Amendment_No._0002.pdf

(x)

140R6018R0005 x x copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted ; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGEMENT TO BE RECEIVED AT

THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted , such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

x

Billings MT 59107

R60

PO Box 36900 Regional Office Great Plains Region Bureau of Reclamation

06/11/20180002

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS. IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

12. ACCOUNTING AND APPROPRIATION DATA (If required) is not extended.is extended, Items 8 and 15, and returning

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended , by one of the following methods: (a) By completing

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

FACILITY CODE CODE

10B. DATED (SEE ITEM 13)

10A. MODIFICATION OF CONTRACT/ORDER NO.

9B. DATED (SEE ITEM 11)

9A. AMENDMENT OF SOLICITATION NO.

CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

7. ADMINISTERED BY (If other than Item 6)CODE 6. ISSUED BY

PAGE OF PAGES

4. REQUISITION/PURCHASE REQ. NO.3. EFFECTIVE DATE2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO. (If applicable)

1. CONTRACT ID CODE

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

05/16/2018

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

E. IMPORTANT: Contractor is not, is required to sign this document and return __________________ copies to the issuing office.

ORDER NO. IN ITEM 10A.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Guernsey Powerplant - Surge Tank Recoating, North Platte Project, Wyoming

See attachment for changes incorporated by this amendment:

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)15A. NAME AND TITLE OF SIGNER (Type or print)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA 15B. CONTRACTOR/OFFEROR 16C. DATE SIGNED

(Signature of person authorized to sign) (Signature of Contracting Officer)

Gerri Voto-Braun

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

NSN 7540-01-152-8070

Previous edition unusable

Except as provided herein, all terms and conditions of the document referenced in Item 9 A or 10A, as heretofore changed, remains unchanged and in full force and effect .

Solicitation Number 140R6018R0005 Amendment No. 0002

Description of Changes:

1. Remove Foreword in its entirety and substitute therefor the attached revised Foreword.

2. Remove page i and ii of the Table of Contents and substitute therefor the attached revised page i and ii.

3. In Part I – The Schedule, Section C – Specifications, remove Section 01 11 00 – Summary of Work in its entirety and substitute therefor the attached revised Section 01 11 00.

4. In Part I – The Schedule, Section C – Specifications, Section 01 33 00 – Submittals, remove pages 01 33 00-7 through 01 33 00-10 and substitute therefor the attached revised pages 01 33 00-7 through 01 33 00-10.

5. In Part I – The Schedule, Section C – Specifications, remove Section 02 89 10 – Removal and

Disposal of Coatings Containing Coal Tar Products in its entirety and substitute therefor the attached revised Section 02 89 10 – Removal and Disposal of Coatings Containing Coal Tar Products and Heavy Metals.

6. In Part I – The Schedule, Schedule C – Specifications, the attached new Section 51 00 10 –

Guernsey Powerplant Surge Tank Inspection is incorporated into and made a part of the solicitation.

7. In Part I – The Schedule, remove Section F – Deliveries or Performance in its entirety and substitute therefor the attached revised Section F.

8. In Part IV – Representatives and Instructions, Section L – Instructions, Conditions and Notices to

Bidders, remove page L-15 and L-16 and substitute therefor the attached revised page L-15 and L- 16.

9. In Part IV – Representatives and Instructions, Section M – Evaluation Factors for Award, remove page M-1 and M-2 and substitute therefor the attached revised page M-1 and M-2.

For convenience, essential changes on the revised solicitation pages are indicated by a vertical line in the margin where lines or paragraphs changed from the previous version. However, all portions of the revised solicitation pages shall apply whether changes thereon have or have not been indicated.

Acknowledgement: See Block 11 on the SF-30 regarding how to acknowledge this amendment. The Government must receive the acknowledgement at the place designated for receipt of bids (See Block 10 of the Standard Form 1442).

Receipt of Proposals: The hour and date for receipt of proposals is extended to 2:00 pm MDT on June 27, 2018.

Third Party: If you have given a copy of the solicitation to someone else, please forward this amendment accordingly.

Questions from prospective contractors and their respective answers are attached for information only.

The following contractors were in attendance at the organized site visit, which took place on June 6, 2018:

Alfonso Trujillo Coblaco Alfonso@coblaco.com Albert Rangel Coblaco Albert@coblaco.com Ben Nicholson TMI Coatings, Inc. bnicholson@tmicoatings.com David Hole Blastco David.Hole@tfwarren.com Lindsey Beasley International Paint Lindsey.Beasley@akzonobel.com

Solicitation No. 140R6018R0005 – Guernsey Powerplant – Surge Tank Recoating Prospective Contractor Questions and Answers

1. SF1442 lists a project completion date of 200 cd after receiving Notice to Proceed, but since this work is on the Surge Tank, which is an integral part of the Hydro Electric water flow system, is there a specific "outage" period, at the Guernsey powerplant, that the USBOR expects the Surge Tank recoating work to be performed?

Refer to revised Section F.1

2. Section 011100 Summary of Work: states the scope of work involves the Removal and Disposal of existing Coal Tar lining System, and Relining the INTERIOR surfaces of the surge tank. Under Section L.18 Technical Proposal Instructions, under 1. Technical Plan for Design and Construction, paragraph 1.B on page L-15 it asks to submit a narrative detailing the Containment, Surface Prep and Recoating of the EXTERIOR surfaces and the INTERIOR surfaces. Is the Exterior of the Surge Tank included in the scope of work?

Refer to revised Sections L & M attached.

3. Is there any information available on what the thickness of the existing Coal Tar lining system is?

Yes. According to previous Reclamation contract documents dated 1979, the final film thickness was 24 mils (+/- 6 mils).

4. Does the surge tank have a roof structure or is the top of it open to the environment?

The surge tank top is open. Refer to attached specifications Section 51 00 10.

5. Can the Contractor inspect the tank interior?

No. Refer to attached specifications Section 51 00 10.

6. The wage rate determination provided does not have a “Painter Wage.” Can you provide another wage schedule with a painter wage?

There is no wage rate for a painter in the Wage Rages included in the solicitation. Prospective contractors shall perform a survey to determine what they believe is a reasonable wage rate and fringe for this labor classification in Platte County. These rates and fringes shall be used as the basis of their price proposal. After award, the successful contractor shall submit a Standard Form 1444 requesting approval for their proposed rate and fringes. If DOL later requires a higher rate and fringe, the Contractor may submit a request for equitable adjustment.

7. Can the contractor install a new (2nd) or enlarge the existing lower shell manway if needed for tank access?

No. The Contractor has three points of access into the tank, including the top, side manhole, and bottom.

1 (Revised)

GUERNSEY POWERPLANT – SURGE TANK RECOATING

NORTH PLATTE PROJECT

WYOMING

FOREWORD

Work to be performed under this solicitation is to be performed at the Bureau of Reclamation’s Guernsey Powerplant facility in Wyoming. Guernsey Powerplant is located approximately 2 miles northwest of Guernsey, Wyoming, in Platte County.

Work under these specifications:

A. Removal and disposal of existing coal tar and metals lining system on the interior surfaces of surge tank.

B. Relining interior surfaces of the surge tank.

INQUIRIES REGARDING THIS SOLICITATION SHOULD BE MADE TO:

Contractual Matters: Contracting Officer Attention: Gerri Voto-Braun Billings, Montana Telephone: 406-247-7809 gvotobraun@usbr.gov

FOR DATE AND PLACE PROPOSALS ARE DUE, SEE “SOLICITATION, OFFER AND AWARD”

STANDARD FORM 1442 IMMEDIATELY FOLLOWING THE TABLE OF CONTENTS.

FOR INFORMATION REGARDING BUREAU OF RECLAMATION’S PUBLICATION “RECLAMATION

SAFETY AND HEALTH STANDARDS” (2009 EDITION) WHICH IS APPLICABLE TO WORK UNDER

THIS CONTRACT, SEE WBR 1452.223-81 SAFETY AND HEALTH.

ORGANIZED SITE VISIT: AN ORGANIZED SITE VISIT HAS BEEN SCHEDULED FOR WEDNESDAY,

JUNE 6, 2018 AT 10:00 AM. INTERESTED CONTRACTORS SHALL MAKE ARRANGEMENTS IN

ATTENDING THE SITE VISIT BY CONTACTING MR. DAVID WARD AT 970-962-4504 OR VIA E-MAIL

AT DWARD@USBR.GOV. SEE PARAGRAPH L.21 FOR INFORMATION REGARDING THE ORGANIZED

SITE VISIT. SINCE IT IS NOT AN ACTIVE CONSTRUCTION SITE, HARD HATS AND STEEL TOE BOOTS

ARE NOT REQUIRED, HOWEVER ATTENDEES SHALL WEAR LONG PANTS, CLOSED TOE SHOES AND

AN ORANGE SAFETY VEST. ALTHOUGH THE ORGANIZED SITE VISIT IS NOT MANDATORY,

PROSPECTIVE CONTRACTORS ARE STRONGLY ENCOURAGED TO ATTEND THE SITE VISIT TO

GAIN A BETTER UNDERSTANDING OF THE WORK REQUIREMENTS AND THE SITE CONDITIONS.

SAM: EFFECTIVE JULY 29, 2012, ANY CONTRACTOR INTERESTED IN DOING BUSINESS WITH

THE GOVERNMENT MUST REGISTER IN THE SYSTEM FOR AWARD MANAGEMENT (SAM)

DATABASE PRIOR TO AWARD OF A CONTRACT OR AGREEMENT. SAM IS A FEDERAL

2 (Revised)

GOVERNMENT OWNED AND OPERATED WEBSITE THAT IS CONSOLIDATES THE CENTRAL

CONTRACTOR REGISTRATION (CCR), THE ONLINE REPRESENTATIONS AND CERTIFICATIONS

(ORCA) AND THE EXCLUDED PARTIES LIST SYSTEM (EPLS).

THE VENDOR’S DUNS AND BRADSTREET NUMBER AND BANKING INFORMATION ARE REQUIRED

FOR REGISTRATION. CONTRACTORS MAY OBTAIN INFORMATION ON REGISTRATION AND

ANNUAL CERTIFICATION REQUIREMENT’S VIA THE SAM WEBSITE

HTTPS://WWW.SAM.GOV/PORTAL/PUBLIC/SAM/ OR THE FEDERAL SERVICE HELP DESK AT 866-

606-8220.

PAYMENT REQUESTS FOR THE ANTICIPATED CONTRACT MUST BE SUBMITTED

ELECTRONICALLY THROUGH THE U.S. DEPARTMENT OF THE TREASURY’S INTERNET

PAYMENT PLATFORM (IPP) SYSTEM. THE IPP WEBSITE IS HTTPS://WWW.IPP.GOV. THE

CONTRACTOR MUST USE THE IPP WEBSITE TO REGISTER ACCESS AND USE IPP FOR

SUBMITTING REQUESTS FOR PAYMENT. CONTRACTOR ASSISTANCE WITH ENROLLMENT CAN BE

OBTAINED BY CONTACTING THE IPP PRODUCTION HELPDESK VIA E-MAIL

IPPGROUP@BOS.FRB.ORG OR PHONE (866) 973-3131. IF THE CONTRACTOR IS UNABLE TO

COMPLY WITH THE REQUIREMENT TO USE IPP FOR SUBMITTING INVOICES FOR PAYMENT, THE

CONTRACTOR MUST SUBMIT A WAIVER REQUEST IN WRITING TO THE CONTRACTING OFFICER

WITH ITS PROPOSAL OR BID.

i (Revised)

TABLE OF CONTENTS

PART 1 – THE SCHEDULE

SECTION A – Solicitation, Offer and Award, Standard Form 1442

SECTION B – Schedule

SECTION C - Specifications

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work 01 14 10 Use of Site 01 32 20 Construction Program 01 33 00 Submittals 01 35 10 Safety Data Sheets 01 35 20 Safety and Health 01 35 30 Contractor’s Onsite Safety Personnel 01 42 10 Reference Standards 01 46 00 Quality Procedures 01 51 00 Temporary Utilities 01 55 00 Vehicular Access and Parking 01 56 10 Protection of Existing Installations 01 57 20 Environmental Controls 01 74 00 Cleaning and Waste Management

DIVISION 02 - EXISTING CONDITIONS

02 89 10 Removal and Disposal of Coatings Containing Coal Tar Products and Heavy Metals

DIVISION 09 - FINISHES

09 96 20 Coatings

DIVISION 51 - INFORMATION AVAILABLE TO OFFERORS

51 00 00 Information Available to Offerors 51 00 10 Guernsey Surge Tank Inspection 51 00 20 Hazardous Materials Report

DIVISION 52 - DRAWINGS

52 00 00 Drawings

SECTION D – Not Used

SECTION E – Inspection and Acceptance Material and Workmanship ............................................................................................................. E-1 Inspection of Construction .............................................................................................................. E-1 Warranty of Construction ................................................................................................................ E-2

SECTION F – Deliveries or Performance Commencement, Prosecution and Completion of Work .................................................................. F-1 Suspension of Work ......................................................................................................................... F-1

SECTION G -- Contract Administration Data Authorities and Delegations ............................................................................................................ G-1 Electronic Invoicing and Payment Requirements – Internet Payment Platform ............................. G-1 Post Award Conference ................................................................................................................... G-2

SECTION H -- Special Contract Requirements Site Security .................................................................................................................................... H-1 ii (Revised)

PART II – CONTRACT CLAUSES

SECTION I -- Contract Clauses Clauses Incorporated by Reference .................................................................................................. I-1 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements .................... I-2 Commercial and Governmental Entity Code Maintenance .............................................................. I-3 Basic Safeguarding of Covered Contractor Information Systems .................................................... I-4 Order of Precedence – Uniform Contract Format ............................................................................ I-5 Minimum Wages under Executive Order 13658 .............................................................................. I-5 Buy American Act – Construction Materials ................................................................................... I-9 Bid Guarantee ................................................................................................................................. I-11 Additional Bond Security ............................................................................................................... I-11 Performance and Payment Bonds – Construction .......................................................................... I-12 Federal, State and Local Taxes ....................................................................................................... I-13 Payments Under Fixed-Price Construction Contracts .................................................................... I-14 Prompt Payment for Construction Contracts .................................................................................. I-16 Differing Site Conditions ............................................................................................................... I-22 Accident Prevention ....................................................................................................................... I-22 Specifications and Drawings for Construction ............................................................................... I-23 Changes .......................................................................................................................................... I-24 Authorized Deviations in Clauses .................................................................................................. I-24 Restrictions on Endorsements – Department of the Interior ........................................................... I-25 Release of Claims – Department of the Interior ............................................................................. I-25 Examination of Records by the Department of the Interior ............................................................ I-25 Liability Insurance – Department of the Interior ............................................................................ I-25 Incorporation of Technical Proposal – Bureau of Reclamation ..................................................... I-25 Asbestos-Free Warranty – Bureau of Reclamation ........................................................................ I-26 Safety and Health – Bureau of Reclamation .................................................................................. I-26 Protesting Federal Employees and the Public from Exposure to Tobacco and Smoke in the Federal Workplace – Bureau of Reclamation ........................................................... I-26 Hazardous Substances .................................................................................................................... I-27 Nonconforming Hazardous Materials ............................................................................................ I-27 Preservation, Packaging, Packing, Marking, and Labeling of Hazardous Materials (HAZMAT) For Shipment .................................................................................................................................. I-27 Certification of Representatives for Corporate Sureties – Bureau of Reclamation ........................ I-28 Equipment Ownership and Operating Expense – Bureau of Reclamation ..................................... I-29 Payment for Mobilization and Preparatory Work – Alternate I – Bureau of Reclamation ............ I-30 Payment for Technical Data – Bureau of Reclamation .................................................................. I-31 Claims Accounting – Bureau of Reclamation ................................................................................ I-32 Other Contracts (DEVIATION) – Bureau of Reclamation ............................................................ I-32 Preservation of Cultural Resources – Bureau of Reclamation ....................................................... I-32 Security Requirements – Bureau of Reclamation ........................................................................... I-33 Modification Proposals – Alternate IV – Bureau of Reclamation .................................................. I-38

PART III – DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

SECTION J – DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

Attachment No. 1 General Decision WY180037, dated April 13, 2018 Attachment No. 2 Standard Form 24, Bid Bond Attachment No. 3 Past Performance Questionnaire

PART IV – REPRESENTATIONS AND INSTRUCTIONS

SECTION K -- Representations, Certifications and Other Statements of Offerors Annual Representations and Certifications ..................................................................................... K-1 Information Regarding Responsibility Matters ............................................................................... K-3

Guernsey Powerplant Surge Tank Recoating Amendment No. 002

Summary of Work

Revised 01 11 00 - 1

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.01 LOCATION

A. Work is located approximately 2 miles northwest of Guernsey, Wyoming, in Platte County.

1.02 PRINCIPAL COMPONENTS OF WORK

A. Removal and disposal of existing coal tar with metals lining system on the interior surfaces of surge tank.

B. Relining interior surfaces of the surge tank.

1.03 SPECIFICATIONS REQUIREMENTS

A. Requirements in Division 1, General Requirements, apply to Divisions 2 through 52.

B. Imperative statements in these specifications are Contractor requirements, unless otherwise stated.

C. Where specifications are written in streamlined form, words “shall be” are included by inference where a colon (:) is used within sentence or phrase.

1.04 DEFINITIONS

A. When specifications use a word or term defined in Federal Acquisition Regulations (FAR), definition of the word or term shall be in accordance with FAR sections in effect at the time solicitation was issued.

1.05 ACRONYMS

A. The following acronyms apply to specifications Divisions 1 through 52:

1. CO: Contracting Officer.

2. COR: Contracting Officer’s Representative.

PART 2 PRODUCTS

Not Used

Summary of Work

Revised 01 11 00 - 2

PART 3 EXECUTION

END OF SECTION

Submittals

Revised 01 33 00 - 7

Table 01 33 00A. - List of Submittals

** CO indicates Contracting Officer, COR indicates Contracting Officer’s Representative.

RSN

Clause or Section

Title Submittals required

Due date or delivery time

Respon-sible code

Sets to be sent: **

CO COR

01 35 20-2 Safety and Health Monthly Accident Summary Report

Monthly COR 0 1 paper + 1 electronic

01 35 20-3 Safety and Health Respirator User

Documentation At least 28 days before beginning onsite work

COR 0 1 paper + 1

01 35 20-4 Safety and Health Crane Training Certificates

At least 28 days

01 35 20-5 Safety and Health Other Training Certificates

At least 28 days

01 35 30-1 Contractor’s Onsite Safety Personnel

Resumes At least 28 days

COR 0 2 paper

01 35 30-2 Contractor’s Onsite Safety Personnel

CIH Inspection Reports

Weekly

01 35 30-3 Contractor’s Onsite Safety Personnel

Safety Inspection Reports

01 46 00-1 Quality Procedures Contractor Quality Control Program

At least 28 days before commencing construction activities

COR 0 1 paper + 1 electronic

01 46 00-2 Quality Procedures Contractor’s Daily Reports

Submit daily reports on a weekly basis per the spec section

01 46 00-3 Quality Procedures Quality Control Supervisor

At least 28 days before commencing construction activities

01 46 00-4 Quality Procedures Contractor Quality Testing Plan

At least 28 days before commencing construction activities

Revised 01 33 00 - 8

Title Submittals required

Due date or delivery time

Respon-sible code

Sets to be sent: **

CO COR

01 46 00-5 Quality Procedures Summary Weekly Test Results

01 46 00-6 Quality Procedures Summary Monthly Test Results

Monthly

01 74 00-1 Cleaning and Waste Management

Waste Production and Disposal Plan

At least 28 days before starting onsite work

01 74 00-2 Cleaning and Waste Management

Waste Production and Disposal Records

Within 7 days of waste disposal

01 74 00-3 Cleaning and Waste Management

Environmental Consultant Resume

At least 35 days before beginning environmental assessment

COR 0 2 paper

01 74 00-4 Cleaning and Waste Management

Environmental Site Assessment

Within 14 days of completion of work

02 89 10-1 Removal & Disposal of Coatings Containing Coal Tar Products and Heavy Metals

Resumes, Certificates and Qualifications

At least 28 days before beginning work

COR 0 2 paper

02 89 10-2 Removal & Disposal of Coatings Containing Coal Tar Products and Heavy Metals

Written Compliance Program for Worker Protection

At least 28 days before beginning work

02 89 10-3 Removal & Disposal

Containing Coal Tar Products and Heavy Metals

Plans At least 28 days before beginning work

02 89 10-4 Removal & Disposal

Containing Coal Tar Products and Heavy Metals

Preconstruction Test Results

At least 28 days before beginning work

Revised 01 33 00 - 9

Title Submittals required

Due date or delivery time

Respon-sible code

Sets to be sent: **

CO COR

02 89 10-5 Removal & Disposal of Coatings Containing Coal Tar Products and Heavy Metals

Working Level Test Results

At least once each week

02 89 10-6 Removal & Disposal

Containing Coal Tar Products and Heavy Metals

Post-Construction Test Results

At least 21 days after completion of work

02 89 10-7 Removal & Disposal

Containing Coal Tar Products and Heavy Metals

Certificate of Disposal

At least 21 days after completion of work

09 96 20-1 Coatings Approval Data At least 30 days prior to starting onsite

09 96 20-2 Coatings Final Approval Data At least 30 days prior

09 96 20-3 Coatings Certifications Prior to employment COR 0 1 paper + 1

09 96 20-4 Coatings Documentation At least 30 days prior

Revised 01 33 00 - 10

This page intentionally left blank.

Removal and Disposal of Coatings Containing Coal Tar Products and Heavy Metals

Revised 02 89 10 – 1

SECTION 02 89 10

REMOVAL AND DISPOSAL OF COATINGS CONTAINING COAL TAR PRODUCTS

AND HEAVY METALS

PART 1 GENERAL

1.01 MEASUREMENT AND PAYMENT

A. Cost:

1. Include in prices offered in the Price Schedule for items requiring removal and disposal of coatings containing coal tar products and heavy metals.

1.02 REFERENCE STANDARDS

A. American Conference of Governmental Industrial Hygienists (ACGIH)

1. Threshold Limit Values Chemical Substances Threshold Limit Values. TLVs information available at www.usbr.gov/power/data/fist_pub.html

B. American Society of Civil Engineers

1. ASCE 7-10 Minimum Design Loads for Buildings and Other Structures

C. Bureau of Reclamation (USBR)

1. RSHS Reclamation Safety and Health Standards, www.usbr.gov/power/data/fist_pub.html

D. Code of Federal Regulations (CFR)

1. 29 CFR 1910.134 Respiratory Protection

2. 29 CFR 1910.1000 Air Contaminants

3. 29 CFR 1926.55 Gases, Vapors, Fumes, Dusts, and Mists

4. 40 CFR 261 Identification and Listing of Hazardous Waste

5. 40 CFR 262 Standards Applicable to Generators of Hazardous Waste

6. 40 CFR 263 Standards Applicable to Transporters of Hazardous Waste

7. 40 CFR 264 Standards for Owners and Operators of Hazardous Waste Treatment, Storage, Disposal Facilities

8. 40 CFR 268 Land Disposal Restrictions http://www.www.acgih.org/ http://www.usbr.gov/ssle/safety/RSHS/rshs.html

Revised 02 89 10 – 2

9. 40 CFR 700-766 Toxic Substances Control Act

10. 49 CFR 107 Hazardous Materials Program Procedures

11. 49 CFR 178 Specifications for Packaging

12. 49 CFR Chapter 1 Research and Special Programs Administration, Department of Transportation, Hazardous Materials Regulations

E. Environmental Protection Agency (EPA)

1. EPA Test Method TO-13A Testing for Polynuclear Aromatic Hydrocarbons (PAH) in Ambient Air Analyzed by GC/MS

F. International Code Council, Inc. (ICC)

1. IBC 15 International Building Code

G. Society For Protective Coatings (SSPC)

1. SSPC-Guide 6 - 2012 Guide for Containing Surface Preparation Debris Generated During Paint Removal Operations

2. SSPC-QP2 - 2009 Procedure for Evaluating the Qualifications of Painting Contractors (Field Removal of Hazardous Coatings From Complex Structures)

H. State of Wyoming Department of Employment OSHA Standards

I. Wyoming Department of Environmental Quality Solid and Hazardous Waste Division - Hazardous Waste Rules

1.03 DEFINITIONS

A. ABIH: American Board of Industrial Hygiene.

B. CIH: Certified Industrial Hygienist.

C. Competent Person:

1. For designing and implementing technical controls to limit employee exposure to airborne contaminants: As defined in 29 CFR 1926.55.

2. Qualified to design abatement and containment systems.

D. Handling: Includes containment, collection, storage, transportation, and disposal.

Revised 02 89 10 – 3

E. NELAP: National Environmental Laboratory Accreditation Program. The national program operated by The National Environmental Laboratory Accreditation Conference Institute (TNI).

F. PFT: Pulmonary Function Tests.

G. Regulated Area: Areas on project site where EPA or Wyoming State Action Levels may be exceeded for coal tar creosote, coal tar, and/or coal tar pitch and components.

H. RCRA: Resource Conservation and Recovery Act.

I. TSCA: Toxic Substances Control Act.

J. Coal Tar Products:

1. Coating containing coal tar, coal tar creosote, and/or coal tar pitch and other hazardous material components which may be present in such quantities that solid waste generated from paint removal operations would be hazardous in accordance with 40 CFR 261.24, Toxic Characteristic Leaching Procedures (TCLP) for PAHs.

2. Coatings which would generate release of coal tar components into air during removal which exceed OSHA Permissible Exposure Limit (PEL).

1.04 SUBMITTALS

A. Submit the following in accordance with Section 01 33 00 – Submittals.

B. RSN 02 89 10-1, Resumes, Certificates, and Qualifications:

1. Qualifications of Onsite Supervisor.

2. Qualifications of Design Professional. For the design of abatement and containment systems.

3. Current copy of SSPC-QP2 certification for hazardous coating removal.

4. Independent Testing Laboratory:

a. NELAP laboratory accreditation number for coal tar analysis.

b. Name, address, and telephone number.

5. Corporate resumes for subcontractors.

6. Resumes of abatement and coating removal workers.

7. First aid and cardiopulmonary resuscitation (CPR) certificates for persons designated to provide first aid.

8. Certificates of Employee Training:

a. Employees have received training in hazardous materials, hazard communication, and proper handling of hazardous materials in accordance with local, state, and federal regulations. This includes, but not limited to, Revised 02 89 10 – 4 respiratory protection, hearing conservation, and Personal Protective Equipment (PPE).

b. Understands health implications and risks involved, including illnesses possible from exposure to airborne contaminants.

c. Understands use and limits of respiratory equipment to be used.

d. Understands results of monitoring of airborne quantities of contaminants.

e. Document dates of training, training entity, names of instructors, and qualification of instructors.

9. Transporter Qualifications:

a. Written evidence that the transporter to be used is approved for hazardous waste transport in accordance with local, state, and federal regulations.

10. Disposal Facility Qualifications:

a. Written evidence that the facility to be used is approved for hazardous waste disposal in accordance with local, state, and federal regulations.

C. RSN 02 89 10-2, Written Compliance Program for Worker Protection:

1. Submit program, for approval, which details engineering controls, administrative controls and personal protective equipment to be implemented for worker protection during equipment removal and disposal activities, coating removal and disposal activities and coating re-application activities.

2. Describe procedures, equipment and training of employees on hazardous involved with handling and disposing of coatings.

3. PFT for respirator usage: Record of diagnostic test and examination by a Board Eligible or Certified Occupational Medicine Physician. Verify PFT will be sufficient for each worker. Confirm and release information in accordance with the Health Insurance Portability and Accountability Act.

4. Respiratory protection program as required by 29 CFR 1910.134.

5. Reviewed and signed by CIH.

D. RSN 02 89 10-3, Plans:

1. Containment System Plan:

a. Submit detailed plan to prevent release of coal tar dust during removal of coatings using filtered, ventilated containment system in accordance with SSPC Guide 6. If there are conflicts between these specifications and the SSPC Guide, the most stringent shall apply.

b. Include descriptions, design, detail project drawings, and site layout.

1) Describe work site containment area techniques, local exhaust ventilation system locations, decontamination units, temporary waste storage facility, location of temporary utilities, and

Revised 02 89 10 – 5 boundaries of each regulated area. Include: Drawings showing layout, attachment to structure, and relationship to structure.

2) Design calculations for ventilation systems.

3) Load analysis for containment systems loading on structure.

a) Include wind loads and dead load on containment systems from debris.

4) If a modified containment area, glove-bag or outdoor technique can be safely used, these should be specified in detail.

5) Performance criteria for the containment. Emission of dusts, metals, toxic vapors or gases into the plant or surrounding environment are prohibited.

c. Signed and sealed by qualified professional.

2. Emissions and Exposure Monitoring Plan for Coal Tar Dust:

a. Submit detailed monitoring plan, designed and signed by a CIH. Include the following:

b. Detailed air monitoring plan for coating removal operations.

1) The plan shall include but not limited to equipment specifications, analytical containment list sampling and analysis methods, equipment calibration information, name of person conducting sampling, type and location of sampling (personal or area), collection media specifications, flow rates and duration of samples.

2) The plan shall include laboratory information including name, address and phone number of lab. The lab shall be certified to analyze for coal tar chemicals.

3) The plan shall include pre-construction and post construction sampling information.

3. Waste Characterization, Handling, and Disposal Plan:

a. Plan for sampling, testing, characterization of waste:

1) Include required method detection limits.

2) Describe analytical data delivery package including quality control and quality assurance.

3) Plan for collecting samples from waste and analytical test methods that will be used to characterize the waste.

4) Test results of waste for Cresol by TCLP.

b. Plan for handling, storage, transporting, and disposal of project-generated waste and cleaning of reusable items.

Revised 02 89 10 – 6

c. Plan for disposal of wastewater: Include name, location, and address of proposed treatment facility and contact person at proposed treatment facility.

d. Name, address and qualifications of testing laboratory.

e. Name, address and qualifications of transporter.

f. Name, address and qualifications of disposal facility.

g. Written notice from owner or operator of disposal facility documenting permits and agreement to accept waste generated under this contract.

E. RSN 02 89 10-4, Preconstruction Test Results:

1. Submit following background results:

a. Area ambient air monitoring results by EPA Air Method TO-13A.

b. Wipe sampling in coating removal work area for coal tar components.

2. Include map indicating location of each sample.

3. Provide appropriate quality control information to supplement analytical data.

Include from blanks, laboratory control samples with percent recovery, duplicates, matrix spike samples with percent recovery, and other appropriate quality control measures.

F. RSN 02 89 10-5, Working Level Test Results:

1. Submit the following test results during work activities:

a. Personal and area air monitoring results for coal tar concentrations during coating removal activities. Air Samples for coal tar components are to be analyzed by EPA Air Method TO-13A.

2. Include map indicating location of each sample.

3. Provide appropriate quality control information to supplement analytical data.

Include from blanks, laboratory control samples with percent recovery, duplicates, matrix spike samples from project with percent recovery, and other appropriate quality control measures.

4. Provide these sample results to employees represented by the samples and the USBR within 5 days after the samples were collected.

G. RSN 02 89 10-6, Post-Construction Test Results:

1. Submit post-construction test results for:

a. Area ambient air monitoring results by TO-13A for coal tar components.

b. Wipe sampling in coating removal work area for coal tar components.

2. Compare with preconstruction test results for increased contaminant levels.

3. Include map indicating location of each sample.

Revised 02 89 10 – 7

4. Provide appropriate quality control information to supplement analytical data.

Include from blanks, laboratory control samples with percent recovery, duplicates, matrix spike samples from project with percent recovery, and other appropriate quality control measures.

H. RSN 02 89 10-7, Certificate of Disposal:

1. Submit certification that all hazardous materials and wastes have been treated and disposed of.

1.05 QUALIFICATIONS

A. Onsite Supervisor Qualifications:

1. Capable of identifying existing hazards and selecting appropriate control strategy.

2. Has the authority to take prompt corrective measures to eliminate them.

3. On jobsite during all hazardous waste related activities.

4. Duties include:

a. Control entry to and from any regulated area;

b. Assure employees wear appropriate PPE, are trained in the use of appropriate methods for exposure control, use proper hygiene methods and decontamination procedures;

c. Ensure engineering controls in use are in proper operating condition and are functioning properly.

d. Responsible for compliance with applicable federal, State of Wyoming, and local requirements, the contractors Accident Prevention Plan (Safety Plan), and Hazard Abatement Plan.

e. Helps develop and sign all plans relating to work he or she is supervising.

B. Certified Industrial Hygienists (CIH):

1. Certified by ABIH.

2. Experienced in designing, implementing, directing, and monitoring Emission and Exposure Monitoring Plan.

3. Completely independent from the Contractor.

C. Laboratory Qualifications:

1. Proficient in conducting coal tar analysis and accredited under a national accredited organization (EPA, AIHA, etc.).

D. Disposal Facility Qualifications for Hazardous Waste:

1. Approved for hazardous waste disposal as appropriate by the EPA, state, and local regulatory agencies.

Revised 02 89 10 – 8

1.06 REGULATORY REQUIREMENTS

A. Solid and hazardous waste debris is subject to all applicable Federal, State, local, requirements. The most stringent regulation shall apply. Listing and interpretations of regulations contained in this section do not relieve the Contractor from compliance with all regulations.

1.07 SAFETY AND HEALTH REGULATIONS

A. Comply with RSHS.

B. Comply with the Occupational Safety and Health Administration (OSHA) standards found in 29 CFR 1926.

C. Comply with State of Wyoming Department of Employment OSHA Standards.

D. Limit employee exposure to coal tar components and other airborne containments in accordance with ACGIH TLVs.

1.08 PROJECT CONDITIONS

A. Existing coating appears to be coal tar based and contains coal tar products and heavy metals. For laboratory report, see Section 51 00 20 – Hazardous Materials Report.

1.09 CONTRACTOR RESPONSIBILITIES

A. Obtain EPA Identification number from facility owner before treating, storing, or transporting hazardous waste.

B. Prepare manifest, in accordance with 40 CFR 262 Subpart B, before transporting hazardous waste for offsite treatment, storage, or disposal.

C. Before transporting hazardous waste, obtain written notice from owner or operator of hazardous waste facility, including documentation that facility has required permits and that facility will accept waste to be shipped under this Contract, in accordance with

40 CFR 264.12.

D. Determine proper disposal method for project solid waste or hazardous waste in accordance with EPA and Wyoming regulations.

E. Obtain certificate of disposal from disposal facility when hazardous waste has been treated or disposed.

F. Obtain required transportation permits.

PART 2 PRODUCTS

Revised 02 89 10 – 9

PART 3 EXECUTION

3.01 ABATEMENT AND CONTAINMENT SYSTEM

A. Design and construct abatement and containment systems to control releases and emissions to the environment in conformance with Federal, State, and local regulations and the following criteria:

1. Do not exceed ambient air quality standards.

2. Prevent contamination of any reservoir, watercourse, or water systems.

3. Prevent contamination of sediment in any reservoir or watercourse.

4. Prevent contamination of soil.

B. Design and construct abatement and containment systems for following:

1. Abatement components for removal and disposal of equipment.

2. Containment and ventilation components in accordance with SSPC Guide 6 for coating removal and reapplication.

C. The Upper Opening Containment shall be designed in accordance with IBC 2012, Chapter 16, and ASCE 7-10. The temporary structure shall be considered an Occupancy Category I structure with a Category C Exposure.

D. Perform the following activities within containment systems:

1. Coating removal.

2. Surface preparation.

3. Waste and debris containerization.

4. Activities which may prevent the spread contamination outside contained area.

E. Provide signs and barriers at each point of entry to containment area to deter unauthorized personnel access.

3.02 WASTE CHARACTERIZATION, HANDLING, AND DISPOSAL

A. Characterize solid waste debris generated from removal operations, in accordance with 40 CFR 261, TCLP Method 1311. Presume waste is hazardous until characterized.

B. Comply with approved written Plan for Waste Characterization, Handling, and Disposal.

C. RCRA-defined Hazardous Waste:

1. Comply with 40 CFR 262 and 40 CFR 268 (RCRA).

2. Comply with 40 CFR 700 – 766 (TSCA).

3. Comply with Wyoming Department of Environmental Quality Solid and Hazardous Waste Division - Hazardous Waste Rules.

Revised 02 89 10 – 10

4. Do not co-mix different types of hazardous and non-hazardous waste materials.

5. Store coating debris in EPA approved weatherproof, watertight steel containers.

6. Seal, label, and store in accordance with 49 CFR 178.

7. Dispose of waste at EPA permitted RCRA Subtitle C disposal facility.

D. Non-hazardous Waste:

1. Store in closed containers separate from hazardous waste storage areas.

2. Dispose waste in accordance with local, county, state, and federal regulations.

3. Comply with Section 01 74 00 – Cleaning and Waste Management.

E. Wastewater from Coating Removal Operations:

1. Filter water contaminated with organics-containing coating debris.

2. Dispose of wastewater in accordance with local, county, state, and federal regulations.

F. Transport hazardous waste materials in accordance with 40 CFR 263, 49 CFR 107, and applicable regulations contained in 49 CFR Chapter I.

G. Determine proper method of disposal for solid waste and hazardous waste materials.

3.03 EMISSIONS MONITORING, GENERAL

A. Sampling Protocol: In accordance with EPA, NIOSH, or OSHA sampling criteria.

B. Monitor for Components of Coal Tar Organics:

1. Air monitoring of emissions using high volume area sampling monitors.

2. Soil analysis for coal tar components.

C. Conduct visual inspections for visible emissions, spills, or deposits of contaminated materials (i.e., coating debris, dusts, stripping or blasting abrasives, etc.) into the water or onto the ground, ground cover, asphalt pavement, concrete pavement, soil, or slope protection. Include verification that proper cleanup is undertaken and that the cause(s) of unacceptable releases is corrected prior to resuming work.

3.04 AIR QUALITY MONITORING BY AREA AND EMPLOYEE EXPOSURE

PERSONNEL MONITORS

A. Perform employee exposure monitoring to determine exposure to coal tar coating components in accordance with EPA, NIOSH, or OSHA analytical sampling methods.

B. Do not exceed emissions limit standards in the ACGIH TLVs, 29 CFR 1910.1000 and

29 CFR 1926.55.

Revised 02 89 10 – 11

C. At the same time that employee exposure monitoring is done, monitor airborne contaminants at boundary of regulated area.

D. If emissions exceed specified maximum allowable concentrations, stop work until the containment system is corrected to meet required standards.

3.05 REPORTABLE RELEASES

A. Notify applicable agencies and COR.

3.06 CLEARANCE TESTING

A. Non-porous Surfaces:

1. Take wipe samples to collect surface dust at locations directed by COR in accordance with approved Emissions Monitoring Plan.

2. Analyze samples for coal tar components.

3. Acceptance criteria: Not to exceed background levels.

B. Porous Surfaces:

1. Visual Methods:

a. Visible paint chips and dust.

b. Visible abrasives.

3.07 DECONTAMINATION OF CONTAMINATED AREAS

A. Clean and decontaminate areas, surfaces, or soils contaminated with coal tar coating components or dusts from work activities to restore to background pre-construction levels.

Revised 02 89 10 – 12

This page intentionally left blank.

Guernsey Powerplant Surge Tank Inspection

NEW 51 00 10 –1

SECTION 51 00 10

GUERNSEY POWERPLANT SURGE TANK INSPECTION

PART 1 GENERAL

1.01 GUERNSEY POWERPLANT SURGE TANK INSPECTION (July 18, 2007)

A. Tank Inspection Report

NEW 51 00 10 –2

B. Photographs

NEW 51 00 10 –3

NEW 51 00 10 –4

NEW 51 00 10 –5

NEW 51 00 10 –6

NEW 51 00 10 –7

NEW 51 00 10 –8

NEW 51 00 10 –9

NEW 51 00 10 –10

NEW 51 00 10 –11

NEW 51 00 10 –12

NEW 51 00 10 –13

NEW 51 00 10 –14

NEW 51 00 10 –15

NEW 51 00 10 –16

C. Specification 1979

NEW 51 00 10 –17

NEW 51 00 10 –18

NEW 51 00 10 –19

NEW 51 00 10 –20

NEW 51 00 10 –21

NEW 51 00 10 –22

NEW 51 00 10 –23

NEW 51 00 10 –24

NEW 51 00 10 –25

NEW 51 00 10 –26

Guernsey Surge Tank Recoating Solicitation No. 140R6018R0005

F - 1 (Revised)

SECTION F -- DELIVERIES OR PERFORMANCE

F.1 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF

WORK

APR 1984

The Contractor shall be required to:

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) Prosecute the work diligently, and (c) Complete the entire work ready for use not later than 200 calendar days after the date the Contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises.

On-site work may commence on or after October 1, 2018.

F.2 52.242-14 SUSPENSION OF WORK APR 1984

(a) The Contracting Officer may order the Contractor, in writing, to suspend, delay, or interrupt all or any part of the work of this contract for the period of time that the Contracting Officer determines appropriate for the convenience of the Government.

(b) If the performance of all or any part of the work is, for an unreasonable period of time, suspended, delayed, or interrupted (1) by an act of the Contracting Officer in the administration of this contract, or (2) by the Contracting Officer's failure to act within the time specified in this contract (or within a reasonable time if not specified), an adjustment shall be made for any increase in the cost of performance of this contract (excluding profit) necessarily caused by the unreasonable suspension, delay, or interruption, and the contract modified in writing accordingly. However, no adjustment shall be made under this clause for any suspension, delay, or interruption to the extent that performance would have been so suspended, delayed, or interrupted by any other cause, including the fault or negligence of the Contractor, or for which an equitable adjustment is provided for or excluded under any other term or condition of this contract.

(c) A claim under this clause shall not be allowed -

(1) For any costs incurred more than 20 days before the Contractor shall have notified the Contracting Officer in writing of the act or failure to act involved (but this requirement shall not apply as to a claim resulting from a suspension order); and

(2) Unless the claim, in an amount stated, is asserted in writing as soon as practicable after the termination of the suspension, delay, or interruption, but not later than the date of final payment under the contract.

Guernsey Surge Tank Recoating Solicitation No. 140R6018R0005

F - 2 (Revised)

THIS PAGE INTENTIONALLY LEFT BLANK

Guernsey Surge Tank Recoating Solicitation No. 140R6018R0005

L - 15 (Revised) within the time allowed for performance. Discuss how subcontractors will be integrated into the project.

Include anticipated crew sizes, number of crews, composition of each crew, hours per day and hours per week that work will be occurring. In addition to the information addressed above, the schedule shall address major milestones:

1. Key RSNs that are required prior to commencing on-site work

2. Construction of containments

3. Coating removal, coating application and waste removal

4. Overall completion including final cleanup

1B. Procedure for coating removal, surface preparation, coating application and waste management – Submit a narrative detailing sealed Class I containments for the interior blasting, surface prep, and recoating operations in confined space. At a minimum, the contractor shall discuss work practices for hazardous materials, monitoring, work positioning, decontamination facilities, equipment and equipment positioning, filtration, thermal and moisture control, access/egress and rescue.

2. Company Experience – Furnish a list of Federal, State, local government or commercial projects similar in scope, complexity, and magnitude to the work required under this solicitation which the offeror has completed during the last 5-years, which clearly demonstrate ability to successfully accomplish projects in a timely manner, utilize resources and work with project owners. Projects of similar scope and complexity should involve industrial coatings, Class I containments, coatings in confined space, QP1 and QP2 certifications. The descriptions of work should include types of equipment used, accident prevention measures implemented, and supporting details which indicate similarities to those tasks identified in the solicitation.

Provide at a minimum the following information for each project:

1. Name and location of project.

2. Description of Work.

3. Original completion time and date, and actual dates and duration of each project.

4. Name, address and telephone number of owner.

5. Initial contract amount and final contract amount (including modifications).

6. Any problems encountered in performance of the work and corrective actions taken.

7. Name(s) and telephone number(s) of references who may be contacted for further information. Please ensure the telephone number(s) are accurate.

Include same information for any subcontractors who will perform significant portion of the work.

3. Key Personnel – Furnish resume information, which includes previous jobsite responsibilities on major contracts for individuals who will perform key functions on this project.