��"��
&��	+��'��$��	��	��

��"�.��	��$��"��$�
	�,��

��	��.��/��0!�1�� 2��/��0!�1��3,�!�%
��	��
�#��$	��

	�*�	&��	��	��"��
&��	+��

�� 4��%

&&��	��
��"5��	�

	��"�
��	��
	��.#��"��	6�$��$�

��	��$	��
��&��	��

��7,�-��$

��	��
��	��	��&��

�#�'	��.�	��&"��&��'	��,��
��	+��

�� 8888888888888888888888888888888888888888888888888888888888888888��9��)0�:9�9!��9�-�-)�;��

15BFA025B00000036/0001 Page 13 of 13

File details come from the government source that posted it. Updated Oct 3, 2025.