Attachment_1_Part_1_Final_CD_Specifications_PORE_149469.pdf

FINAL CONSTRUCTION DOCUMENTS SPECIFICATIONS

Rehabilitate the Historic

Point Reyes Lighthouse Point Reyes National Seashore | September 12, 2017

Architecture

Planning

Conservation

TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00 Summary of Work

01 26 01 Contract Modification Procedures

01 27 00 Definition of Contract Line Items

01 31 00 Project Management & Coordination

01 32 16 Construction Schedule

01 32 33 Photo Documentation for Historic Preservation Projects

01 33 23 Submittal Procedures

01 35 13.22 Archeological Protection

01 35 23 Safety Requirements

01 35 91 Historic Preservation Treatment Procedures

01 40 00 Quality Requirements

01 42 00 References

01 50 00 Temporary Facilities and Controls

01 57 19.11 Indoor Air Quality Management

01 57 19.12 Noise & Acoustics Management

01 57 23 Temporary Storm Water Pollution Prevention

01 67 00 Product Requirements

01 73 40 Execution

01 74 19 Construction Waste Management and Disposal

01 77 00 Closeout Procedures

01 78 23 Operation and Maintenance Data

01 81 13 Sustainable Design Requirements

DIVISION 02 - EXISTING CONDITIONS

02 07 00 Selective Demolition

02 41 19.16 Selective Interior Demolition

02 82 13 Asbestos Abatement

02 82 33 Removal, Control and Disposal of Paint with Lead

02 84 33 Removal and Disposal of PCBs

DIVISION 03 - CONCRETE

03 01 30 Treatment of Historic Concrete

DIVISION 04 - MASONRY

04 01 40.62 Stone Repointing

DIVISION 05 - METALS

05 12 00 Structural Steel

05 52 00 Aluminum Handrails

05 56 02 Existing Wrought Iron

05 56 10 Ductile Iron Castings

05 90 00 Metal Restoration and Cleaning

DIVISION 06 - WOOD, PLASTICS, & COMPOSITES

06 10 00 Rough Carpentry

06 20 13 Exterior Finish Carpentry

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 01 50.19 Preparation for Re-Roofing

07 31 29 Wood Shingles and Shakes

07 61 00 Sheet Metal Roofing

07 92 00 Joint Sealants

DIVISION 08 - OPENINGS

08 01 52 Treatment of Historic Wood Windows

08 03 14 Treatment of Historic Wood Doors

08 14 33 Stile and Rail Wood Doors

08 70 00 Door Hardware

08 80 00 Glazing

DIVISION 9 - FINISHES

09 64 33 Engineered Wood Flooring

09 65 00 Resilient Flooring

09 90 00 Painting and Coating

09 96 50 Thermally Sprayed Metallic Coating

DIVISION 26 – ELECTRICAL

26 05 00 Basic Electrical Requirements

26 08 00 Testing

26 27 00 Basic Electrical Materials and Methods

DIVISION 31 – EARTHWORK

31 11 00 Clearing and Grubbing

31 23 00 Site Excavation and Grading

31 23 33 Utility Trenching and Backfilling

31 37 00 Rip Rap

DIVISION 32 – EXTERIOR IMPROVEMENTS

32 11 23 Aggregate Base Course

32 13 13 Concrete Paving

32 16 13 Cast-In-Place Concrete Curbs

32 31 13 Chain Link Fences and Gates

32 31 29 Wood Fences and Gates

32 92 50 Broadcast Seeding

DIVISION 33 – SITE UTILITIES

33 41 13 Storm Drain Pipe and Appurtenances

ATTACHMENT

Point Reyes Lighthouse Collection Condition Survey

PORE - 149469 01 11 00 - 1

091015 SUMMARY OF WORK

SECTION 01 11 00 - SUMMARY OF WORK

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes the following:

1. Work covered by the Contract Documents.

2. Contractor use of site.

3. Public use of site.

4. Occupancy requirements for buildings.

5. Work Restrictions.

6. Special Construction Requirements.

7. Additional Reports.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

A. Project Location: Point Reyes National Seashore, California.

1. Point Reyes Lighthouse Area is approximately 20 miles west of park headquarters and the

Bear Valley Visitor Center. To get to the Lighthouse and Visitor Center from the visitors' parking lot, walk past the gate and continue west 0.4 miles. The Lighthouse Visitor Center and the 308 steps leading down to the Lighthouse are only open four or five days a week from 10 am to 4:30 pm.

B. The Work consists of the following:

1. Note that all structures included in this project are considered historically significant and all work performed must meet The Secretary of the Interior’s Standards for the Treatment of Historic Properties. See Section 01 35 91 – Historic Preservation Treatment Procedures for additional requirements specific to historic properties.

2. The Work includes rehabilitation of the Lighthouse at the Point Reyes Light Station and related work, including:

a. Restoration at Lighthouse lens and clockworks.

b. Accessibility improvements at upper Lighthouse area

c. New exhibits at site, Visitor Center, Lighthouse, and Fog Signal Equipment Building

d. Exterior rehabilitation of other historic buildings throughout site, including Fog

Signal Equipment Building and several outbuildings.

e. Repairs at stone wall, concrete cistern, and watershed.

f. Landscape and site rehabilitation, including new grading, paving, and fencing.

C. Project will be constructed under a single prime contract. Reference 01 27 00 – Definition of Contract

Line Items to clarify which scope items are bid alternates.

PORE - 149469 01 11 00 - 2

1.3 CONTRACTOR USE OF SITE

A. General: Contractor shall have limited use of the site for construction operations. Limit use of premises to areas within the Contract limits indicated. Do not disturb portions of Project site beyond areas in which the Work is indicated.

1. Limits: Confine constructions operations to limits of construction indicated at upper and lower Lighthouse areas.

2. Limit site disturbance, including earthwork and clearing of vegetation, to 40 feet beyond building perimeter; 10 feet beyond surface walkways, patios, surface parking, and utilities less than 12 inches in diameter; 15 feet beyond primary roadway curbs and main utility branch trenches; and 25 feet beyond constructed areas with permeable surfaces (such as pervious paving areas, storm water detention facilities, and fields) that require additional staging areas in order to limit compaction in the constructed area.

B. Storage of Materials: Confine storage of materials to staging areas indicated. NPS may make available some space at Garage interior for storage of sensitive materials.

C. Preservation of Natural Features:

1. Prevent damage to natural surroundings. Restore damaged areas, repairing or replacing damaged trees and plants, at no additional expense to the Government.

2. Provide temporary barriers to protect existing trees and plants and root zones.

3. Do not remove, injure, or destroy trees or other plants without prior approval. Consult with

Contracting Officer and remove agreed-on roots and branches that interfere with construction.

4. Do not fasten ropes, cables, or guys to existing trees.

5. Carefully supervise excavating, grading, filling, and other construction operations near trees to prevent damage.

D. Driveways and Entrances: Keep driveways and pedestrian walkways and entrances serving premises clear and available to Government, Government's employees, and emergency vehicles at all times.

Do not use these areas for parking or storage of materials.

1. Schedule deliveries to minimize use of driveways and entrances.

2. Schedule deliveries to minimize space and time requirements for storage of materials and equipment on-site.

E. Construction Camp: Establishment of a camp within the park will not be permitted.

F. Hauling Restrictions: Comply with all legal load restrictions in the hauling of materials. Load restrictions on park roads are identical to the state load restrictions with such additional regulations as may be imposed by the Park Superintendent. Information regarding rules and regulations for vehicular traffic on park roads may be obtained from the Office of the Park Superintendent. A special permit will not relieve Contractor of liability for damage which may result from moving of equipment.

G. Preservation of Cultural Resources:

1. The Point Reyes Light Station contains a lighthouse tower with first order Fresnel lens and several associated historic buildings that convey the history of a late 19th/early 20th century

PORE - 149469 01 11 00 - 3

light station. According to the National Register nomination for the Light Station, it is significant for its association with maritime transportation and the aids that made navigation possible.

2. NPS manages the totality of this property as a cultural resources asset. Work must be approached with care and discretion to ensure that no harm, damage or loss will result from direct or indirect actions taken by Contractor. All work, unless noted otherwise, will be undertaken in compliance with the Secretary of the Interior’s Standards for Treatment of

Historic Properties, and in accordance with Guidelines for the Treatment of Cultural

Landscapes.

3. Contributing Properties include, and are not limited to:

a. Point Reyes Lighthouse

b. Fog Signal Equipment Building

c. Transformer Building

d. Keeper’s Garage (Visitor’s Center)

e. Pump House 1

f. Fuel and Paint Storage

4. Preservation treatment approaches are preferred. Contractor shall not use short cuts, unproven means and methods, new materials or systems, or non-traditional practices unless properly reviewed and approved in advance by the Contracting Officer.

1.4 PUBLIC USE OF SITE

A. The site will be partially open to the public during construction. Coordinate any necessary site closures with the CO and provide at least 2 weeks advance notice.

1.5 OCCUPANCY REQUIREMENTS FOR BUILDINGS

A. Existing Buildings

1. Full Government Occupancy: Government will occupy buildings that will be under construction during the entire contract period and buildings adjacent to site work.

Cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Perform the Work so as not to interfere with Government's day-to-day operations and housing. Maintain existing exits, unless otherwise indicated.

a. Maintain access to existing walkways, corridors, and other adjacent occupied or used facilities. Do not close or obstruct walkways, corridors, or other occupied or used facilities without written permission from the CO.

b. Maintain existing buildings in a weather tight condition throughout construction period. Repair damage caused by construction operations. Protect buildings and occupants during construction period.

c. Minimize disruptions and disturbances near employee housing building.

1.6 CONDUCT OF OPERATIONS

A. At all times the contractor shall conduct his operations in conformance with the rules and regulations promulgated by the Secretary of the Interior for the National Park Service, and applicable park rules and regulations prescribed by the Park Superintendent.

PORE - 149469 01 11 00 - 4

B. Work on Saturdays, Sundays, Federal holidays or at night may not be performed without prior consent from the Contracting Officer. Submit requests 48 hours in advance of the work to the

Contracting Officer for approval.

C. No signs or advertisements (except those specified herein) shall be displayed on the construction site or within the park unless approved by the Contracting Officer.

1.7 WORK RESTRICTIONS

A. On-Site Work Hours: Work shall be generally performed during normal business working hours of

7 a.m. to 5 p.m., Monday through Friday, except when otherwise indicated.

1. Weekend Hours: With Contracting Officer approval only.

B. Existing Utilities

1. Existing Utilities: Notify Contracting Officer and utility companies of proposed locations and times for excavation.

2. Contractor shall be responsible for locating and preventing damage to known utilities. If damage occurs, repair utility at no additional expense to the Government.

3. If damage occurs to an unknown utility, repair utility. An equitable adjustment will be made in accordance with the Changes clause of the contract.

C. Existing Utility Interruptions: Do not interrupt utilities serving facilities occupied by Government or others unless permitted under the following conditions and then only after arranging to provide temporary utility services according to requirements indicated:

1. Notify Contracting Officer not less than three days in advance of proposed utility interruptions.

2. Do not proceed with utility interruptions without Contracting Officer’s written permission.

3. Unless otherwise approved by Contracting Officer, limit utility interruption to no more than four hours.

D. Nonsmoking Building: Smoking is not permitted within the building or within 25 feet of entrances, operable windows, or outdoor air intakes.

1.8 SPECIAL CONSTRUCTION REQUIREMENTS

A. Project Website: A project website administered by the Contracting Officer will be used for purposes of managing communication and documents during the construction stage.

1. See Section 01 31 00 “Project Management and Coordination” for requirements on using the Project Website.

B. The Lighthouse is accessed via a walkway with 308 concrete steps. The contractor will need to move all construction materials for the lower Lighthouse complex via hand or wheeled cart.

PORE - 149469 01 11 00 - 5

1.9 ADDITIONAL REPORTS

A. A report entitled Environmental Inspection Report, August 17, 2015 has been prepared by VBA, Inc.

and is included in this document after section 02 07 00 Selective Demolition.

B. If conflicts occur between the report and drawings or specifications, the drawings and specifications govern.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION (Not Used)

END OF SECTION 01 11 00

PORE - 149469 01 26 01 - 1

031414 CONTRACT MODIFICATION PROCEDURES

SECTION 01 26 01 – CONTRACT MODIFICATION PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. The work of this section consists of administrative and procedural requirements for contract modifications.

1.2 DEFINITIONS AND ALLOWANCES

A. Home Office Overhead: Those costs incurred in support of all of a contractor’s projects and not attributable to a specific job. The cost for home office overhead is only allowed as a percentage of all direct work excluding profit. The following items represent allowable home office overhead costs identified in Part 31 of the Federal Acquisition Regulation (FAR):

1. Rent

2. Utilities

3. Furnishings

4. Office equipment

5. Executive and management staff not exclusively assigned to the project

6. Support, accounting, and administrative staff

7. Preparation of cost proposals, estimating, and schedule analyses connected with

Modifications

8. Estimating and preconstruction services

9. Mortgage costs

10. Real estate and corporate taxes

11. Automobile maintenance and travel costs for home office personnel

12. Home office insurances i.e. structure, automotive, umbrella, flood, etc.

13. Depreciation of equipment and other assets

14. Home office supplies (paper, staples, etc.)

15. Legal services

16. Accounting and data processing

17. Professional fees/registration

B. General Conditions (Field Office Overhead): Management and administrative costs incurred on site for the designated project. Costs associated with the preparation of modifications will not be allowed. The costs for these items are to be included only in the general conditions of the modification estimate. Only in the case of a contract time extension are additional general conditions included in modifications. The following items, if applicable, are considered allowable costs for calculating General Conditions:

1. Project Manager, Assistant Project Manager

2. Superintendent, Assistant Superintendent

3. Quality Control, Safety Officer, Environmental Manager, etc.

4. Engineers

5. Travel, lodging, and per diem (as established by Federal Travel Regulations)

PORE - 149469 01 26 01 - 2

6. Scheduling

7. Field Office Trailers and associated temporary utilities

8. Field office supplies

a. Mailing and couriers

b. Reproduction costs

c. Storage

d. Phones

e. Computers

f. Copiers

9. Personal vehicles i.e. Superintendent Pickup trucks

C. General Requirements: These are costs directly associated with the project and are necessary to perform the actual work of the modification. These costs shall be shown as direct costs in the estimate. The following items, if applicable, are considered allowable costs for calculating General Requirements:

1. Hoisting

2. Material handling

3. Temporary fencing

4. Port-a-lets

5. Trash removal, dumpsters

6. Barricades

7. Small tools

8. Safety supplies

9. Scaffolding

10. Daily cleaning

11. Traffic control

12. Temporary signage

13. Temporary heating and power

D. Personnel Costs: Costs included in the modification must only be for General Conditions staff and workers actually present and working on the project site. Modification costs for salaried workers are only allowed within the structure of a 40 hour week and no overtime or holiday pay will be allowed.

1. Worker Hourly Rates are costs directly associated with the individual worker and consist of the following:

a. Base Rate: This is the hourly rate paid directly to the worker

b. Labor Burden: Employer payments of all applicable burdens, this includes insurance and taxes that the business must pay on behalf of the worker to government entities and educational forums , such as:

1) Social Security

2) Medicare

3) Workers Compensation– Policy and company calculation to be made available.

4) FUTA– Cap Rate and percentage to be proportionally allocated over one year.

5) SUTA– Cap Rate and percentage to be proportionally allocated over one year.

PORE - 149469 01 26 01 - 3

6) Union agreement costs – Other costs required under an enforceable collective bargaining agreement.

c. Fringe Benefits: Various non-wage compensations provided to employees such as:

1) Health Care Insurance Premiums

2) Cell Phone

3) Clothing

4) 401K and Pensions

5) Vehicle allowances

6) Gas allowance

7) Life insurance premiums

8) Disability insurance

9) Other Fringe Benefits required under an enforceable collective bargaining agreement

E. Bonuses or Deferred Compensation: No Bonus or Deferred Compensation will be allowed within any components of pricing including Home Office Overhead, General Conditions, General Requirements, Hourly Worker Rates, or the direct costs of work.

F. General Liability Insurance: An insurance policy that protects the contractor from claims resulting from bodily injury or property damage to a third party. Include this as a separate line item within all modification proposals and provide a current insurance quote upon request.

G. Performance and Payment Bonds: A performance bond is a surety bond issued by an insurance company or bank to guarantee satisfactory completion of a project. The Payment Bond guarantees that the contractor will pay the labor and material costs they have incurred. Banks and Insurance companies charge a premium for each individual project based on a sliding scale which relates to the size of the project. Include this as a separate line item in modification proposals and provide current company bonding rates upon request.

H. Builder’s Risk Insurance: This covers the contractor’s loss due to fire, high winds, or other natural forces. This is not reimbursed by the National Park Service (NPS) and shall not be included in modification proposals.

1.3 MODIFICATION PROPOSAL PRICING REQUIREMENTS

A. General:

1. Your proposal must be received in the format and within the time frame specified in the Request for Proposal letter. Costs or delays resulting from failure of contractor to submit within the time frame specified will not be compensable.

2. The proposal must be detailed with itemized lists of equipment, materials, labor, production rates, overhead, profit, and bond markup for each item. Labor costs must be itemized by craft and hourly rate, including Fringe Benefits and Labor Burden. If the costs of Fringe Benefits and Labor Burden are not itemized, it is assumed that that they are included in the hourly rate shown, or contractor is not requesting reimbursement.

Contractor may utilize the government provided Contractor Estimate Form, or their http://en.wikipedia.org/wiki/Employee http://en.wikipedia.org/wiki/Surety_bond http://en.wikipedia.org/wiki/Insurance http://en.wikipedia.org/wiki/Bank http://www.nps.gov/dscw/publicforms.htm

PORE - 149469 01 26 01 - 4

own form, provided that it contains the same information and level of detail as the Gov’t provided form.

3. Requests for extensions of contract time as a result of this change must be justified with a Time Impact Analysis (TIA). Refer to Division 01 Specification, “Construction Schedule”, for time impact analysis requirements. TIA and associated costs must be received with the proposal by the date shown within the Request for Proposal letter.

Contractor’s failure to submit within the specified time frame will be construed as the Contractor waiving the right for additional time and no time extension will be allowed.

4. All supporting documentation used to justify the proposed modification will be made available to the Contracting Officer upon request.

5. Contractor must review and approve all subcontractor/supplier pricing in detail for proper format, scope, production rates, and pricing prior to submission to the Contracting Officer. All delay costs associated with not reviewing and approving subcontractor/supplier pricing will be borne by the Contractor.

6. All pricing and production rates within the estimate must be based on fair and reasonable pricing and cannot include built-in contingency.

B. Labor:

1. Contractor shall estimate the cost of labor by itemizing each craft involved, indicating worker hourly rate (base rate + labor burden + fringe benefits) for each and itemizing the hours required for each craft that will be directly engaged in modification work.

Any work proposed that will require overtime work or premium pay shall be itemized separately. All rates shall be in accordance with the Davis-Bacon Act as incorporated herein. Labor Burden may include payroll taxes, Social Security, unemployment insurances, workers compensation insurance, FICA, FUTA, and other direct costs resulting from Federal, State or local laws.

2. Itemize labor costs for equipment operators separate from equipment costs.

3. The labor cost for foremen shall only be costs for related work required for the modification.

C. Materials:

1. The estimated cost for materials shall include quotes from multiple sources. Material prices must include all applicable fees and credits, including but not limited to, sales tax, freight and delivery charges, and tax rebates.

2. No markup shall be applied to any material provided by the NPS.

D. Equipment:

1. Equipment used for the project must be appropriately sized for the work being performed.

2. Do not include costs for “miscellaneous tools and equipment”, in your proposal for a replacement value of $500 or less. Costs shown in excess of $500 must be broken out separately.

3. Regardless of ownership, the rates to be used in determining equipment rental costs shall be the lowest cost from one of the following sources:

a. U.S. Army Corps of Engineers , Ownership and Operating Expense Schedule (use latest edition and applicable region)

b. Construction Blue Book

PORE - 149469 01 26 01 - 5

c. Local equipment rental rates, documented by actual invoice charges, or itemized vendor quotes.

4. The estimated equipment rates shall include the operating costs of all fuel, oil, lubrication, supplies, small tools, necessary attachments, ground engaging components, tires & tracks, routine repairs and maintenance (cost of major repair and overhaul is not allowed per FAR 31.105(d)(2)), depreciation, storage, insurance, and all incidentals.

Mobilization, if applicable, may be included for equipment solely used on the modification work but must be listed separately.

5. Estimate the full rate for equipment only for the duration that the equipment will be utilized to accomplish the work of the modification.

6. Standby unit rates used are to be in accordance with paragraph 1.3, D, 2, above. If the US Army Corp of Engineers is utilized then their standby rates prevail. If Bluebook or local equipment pricing is accepted, then ½ of the equipment costs minus any operating costs, major repair and overhaul will be accepted.

7. If equipment is in standby mode due solely to a documented NPS delay, the established standby rate shall apply from the first day of the delay.

8. Equipment that is not used and on the jobsite for up to five consecutive days may be classified at standby rates, provided that the equipment is or has been used solely to perform work on the modification and will be necessary to complete additional modification work. Equipment that is still on the jobsite but not in use after five consecutive days will not be considered in the modification pricing.

9. Requests for compensation for equipment stand by time must be justified, documented and itemized separately.

10. The estimated timeframe (daily, weekly, monthly) for use of the equipment must reflect the lowest cost to the Government.

E. Establishment and Application of Overhead and Profit Percentages:

1. Home Office Overhead and Profit (OH&P) shall be applied to direct costs only. Profit shall not be applied to overhead amounts; and overhead shall not be applied to profit.

Home office overhead shall contain only allowable, allocable, and reasonable costs per the contract documents and FAR Part 31. Profit percentages are based on risk factors found in FAR Part 31which have been applied to the specific type of work included in this project. Negotiated rates shall not exceed the following percentages for OH&P for contractor self-performed work:

Overhead………………10% Profit…………………..7.5%

2. Total aggregate limit of markup (OH&P) for contractor and subcontractors on modification work shall not exceed 25%. The NPS will not be responsible for allocation of percentages between contractor and subcontractors at any tier.

3. If contractors form a partnership, than the partnership may only receive home office overhead and profit in the same amount as an individual contractor (refer to par 1.3,E,1 above). It is the responsibility of the partners to decide on the division of revenue.

4. Combined Increases and Decreases: On proposals involving both increases and decreases in the Contract Price, the overhead and profit mark-ups are required on the net increases and deducted on net decreases.

5. At no time can profit be calculated on Overhead or itself, it must be calculated on direct costs of work only.

PORE - 149469 01 26 01 - 6

PART 2 - PRODUCTS

PART 3 - EXECUTION

END OF SECTION 012601

PORE - 149469

082714

01 27 00 - 1

DEFINITION OF CONTRACT LINE ITEMS

SECTION 01 27 00 – DEFINITION OF CONTRACT LINE ITEMS

PART 1 - GENERAL

1.1 SUMMARY

A. The intent of this section is to explain, in general, what is and what is not included in a contract line item, and the limits or cut-off points where one item ends and another begins.

B. If no contract line item exists for a portion of the work, include the costs in a related item.

PART 2 - PRODUCTS (Not Used)

PART 3 - EXECUTION

3.1 LIST OF CONTRACT LINE ITEMS

A. Contract Line Item No. 1 Rehabilitate Lighthouse

1. This item consists of rehabilitation of the Lighthouse as described on sheets labeled “base project” including:

a. Protective scaffolding to enclose lighthouse for the duration of work

b. Removal and reinstallation of interior paneling

c. Replacement of roofing

d. Replacement of glazing assembly, including glazing, putty and sealants, and copper alloy astragals

e. New door at ground floor and repair of door at first floor

f. Blast cleaning of all cast and wrought iron components

g. Special inspections, testing, documentation and analysis of existing cast and wrought iron components

h. New cast or wrought iron replacement components and new fasteners

i. Welding repairs

j. Zinc thermal metallizing spray at all cast and wrought iron components

k. New high performance coatings at all cast and wrought iron components

l. Improvements to electrical service

m. Replacement of wood footbridge at first floor

2. Payment will be made at the contract lump sum price.

B. Contract Line Item No. 2: Rehabilitate Fresnel Lens

01 27 00 - 2

DEFINITION OF CONTRACT LINE ITEMS

1. This item consists of cleaning and restoration of the historic Fresnel lens inside the

Lighthouse. This includes disassembly, moving, and reinstallation of the entire lens and assembly.

2. Payment will be made at the contract lump sum price.

C. Contract Line Item No. 3: Rehabilitate Clockworks

1. This item consists of cleaning and restoration of the historic clockworks inside the

Lighthouse. This includes disassembly, moving, and reinstallation of the entire clockwork assembly.

2. Payment will be made at the contract lump sum price.

D. Contract Line Item No. 4: Bid Alternate A, Accessible Path of Travel

1. This item consists of creating an accessible path of travel from the accessible parking area east of the employee housing building to the observation deck, and related landscape improvements described on sheets labeled “bid alternate A” including:

a. Demolition of existing pathways and paving

b. New grading and site drainage

c. New retaining wall at employee parking turnout

d. New pedestrian concrete and paving

e. New vehicular concrete and paving

f. New fencing and handrails

g. New parking signage

h. Marking of previous historic building locations with concrete bands

i. New exterior lighting and electrical upgrades

j. To demolish the existing trash shed and construct a new trash shed at Employee

Housing building

k. New accessible parking

2. Payment will be made at the contract lump sum price.

E. Contract Line Item No. 5: Bid Alternate B, Fog Signal Bldg, Visitor Center

1. This item consists of rehabilitation of the Fog Signal Equipment Building and Keeper’s

Garage/Visitor Center as described on sheets labeled “bid alternate B” including:

a. At the Fog Signal Equipment Building:

1) Repair of exterior wood siding, windows and doors

2) Exterior painting

3) Install new wood shingle roofing

4) Repair interior cabinetry

5) Refinish interior wood paneling at walls and ceiling

6) Repair and paint interior concrete floor

7) Upgrade electrical systems

b. At the Visitor Center/Keeper’s Garage:

1) Repair of exterior wood siding, windows, and a new front door

2) Exterior painting

3) Demolition of interior casework and finishes

4) Installation of new interior finishes

5) Upgrade electrical systems

2. Payment will be made at the contract price per lump sum price.

01 27 00 - 3

DEFINITION OF CONTRACT LINE ITEMS

F. Contract Line Item No. 6: Bid Alternate C, Rehabilitate Site

1. This item consists of repair of historic site features as described on sheets labeled “bid alternate C” including:

a. Repairs at concrete cistern and large watershed

b. Repairs at smaller concrete watershed

c. Repointing at stone retaining wall below cistern

d. Installation of anchors at former winch house location

2. Payment will be made at the contract price per lump sum price.

G. Contract Line Item No. 7: Bid Alternate D, Rehabilitate Outbuildings

1. This item consists of all labor and materials to complete repairs at the following buildings, as described on sheets labeled “bid alternate D”:

a. Fuel and Paint Storage Building

b. Pump House #1

c. Transformer House

d. Garage

2. Payment will be made at the contract price per lump sum price.

END OF SECTION 01 27 00

PORE - 149469 01 31 00 - 1

091015 PROJECT MANAGEMENT AND COORDINATION

SECTION 01 31 00 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. This Section includes administrative provisions for coordinating construction operations on

Project including, but not limited to, the following:

1. Definitions

2. Construction Coordination.

3. Submittals

4. Coordination Drawings.

5. Requests for Information (RFIs).

6. NPS/DSC SharePoint Project Website.

7. Project meetings.

8. Environmental Coordination.

9. Permits

B. Related Requirements:

1. Section 01 32 16 “Construction Schedule” for preparing and submitting Contractor’s construction schedule.

2. Section 01 73 40 “Execution” for procedures for coordinating general installation and field-engineering services, including establishment of benchmarks and control points.

3. Section 01 77 00 “Closeout Procedures” for coordinating closeout of the Contract.

4. Section 01 91 14 “Total Building Commissioning” for coordinating the work with

Contracting Officer’s Commissioning Authority.

1.2 DEFINITIONS

A. Agency with Jurisdiction

B. Construction Permits – Contractor Provided

C. Government Furnished Permits

1.3 CONSTRUCTION COORDINATION

A. Coordination: Coordinate construction operations included in different Sections of the

Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

2. Coordinate installation of different components with other Contractors to ensure maximum accessibility for required maintenance, service, and repair.

http://www.nps.gov/dscw/definitionsdc_a.htm http://www.nps.gov/dscw/definitionsdc_c.htm http://www.nps.gov/dscw/definitionsdc_g.htm

PORE - 149469 01 31 00 - 2

3. Make adequate provisions to accommodate items scheduled for later installation.

4. Where availability of space is limited, coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair of all components, including mechanical and electrical.

5. Properly plan construction operations to include permit requirements. Allow enough time to execute permit provisions to maintain work schedule, site visits, inspections, and reporting deadlines.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities and activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's Construction Schedule.

2. Preparation of the Schedule of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Permit requirements.

7. Pre-installation conferences.

8. Project closeout activities.

9. Commissioning activities.

1.4 SUBMITTALS

A. Coordination Drawings: Prepare Coordination Drawings if limited space availability necessitates maximum utilization of space for efficient installation of different components or if coordination is required for installation of products and materials fabricated by separate entities.

1. Content: Project-specific information, drawn accurately to scale. Do not base

Coordination Drawings on reproductions of the Contract Documents or standard printed data. Include the following information, as applicable:

a. Indicate functional and spatial relationships of components of architectural, structural, civil, mechanical, and electrical systems.

b. Indicate dimensions shown on the Contract Drawings and make specific note of dimensions that appear to be in conflict with submitted equipment and minimum clearance requirements. Provide alternate sketches to the Contracting Officer (CO) for resolution of such conflicts.

c. Indicate space requirements for routine maintenance and for anticipated replacement of components during the life of the installation.

d. Show location and size of access doors required for access to concealed dampers, valves, and other controls.

e. Indicate required installation sequences.

PORE - 149469 01 31 00 - 3

2. Sheet Size: At least 8-1/2 by 11 inches (215 by 280 mm) but no larger than 30 by 40 inches

(750 by 1000 mm).

3. Number of Copies: Submit three opaque copies of each submittal. Contracting Officer will return one copy.

4. Refer to individual Sections for Coordination Drawing requirements for Work in those

Section

B. Coordination Drawing Organization: Organize coordination drawings as follows:

1. Floor Plans and Reflected Ceiling Plans: Show architectural and structural elements, and mechanical, plumbing, fire-protection, fire-alarm, and electrical Work. Show locations of visible ceiling-mounted devices relative to acoustical ceiling grid. Supplement plan drawings with section drawings where required to adequately represent the Work.

2. Plenum Space: Indicate subframing for support of ceiling and wall systems, mechanical and electrical equipment, and related Work. Locate components within ceiling plenum to accommodate layout of light fixtures indicated on Drawings. Indicate areas of conflict between light fixtures and other components.

3. Mechanical Rooms: Provide coordination drawings for mechanical rooms showing plans and elevations of mechanical, plumbing, fire-protection, fire-alarm, and electrical equipment.

4. Structural Penetrations: Indicate penetrations and openings required for all disciplines.

5. Slab Edge and Embedded Items: Indicate slab edge locations and sizes and locations of embedded items for metal fabrications, sleeves, anchor bolts, bearing plates, angles, door floor closers, slab depressions for floor finishes, curbs and housekeeping pads, and similar items.

6. Mechanical and Plumbing Work: Show the following:

a. Sizes and bottom elevations of ductwork, piping, and conduit runs, including insulation, bracing, flanges, and support systems.

b. Dimensions of major components, such as dampers, valves, diffusers, access doors, cleanouts and electrical distribution equipment.

c. Fire-rated enclosures around ductwork.

7. Electrical Work: Show the following:

a. Runs of vertical and horizontal conduit 1-1/4 inches (32 mm) in diameter and larger.

b. Light fixture, exit light, emergency battery pack, smoke detector, and other fire-alarm locations.

c. Panel board, switch board, switchgear, transformer, busway, generator, and motor control center locations.

d. Location of pull boxes and junction boxes, dimensioned from column center lines.

8. Fire-Protection System: Show the following:

a. Locations of standpipes, mains piping, branch lines, pipe drops, and sprinkler heads.

9. Review: Contracting Officer (CO) will review coordination drawings to confirm that the

Work is being coordinated, but not for the details of the coordination, which are

Contractor's responsibility. If CO determines that coordination drawings are not being prepared in sufficient scope or detail, or are otherwise deficient, CO will so inform

Contractor, who shall make changes as directed and resubmit.

PORE - 149469 01 31 00 - 4

10. Coordination Drawing Prints: Prepare coordination drawing prints according to requirements in Section 01 33 23 "Submittal Procedures."

C. Coordination Digital Data Files: Prepare coordination digital data files according to the following requirements:

1. File Preparation Format: Same digital data software program, version, and operating system as original Drawings.

2. File Preparation Format: AutoCad.dwg, Version 2004 or later operating in Microsoft

Windows operating system.

3. File Submittal Format: Submit or post coordination drawing files using Portable Document

Format (PDF) file format.

4. Contracting Officer (CO) will furnish Contractor one set of digital data files

(AutoCad.dwg) of Drawings for use in preparing coordination digital data files.

a. CO makes no representations as to the accuracy or completeness of digital data files as they relate to Drawings.

b. Digital Data Software Program: Drawings are available in AutoCad.dwg.

D. Division 01 documents: The following items shall be submitted a minimum of one week prior to the Preconstruction Conference. Contracting Officer will notify Contractor of tentative date for the Pre-Construction Conference.

1. Letter designating Project Superintendent.

2. Construction Schedule.

3. A comprehensive breakdown of the Schedule of Values.

4. Accident Prevention Plan.

5. A list of Subcontractors for this project.

6. Written statements from subcontractors certifying compliance with applicable labor standard clauses.

7. Satisfactory evidence of liability insurance coverage and workman’s compensation for the

Contactor and all subcontractors.

8. Waste Management Plan.

9. Quality Control Plan.

10. Temporary Storm Water Pollution Prevention Plan (SWPP or UPPP).

11. Indoor Air Quality (IAQ) Management Plan.

12. Contractors Commissioning Plan.

13. Historic Preservation Treatment Plan.

14. List of Required Construction Permits. Include the following information for each permit:

a. Name of Permit.

b. The Agency(ies) with Jurisdiction issuing the permit.

c. Information required from the Government to complete the permit application.

E. All items listed must be provided to the Contracting Officer before the Pre-Construction

Conference is held. If all of these documents have not been received one week prior to the scheduled Pre-Construction Conference date, the conference will be cancelled, Notice to Proceed will not be issued, and the Contracting Officer will consider other contractual remedies. Work shall not commence until written Notice to Proceed has been issued.

PORE - 149469 01 31 00 - 5

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the

Contract Documents, Contractor shall prepare and submit an RFI utilizing the form created on the NPS/DSC SharePoint Project website.

1. CO will not respond to RFIs submitted by other entities controlled by Contractor.

2. Coordinate and submit RFIs in a prompt manner to avoid delays in the work.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. RFI number, numbered sequentially.

2. Date.

3. RFI subject.

4. Specification Section number and title and related paragraphs, as appropriate.

5. Drawing number and detail references, as appropriate.

6. Field dimensions and conditions, as appropriate.

7. Contractor's suggested resolution. If Contractor's suggested resolution impacts the

Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

8. Contractor's signature.

9. Requested date for response.

10. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop

Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

a. Include dimensions, thicknesses, structural grid references, and details of affected materials, assemblies, and attachments on attached sketches.

C. RFI Form: Complete the RFI Form on the NPS/DSC SharePoint website as follows:

1. Enter the general information at the top of the form.

2. Under the “Action” section at the bottom of the form, select “Question” then select “CMR” in the drop-down of the “Send to” box.

3. Enter the details of the question and attach related documents.

4. Select “Submit Form” at the bottom of the page.

D. Contracting Officer’s Action: CO will review each RFI, determine action required, and respond.

CO will determine the critical nature of each RFI and issue a response accordingly.

1. The following are not considered to be RFIs and will receive no action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for approval of Contractor's means and methods.

d. Requests for coordination information already indicated in the Contract Documents.

e. Requests for adjustments in the Contract Time or the Contract Sum.

f. Requests for interpretation of Architect's actions on submittals.

g. Incomplete RFIs or inaccurately prepared RFIs.

PORE - 149469 01 31 00 - 6

2. CO's action may include a request for additional information, in which case time for response will date from time of receipt of additional information.

3. CO's action on RFIs may result in the need for a change to the Contract Time or the

Contract Sum. All contract changes will be processed following the terms and conditions of the contract.

1.6 PROJECT WEB SITE

A. Use the NPS/DSC SharePoint Project website for communication throughout the contract period.

The NPS/DSC SharePoint Project website will be used for the following functions:

1. Project directory.

2. Project correspondence.

3. Meeting agendas and minutes.

4. Contract modifications forms and logs.

5. RFI form and processing.

6. Task and issue management.

7. Photo documentation.

8. Baseline schedule, schedule updates and calendar management.

9. Submittal form and processing.

10. Payment coordination documentation.

11. Drawing and specification document hosting, viewing, and updating.

12. Online document collaboration.

13. Reminder and tracking functions.

14. Archiving functions.

15. Notification of submittal and RFI statuses and current responsible party.

16. Permits and addendums

B. Some documents however are not suitable to be shared using the NPS/DSC SharePoint Project website. Documents containing Personal Identifying Information (PII) (i.e. certified payrolls) shall not be shared using the NPS/DSC SharePoint Project website and shall be coordinated with the SharePoint Project team as appropriate.

C. Submit to the CO a list of all employees who will need access to the website. The users will receive an invitation to register from the Department of Interior (DOI). Once the user is registered on the DOI website, they will be given access to the NPS/DSC SharePoint Project website. For login procedures and other SharePoint information, refer to the Workflows website at http://www.nps.gov/dscw/precon_spproj.htm.

D. All users will be required to have the following software packages:

1. Internet Explorer version 7 or later.

2. Adobe Acrobat Professional (Pro) version 9 or later

1.7 PROJECT MEETINGS

A. Preconstruction Conference: Before start of construction, Contracting Officer will arrange an on-site meeting with Contractor. The meeting agenda will include the following as a minimum:

http://www.nps.gov/dscw/precon_spproj.htm

PORE - 149469 01 31 00 - 7

1. Roles & Responsibilities/ Lines of Authority.

2. Park rules and regulations.

3. Jobsite Safety.

4. Resolution of comments on required Division 01 documents.

5. Coordination of Subcontractors.

6. Labor law application.

7. Modifications.

8. Payments to Contractor.

9. Payroll reports.

10. Contract time.

11. Liquidated damages.

12. Contractor Performance Evaluation.

13. Display of Hotline posters.

14. Notice to proceed.

15. Correspondence procedures.

16. NPS/DSC SharePoint Project website.

17. Acceptance/rejection of work.

18. Progress meetings.

19. Submittal procedures.

20. NPS Final Accessibility Inspection.

21. Environmental requirements.

22. Permit requirements.

23. As-constructed drawings/operation and maintenance (O&M) manuals.

24. Saturday, Sunday, holiday and night work.

25. Reference materials.

26. Value engineering.

27. Interim Accessibility Inspection Report

28. Schedule of Values

B. Progress Meetings: The Contracting Officer will schedule weekly meetings with the Contractor.

1. Attendees: In addition to Government Representatives, each Contractor, Subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings. All participants at the meeting shall be familiar with the Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. The meeting agenda will include the following:

a. Approval of minutes of previous meetings.

b. Submittal status.

c. Review of off-site fabrication and delivery schedules.

d. Requests for information (RFI) and other issues.

e. Modifications.

f. Work in progress and projected.

1) Status of required inspections (Special Inspections, Accessibility, etc.)

g. Inspections of work in progress and projected (Special inspections,

h. Construction Schedule update (provide updated CPM).

i. Status of Project Record Drawings and O&M manuals.

j. Other business relating to work.

PORE - 149469 01 31 00 - 8

k. Permit requirements.

C. Preinstallation Conferences: Conduct a preinstallation conference at Project site before each construction activity that requires coordination with other construction.

1. Attendees: Installer and representatives of manufacturers and fabricators involved in or affected by the installation and its coordination or integration with other materials and installations that have preceded or will follow, shall attend the meeting. Advise CO of scheduled meeting dates.

2. Agenda: Review progress of other construction activities and preparations for the particular activity under consideration, including requirements for the following:

a. Contract Documents.

b. Options.

c. Related RFIs.

d. Related Change Orders.

e. Purchases.

f. Deliveries.

g. Submittals.

h. Review of mockups.

i. Possible conflicts.

j. Compatibility requirements.

k. Time schedules.

l. Weather limitations.

m. Manufacturer's written instructions.

n. Warranty requirements.

o. Compatibility of materials.

p. Acceptability of substrates.

q. Temporary facilities and controls.

r. Space and access limitations.

s. Regulations of agency(ies) with jurisdiction.

t. Testing and inspecting requirements.

u. Installation procedures.

v. Coordination with other work.

w. Required performance results.

x. Protection of adjacent work.

y. Protection of construction and personnel.

3. Record significant conference discussions, agreements, and disagreements, including required corrective measures and actions.

4. Reporting: Distribute minutes of the meeting to each party present and to other parties requiring information.

5. Do not proceed with installation if the conference cannot be successfully concluded.

Initiate whatever actions are necessary to resolve impediments to performance of the Work and reconvene the conference at earliest feasible date.

PORE - 149469 01 31 00 - 9

1.8 ENVIRONMENTAL COORDINATION

A. Contractor’s Environmental Manager: Designate an on-site party responsible for overseeing the

Contractor’s conformance to environmental goals for the project and implementing procedures for environmental protection.

1. Qualifications: Minimum 3 years Construction experience on projects of similar size and scope; with environmental procedures similar to those of this project; must be familiar with environmental regulations applicable to construction operations.

2. Responsibilities: Responsibilities shall include:

a…