B08_140P2025R0044_ACAD_255256_AM_004_0004.pdf
PDF 81 KB Posted
- Attached to
- ACAD 255256 - Replace Harden Farm Sewer
- Solicitation number
- 140P2025R0044
About this file
This document is a solicitation for a federal contract opportunity to replace the Harden Farm Sewer system. The project is a Total Small Business Set-Aside issued by the Department of the Interior National Park Service, with solicitation number 140P2025R0044. Key contract terms include a 425-calendar day completion timeline, with a requirement to commence work within 10 calendar days of receiving the notice to proceed. The contract includes liquidated damages of $1,501 per calendar day for delays, payable to the government if the contractor fails to complete the work within the specified timeframe.
The solicitation outlines detailed requirements for work performance, inspection, and potential corrections, with provisions for government oversight and contractor accountability. The project involves replacing the sewage system with connection to municipal facilities, though specific technical details are not fully elaborated in this excerpt. Potential bidders are advised to contact the Contracting Officer, Tony Jasper, for additional information about the solicitation.
View the file
Other files
Show all 16
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Solicitation 5/23/2025
Document No.
140P2025R0044
Document Title
ACAD 255256 – Replace Harden Farm Sewer
Government shall perform all inspections and tests in a manner that will not unnecessarily delay the work. Special, full size, and performance tests shall be performed as described in the contract.
(f) The Contractor shall, without charge, replace or correct work found by the Government not to conform to contract requirements, unless in the public interest the Government consents to accept the work with an appropriate adjustment in contract price. The Contractor shall promptly segregate and remove rejected material from the premises.
(g) If the Contractor does not promptly replace or correct rejected work, the Government may—
(1) By contract or otherwise, replace or correct the work and charge the cost to the Contractor; or
(2) Terminate for default the Contractor’s right to proceed.
(h) If, before acceptance of the entire work, the Government decides to examine already completed work by removing it or tearing it out, the Contractor, on request, shall promptly furnish all necessary facilities, labor, and material. If the work is found to be defective or nonconforming in any material respect due to the fault of the Contractor or its subcontractors, the Contractor shall defray the expenses of the examination and of satisfactory reconstruction. However, if the work is found to meet contract requirements, the Contracting Officer shall make an equitable adjustment for the additional services involved in the examination and reconstruction, including, if completion of the work was thereby delayed, an extension of time.
(i) Unless otherwise specified in the contract, the Government shall accept, as promptly as practicable after completion and inspection, all work required by the contract or that portion of the work the Contracting Officer determines can be accepted separately. Acceptance shall be final and conclusive except for latent defects, fraud, gross mistakes amounting to fraud, or the Government’s rights under any warranty or guarantee.
(End of clause)
SECTION F – DELIVERIES OR PERFORMANCE
52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)
The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 425 calendar days after receipt of Notice to Proceed. The time stated for completion shall include final cleanup of the premises.
(End of clause)
52.211-12 LIQUIDATED DAMAGES—CONSTRUCTION (SEPT 2000)
(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,501 for each calendar day of delay until the work is completed or accepted.
(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.
(End of clause)
52.211-13 TIME EXTENSIONS (SEPT 2000)
File details come from the government source that posted it. Updated .