Amendment_0005_0005.pdf

(x)

140R6021R0005 x x copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR

OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

R60

08/12/20210005

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

Bureau of Reclamation Missouri Basin Region Regional Office PO Box 36900 Billings MT 59107

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

06/21/2021

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Gerri Voto-Braun

STANDARD FORM 30 (REV. 11/2016)

Prescribed by GSA FAR (48 CFR) 53.243

Previous edition unusable

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

GREEN MOUNTAIN POWERPLANT

PENSTOCK REHABILITATION

Colorado-Big Thompson Project, Colorado

See attached for changes incorporated by this amendment.

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

Solicitation No. 140R6021R0005 Amendment No. 0005

Description of Changes: The following changes are hereby incorporated into and made a part of this solicitation:

1) In Section C, remove Section 52 00 00 -Drawings in its entirety and substitute therefore the attached revised Section 52 00 00 -Drawings.

2) Remove Section L in its entirety and substitute therefore the attached revised Section L to include an On-Site Visit on August 20, 2021.

For convenience, essential changes on the revised solicitation pages are indicated by a vertical line in the margin where lines or paragraphs changed from the previous version. However, all portions of the revised solicitation pages shall apply whether changes thereon have or have not been indicated.

Receipt of Bids: The hour and date for receipt of offers remains the same at 1300 (1:00 PM Local Time) on September 3, 2021.

Acknowledgement: See Block 11 above regarding how to acknowledge this amendment. The Government must receive the acknowledgement at the place designated for receipt of bids (See Block 10 of the Standard Form 1442).

Third Party: If you have given a copy of the solicitation to someone else, please forward this amendment accordingly.

Subcontracting Plan – A word version of the template for the subcontracting plan is included as an attachment in SAM.Gov and shall be used by large business concerns in the preparation of their draft subcontracting plan.

Additional questions will be addressed in a subsequent amendment. The Government will not respond to any questions submitted after 5:00 pm MT on August 23, 2021.

Green Mountain Powerplant Penstock Rehabilitation Colorado-Big Thompson Project, Colorado Amendment No. 0005

Drawings

Revised 52 00 00 - 1

SECTION 52 00 00

DRAWINGS

PART 1 GENERAL

1.01 DISCREPANCIES, ERRORS, OR OMISSIONS

A. Inform the CO of discrepancies discovered on drawings in accordance with clause at FAR 52.236-21, Specifications and Drawings for Construction.

B. In accordance with clause at FAR 52.236-21, Specifications and Drawings for Construction, in case of discrepancies, written specifications take precedence over drawings unless otherwise specified.

1.02 PROJECT CONDITIONS

A. Where there are differences as determined by the CO between details and dimensions shown on drawings and details and dimensions of existing features at jobsite, use details and dimensions of existing features at jobsite.

1.03 SPECIFICATION DRAWINGS

A. Reference drawings referred to on specification drawings and not considered necessary for contract purposes are not included in specifications.

1.04 INFORMATION DRAWINGS

A. Drawings marked "For Information Only" in the drawing list are included to show existing features about which knowledge is required to perform work under this contract.

These drawings do not show work to be performed under this contract.

B. If there are differences as determined by the CO between details and dimensions shown on these drawings and those of existing features at jobsite, use details and dimensions of existing features at jobsite.

1.05 STANDARD DRAWINGS

A. Standard drawings may show details which are not a part of work under this contract.

Disregard details shown on these drawings which are not applicable to work under this contract.

1.06 COPIES OF DRAWINGS

A. Two sets of full-size (22 inches by 34 inches) drawings, except standard drawings, will be furnished to the Contractor.

Revised 52 00 00 - 2

B. Upon request, additional half-size (11 inches by 17 inches) copies of standard drawings will be furnished to the Contractor.

1.07 LIST OF DRAWINGS

A. Drawings listed in Table 52 00 00A – List of Drawings, are made a part of Section C – Description/Specifications.

1.08 DRAWING NUMBERS IN NUMERICAL ORDER

A. Specification drawings are listed in numerical order in Table 52 00 00B - Drawings in Numerical Order.

PART 2 PRODUCTS

Not Used

PART 3 EXECUTION

Not Used

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

General:

1 245-D-60046 Location Map

2 245-D-60047 (Rev. 1)

Site Use Plan

3 245-D-60048 (Rev. 1)

Major Work Items – Rehabilitation Plan and Sections

Metalwork:

4 245-D-60065 (Rev. 1)

Miscellaneous Metalwork – Walkway, Landings, and Ladders – Elevation, Plan and Section – Sheet 1 of 1

5 245-D-60066 Miscellaneous Metalwork – Walkways – Plans and Sections

– Sheet 1 of 1

6 245-D-60067 Miscellaneous Metalwork – Pipe Guardrails – Sections and Details – Sheet 1 of 1

7 245-D-60068 (Rev. 1)

Miscellaneous Metalwork – Landing L1 – Plan, Sections, and Details – Sheet 1 of 1

Revised 52 00 00 - 3

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

8 245-D-60069 Miscellaneous Metalwork – Beams and Grating - El.

7704.00 – Plan and Sections – Sheet 1 of 1

Mechanical:

9 245-D-60037 (Rev. 1)

40-Inch Jet-Flow Gate – Installation – Sheet 1

10 245-D-60038 (Rev. 1)

40-Inch Jet-Flow Gate – Assembly – Sheet 2

11 245-D-60039 (Rev. 2)

40-Inch Jet-Flow Gate – List of Parts – Sheet 3

12 245-D-60040 (Rev. 2)

40-Inch Jet-Flow Gate – Upstream Body – Sheet 4

13 245-D-60041 (Rev. 2)

40-Inch Jet-Flow Gate – Downstream Body – Sheet 5

14 245-D-60042 (Rev. 1)

40-Inch Jet-Flow Gate – Bonnet Cover – Seal Ring – Seal Clamp Ring – Sheet 6

15 245-D-60043 (Rev. 2)

40-Inch Jet-Flow Gate – Leaf – Sheet 7

16 245-D-60044 (Rev. 2)

40-Inch Jet-Flow Gate – Stem – Stem Block Key – Stem Block and Spacer – Seats – Seat Brackets – Sheet 8

17 245-D-60045 (Rev. 2)

40-Inch Jet-Flow Gate – Stand – Stem Cover – Gate Bodies Isometric – Sheet 9

18 245-D-60060 (Rev. 1)

3-Inch Air Vent – Sheet 1

19 245-D-60061 14-Inch Air Vents – Sheet 1

20 245-D-60062 Valves and Equipment – Sheet 1

21 245-D-60063 Expansion Joint Packing – Sheet 1

22 245-D-60064 (Rev. 1)

Jet Flow Gate Pipe – Spool – Sheet 1

Electrical:

23 245-D-60071 (Rev. 1)

Conduit Plan – Jet-Flow Gates and Flowmeters – Sheet 1

Revised 52 00 00 - 4

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

24 245-D-60072 (Rev. 1)

Conduit Plan – Jet-Flow Gates Conduit Routing – Details – Sheet 1

25 245-D-60073 (Rev. 2)

Network Diagram – Jet-Flow Gates and Flowmeters Communications – Sheet 1

26 245-D-60074 (Rev. 1)

Single Line Diagram – 240/120 VAC Station Service System – Sheet 1

27 245-D-60075 (Rev. 1)

Cabinet Layout – Jet-Flow Gates – Control Panel – Sheet 1

28 245-D-60077 (Rev. 2)

Block Diagram – Jet-Flow Gates Power and Communications – Sheet 1

29 245-D-60078 Block Diagram – Flowmeters Power and Communications – Sheet 1

30 245-D-60079 Conduit Plan – Flowmeters – Sheet 1

Information Drawings:

31 245-D-406 Green Mountain Dam – General Plan and Sections

32 245-D-410 Green Mountain Dam – Outlet Works – Alinement, Profile and Sections

33 245-D-411 Green Mountain Dam – Outlet Works – Gate Chamber, Shaft and Hoist House

34 245-D-514 Green Mountain Dam – Blue River Bridge – Plan – Elevation – Sections – Sheet 1 of 4

35 245-D-515 Green Mountain Dam – Blue River Bridge – Abutment – Skewbacks – Sheet 2 of 4

36 245-D-516 Green Mountain Dam – Blue River Bridge – Railing – Deck Slab – Floor System – Sheet 3 of 4

37 245-D-517 Green Mountain Dam – Blue River Bridge – Steel Arch – Bearings – Sheet 4 of 4

38 245-D-541 Green Mountain Dam – Blue River Bridge – Deck Slab – Bar Placing Diagram – Sheet 1 of 2

39 245-D-849 Green Mountain Power Plant – General Arrangement – Transverse Sections

Revised 52 00 00 - 5

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

40 245-D-850 Green Mountain Power Plant – General Arrangement – Plan

– Floor El. 7704.0 – 7715.25 – 7724.0

41 245-D-851 Green Mountain Power Plant – General Arrangement – Plan

– Floor El. 7690.00 and Longitudinal Section

42 245-D-1020 Green Mountain Power Plant – Station Service and Control System – Conduit Installation – El. 7700 to El. 7712

43 245-D-1024 Green Mountain Power Plant – Substructure – Concrete Outline – Plan Thru Draft Tubes

44 245-D-1025 Green Mountain Power Plant – Substructure – Concrete Outline – Plan at El. 7690.00 – First Stage

45 245-D-1026 Green Mountain Power Plant – Substructure – Concrete Outline – Plan at El. 7704.00 – First Stage

46 245-D-1027 Green Mountain Power Plant – Substructure – Concrete Outline – Plan at El. 7704.00 – First and Second Stage

47 245-D-1028 Green Mountain Power Plant – Substructure – Concrete Outline – Front and Rear Elevations E-E and K-K

47A 245-D-1029 Green Mountain Power Plant – Substructure – Concrete Outline – Longitudinal Sections H-H and J-J

48 245-D-1030 Green Mountain Power Plant – Substructure – Concrete Outline – Longitudinal Sections F-F and G-G

49 245-D-1032 Green Mountain Power Plant – Substructure – Concrete Outline – Transverse Sections L-L and M-M

50 245-D-1089 Green Mountain Dam – Outlet Works – 44” Tube Valve – Valve to Wall Connection Gland

51 245-D-1090 Green Mountain Dam – Outlet Works – 3” Air Outlet and 14” Air Inlet Pipes above El. 7954.00

52 245-D-1107 Green Mountain Dam – Outlet Works – Penstock Encasement – Concrete Outline – Floor and Sump

53 245-D-1181 Green Mountain Dam – Outlet Works – Gate Chamber Control Piping – General Arrangement

54 245-D-1182 Green Mountain Dam – Outlet Works – Gate Chamber Control Piping – Pressure Supply and Sump Drain Piping

Revised 52 00 00 - 6

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

55 245-D-1183 Green Mountain Dam – Outlet Works – Gate Chamber Control Piping – Seal Control Valve and Gate Blow Off Piping

56 245-D-1184 Green Mountain Dam – Outlet Works – Gate Chamber Control Piping – Gate Air Piping Below El. 7958.50

57 245-D-1195 Green Mountain Dam – Outlet Works – 44” Tube Valve – Control Piping

58 245-D-1205 Green Mountain Dam – Penstocks and Outlet Pipes – Plan and Elevation – Tunnel Portion

59 245-D-1206 Green Mountain Dam – Penstocks and Outlet Pipes – Plan – Embedded Portion

60 245-D-1207 Green Mountain Dam – Penstocks and Outlet Pipes – Sections and Drains

61 245-D-1209 Green Mountain Dam – Penstocks and Outlet Pipes – Expansion Joint and Piezometer Connection

62 245-D-1210 Green Mountain Dam – Penstocks and Outlet Pipes – Supporting Rings

63 245-D-1211 Green Mountain Dam – Penstocks and Outlet Pipes – Branch Outlet

64 245-D-1212 Green Mountain Dam – Penstocks and Outlet Pipes – Flanges and Turbine Connections

65 245-D-1213 Green Mountain Dam – Penstocks and Outlet Pipes – Manholes

66 245-D-1214 Green Mountain Dam – Penstocks and Outlet Pipes – Stair and Walkway – Sheet 1 of 2

67 245-D-1215 Green Mountain Dam – Penstocks and Outlet Pipes – Stair and Walkway – Sheet 2 of 2

68 245-D-1217 Green Mountain Power Plant – Miscellaneous Structural Steel – Hatch Frames – Covers - Rails

69 245-D-1245 Green Mountain Power Plant – Architectural Elevations and Details

Revised 52 00 00 - 7

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

70 245-D-1248 Green Mountain Power Plant – Superstructure – Concrete Outline – Plan at El. 7724.00

71 245-D-1260 Green Mountain Power Plant – Superstructure – Concrete Outline – Transverse Sections

72 245-D-1276 Green Mountain Dam – Outlet Works – 44” Regulating Tube Valve – Installation – Sheet 1 of 1

73 245-D-1277 Green Mountain Dam – Outlet Works – 44” Regulating Tube Valve – Assembly – Sheet 1 of 8

74 245-D-1279 Green Mountain Dam – Outlet Works – 44” Regulating Tube Valve – Body – Sheet 3 of 8

75 245-D-1280 Green Mountain Dam – Outlet Works – 44” Regulating Tube Valve – Bearing Carrier – Stem Cap – Bearing – Sheet

76 245-D-1281 Green Mountain Dam – Outlet Works – 44” Regulating Tube Valve – Bevel Gear – Pinion – Shaft – Seal – Ring – Sheet 5 of 8

77 245-D-1283 Green Mountain Dam – Outlet Works – 44” Regulating Tube Valve – Tube – Seat Ring – Gland – Packing – Sheet 7 of 8

78 245-D-1285 Green Mountain Dam – Outlet Works – 44” Regulating Tube Valve Control – Assembly – Sheet 1 of 8

79 245-D-1301 Green Mountain Power Plant – Drainage of Powerhouse Area – Sections – Sheet 2 of 2

80 245-D-1526 Green Mountain Power Plant – Substructure – Concrete Outline – Sectional Plan at Elevation 7704.00 – Second Stage

81 245-D-1527 Green Mountain Power Plant – Substructure – Concrete Outline – Sectional Plan Thru Passageways – Second Stage

82 245-D-1528 Green Mountain Power Plant – Substructure – Concrete Outline – Longitudinal Sections – Second Stage – Sheet 1 of 2

83 245-D-1531 Green Mountain Power Plant – Substructure – Concrete Outline – Transverse Sections and Plan of Generator Foundation – Second Stage

Revised 52 00 00 - 8

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

84 245-D-1544 Green Mountain Dam – Outlet Works – Penstock Encasement – Plan at El. 7709.00 – Concrete Outline

85 245-D-1546 Green Mountain Dam – Outlet Works – Penstock Encasement – Sections – Concrete Outline

86 245-D-1554 Green Mountain Dam – Outlet Works – Penstock Tunnel – Electrical Installation

87 245-D-1678 Green Mountain Dam – Outlet Works – Pressure Supply and Penstock Drain Lines

88 245-D-1692 Green Mountain Dam – Outlet Works – Gate Chamber Tunnel Plug – 102” Ring Seal Gates - Reinforcement

89 245-D-1693 Green Mountain Dam – Outlet Works – Gate Chamber Tunnel Plug – 102” Conduits and Inlet Transition – Reinforcement

90 245-D-1719 Green Mountain Dam – Outlet Works – Gate Chamber Tunnel Plug – Concrete Outline

91 245-D-1720 Green Mountain Dam – Outlet Works – Gate Chamber Tunnel Plug – Inlet Transition – Interior Outline

92 245-D-1779 Green Mountain Power Plant – Station Service and Control System – Exposed Conduit – Details – El. 7690.0 to El.

7722.00

93 245-D-9601 Green Mountain Powerplant and Switchyard – Electrical Installation – Equipment Location Key Plan

94 245-D-60024 Stoplog Layout – Installation – Sheet 1 of 1

95 245-600-1916 Green Mountain Powerplant – Repairs to Stoplog Guides – Plan and Section A-A – Sheet 1 of 3

96 245-600-1915 Green Mountain Powerplant – Repairs to Stoplog Guides – Sections, Typical Pier, and Detail – Sheet 2 of 3

97 245-713-1543 Green Mountain Powerplant – Outlet Works – Bypass Valves - Control Cabinet SX Schematic Diagram – Sheet 1 of 1

98 245-713-1544-01 Green Mountain Powerplant – Outlet Works – Bypass Valves – Control Cabinet SX, S7, & S8 – Wiring Diagram – Sheet 1 of 3

Revised 52 00 00 - 9

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

99 245-713-1544-02 Green Mountain Powerplant – Outlet Works – Bypass Valves – Control Cabinet SX, S7, & S8 – Wiring Diagram – Sheet 2 of 3

100 245-713-1544-03 Green Mountain Powerplant – Outlet Works – Bypass Valves – Control Cabinet SX, S7, & S8 – Wiring Diagram – Sheet 3 of 3

101 154620 Green Mountain Power Plant – Colorado-Big Thompson Project, Colorado – General Arrangement – Single Vertical Turbine

102 154623 Green Mountain Power Plant – Colorado-Big Thompson Project, Colorado – Foundation – Single Vertical Turbine

103 154624 Green Mountain Power Plant – Colorado-Big Thompson Project, Colorado – Draft Tube – Single Vertical Turbine

104 154625 Draft Tube Liner – Single Vertical Turbine

105 154626 Spiral Casing – Single Vertical Turbine

106 154628 Speed Ring – Single Vertical Turbine

107 154629 77” #136 R. H. Runner and Runner Tip – Single Vertical Turbine

108 CCSA-1 Rev B Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSA Cabinet Layout. – Sheet 1 of 7

109 CCSA-2 Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSA PLC AA Modules Wiring Diagram – Sheet 2 of 7

110 CCSA-3 Rev-A Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSA PLC AB Modules Wiring Diagram – Sheet 3 of 7

111 CCSA-4 Rev B Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSA Right Side – Wiring Diagram – Sheet 4 of 7

112 CCSA-5 Rev E Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSA Back Panel (1 of 2) Wiring Diagram – Sheet 5 of 7

113 CCSA-6 Rev D Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSA Back Panel Wiring Diagram – Sheet 6 of 7

114 CCSA-7 Rev B Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSA Left Side Wiring Diagram – Sheet 7 of 7

Revised 52 00 00 - 10

Table 52 00 00A - List of Drawings

Sheet No.

Drawing No. Title

115 CCSE-1 Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSE Cabinet Layout – Sheet 1 of 6

116 CCSE-2 Rev A Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSE PLC AC Modules Wiring Diagram – Sheet 2 of 6

117 CCSE-3 Rev A Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSE PLC AD Modules Wiring Diagram – Sheet 3 of 6

118 CCSE-4 Rev A Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSE Right Side Panel Wiring Diagram – Sheet 4 of 6

119 CCSE-5 Rev D Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSE Back Side Wiring Diagram – Sheet 5 of 6

120 CCSE-6 Rev B Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSE Left Side Panel Wiring Diagram – Sheet 6 of 6

121 CCSE-7 Supervisory Control Remote Terminal Unit (RTU) – Cabinet CCSE Watchdog Timer Schematic – Sheet 7 of 7

Standard Drawings:

121A 40-D-6234 Standard Nameplates

122 40-D-6602 Ladders – Ladder Type 3 – Elevations and Sections

123 40-D-6603 Ladders – Ladder Type 4 – Elevation, Section, and Detail

124 40-D-7094 Electrical Installation – Conduit Clamp and Conduit Supports – Typical Details – Sheet 1 of 1

125 40-D-7102 Government Drawing Format - Drawing Border, Sample Title Block and Signature Lines

126 104-D-1150 Major Power/Pumping Plants – Electrical Installation – Device Designations and Symbols To Be Used on Single- Line and Schematic Diagrams

127 104-D-1165 Design Data Typical Power Plant_Pumping Plant – Electrical Installation – Main Control Board – CSA – Panel 7R – Wiring Diagram

Revised 52 00 00 - 11

Table 52 00 00B - Drawings in Numerical Order

Drawing No. Sheet No.

245-D-

245-D-406 31

245-D-410 32

245-D-411 33

245-D-514 34

245-D-515 35

245-D-516 36

245-D-517 37

245-D-541 38

245-D-849 39

245-D-850 40

245-D-851 41

245-D-1020 42

245-D-1024 43

245-D-1025 44

245-D-1026 45

245-D-1027 46

245-D-1028 47

245-D-1029 47A

245-D-1030 48

245-D-1032 49

245-D-1089 50

245-D-1090 51

245-D-1107 52

245-D-1181 53

245-D-1182 54

Revised 52 00 00 - 12

Table 52 00 00B - Drawings in Numerical Order

Drawing No. Sheet No.

245-D-1183 55

245-D-1184 56

245-D-1195 57

245-D-1205 58

245-D-1206 59

245-D-1207 60

245-D-1209 61

245-D-1210 62

245-D-1211 63

245-D-1212 64

245-D-1213 65

245-D-1214 66

245-D-1215 67

245-D-1217 68

245-D-1245 69

245-D-1248 70

245-D-1260 71

245-D-1276 72

245-D-1277 73

245-D-1279 74

245-D-1280 75

245-D-1281 76

245-D-1283 77

245-D-1285 78

245-D-1301 79

245-D-1526 80

Revised 52 00 00 - 13

Table 52 00 00B - Drawings in Numerical Order

Drawing No. Sheet No.

245-D-1527 81

245-D-1528 82

245-D-1531 83

245-D-1544 84

245-D-1546 85

245-D-1554 86

245-D-1678 87

245-D-1692 88

245-D-1693 89

245-D-1719 90

245-D-1720 91

245-D-1779 92

245-D-9601 93

245-D-60024 94

245-D-60037 9

245-D-60038 10

245-D-60039 11

245-D-60040 12

245-D-60041 13

245-D-60042 14

245-D-60043 15

245-D-60044 16

245-D-60045 17

245-D-60046 1

245-D-60047 2

245-D-60048 3

Revised 52 00 00 - 14

Table 52 00 00B - Drawings in Numerical Order

Drawing No. Sheet No.

245-D-60060 18

245-D-60061 19

245-D-60062 20

245-D-60063 21

245-D-60064 22

245-D-60065 4

245-D-60066 5

245-D-60067 6

245-D-60068 7

245-D-60069 8

245-D-60071 23

245-D-60072 24

245-D-60073 25

245-D-60074 26

245-D-60075 27

245-D-60077 28

245-D-60078 29

245-D-60079 30

245-600-

245-600-1915 96

245-600-1916 95

245-713-

245-713-1543 97

245-713-1544-01 98

245-713-1544-02 99

245-713-1544-03 100

Revised 52 00 00 - 15

Table 52 00 00B - Drawings in Numerical Order

Drawing No. Sheet No.

154620 101

154623 102

154624 103

154625 104

154626 105

154628 106

154629 107

CSSA

CCSA-1 Rev B 108

CCSA-2 109

CCSA-3 Rev-A 110

CCSA-4 Rev B 111

CCSA-5 Rev E 112

CCSA-6 Rev D 113

CCSA-7 Rev B 114

CSSE

CCSE-1 115

CCSE-2 Rev A 116

CCSE-3 Rev A 117

CCSE-4 Rev A 118

CCSE-5 Rev D 119

CCSE-6 Rev B 120

CCSE-7 121

40-D-

40-D-6234 121A

40-D-6602 122

Revised 52 00 00 - 16

Table 52 00 00B - Drawings in Numerical Order

Drawing No. Sheet No.

40-D-6603 123

40-D-7094 124

40-D-7102 125

104-D-

104-D-1150 126

104-D-1165 127

END OF SECTION

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 1 (Revised)

SECTION L -- INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

L.1 52.204-7 SYSTEM FOR AWARD MANAGEMENT OCT 2018

(a) Definitions. As used in this provision—

“Electronic Funds Transfer (EFT) indicator” means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

“Registered in the System for Award Management (SAM) database” means that—

(1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14), into the SAM database;

(2) The offeror has completed the Core, Assertions, and Representations and Certification, and Points of contact sections of the registration in the SAM database;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process.

(4) The Government has marked the record “Active”.

“Unique entity identifier” means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b)(1) By submission of an Offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation “Unique Entity Identifier” followed by the unique entity identifier that identifies the Offeror’s name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable. The unique entity identifier will be used by the Contracting Officer to verify that the Offeror is registered in the SAM database.

(c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at www.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information:

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 2 (Revised)

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company physical street address, city, state and Zip Code.

(4) Company mailing address, city, state and Zip Code (if separate from physical).

(5) Company telephone number.

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company Headquarters name and address (reporting relationship within your entity).

(d) If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror.

(e) Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

(f) Offerors may obtain information on registration at https://www.acquisition.gov.

L.2 52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE

REPORTING

AUG 2020

(a) Definition. As used in this provision – Commercial and Government Entity (CAGE) code means–

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) The Offeror shall provide its CAGE code with its offer with its name and location address or otherwise include it prominently in its proposal. The CAGE code must be for that name and location address. Insert the word "CAGE" before the number. The CAGE code is required prior to award.

(c) CAGE codes may be obtained via–

(1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 3 (Revised)

CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

(2) The DLA Contractor and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the Offeror does not otherwise register in SAM, an Offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity's country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity’s country is not a member of NATO or a sponsored nation. Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil.

(e) When a CAGE code is required for the immediate owner and/or the highest-level owner by Federal Acquisition Regulation (FAR) 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE code from that entity to supply the CAGE code to the Government.

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(g) If the solicitation includes FAR clause 52.204-2, Security Requirements, a subcontractor requiring access to classified information under a contract shall be identified with a CAGE code on the DD Form 254. The Contractor shall require a subcontractor requiring access to classified information to provide its CAGE code with its name and location address or otherwise include it prominently in the proposal. Each location of subcontractor performance listed on the DD Form 254 is required to reflect a corresponding unique CAGE code for each listed location unless the work is being performed at a Government facility, in which case the agency location code shall be used. The CAGE code must be for that name and location address. Insert the word "CAGE" before the number. The CAGE code is required prior to award.

L.3 52.204-22 ALTERNATIVE LINE ITEM PROPOSAL JAN 2017

(a) The Government recognizes that the line items established in this solicitation may not conform to the Offeror's practices. Failure to correct these issues can result in difficulties in acceptance of deliverables and processing payments. Therefore, the Offeror is invited to propose alternative line items for which bids, proposals, or quotes are requested in this solicitation to ensure that the

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 4 (Revised) resulting contract is economically and administratively advantageous to the Government and the Offeror.

(b) The Offeror may submit one or more additional proposals with alternative line items, provided that alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation.

However, acceptance of an alternative proposal is a unilateral decision made solely at the discretion of the Government. Offers that do not comply with the line items specified in this solicitation may be determined to be nonresponsive or unacceptable.

L.4 52.211-1 AVAILABILITY OF SPECIFICATIONS LISTED IN THE

GSA INDEX OF FEDERAL SPECIFICATIONS,

STANDARDS AND COMMERCIAL ITEM

DESCRIPTIONS, FPMR PART 101-29

AUG 1998

(a) The GSA Index of Federal Specifications, Standards and Commercial Item Descriptions, FPMR Part 101-29, and copies of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained for a fee by submitting a request to--

GSA Federal Supply Service Specifications Section, Suite 8100 470 East L’Enfant Plaza SW Washington, DC 20407 Telephone (202) 619-8925 Facsimile (202) 619-8978.

(b) If the General Services Administration, Department of Agriculture, or Department of Veterans

Affairs issued this solicitation, a single copy of specifications, standards, and commercial item descriptions cited in this solicitation may be obtained free of charge by submitting a request to the addressee in paragraph (a) of this provision. Additional copies will be issued for a fee.

L.5 52.211-2 AVAILABILITY OF SPECIFICATIONS, STANDARDS,

AND DATA ITEM DESCRIPTIONS LISTED IN THE

ACQUISITION STREAMLINING AND

STANDARDIZATION INFORMATION SYSTEM

(ASSIST)

APR 2014

(a) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(1) ASSIST (https://assist.dla.mil/online/start/ );

(2) Quick Search (http://quicksearch.dla.mil/ );

(3) ASSISTdocs.com (http://assistdocs.com).

(b) Documents not available from ASSIST may be ordered from the Department of Defense Single

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 5 (Revised)

Stock Point (DoDSSP) by—

(1) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm );

(2) Phoning the DoDSSP Customer Service Desk (215) 697-2197, Mon-Fri, 0730 to 1600 EST;

or

(3) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone (215) 697-2667/2179, Facsimile (215) 697-1462.

L.6 52.211-6 BRAND NAME OR EQUAL

AUG 1999

(a) If an item in this solicitation is identified as "brand name or equal," the purchase description reflects the characteristics and level of quality that will satisfy the Government’s needs. The salient physical, functional, or performance characteristics that "equal" products must meet are specified in the solicitation.

(b) To be considered for award, offers of "equal" products, including "equal" products of the brand name manufacturer, must-

(1) Meet the salient physical, functional, or performance characteristic specified in this solicitation;

(2) Clearly identify the item by-

(i) Brand name, if any; and

(ii) Make or model number;

(3) Include descriptive literature such as illustrations, drawings, or a clear reference to previously furnished descriptive data or information available to the Contracting Officer; and

(4) Clearly describe any modifications the offeror plans to make in a product to make it conform to the solicitation requirements. Mark any descriptive material to clearly show the modifications.

(c) The Contracting Officer will evaluate "equal" products on the basis of information furnished by the offeror or identified in the offer and reasonably available to the Contracting Officer. The Contracting Officer is not responsible for locating or obtaining any information not identified in the offer.

(d) Unless the offeror clearly indicates in its offer that the product being offered is an "equal" product, the offeror shall provide the brand name product referenced in the solicitation.

L.7 52.214-34 SUBMISSION OF OFFERS IN THE ENGLISH

LANGUAGE

APR 1991

Offers submitted in response to this solicitation shall be in the English language. Offers received in other than English shall be rejected.

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 6 (Revised)

L.8 52.214-35 SUBMISSION OF OFFERS IN U.S. CURRENCY APR 1991

Offers submitted in response to this solicitation shall be in terms of U.S. dollars. Offers received in other than U.S. dollars shall be rejected.

L.9 52.215-1 INSTRUCTIONS TO OFFERORS -- COMPETITIVE

ACQUISITION

JAN 2017

(a) Definitions. As used in this provision --

“Discussions” are negotiations that occur after establishment of the competitive range that may, at the Contracting Officer’s discretion, result in the offeror being allowed to revise its proposal.”

“In writing,” “writing,” or “written” means any worded or numbered expression which can be read, reproduced, and later communicated, and includes electronically transmitted and stored information.

“Proposal modification” is a change made to a proposal before the solicitation’s closing date and time, or made in response to an amendment, or made to correct a mistake at any time before award.

“Proposal revision” is a change to a proposal made after the solicitation closing date, at the request of or as allowed by a Contracting Officer as the result of negotiations.

“Time,” if stated as a number of days, is calculated using calendar days, unless otherwise specified, and will include Saturdays, Sundays, and legal holidays. However, if the last day falls on a Saturday, Sunday, or legal holiday, then the period shall include the next working day.

(b) Amendments to solicitations. If this solicitation is amended, all terms and conditions that are not amended remain unchanged. Offerors shall acknowledge receipt of any amendment to this solicitation by the date and time specified in the amendment(s).

(c) Submission, modification, revision, and withdrawal of proposals.

(1) Unless other methods (e.g., electronic commerce or facsimile) are permitted in the solicitation, proposals and modifications to proposals shall be submitted in paper media in sealed envelopes or packages

(i) addressed to the office specified in the solicitation, and

(ii) showing the time and date specified for receipt, the solicitation number, and the name and address of the offeror. Offerors using commercial carriers should ensure that the proposal is marked on the outermost wrapper with the information in paragraphs (c)(1)(i) and (c)(1)(ii) of this provision.

(2) The first page of the proposal must show –

(i) The solicitation number;

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 7 (Revised)

(ii) The name, address, and telephone and facsimile numbers of the offeror (and electronic address if available);

(iii) A statement specifying the extent of agreement with all terms, conditions, and provisions included in the solicitation and agreement to furnish any or all items upon which prices are offered at the price set opposite each item;

(iv) Names, titles, and telephone and facsimile numbers (and electronic addresses if available) of persons authorized to negotiate on the offeror’s behalf with the Government in connection with this solicitation; and

(v) Name, title, and signature of person authorized to sign the proposal. Proposals signed by an agent shall be accompanied by evidence of that agent’s authority, unless that evidence has been previously furnished to the issuing office.

(3) Submission, modification, revision, and withdrawal of proposals.

(i) Offerors are responsible for submitting proposals, and any modification, or revisions so as to reach the Government office designated in the solicitation by the time specified in the solicitation. If no time is specified in the solicitation, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that proposal or revision is due.

(ii)(A) Any proposal, modification, or revision received at the Government office designated in the solicitation after the exact time specified for receipt of offers is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late offer would not unduly delay the acquisition; and –

(1) If it was transmitted through an electronic commerce method authorized by the solicitation, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of proposals; or

(2) There is acceptable evidence to establish that it was received at the

Government installation designated for receipt of offers and was under the Government’s control prior to the time set for receipt of offers; or

(3) It is the only proposal received.

(B) However, a late modification of an otherwise successful proposal that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 8 (Revised)

(ii) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the proposal wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(iii) If an emergency or unanticipated event interrupts normal Government processes so that proposals cannot be received at the office designated for receipt of proposals by the exact time specified in the solicitation, and urgent Government requirements preclude amendment of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(iv) Proposals may be withdrawn by written notice received at any time before award. Oral proposals in response to oral solicitations may be withdrawn orally.

If the solicitation authorizes facsimile proposals, proposals may be withdrawn via facsimile received at any time before award, subject to the conditions specified in the provision at 52.215-5, Facsimile Proposals. Proposals may be withdrawn in person by an offeror or an authorized representative, if the identity of the person requesting withdrawal is established and the person signs a receipt for the proposal before award.

(4) Unless otherwise specified in the solicitation, the offeror may propose to provide any item or combination of items.

(5) Offerors shall submit proposals in response to this solicitation in English, unless otherwise permitted by the solicitation, and in U.S. dollars, unless the provision at FAR 52.225-17, Evaluation of Foreign Currency Offers, is included in the solicitation.

(6) Offerors may submit modifications to their proposals at any time before the solicitation closing date and time, and may submit modifications in response to an amendment, or to correct a mistake at any time before award.

(7) Offerors may submit revised proposals only if requested or allowed by the Contracting Officer.

(8) Proposals may be withdrawn at any time before award. Withdrawals are effective upon receipt of notice by the Contracting Officer.

(d) Offer expiration date. Proposals in response to this solicitation will be valid for the number of days specified on the solicitation cover sheet (unless a different period is proposed by the offeror).

(e) Restriction on disclosure and use of data. Offerors that include in their proposals data that they do not want disclosed to the public for any purpose, or used by the Government except for evaluation purposes, shall --

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 9 (Revised)

(1) Mark the title page with the following legend:

This proposal includes data that shall not be disclosed outside the Government and shall not be duplicated, used, or disclosed -- in whole or in part -- for any purpose other than to evaluate this proposal. If, however, a contract is awarded to this offeror as a result of -- or in connection with -- the submission of this data, the Government shall have the right to duplicate, use, or disclose the data to the extent provided in the resulting contract. This restriction does not limit the Government’s right to use information contained in this data if it is obtained from another source without restriction. The data subject to this restriction are contained in sheets [insert numbers or other identification of sheets]; and

(2) Mark each sheet of data it wishes to restrict with the following legend:

Use or disclosure of data contained on this sheet is subject to the restriction on the title page of this proposal.

(f) Contract award.

(1) The Government intends to award a contract or contracts resulting from this solicitation to the responsible offeror(s) whose proposal(s) represents the best value after evaluation in accordance with the factors and subfactors in the solicitation.

(2) The Government may reject any or all proposals if such action is in the Government’s interest.

(3) The Government may waive informalities and minor irregularities in proposals received.

(4) The Government intends to evaluate proposals and award a contract without discussions with offerors (except clarifications as described in FAR 15.306(a)). Therefore, the offeror’s initial proposal should contain the offeror’s best terms from a cost or price and technical standpoint. The Government reserves the right to conduct discussions if the Contracting Officer later determines them to be necessary. If the Contracting Officer determines that the number of proposals that would otherwise be in the competitive range exceeds the number at which an efficient competition can be conducted, the Contracting Officer may limit the number of proposals in the competitive range to the greatest number that will permit an efficient competition among the most highly rated proposals.

(5) The Government reserves the right to make an award on any item for a quantity less than the quantity offered, at the unit cost or prices offered, unless the offeror specifies otherwise in the proposal.

(6) The Government reserves the right to make multiple awards if, after considering the additional administrative costs, it is in the Government’s best interest to do so.

(7) Exchanges with offerors after receipt of a proposal do not constitute a rejection or counteroffer by the Government.

(8) The Government may determine that a proposal is unacceptable if the prices proposed are

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 10 (Revised) materially unbalanced between line items or subline items. Unbalanced pricing exists when, despite an acceptable total evaluated price, the price of one or more line items is significantly overstated or understated as indicated by the application of cost or price analysis techniques. A proposal may be rejected if the Contracting Officer determines that the lack of balance poses an unacceptable risk to the Government.

(9) If a cost realism analysis is performed, cost realism may be considered by the source selection authority in evaluating performance or schedule risk.

(10) A written award or acceptance of proposal mailed or otherwise furnished to the successful offeror within the time specified in the proposal shall result in a binding contract without further action by either party.

(11) If a post-award debriefing is given to requesting offerors, the Government shall disclose the following information, if applicable:

(i) The agency’s evaluation of the significant weak or deficient factors in the debriefed offeror’s offer.

(ii) The overall evaluated cost or price and technical rating of the successful and the debriefed offeror and past performance information on the debriefed offeror.

(iii) The overall ranking of all offerors, when any ranking was developed by the agency during source selection.

(iv) A summary of the rationale for award.

(v) For acquisitions of commercial items, the make and model of the item to be delivered by the successful offeror.

(vi) Reasonable responses to relevant questions posed by the debriefed offeror as to whether source-selection procedures set forth in the solicitation, applicable regulations, and other applicable authorities were followed by the agency.

L.10 52.216-1 TYPE OF CONTRACT APR 1984

The Government contemplates award of a Firm Fixed-Price contract resulting from this solicitation.

L.11 52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS—

SECONDARY SITE OF THE WORK

MAY 2014

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements, of this solicitation.

Colorado-Big Thompson Project, Colorado Amendment No. 0005

L - 11 (Revised)

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(c) The due date for receipt of offers will not be extended as a result of an offeror’s request for a wage determination for a secondary site of the work.

L.12 52.225-12

NOTICE OF BUY AMERICAN REQUIREMENT-

CONSTRUCTION MATERIALS UNDER TRADE

AGREEMENTS

MAY 2014

(a) Definitions. "Commercially available off-the-shelf (COTS) item," "construction material," "designated country construction material," "domestic construction material," and "foreign construction material," as used in this provision, are defined in the clause of this solicitation entitled "Buy American-Construction Materials Under Trade Agreements" (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers.

(1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered…