Attach_5_Spec_Vol_2.pdf

VALLEY FORGE NATIONAL

HISTORICAL PARK

York County, Pennsylvania

Rehabilitate Visitor Center for Energy Efficiency, Safety and ADA Access Project

VAFO

PMIS NO. 211497

PROJECT SPECIFICATIONS

VOL. 2

NATIONAL PARK SERVICE

DENVER SERVICE CENTER

JULY 10, 2018

VAFO 211497 000110

071018

TABLE OF CONTENTS

DIVISION SECTION TITLE

DIVISION 00 – PROCUREMENT AND CONTRACTING REQIREMENTS

000110 TABLE OF CONTENTS

DIVISION 01 – GENERAL REQUIREMENTS

011100 SUMMARY

012601 CONTRACT MODIFICATION PROCEDURES

012700 DEFINITION OF CONTRACT LIMIT LINES

013100 PROJECT MANAGEMENT & COORDINATION

013216 CONSTRUCTION SCHEDULE

0132 33 PHOTOGRAPHIC DOCUMENTATION

0133 23 SUBMITTAL PROCEDURES

013523 SAFETY REQUIREMENTS

014000 QUALITY REQUIREMENTS

014200 REFERENCE STANDARS

015000 TEMPORARY FACILITIES AND CONTROLS

015639 TEMPORARY TREE AND PLANT PROTECTION

015719.11 INDOOR AIR QUALITY MANAGEMENT

015719.12 NOISE & ACOUSTICS MANAGEMENT

015723 TEMPORARY STORM WATER POLLUTION PREVENTION

016700 PRODUCT REQUIREMENTS

017329 CUTTING AND PATCHING

017340 EXECUTION

017419 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

017700 CLOSEOUT PROCEDURES

017823 OPERATION AND MAINTENANCE DATA

017900 DEMONSTRATION AND TRAINING

018113 SUSTAINABLE DESIGN REQUIREMENTS FOR NON-LEED PROJECTS

019114 TOTAL BUILDING COMMISSIONING

TABLE OF CONTENTS

DIVISION SECTION TITLE

TECHNICAL SECTIONS

DIVISION 02 – EXISTING CONDITIONS

024119 SELECTIVE DEMOLITION

DIVISION 03 - CONCRETE

033000

CAST-IN-PLACE CONCRETE

033543 SPECIAL CONCRETE FLOOR FINISHES

DIVISION 04 – MASONRY

042200 CONCRETE UNIT MASONRY

047200 CAST STONE MASONRY

DIVISION 05 - METALS

051200 STRUCTURAL STEEL

053000 STEEL DECK

055000 METAL FABRICATIONS

055213 PIPE AND TUBE RAILINGS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

061053 MISCELLANEOUS ROUGH CARPENTRY

064113 WOOD AND PLASTIC-FACED ARCHITECTURAL CABINETS

064116 PLASTIC LAMINATE-CLAD ARCHITECTURAL CABINETS

DIVISION 07 – THERMAL AND MOISTURE PROTECTION

070150.19 PREPARATION FOR REROOFING

072100 THERMAL INSULATION

075216 SBS-MODIFIED BITUMEN MEMBRANE ROOFING

076200 SHEET METAL FLASHING AND TRIM

077200 ROOF ACCESSORIES

078413 PENETRATION FIRESTOPPING

079200 JOINT SEALANTS

TABLE OF CONTENTS

DIVISION SECTION TITLE

DIVISION 08 – OPENINGS

081113

HOLLOW METAL DOORS AND FRAMES

083213 INTERIOR SLIDING GLASS DOORS

084113 ALUMINUM-FRAMED ENTRANCES AND STOREFRONTS

084213 ALUMINUM-FRAMED ENTRANCES

084229.33 SWINGING AUTOMATIC ENTRANCES

087100 DOOR HARDWARE

088000 GLAZING

088000.13 INTERIOR GLAZING

DIVISION 09 - FINISHES

092116.23 092216

GYPSUM BOARD SHAFT WALL ASSSEMBLIES

NON-STRUCTURAL METAL FRAMING

092900 GYPSUM BOARD

093013 CERAMIC TILING

095113 ACOUSTICAL PANEL CEILINGS

096513 RESILIENT BASE AND ACCESSSORIES

096519 RESILIENT TILE FLOORING

096813 TILE CARPETING

096816 SHEET CARPETING

098436 SOUND ABSORBING CEILING UNITS

099123 INTERIOR PAINTING

DIVISION 10 - SPECIALTIES

101423

PANEL SIGNAGE

102113.13 METAL TOILET COMPARTMENTS

102800 TOILET, BATH AND LAUNDRY ACCESSORIES

105123 PLASTIC-LAMINATE-CLAD WOOD LOCKERS

107500 FALL RESTRAINT

DIVISION 11 - EQUIPMENT

113100 RESIDENTIAL APPLIANCES

TABLE OF CONTENTS

DIVISION SECTION TITLE

DIVISION 12 - FURNISHINGS

122413

ROLLER WINDOW SHADES

123661.19 QUARTZ AGGLOMORATE COUNTER TOPS

124816 ENTRANCE FLOOR GRILLES

DIVISION 14 - CONVEYING EQUIPMENT

142600

LIMITED-USE-LIMITED-APPLICATION ELEVATORS

DIVISION 21 - FIRE SUPPRESSION

21 00 01

SEPARATION OF WORK BETWEEN THE TRADES

21 00 02 FIRE PROTECTION SPECIAL CONDITIONS

21 00 03 SCOPE OF WORK

21 05 17 SLEEVES AND SEALS FOR FIRE SUPPRESSION PIPING

21 05 18 ESCUTCHEONS FOR FIRE SUPPRESSION PIPING

21 05 20 PIPING AND FITTING MATERIALS

21 05 23 FIRE SUPPRESSION VALVES

21 05 29 HANGERS, SUPPORTS, ANCHORS AND GUIDES FOR FIRE SUPPRESSION SYSTEMS

21 05 48 VIBRATION AND SEISMIC CONTROLS FOR FIRE SUPPRESSION PIPING AND EQUIPMENT

21 05 53 IDENTIFICATION OF FIRE SUPPRESSION PIPING AND EQUIPMENT

21 05 80 ACCESS DOORS IN GENERAL CONSTRUCTION

21 05 85 FIRE PROTECTION FIRESTOPPING

21 05 95 FIRE PROTECTION BASIC MATERIALS AND METHODS

21 08 00 COMMISSIONING OF FIRE PROTECTION SYSTEMS

21 12 00 STANDPIPE AND HOSE SYSTEMS

21 13 13 WET PIPE SPRINKLER SYSTEMS

DIVISION 22 - PLUMBING

22 00 01

SEPARATION OF WORK BETWEEN TRADES

22 00 02 PLUMBING SPECIAL CONDITIONS

22 00 03 SCOPE OF WORK

22 05 17 SLEEVES AND SLEEVE SEALS FOR PLUMBING PIPING

22 05 18 ESCUTCHEONS FOR PLUMBING PIPING

22 05 20 PIPING AND FITTING MATERIALS

22 05 23 VALVES

22 05 29 HANGERS, SUPPORTS, ANCHORS AND GUIDES

22 05 30 DISINFECTING OF WATER SUPPLY SYSTEM

22 05 35 BACKFLOW PREVENTION

22 05 48 VIBRATION ISOLATION AND SEISMIC CONTROL FOR PLUMBING SYSTEM

22 05 53 IDENTIFICATION OF PLUMBING PIPING AND EQUIPMENT

22 05 80 ACCESS DOORS IN GENERAL CONSTRUCTION

22 05 85 PLUMBING FIRESTOPPING

22 05 90 TESTING

22 05 95 PLUMBING BASIC MATERIALS AND METHODS

22 07 19 INSULATION

22 08 00 COMMISSIONING OF PLUMBING SYSTEM

22 11 16 DOMESTIC WATER PIPING AND FITTING MATERIALS

22 11 19 DOMESTIC WATER SPECIALTIES

22 13 16 SANITARY WASTE AND VENT PIPING AND FITTING MATERIALS

22 13 19 SANITARY WASTE PIPING SPECIALTIES

22 42 00 PLUMBING FIXTURES AND TRIM

DIVISION 23 - HVAC

23 00 02 HEATING, VENTILATION, AND AIR CONDITIONING GENERAL CONDITIONS

23 00 05 ACCESS DOORS IN GENERAL CONSTRUCTION

23 02 00 FIRESTOPPING

23 05 13 ELECTRIC MOTORS

23 05 16 EXPANSION COMPENSATORS

23 05 23 VALVES

23 05 29 HANGERS, ANCHORS AND SUPPORTS

23 05 40 ACOUSTICS

23 05 48 VIBRATION ISOLATION

23 05 53 SYSTEMS IDENTIFICATION

23 05 93 TESTING, ADJUSTING AND BALANCING

23 07 00 INSULATION

23 09 00 INSTRUMENTS

23 09 23

BUILDING MANAGEMENT AND CONTROL SYSTEMS (BMCS)

23 11 13 SHEET METAL, DUCTWORK, AND ACCESSORIES

23 21 23 PUMPS

23 25 00 PIPE CLEANING AND CHEMICAL WATER TREATMENT

23 26 00 WATER SPECIALTIES

23 33 13 DAMPERS

23 33 20 DUCT CLEANING

23 36 00 AIR TERMINAL UNITS

23 36 10 AIR OUTLETS AND INLETS

23 41 00 AIR FILTERS AND CLEANERS

23 52 10 PIPING AND ACCESSORIES

23 55 10 REFRIGERATION MACHINES (AIR COOLED)

23 73 00 FACTORY ASSEMBLED AIR HANDLING UNITS

23 73 05 FANS

23 82 16 COILS

23 82 19 FAN COIL UNITS

23 84 13 STEAM HUMIDIFIERS

23 84 40 SPACE HEATING UNITS

23 85 00 VARIABLE FREQUENCY CONTROLLERS

DIVISION 26 – ELECTRICAL

26 00 01 ELECTRICAL GENERAL CONDITIONS

26 00 05 ACCESS DOORS IN GENERAL CONSTRUCTION

26 02 50 SYSTEMS IDENTIFICATION

26 02 70 TEMPORARY LIGHTING AND POWER

26 02 80 EQUIPMENT CONNECTIONS AND COORDINATION

26 02 90 CEILING, FLOOR AND WALL ELECTRICAL PENETRATION FIRE SEALS

26 05 19 600 VOLT WIRE AND CABLE

26 05 33 RACEWAYS AND BOXES

26 05 48 VIBRATION ISOLATION AND SEISMIC RESTRAINTS

26 05 73

OVERCURRENT PROTECTIVE DEVICE

COORDINATION STUDY

26 08 00 COMMISSIONING OF ELECTRICAL SYSTEMS

26 09 36 MODULAR DIMMING CONTROLS

26 24 16 PANELBOARDS

26 27 26 WIRING DEVICES

26 28 16 DISCONNECT SWITCHES

26 31 00 PHOTOVOLTAIC SYSTEM

26 50 00 LUMINAIRES AND ACCESSORIES

26 50 06 LIGHTING CONTROL DEVICES

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 00 00

SECURITY GENERAL SYSTEM REQUIREMENTS

28 05 28 FIRESTOPPING FOR COMM-SECURITY SYSTEMS

28 13 00 ACCESS CONTROL SYSTEM

28 13 01 ACCESS CONTROL CARD READERS

28 16 00 INTRUSION DETECTION SYSTEM

28 21 00 VIDEO SURVEILLANCE REMOTE SENSORS AND DEVICES

28 23 00 VIDEO SURVEILLANCE MANAGEMENT SYSTEM

28 31 11 LIFE SAFETY ALARM SYSTEM

DIVISION 32 – EXTEROR IMPROVEMENTS

321216

ASPHALT PAVING

321223 IMPRINTED ASPHALT

321313 CONCRETE PAVING

END OF TABLE OF CONTENTS

https://www.arcat.com/sd/divs/sd_div28.shtml

VAFO - 211497 210001 - 1

071018 DESIGN DOCUMENTS –

SEPARATION OF WORK BETWEEN

THE TRADES

SECTION 210001 – DESIGN DOCUMENTS – SEPARATION OF WORK BETWEEN THE TRADES

PART 1 - GENERAL

1.1 DESCRIPTION

A. The specifications delineate various items of related work under separate trade headings in accordance with the Design Documents as listed below.

B. Indications that the electrical and mechanical trades are to perform an item of work means that they are to perform the work for their own accommodation only, except as specifically noted otherwise.

C. Key to Abbreviations:

"OTHER" = Provided for Owner by General Contractor

"PLBG" = Plumbing

"FP" = Fire Protection

"HVAC" = Heating, Ventilating and Air Conditioning

"ELECT" = Electrical

"F" = Furnished

"I" = Installed

"P" = Provided (Furnished and Installed)

"C" = Final Connection

D. The following is a list of work and the trade or trades that perform the work:

Other Plbg FP HVAC Elect Notes

Temporary Heat P

Temporary Water P

Temporary Light & Power P

Temporary Fire Standpipe P

Temporary Toilets P

VAFO - 211497 210001 - 2

SEPARATION OF WORK BETWEEN

THE TRADES

Other Plbg FP HVAC Elect Notes

Excavation & Backfill for M&E Inside Bldg for M&E Outside Bldg

P P P P P

Dewatering Site & Excavation P

Subsoil Drainage Inside Building Outside Building

P P

C C

Footing Drains P C

Drywells P

Manhole & Covers P P P P

Concrete Equipment Bases and Pads:

Inside Building Outside Building

P P

Masonry Pits P

Pit Frames & Covers I F

Fuel Oil Tank Cradle P

Trenches in Floor Slabs P

Anchors and Vibration Mounts in Inertia Blocks

I F F F F

Concrete Encasement of Underground Runs P P P P

Fastening and Supports P P P P

Cutting, Chasing and Patching P P P P

Framed Slots and Openings I F F F F

Sleeves through Slabs, Decks and Walls P P P P

Waterproof Sealing of Openings P P P P

Fireproof Sealing of Excess Openings P P P P

Drilling & Cutting of all Holes P P P P

Hoisting and Rigging P P P P

Floor Drain Flashing P

Base Flashing for all Roof Penetrations P

Cap Flashing for all Roof Piping Penetrations

P P P P

VAFO - 211497 210001 - 3

SEPARATION OF WORK BETWEEN

THE TRADES

Other Plbg FP HVAC Elect Notes

Roof Curb Base Flashing P

Roof Curb Cap Flashing P

Prime Painting M&E Work P P P P

Field Touch-Up Painting P P P P

Rustproofing Field Cut Iron Work P P P P

Color Coding M&E Work P P P P

Precast Receptors P

Shower Stall Pan Flashing P

Toilet Room Accessories P

Soap Dispensers P

Domestic Water Make-Up P

Fire Hose & Cabinets P

Fire Extinguishers P

Fire Extinguisher Cabinets P

Finished Access Doors & Frames I F F F F

Ladders & Catwalks P

Motors for Mechanical Equipment P P P

Loose Motor Controls for Mechanical Equipment

F F F I

Motor Control Centers P

Disconnect Switches P

Wiring for Equipment Motors and Starters P

Premounted & Prewired Starters and Disconnects

P P P C

Electric Radiators and Convectors P

Electric Duct Heaters P C

Heat Tracing Cable F F F I

Electric Water Heater P C

Plaster Frames for Ceiling Mounted Fixtures, Ceiling Diffusers, etc.

I F F

VAFO - 211497 210001 - 4

SEPARATION OF WORK BETWEEN

THE TRADES

Other Plbg FP HVAC Elect Notes

Cellular Decking P

Trench Headers P

Preset Activation Kits P

Power Circuit to Starter Disconnect Switch and Motor

P

Line Voltage Control Device (Aquastat) etc. P P C

Control Device Not in Power Circuit to Motor

P P

Temperature Control Device & Electric Actuator

P P

Sprinkler & Standpipe Alarm System:

Devices Panels

P C P

Halon, Deluge and Pre-Action Sprinkler, Smoke and Thermal Detection

P

Space Smoke Detector P

Duct Smoke Detector I F&C

Smoke Control/Fire Alarm Panel P

Boiler and Refrigeration Room Shut-off & Break Glass

P C

Kitchen Hood Fire Suppression System P C

Lighting Fixtures P

Exterior Wall Louvers P

Radiator Enclosures P

Ornamental Grilles P

Air Boots for Air/Light Fixtures and Perimeter Slots

P

Raised Floor P

Air Outlets in Raised Floor I F

Masonry Chimney Breeching Frame P

Masonry Chimney Cleanout Door P

Prefabricated Chimney P

VAFO - 211497 210001 - 5

SEPARATION OF WORK BETWEEN

THE TRADES

Other Plbg FP HVAC Elect Notes

Kitchen Range Hood P

Dishwashing Hoods P

Food Service Equipment P C C C

Refrigerators P C

Refrigerator Condensing Units, Air Cooled P C

Refrigerator Condensing Units, Water Cooled

P C C

Lightning Protection P

Surgical Lights P C

Pneumatic Tube System P C

Exterior Transformer Vault P

Incinerator P C C C

Elevator P C

Escalator P C

Lifts P C

Laboratory Equipment P C C C

Hospital Equipment P C C C

Laundry Equipment P C C C

Window Washing Machines P C C

Linen/Garbage Chutes P C

Vermiculite Fireproofing P

Rubbish Removal P P P P

Maintenance Tools F F F F

E. SPECIFIC NOTES:

1. Plumbing Trade to provide sizes and locations.

2. Covers and Frames for sewage ejectors, sump pump and silt pits furnished by Plumbing Trade.

3. Details furnished by individual Trades.

VAFO - 211497 210001 - 6

SEPARATION OF WORK BETWEEN

THE TRADES

4. Final connections included in HVAC work.

5. When not part of premounted starter.

6. Insulation covering by each Trade after heating cable is connected and tested.

7. Preparation of cells for electricification is in Electrical work.

8. Purchased by Electrical Trade.

9. Power to Halon Control Panel by Electrical Trade; tie into fire alarm system by Electrical Trade; all other by Fire Protection Trade.

10. Power to Kitchen Hood Fire Protection System and gas pipe solenoid valve by Electrical Trade; tie into fire alarm system by Electrical Trade.

11. Duct connections and safing of unused portions of louvers by HVAC Trade.

12. Except where custom enclosures are provided by others.

13. Where one Trade furnishes and another installs, the installing Trade removes the shipping and packing materials where accumulated.

PART 2 - PRODUCTS

2.1 NOT USED.

PART 3 - EXECUTION

3.1 NOT USED.

END OF SECTION 210001

VAFO - 211497 210002 - 1

071018 FIRE PROTECTION SPECIAL CONDITIONS

SECTION 210002 – FIRE PROTECTION SPECIAL CONDITIONS

PART 1 - GENERAL

1.1 DESCRIPTION

A. The General and Supplementary Conditions accompanying these Specifications are hereby made a part of the requirements for the work under this Division of the Specification.

1.2 WORK INCLUDED

A. Provide labor and materials required to install, test and place into operation the fire protection systems as called for in the contract documents, and according to applicable codes and regulations.

B. Furnish and install all labor, materials, apparatus, and appliances essential to the complete functioning of the systems described and/or indicated herein, or which may be reasonably implied as essential whether mentioned in the Contract Drawings and Specifications or not.

1.3 SUBMITTALS

A. Submit all shop drawings, manufacturer's data, samples and test reports as called for hereinafter.

B. Submit a single guarantee stating that all parts of the work are in accordance with Contract requirements. Guarantee work against faulty and improper material and workmanship for a period of one (1) year from date of final acceptance by the Contracting Officer, except that where guarantees or warranties for longer terms are specified herein, such longer term to apply. Within 24 hours after notification, correct any deficiencies which occur during the guarantee period at no additional cost to the Contracting Officer, to the satisfaction of the Contracting Officer. Obtain similar guarantees from subcontractors, manufacturers, suppliers and subtrade specialists.

C. Indemnify the Contracting Office against loss, liability, damage or expense, including attorneys' fees, in connection with any claim resulting from damage which may be asserted by any third party.

1.4 QUALITY ASSURANCE

A. Comply with current governing codes, ordinances and regulations, as well as with requirements of EPA, U.L. and all other applicable codes.

B. Comply with the requirements of agencies or authorities having jurisdiction over any part of the work and secure all necessary permits.

C. Where codes or standards are listed herein, the applicable portions apply.

VAFO - 211497 210002 - 2

D. Plans, specifications, codes and standards are minimum requirements. Where requirements differ, apply the more stringent.

E. Should any change in plans or specifications be required to comply with governing regulations, notify the Contracting Officer at the time of submitting this bid.

F. Execute work in strict accordance with the best practices of the trades in a thorough, substantial, workmanlike manner by competent workmen. Provide a competent, experienced full-time Superintendent who is authorized to make decisions on behalf of the Contractor.

1.5 ABBREVIATIONS AND DEFINITIONS

A. Abbreviations

1. AGA American Gas Assoc.

2. ANSI American National Standards Institute

3. ASA Acoustical Society of America

4. ASHRAE American Society of Heating, Refrigerating, and Air Conditioning

Engineers

5. ASME American Society of Mechanical Engineers

6. ASPE American Society of Plumbing Engineers

7. ASTM American Society for Testing and Materials

8. ASSE American Society of Sanitary Engineers

9. AWWA American Water Works Association

10. AWS American Welding Society

11. EPA Environmental Protection Agency

12. FM (FMS) Factory Mutual (Factory Mutual System)

13. FS Federal Specifications

14. NAPHCC National Association of Plumbing Heating & Cooling Contractors

15. NEMA National Electrical Manufacturers Association

16. NFPA National Fire Protection Association

17. OSHA Occupational Safety and Health Administration

18. U.L. Underwriters Laboratories

B. Definitions

1. "PROVIDE" means to "Furnish" and "Install".

2. "INSTALL" means to join, unite, fasten, link, attach, set up or otherwise connect together before testing and turning over to Contracting Officer, complete and ready for regular operation, the particular work referred to.

3. "FURNISH" means to purchase and supply all materials, labor, equipment, testing apparatus, controls, tests, accessories and all other items customarily required for the proper and complete application for the particular work referred to.

4. "AS DIRECTED" means as directed by the Architect/Engineer, or his representative.

5. "CONCEALED" means embedded in masonry or other construction, installed behind wall furring or within double partitions, or installed within hung ceilings or shafts.

6. "SUBMIT" means submit to Engineer for review. Refer to Architectural General and

Special Conditions for proper procedures.

VAFO - 211497 210002 - 3

PART 2 - PRODUCTS

2.1 EQUIPMENT AND MATERIALS

A. If products and materials are specified or indicated on the Drawings for a specific item or system, use those products or materials. If products and materials are not listed in either of the above, use first class products and materials, subject to approval of the Engineer.

B. Provide products and materials that are new, clean, free of defects and free of damage and corrosion.

C. All products and materials used in this project will not contain asbestos, P.C.B.'s or any other material which is considered hazardous by the Department of Environmental Protection or any other agency having jurisdiction.

D. Replace materials of less than specified quality as designated by the Engineer and relocate work incorrectly installed as determined by the Engineer.

E. Provide name/data plates on all components of equipment with manufacturer's name, model number, serial number, capacity data and electrical characteristics attached in a conspicuous place.

F. Install materials and equipment with qualified trades people.

G. Maintain uniformity of manufacture for equipment used in similar applications and sizes.

H. Applicable equipment and materials to be listed by Underwriters' Laboratories and manufactured in accordance with ASME, AWWA, or ANSI standards, and as approved by local authorities having jurisdiction.

I. Fully lubricate equipment when installed.

J. Do not operate water or systems until piping has been cleaned and startup strainers are in place.

K. Locate all floor mounted equipment on a 4" high concrete pad. Concrete work to be provided by another trade. Coordinate size and location with General Contractor providing concrete pads.

L. Secure equipment with bolts, washers and locknuts of ample size to support equipment.

Embedded anchor bolts to have bottom plate and pipe sleeves. Grout machinery set in concrete under the entire bearing surface. After grout has set, remove wedges, shims and jack bolts and fill space with grout.

M. Locate valves, access doors, etc. to be easily accessible, either in mechanical spaces or through access panels as specified hereinafter, or as required. Coordinate and obtain Architect's and Engineer's approval of access panel locations.

N. Follow manufacturers' instructions for installing, connecting, and adjusting equipment. Provide one copy of such instructions to the Engineer before installing any equipment. Provide a copy of such instructions and attach to the equipment during work on the equipment.

VAFO - 211497 210002 - 4

O. Pressure vessels and relief valves shall be selected, built and labeled in accordance with ASME.

Obtain a certificate from the authority having jurisdiction showing such acceptance, and mount this certificate in a black frame under glass or laminated plastic adjacent to each pressure vessel and relief valve.

P. Where factory testing of equipment is required to ascertain performance and attendance by the Contracting Officer's representative is required to witness such tests, associated travel costs and subsistence shall be borne by the Contractor.

Q. Equipment capacities, etc., are scheduled or specified for job site operating conditions.

Equipment sensitive to altitude shall be derated with the method of derating identified on shop drawings.

2.2 SHOP DRAWINGS, PRODUCT DATA AND SAMPLES

A. Within two (2) months after notice to proceed by the Contracting Officer, or after execution of Contractor Agreement, submit to the Contracting Officer for review, a complete typed list of all mechanical equipment manufacturers and material suppliers for the equipment intended to be furnished and installed on this project as well as names of all subcontractors.

B. Within four (4) months after notice to proceed by the Contractive Officer, prepare an index of all submittals for the project. Include a submittal identification number, a cross-reference to the Specification sections or Drawing number, and an item description. Prefix the submittal identification number by the Specification sections to which they apply. Indicate on each submittal, the submittal identification number in addition to the other data specified. All subcontractors will utilize the assigned submittal identification number.

C. After the Contract is awarded, obtain complete shop drawings, product data and samples from the manufacturers, suppliers, vendors, and all subcontractors, for all materials and equipment specified in the various sections of the specification. Submit data and details of such materials and equipment for review by the Contracting Officer. Prior to submission of the shop drawings, product data and samples to the Contracting Officer, review and certify that these items are in compliance with the Contract Documents. Check all materials and equipment upon their arrival on the job site and verify their compliance with the Contract Documents. Modify any work which proceeds prior to receiving accepted shop drawings as required to comply with the Contract Documents and the shop drawings, at no cost to the project.

D. Prior to fabrication or installation of any work, completely coordinate work of all trades and prepare a complete set of Coordination Drawings.

2.3 REVIEWS

A. Contracting Officer’s review is for general compliance with the design concept and contract documents. Markings or comments or the lack thereof does not relieve the Contractor from compliance with the project plans and specifications. The Contractor remains solely responsible for details and accuracy, for confirming and correlating all quantities and dimensions, for selecting fabrication processes, for techniques of construction, for performing his work in a safe manner, and for coordinating his work with that of other trades.

VAFO - 211497 210002 - 5

B. No part of the work shall be started in the shop or in the field until the Contracting Officer has reviewed the shop drawings and samples for that portion of the work.

C. A minimum period of ten (10) working days, exclusive of transmittal time, will be required in the Engineer's office each time a shop drawing, product data and/or samples are submitted for review.

This time period must be considered by the Contractor when scheduling his work.

D. Submit two prints of all sheet metal and piping drawings.

1. Submit six (6) copies of catalog cuts.

E. Submissions will be stamped as described in Section 013323.

2.4 ALTERNATIVE MATERIALS AND EQUIPMENT

A. Contract Documents are based on materials specified and on equipment manufacturers indicated on the Drawings. Approval by Contracting Officer of equipment manufacturers other than indicated on the Drawings or materials other than specified, does not relieve Contractor of any responsibility to provide equipment and materials which will meet the performance as stated or implied by the Contract Documents.

B. Only those equipment manufacturers listed in individual sections are acceptable for this project, subject to requirements of contract documents.

C. Submit proposals to supply alternative materials or equipment, in writing, to the Contracting Officer with sufficient lead time for review by Contracting Officer prior to the date equipment must be ordered to maintain project schedule. Contractor submitting alternative will reimburse Contracting Officer for all costs associated with the review of the proposed alternative whether alternative is accepted or rejected. Include the following information with the proposal.

1. A description of the difference between the contract requirements and that proposed, the comparative features of each, and the effect of the change on the end result performance.

Include the impact of all changes on other contractors and acknowledge the inclusion of implementation costs.

2. A list of the contract requirements that must be revised if the change is accepted, including any suggested specification revisions.

3. Include a description and estimate of costs the Contracting Officer may incur in implementing the change, such as test, evaluation, operating and support costs.

4. A projection of any effects the proposed change would have on collateral costs to the National Park Service.

5. A statement of the time by which a contract modification accepting the change must be issued, noting any effect on the contract completion time or the delivery schedule.

6. A statement indicating the reduction to the contract price if the Contracting Officer accepts the change. Be responsible for appropriate modifications to all trades.

D. Include all revisions required to adapt alternatives in such proposals, including revisions by other trades. No increase in the contract price will be considered to accommodate the use of alternative equipment.

E. Wherever operating results such as quantity delivered or pressure obtained are scheduled, or when the make and size of apparatus, for which such quantities are readily determinable, is

VAFO - 211497 210002 - 6

specified, the substitution being proposed must conform substantially to the quantities specified or implied. The substitution must fit into available space conditions and must function properly in coordination with the rest of the system.

PART 3 - EXECUTION

3.1 FEES

A. Pay all required fees.

B. Pay royalties or fees required in connection with the use of patented devices and systems.

C. Provide controlled inspection where required by local authorities or by these specifications.

3.2 DRAWINGS & PRODUCT DATA

A. Submit materials and equipment by manufacturer, trade name and model number. Include copies of applicable brochure or catalog material. Do not assume applicable catalogs are available in the Engineer's office. Maintenance and operating manuals are not suitable substitutes for shop drawings.

B. Identify each sheet of printed submittal pages (using arrows, underlining or circling) to show applicable sizes, types, model numbers, ratings, capacities and options actually being proposed.

Cross out non-applicable information. Note specified features such as special tank linings, pump seals, materials or painting.

C. Include dimensional data for roughing in and installation, technical data sufficient to verify that equipment meets requirements of drawings and specifications. Include wiring, piping and service connection data, motor sizes complete with voltage ratings and schedules.

D. Maintain a complete set of reviewed and stamped shop drawings and product data on site.

E. Prepare and submit detailed shop drawings for ductwork piping work and other distribution services in 3/8" = 1'-0" scale, including locations and sizes of openings in floor decks, walls and roofs.

F. The Contractor is not relieved of the responsibility for dimensions or errors that may be contained on submissions reviewed by the Engineer, or for deviations from requirements in the Contract Documents. Understand clearly that the Engineer's noting some errors but overlooking others does not grant the Contractor permission to proceed in error. Regardless of any information contained in the shop drawings, product data and samples, the Contract Documents govern the work and are neither waived nor superseded in any way by the review of shop drawings, product data and samples.

G. Inadequate or incomplete shop drawings, product data and/or samples will not be reviewed by the Engineer and will be returned to the Contractor for resubmittal.

VAFO - 211497 210002 - 7

H. Indicate in the lower right-hand corner of each shop drawing, and each product data brochure on the front cover, the following: The submittal identification number; title of the sheet or brochure;

name and location of the Project; names of the Architect, Engineer, Contractor, Subcontractor, manufacturer, supplier, and vendor; the date of submittal; and the date of each correction and version and revision. Number all pages and drawings in product data brochures consecutively from beginning to end. Unless the above information is included, the submittal will be returned for resubmission. Include with resubmittals of product data or brochures a cover letter summarizing the corrections made in response to the review comments and the submittal page numbers which were revised.

3.3 CONTRACTOR'S COORDINATION DRAWINGS

A. Coordinate efforts of all trades and furnish, in writing, any information necessary to permit the work of all trades to be installed satisfactorily and with the least possible interference or delay.

B. Prepare a complete set of construction Coordination Drawings indicating the equipment actually purchased and the exact routing for all lines such as piping, busway, conduit, ductwork, etc., including conduit embedded in concrete. Use the sheetmetal shop drawings as the base drawings to which all other contractors will add their work. Complete each Coordination Drawing and have signed-off by the other subcontractors and the General Contractor prior to the installation of the work in the area covered by the specific drawing.

C. Indicate piping loads and support points for all piping 4" and larger, racked piping, racked conduit, and busway, and submit to the Structural Engineer for review and approval. Indicate the elevation, location, support points, static, dynamic and expansion forces and loads imposed on the structure at support, anchor points, and size of all lines. Indicate all beam penetrations and slab penetrations sized and coordinated. Indicate all work routed underground or embedded in concrete by dimension to column and building lines.

D. This requirement for Coordination Drawings is not authorization for the Contractor or Subcontractor to make any unauthorized changes to the Contract Drawings. Maintain all Design Drawing space allocations such as ceiling height, eight (8) inch high zone directly above the ceiling for tenant buildout and flexibility, chase walls, equipment room size, etc., unless prior written authorization is received from the Architect to change them.

E. Work installed which interferes with work of any other trade will be corrected at no cost to the project.

VAFO - 211497 210002 - 8

3.4 COORDINATION OF WORK

A. The fire protection drawings show the general arrangement of piping. Follow these drawings as closely as the actual construction and the work of other trades will permit. Provide offsets, fittings, and accessories which may be required but not shown on the drawings. Investigate the site, structural and finish ground conditions affecting the work, and arrange the work accordingly.

Provide such work and accessories as may be required to meet such conditions, at no additional cost to the project.

B. Certain materials will be provided by other trades. Examine the Contract Documents to ascertain these requirements.

C. Carefully check space requirements with other trades to ensure that material can be installed in the spaces allotted thereto with sufficient access space, including finished suspended ceilings.

D. Wherever work interconnects with work of other trades, coordinate with other trades. Insure that they have the information necessary so that they may properly install the necessary connections and equipment. Identify items (valves, cleanouts, etc.) requiring access in order that the Ceiling Trade will know where to install access doors and panels.

E. Consult with other trades regarding equipment so that, wherever possible, motors, motor controls, pumps and valves are of the same manufacture.

F. Furnish and set sleeves for passage of pipes, ducts and conduits through structural masonry and concrete walls and floors and elsewhere as will be required for the proper protection of each pipe and duct passing through building surfaces.

G. Properly provide firestopping around all pipes, conduits, ducts, sleeves, etc. which pass through rated walls, partitions and floors.

H. Provide detailed information on openings and holes required in precast members for mechanical work. Cast holes 4 inches and larger in diameter. Field-cut holes smaller than 4 inches.

I. Provide required supports and hangers for, piping and equipment, designed so as not to exceed allowable loadings of structures.

J. Examine and compare the contract drawings and specifications with the drawings and specifications of other trades, and report any discrepancies between them to the Engineer and obtain from him written instructions for changes necessary in the work. Install and coordinate the work in cooperation with other related trades. Before installation, make proper provisions to avoid interferences.

VAFO - 211497 210002 - 9

K. Wherever the work is of sufficient complexity, prepare additional detail drawings to scale similar to that of the design drawings, prepared on tracing medium of the same size as contract drawings.

With these layouts, coordinate the work with the work of other trades. Such detailed work to be clearly identified on the drawings as to the area to which it applies. Submit these drawings to the Engineer for review. At completion include a set of such drawings with each set of as-built drawings.

L. Before commencing work, examine adjoining work on which this work is in any way dependent for perfect workmanship and report conditions which prevent performance of first class work.

Become thoroughly familiar with actual existing conditions to which connections must be made or which must be changed or altered.

M. Adjust location of pipes, ducts, panels, equipment, etc., to accommodate the work to prevent interferences, both anticipated and encountered. Determine the exact route and location of each pipe and duct prior to fabrication.

1. Right-of-Way: Lines which pitch have the right-of-way over those which do not pitch. For example: condensate, steam, and plumbing drains normally have right-of-way. Lines whose elevations cannot be changed have right-of-way over lines whose elevations can be changed.

2. Make offsets, transitions and changes in direction in pipes and ducts as required to maintain proper head room and pitch on sloping lines. Furnish and install traps, air vents, drains, etc., as required to affect these offsets, transitions and changes in direction.

N. Install fire protection work to permit removal (without damage to other parts) of coils, heat exchanger plates and tube bundles, fan shafts and wheels, filters, belt guards, sheaves and drives, and other parts requiring periodic replacement or maintenance. Arrange pipes, and equipment to permit access to valves, cocks, traps, starters, motors, and control components, and to clear the openings of swinging doors and access panels.

O. In cases of doubt as to the work intended, or in the event of need for explanation thereof, request supplementary instructions from the Architect and/or Engineer.

P. Immediately upon the award of this Contract, but prior to commencing any work, confer together with designated major subcontractors, with the Contracting Officer concerning the work under this Contract.

3.5 CUTTING AND PATCHING

A. Lay out the work in advance, fully coordinated with other trades. Where cutting, channeling, chasing or drilling of floors, walls, partitions, ceilings or other surfaces is necessary for the proper installation, support or anchorage of ductwork, piping or other equipment, do the work carefully so as not to damage adjacent work. Repair any damage to the building, piping, equipment or defaced finish plaster, woodwork, metalwork, etc. using skilled mechanics of the trades involved at no additional cost to the National Park Service.

B. Do no cutting, channeling, chasing or drilling of unfinished masonry, tile, etc., unless permission from the Architect is first obtained. If permission is granted, perform this work in a manner approved by the Contracting Officer.

VAFO - 211497 210002 - 10

C. Where piping or equipment are mounted on a painted finished surface, or a surface to be painted, paint to match the surface. Cold galvanize bare metal whenever support channels are cut.

D. Provide slots, chases, openings and recesses through floors, walls, ceilings, and roofs as required to properly install work. Be responsible to properly locate such openings and provide for any cutting and patching caused by the neglect to do so.

3.6 RESPONSIBILITY FOR EVALUATION

A. The Engineer makes no representations, regarding the character or extent of the subsoils, water levels, existing structural, mechanical and electrical installations, above or below ground, or other subsurface conditions which may be encountered during the work. This Contractor must make his own evaluation of existing conditions which may affect methods or cost of performing the work, based on his own examination of the facility or other information. Failure to examine the drawings or other information does not relieve the Contractor of his responsibility for satisfactory accomplishment of the work.

3.7 DELIVERY, DRAYAGE AND HAULING

A. Include all drayage, hauling, hoisting, shoring and placement in the building of equipment specified herein. Be responsible for the timely delivery and introduction of equipment to the project as required by the construction schedule for this project. If any item of equipment is received prior to the time it is required, be responsible for its proper storage and protection until such time as it may be required. Pay for all costs of demurrage or storage.

B. If any item of equipment is not delivered to or installed at the project site in a timely manner as required by the project construction schedule, be solely responsible for disassembly, re-assembly, manufacturer's supervision, shoring, general construction modification, delays, overtime costs, etc. No additional cost or delays to be incurred by the National Park Service.

3.8 EQUIPMENT AND MATERIAL PROTECTION

A. Protect the work, equipment and materials of all other trades from damage by work or workmen of this trade, and correct all damage thus caused without additional cost to the National Park Service.

B. Be responsible for all work, materials and equipment until finally inspected, tested and accepted;

protect work against theft, injury or damage; and carefully store material and equipment received on site which are not immediately installed. Close open ends of work with temporary covers or plugs during construction to prevent entry of obstructing material. Cover and protect in an acceptable manner to the Contracting Officer, all equipment and materials from damage due to water, spray-on fireproofing, construction debris, etc.

C. Provide adequate means for fully protecting finished parts of the materials and equipment against damage from whatever cause during the progress of the work until final acceptance. Protect materials and equipment in storage and during construction in such a manner that no finished

VAFO - 211497 210002 - 11

surfaces will be damaged or marred, and moving parts kept clean and dry. If items are damaged, do not install, but take immediate steps to obtain replacement or repair.

3.9 ELECTRICAL EQUIPMENT AND ELECTRICAL ROOM PRECAUTIONS

A. In general, do not install any piping systems not included as part of the electrical work, in any switchgear, transformer, elevator equipment, telephone, or electrical equipment room.

B. Do not install piping above switchboards, panelboards, control panels, motor control centers, individual motor controllers, etc.

C. Provide drip pans under all piping installed in any electrical equipment room. Pan shall be water tight, extending 4" in each direction from the pipe wall and turned up at least one-half the diameter of the pipe, but not less than 2". The pan shall extend at least 1 foot beyond the electrical equipment. Provide a drain pipe to spill into floor drain or service sink.

3.10 EQUIPMENT GUARDS

A. Provide easily removable expanded metal guards for all couplings, and other moving parts of machinery. Provide tachometer openings in the guards at least 2" in diameter, for all belt-driven or variable speed machinery. Comply with OSHA requirements for all equipment guards.

3.11 LUBRICATION

A. Provide means for lubricating all bearings and other machine parts.

B. After installation, properly lubricate all parts requiring lubrication and keep them adequately lubricated with a lubricant recommended by the equipment manufacturer until the Contracting Officer issues a Certificate of Substantial Completion for the specific equipment item or system.

3.12 DATE OF COMPLETION AND TESTING OF FIRE PROTECTION SYSTEMS

A. Comply with the project construction schedule for the date of final performance and acceptance testing, and be sufficiently in advance of the Contract completion date to permit the execution of the testing prior to occupancy and the closeout of the Contract. Complete any adjustments and/or alterations which the final acceptance tests indicate as necessary for the proper functioning of all equipment prior to the completion date. See individual sections for extent of testing required.

B. Provide a detailed schedule of completion indicating when each system is to be completed and outlining when tests will be performed. Submit completion schedule to the Contracting Officer for review within six (6) months after the notice to proceed. Update this schedule periodically as the project progresses.

VAFO - 211497 210002 - 12

3.13 OPERATING INSTRUCTIONS

A. Provide the services of a factory trained specialist to supervise the operation of all equipment specified herein and to instruct the National Park Service operators for a five (5) day operating instruction period. The operating instruction period is defined as straight time working hours and not including nights, weekends or travel time to and from the project. See individual sections for additional instructions by manufacturer's trained specialists.

B. Notify the Contracting Officer in writing at least two (2) weeks before each operating instruction period begins. Commence no instruction period until the Contracting Officer has issued his written acceptance of the starting time.

3.14 OPERATING AND MAINTENANCE BOOKS

A. Provide operating instructions and maintenance data books for all equipment and materials furnished under this Division.

B. Submit three (3) final copies of operating and maintenance data books for review at least ten (10) weeks before final review of the project. Assemble all data in a completely indexed volume or volumes in three-ring binders and identify the size, model, and features indicated for each item.

Print the project name and logo on the outside of the binders.

C. Deliver two (2) initial copies of the operation and maintenance data books to the Engineer six (6) months after notice to proceed has been given by the Owner or Owner's Representative. Include in the initial copies all the information in Paragraph E. below, except Item E.4).

D. Maintenance instruction manuals to include complete oiling, cleaning, and servicing data compiled in clearly and easily understandable form. Show all model numbers of each piece of equipment, complete lists of replacement parts, motor ratings, and actual loads.

E. Include the following information where applicable:

1. Identifying name and mark number.

2. Locations (where several similar items are used, provide a list).

3. Complete nameplate data.

4. Certified Record Drawings and "Final Reviewed" Shop Drawings.

5. Parts list.

6. Performance curves and data.

7. Wiring diagrams.

8. Lubrication charts.

9. Manufacturers' recommended operating and maintenance instructions with all non-applicable information deleted.

10. List of spare parts recommended for normal service requirements.

11. Assembly and disassembly instructions with exploded view drawings where available.

12. Troubleshooting diagnostic instructions where applicable.

3.15 RECORD DRAWINGS

A. Refer to spec section 017700 “Closeout Procedures,” 1.2 for project record drawings.

VAFO - 211497 210002 - 13

B. Upon completion of the installation, obtain from the Engineer, a complete set of CAD files on 700MG CD-ROM with Engineer’s firm name removed. Enter thereon, in an accurate manner, a complete record of all revisions of the original drawings, as actually installed. Bear the cost for the CAD files and for making required changes. The Engineer shall be reimbursed $10/file for the CAD files prior to their release to the Contractor. Submit one (1) set of black and white prints of these revised files to the Engineer for review of completeness. After review by the Engineer, make necessary changes to CAD files and then deliver them to the Contracting Officer for transmittal to the Contracting Officer. Engineer will not review these drawings for accuracy nor will the Engineer bear any responsibility for accuracy or completeness.

C. Mark all As-Built Drawings on the front lower right-hand corner with a rubber stamp impression that states the following:

"AS-BUILT DRAWINGS" (3/8" high letters) To be used for recording Field Deviations and Dimensional Data Only".

(5/16" high letters).

D. The Record Drawings will also consist of a set of prints of the final "Signed Off" Contractor's "Coordination Drawings" prepared by the Subcontractors.

3.16 CERTIFICATION

A. Any certifications required by the Specifications, in addition to those required for shop drawings, product data, equipment and other items, are to be so certified by the authority having jurisdiction.

3.17 FINAL REVIEW

A. At a time designated by the Owner, the entire system will be reviewed for compliance with the Contract Drawings and Specifications. Be available at all times during this review.

B. Demonstrate to the Contracting Officer and/or the Engineer's personnel prior to the Final Review that all systems and all equipment have been properly balanced and adjusted and are in compliance with the requirements of the Contract Documents. After these demonstration tests are satisfactorily completed, but prior to the Final Review field visit, the Contractor will submit to the Engineer a written certification that: 1) attests to the Contract Document compliance for this Project prior to the Engineer's Final Review field visit, and 2) certifies that the equipment and materials installed in this project under this Division contain no asbestos or P.C.B.

C. Operate the entire system properly with all systems balanced and all controls adjusted.

D. Certificates and Documents required herein to be in order and presented to the Contracting Officer at least two (2) weeks prior to the Final Review.

E. After the review, any changes or corrections noted as necessary for the work to comply with these specifications and the Drawings to be accomplished without delay in order to secure final acceptance of the work.

VAFO - 211497 210002 - 14

3.18 EARLY OCCUPANCY

A. Be responsible for completing those systems which are necessary to allow partial occupancy of the buildings even if systems in the unoccupied areas are incomplete. Refer to the Section entitled "Special Conditions" in the Architectural Specifications Documents for the schedule completion dates assigned to the various portions of the project.

Verify requirements for temporary occupancy with the authority having jurisdiction.

END OF SECTION 210002

VAFO - 211497 210003 - 1

071018 SCOPE OF WORK

SECTION 210003 – SCOPE OF WORK

PART 1 - GENERAL

1.1 DESCRIPTION

A. Provide fire protection systems in accordance with the Contract Documents.

1.2 WORK INCLUDED

A. This specification is not intended to be a complete itemization of fire protection required, but is for guidance of this contractor in estimating his work. This contractor shall examine the architectural, mechanical, electrical, plumbing and fire protection plans for all fire protection work required and shall provide same.

B. It is intended that all items of material and equipment mentioned in this specification and shown on the plans shall be read as if the work "Provide" were prefixed thereto.

C. Description of work included:

1. Provide a complete sprinkler system consisting of sprinkler heads, distribution and branch piping, and all associated appurtenances and alarm devices.

2. Provide a complete fire protection system consisting of:

a. Sprinkler:

1) Connection to sprinkler floor control valve assembly, distribution and branch piping, sprinkler heads, all associated appurtenances and alarm devices.

3. Operating manuals and instructions.

4. System cleaning, balancing, testing, adjusting and inspection.

5. Sound and vibration isolation.

6. Painting.

7. Supports, anchors, hangers and auxiliary structural members required for support of mechanical work. Drawings, templates, structural steel, anchor bolts, isolation materials, formwork for concrete and other equipment supports.

8. Internal wiring of factory-assembled prewired equipment.

9. Firestopping of pipe penetrations through rated walls, floors, etc.

1.3 WORK NOT INCLUDED

A. The items listed below are related to this work but…