Atch 1 San Luis-Alamosa HQ Specifications.pdf

UNITED STATES

DEPARTMENT OF THE INTERIOR

FISH AND WILDLIFE SERVICE

REGION 6 ENGINEERING

Lakewood, Colorado

SAN LUIS VALLEY COMPLEX HEADQUARTERS AND

VISITOR CENTER BUILDING

ALAMOSA NATIONAL WILDLIFE REFUGE

Alamosa County, Colorado

19-017

FWS ALAMOSA PROJECT NO. 19-017

SAN LUIS VALLEY NATIONAL WILDLIFE REFUGE

COMPLEX VISITOR CENTER APRIL 30, 2020

INDEX 000001 - 1

DESCRIPTION/SPECIFICATIONS

SAN LUIS VALLEY COMPLEX HEADQUARTERS AND VISITOR CENTER BUILDING

AT

ALAMOSA NATIONAL WILDLIFE REFUGE

(19-017)

INDEX

DIVISION 1 - GENERAL REQUIREMENTS No. of Pages

SECTION 011000 SUMMARY OF WORK 6

012900 PAYMENT PROCEDURES 1

013100 PROJECT MANAGEMENT AND COORDINATION 6

013200 CONSTRUCTION PROGRESS DOCUMENTATION 2

013233 PHOTOGRAPHIC DOCUMENTATION 3

013300 SUBMITTAL PROCEDURES 8

013310 SUBMITTAL TEMPLATE 1

014000 QUALITY REQUIREMENTS 7

015000 TEMPORARY FACILITIES AND CONTROLS 5

017419 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL 5

017700 CLOSEOUT PROCEDURES 2

017823 OPERATION AND MAINTENANCE DATA 7

DIVISION 2 – EXISTING CONDITIONS No. of Pages

SECTION NOT USED NA

DIVISION 3 - CONCRETE No. of Pages

SECTION 033000 CAST-IN-PLACE CONCRETE 16

033511 CONCRETE FLOOR FINISHES 2

033543 POLISHED CONCRETE FINISHING 6

DIVISION 4 - MASONRY No. of Pages

DIVISION 5 - METALS No. of Pages

SECTION 051200 STRUCTURAL STEEL FRAMING 8

055000 METAL FABRICATIONS 4

DIVISION 6 – WOOD, PLASTICS AND COMPOSITES No. of Pages

SECTION 061000 ROUGH CARPENTRY 11

061200 STRUCTURAL INSULATED PANELS 3

061600 SHEATHING 3

061753 SHOP FABRICATED WOOD TRUSSES 3

064023 INTERIOR ARCHITECTURAL WORK 9

641113 WOOD-VENEER-FACED ARCHITECTURAL CABINETS 8

INDEX 000001 - 2

DIVISION 7 - THERMAL & MOISTURE PROTECTION No. of Pages

SECTION 072100 THERMAL INSULATION 5

072500 WEATHER BARRIERS 3

072600 VAPOR RETARDERS 3

074113.16 STANDING-SEAM METAL ROOF PANELS 11

076200 SHEET METAL FLASHING AND TRIM 10

077253 SNOW GUARDS 4

079200 JOINT SEALANTS 10

DIVISION 8 - OPENINGS No. of Pages

SECTION 081416 FLUSH WOOD DOORS 8

083113 ACCESS DOORS AND FRAMES 3

085213 ALUMINUM-CLAD DOUBLE HUNG WINDOWS 6

086223 TUBULAR DAYLIGHTING DEVICES 9

087100 DOOR HARDWARE 14

DIVISION 9 - FINISHES No. of Pages

SECTION 092400 CEMENT PLASTERING 6

092900 GYPSUM BOARD 9

093013 CERAMIC TILING 8

096813 TILE CARPETING 6

099113 EXTERIOR PAINTING 6

099123 INTERIOR PAINTING 6

DIVISION 10 - SPECIALTIES No. of Pages

SECTION 101423 PANEL SIGNAGE 4

102800 TOILET, BATH, AND LAUNDRY ACCESSORIES 5

102824 EMERGENCY EYEWASH AND SAFETY EQUIPMENT 2

104413 FIRE PROTECTION CABINETS 5

104416 FIRE EXTINGUISHERS 3

107516 GROUND-SET FLAGPOLES 4

DIVISION 11 - EQUIPMENT No. of Pages

DIVISION 12 – FURNISHINGS

SECTION 123613 CONCRETE COUNTERTOPS 9

DIVISION 13 THROUGH 21 No. of Pages

INDEX 000001 - 3

DIVISION 22 – PLUMBING No. of Pages

SECTION 220000 PLUMBING GENERAL REQUIREMENTS 8

220500 COMMON WORK RESULTS FOR PLUMBING 8

220517 SLEEVES AND SLEEVE SEALS FOR PLUMBING PIPING 4

220518 ESCUTCHEONS FOR PLUMBING PIPING 2

220519 METERS AND GAGES FOR PLUMBING PIPING 6

220523.12 BALL VALVES FOR PLUMBING PIPING 5

220523.14 CHECK VALVES FOR PLUMBING PIPING 5

220529 HANGARS AND SUPPORTS FOR PLUMBING

PIPING AND EQUIPMENT 8

220548 VIBRATION AND SEISMIC CONTROLS FOR

PLUMBING PIPING AND EQUIPMENT 15

220553 IDENTIFICATIONS FOR PLUMBING

PIPING AND EQUIPMENT 5

220719 PLUMBING PIPING INSULATION 19

221113 FACILITY WATER DISTRIBUTION PIPING 11

221116 DOMESTIC WATER PIPING 14

221119 DOMESTIC WATER PIPING SPECIALTIES 8

221316 SANITARY WASTE AND VENT PIPING 10

221319 SANITARY WASTE PIPING SPECIALTIES 7

223400 FUEL-FIRED, DOMESTIC-WATER HEATERS 5

224213.13 COMMERCIAL WATER CLOSETS 4

224216.13 COMMERCIAL LAVATORIES 4

224216.16 COMMERCIAL SINKS 5

DIVISION 23 – HEATING, VENTILATING,

AND AIR CONDITIONING No. of Pages

SECTION 230000 MECHANICAL GENERAL REQUIREMENTS 9

230500 COMMON WORK RESULTS FOR HVAC 9

230513 COMMON MOTOR REQUIREMENTS FOR HVAC EQUIPMENT 3

230517 SLEEVES AND SLEEVE SEALS FOR HVAC PIPING 4

230518 ESCUTCHEONS FOR HVAC PIPING 2

230529 HANGARS AND SUPPORTS FOR HVAC

PIPING AND EQUIPMENT 8

230548 VIBRATION AND SEISMIC CONTROLS FOR HVAC 15

230593 TESTING, ADJUSTING, AND BALANCING FOR HVAC 8

230713 DUCT INSULATION 14

230719 HVAC PIPING INSULATION 22

230923.11 CONTROL VALVES 12

230923.12 CONTROL DAMPERS 13

230923 DIRECT DIGITAL CONTROL (DDC) SYSTEM FOR HVAC 93

230993.11 SEQUENCE OF OPERATIONS FOR HVAC DDC 6

231126 FACILITY LIQUEFIED-PETROLEUM GAS PIPING 19

232113 HYDRONIC PIPING 13

232116 HYDRONIC PIPING SPECIALTIES 5

232123 HYDRONIC PUMPS 5

232300 REFRIGERANT PIPING 13

233113 METAL DUCTS 13

233300 AIR DUCT ACCESSORIES 15

INDEX 000001 - 4

233423 HVAC POWER VENTILATORS 7

233713 DIFFUSERS, REGISTERS, AND GRILLES 4

233723 HVAC GRAVITY VENTILATORS 5

235100 BREECHINGS, CHIMNEYS, AND STACKS 3

235216 CONDENSING BOILERS 6

235416.13 GAS-FIRED FURNACES 5

236200 PACKAGED COMPRESSOR AND CONDENSER UNITS 5

237200 AIR TO AIR ENERGY RECOVERY EQUIPMENT 4

238123 COMPUTER-ROOM AIR CONDITIONERS 6

238216.13 REFRIGERANT AIR COILS 2

238316 RADIANT-HEATING HYDRONIC PIPING 6

DIVISION 26 - ELECTRICAL No. of Pages

SECTION 260000 ELECTRICAL GENERAL REQUIREMENTS 9

260519 LOW-VOLTAGE ELECTRICAL POWER

CONDUCTORS AND CABLES 6

260526 GROUNDING AND BONDING FOR ELECTRICAL SYSTEMS 4

260529 HANGARS AND SUPPORTS FOR ELECTRICAL SYSTEMS 5

260533 RACEWAY AND BOXES FOR ELECTRICAL SYSTEMS 7

260553 IDENTIFICATION FOR ELECTRICAL SYSTEMS 4

262416 PANELBOARDS 7

262726 WIRING DEVICES 4

262813 FUSES 2

262816 ENCLOSED SWITCHES AND CIRCUIT BREAKERS 5

262913 ENCLOSED CONTROLLERS 4

265100 INTERIOR LIGHTING 6

265600 EXTERIOR LIGHTING 5

DIVISION 27 – COMMUNICATIONS No. of Pages

SECTION 271500 VOICE AND DATA WIRING SYSTEMS 8

DIVISION 28 – ELECTRONIC SAFETY & SECURITY No. of Pages

SECTION 281600 INTRUSION DETECTION 13

282300 SECURITY CAMERA SYSTEM 6

283111 DIGITAL, ADDRESSABLE FIRE ALARM SYSTEM 18

INDEX 000001 - 5

DIVISION 31 - EARTHWORK No. of Pages

SECTION 311000 SITE CLEARING 3

312000 EARTH MOVING 7

DIVISION 32 – EXTERIOR IMPROVEMENTS No. of Pages

SECTION 321313 CONCRETE PAVING 5

321723 PAVEMENT MARKINGS 2

321726 TACTILE WARNING SURFACING 2

329115 SOIL PREPARATION (PERFORMANCE SPECIFICATION) 6

329200 TURN AND GRASSES 4

DIVISION 33 - UTILITIES No. of Pages

SECTION 330500 COMMON WORK FOR UTILITIES 7

331313 CHEMICAL FEED EQUIPMENT FOR PUMP HOUSE 2

331316 DOMESTIC WATER PIPING FOR PUMP HOUSE 3

331416 SITE WATER DISTRIBUTION PIPING 7

333113 SITE SANITARY SEWERS 4

334113 DRAINAGE PIPING AND CATCH BASIN FOR PUMP HOUSE 1

COMPLEX VISITOR CENTER APRIL 30, 2020

SUMMARY 011000 - 1

SECTION 011000 - SUMMARY

PART 1 - GENERAL

1.1 SUMMARY

A. Section Includes:

1. Project information.

2. Work covered by Contract Documents.

3. Work under separate contracts.

4. Access to site.

5. Coordination with occupants.

6. Work restrictions.

7. Coordination with local utilities.

8. Permits and Fees.

9. Applicable codes, standards, and specifications.

10. Means and methods.

11. Safety.

12. Environmental Protection.

B. Related Requirements:

1. Section 015000 "Temporary Facilities and Controls" for limitations and procedures governing temporary use of Government's facilities.

1.2 PROJECT INFORMATION

A. Project Location: Alamosa National Wildlife Refuge, 9383 El Rancho Lane, Alamosa, CO 81101

B. Station Contact Information: Sharon Vaughn, Project Leader, (719) 589-3409.

1.3 WORK COVERED BY CONTRACT DOCUMENTS

A. Construction of the San Luis Valley Complex HQ-Visitor Center building, at Alamosa National Wildlife Refuge. The scope of this project is to construct the new San Luis Valley Complex Headquarters-Visitor Center. Work will include construction of: Parking Lot/Sidewalks, Access Road, new domestic Water Supply Well system to include the enclosure, Liquid Propane and Garbage Dumpster enclosures, mounded Leach field/Septic system, and Exterior Electrical power supply system.

1.4 WORK UNDER SEPARATE CONTRACTS

A. General: In the event there is work being performed under a separate contract the Contractor shall cooperate fully with separate contractors so work on those contracts may be carried out

COMPLEX VISITOR CENTER APRIL 30, 2020

SUMMARY 011000 - 2

smoothly, without interfering with or delaying work under this Contract or other contracts.

Coordinate the Work of this Contract with work performed under separate contracts.

1.5 ACCESS TO SITE

A. All operations of the Contractor (including storage of materials) upon Government premises shall be confined to areas authorized or approved by the Contracting Officer.

B. Limit use of Project site areas within the Contract limits indicated. Do not disturb portions of Project site beyond areas in which the Work is indicated.

1. Limits: Confine construction operations to work site as defined in Contract Documents.

1.6 COORDINATION WITH OCCUPANTS

A. Partial Government Occupancy: Government will occupy the premises during entire construction period, with the exception of areas under construction. Cooperate with Station Manager during construction operations to minimize conflicts and facilitate usage. Perform the Work so as not to interfere with Government operations. Maintain existing exits unless otherwise indicated.

1. Provide not less than 48 hours' notice to Government of activities that will affect Government's operations.

1.7 WORK RESTRICTIONS

A. Work Restrictions, General: Comply with restrictions on construction operations. Comply with limitations on use of public streets and with other requirements of authorities having jurisdiction.

B. On-Site Work Hours: Limit work in the existing building to normal business working hours of 7:00 a.m. to 5:00 p.m., Monday through Friday, unless otherwise indicated.

1. Work on weekends will be restricted to Contracting Officers approval and at the Station Managers discretion.

2. No work will take place over Federally observed holidays.

1.8 COORDINATION WITH LOCAL UTILITIES

A. The Contractor shall be responsible for contracting and arranging with local utility for the termination, moving, or connection of utilities that serve existing buildings and ones that are planned to serve the new Work.

COMPLEX VISITOR CENTER APRIL 30, 2020

SUMMARY 011000 - 3

B. Local utilities that serve Alamosa National Wildlife Refuge are:

1. Communication Ciello 3625 US-160 West Monte Vista, Colorado 81144 Phone: 719-852-6641 Contact: Monroe Johnson

2. Electrical Xcel Energy 400 West Washington Street Alamosa, Colorado 81101 Phone: 719-589-1230 Contact: Jenna Lopez

1.9 PERMITS AND FEES

A. The Contractor shall be responsible for obtaining all necessary local, State, and Federal permits and licenses, and payment of related fees, per the Contract Clauses.

1.10 APPLICABLE CODES, STANDARDS AND SPECIFICATIONS

A. All work shall comply with the codes and standards applicable to each type of work as listed in individual Sections of these Specifications.

B. Where a conflict occurs between a referenced document and the Project Specifications, the Project Specifications govern.

C. Where a conflict occurs between referenced documents, the document containing the most stringent requirements governs.

D. Where referenced documents are not specified by date, the document current at the bid opening applies.

E. Materials, applications, and tests specified by reference to published standards of society, association, code, or other published standards are included in the specifications as if written in their entirety.

F. Conform to all regulations and statutes of the State of Colorado and to all Federal Regulations which apply.

1.11 MEANS AND METHODS

A. Means and methods of construction shall be such as the Contractor or subcontractors may choose;

subject, however, to the Contracting Officer's right to reject means and methods proposed which:

COMPLEX VISITOR CENTER APRIL 30, 2020

SUMMARY 011000 - 4

1. Constitute a hazard to the work, persons, or property.

2. Will not produce finished work in accordance with terms of the contract.

3. Are contrary to specified means or methods included in the contract.

B. The right to reject means and methods of the Contractor or subcontractor shall not be construed or interpreted as acceptance of control of means and methods by the Contracting Officer.

C. The Contracting Officer's approval of means and methods or failure to exercise right to reject means and methods shall not relieve the Contractor of the obligation to complete the work required by the contract.

D. Total responsibility for control of all means and methods lies with the Contractor for all work.

1.12 SAFETY

A. The Contractor shall provide, erect and maintain all necessary barricades, suitable and sufficient flasher lights, flagmen, danger signals and signs, and shall take all necessary precautions for the protection of the work and the safety of the public. All ponds and water control structures shall remain accessible by vehicle. Roads closed to traffic shall be protected by effective barricades and shall be placed with acceptable warning signs. All barricades and obstructions shall be illuminated at night and all lights shall be kept burning from sunset until sunrise. Install appropriate traffic signs at crossroads and approaches to site as needed to direct affected public traffic. Specific signs and barricade requirements are detailed in the U.S. Department of Transportation, "Manual on Uniform Traffic Control Devices".

B. The Contractor shall assume full responsibility and liability for compliance with all applicable Federal, State, and local regulations pertaining to the protection of workers, visitors to the site, and persons occupying areas adjacent to the site, including the provisions of 29CFR1910 and 29CFR1926 of the Code of Federal Regulations. The Contractor shall hold harmless the Government for failure to comply with any applicable safety or health regulation on the part of himself, his employees, or his subcontractors.

C. Provide personal safety equipment and training commensurate with the hazards which may exist at the work site. The personal safety equipment and training shall be determined by a thorough hazard analysis of all work site areas. The safety program available at all work sites shall include a minimum of:

1. One nonfreezing-type fire extinguisher in each workshop and shed used for storage of materials at the work site. Place in location readily accessible to construction personnel.

2. A first aid kit for use of construction personnel commensurate with size of project with items necessary for first aid treatment of all injuries.

3. The Contractor shall conduct regular onsite safety inspections and all construction personnel shall receive a safety orientation.

4. Post telephone numbers of nearest hospital, ambulance service or flight for life, and fire station in conspicuous location. Advise all workers of location of telephone numbers.

COMPLEX VISITOR CENTER APRIL 30, 2020

SUMMARY 011000 - 5

1.13 ENVIRONMENTAL PROTECTION

A. The Contractor shall abate and control all environmental pollution arising from construction activities by complying with all applicable Federal, State, and local laws and regulations concerning environmental pollution control and abatement, as well as the specified requirements in this contract. Compliance with this requirement by subcontractors will be the responsibility of the Contractor.

B. Fossils and Artifacts

1. Should the Contractor discover any fossils or artifacts during construction operations, such objects shall become the property of the Government. The Contractor shall cease construction operations in the area of the "find," and immediately notify the station manager of such discovery. Construction operations may proceed in other areas not affected by this clause. Care shall be exercised by the Contractor not to damage fossils or artifacts uncovered during excavation operations.

2. Failure to comply with this requirement may be considered a violation of the Archeological Resources Protection Act of 1979 as amended. Destruction of historic and prehistoric sites and/or unauthorized collection of cultural materials can result in criminal and/or civil penalties. Penalties can include fines, prison sentences, and/or confiscation of equipment.

3. If the Contractor uses fill from a nongovernmental source to perform work that is required under this project, and a new borrow site is opened or an existing borrow area is expanded in order to obtain such materials, the Contractor shall assure that any new borrow area disturbance meet the requirements of Section 106 of the National Historic Preservation Act.

C. Abatement of Air Pollution

1. The Contractor shall comply with applicable Federal, State, and local laws and regulations concerning the prevention and control of air pollution.

2. Construction activities shall be performed in such a manner that air pollution will be held to a minimum.

3. Burning of materials, trees and brush, combustible construction materials, and rubbish will not be permitted. Construction debris shall be disposed of at a location designated by the Contracting Officer or hauled off the Station to an approved disposal site.

D. Prevention of Water Pollution

1. The Contractor is responsible for implementing the terms and requirements for a National Pollution Discharge Elimination System (NPDES) permit, as required by the Environmental Protection Agency (EPA). The Government and the Contractor will be co-permittees. The Contractor shall prepare and submit all permit application documents for the US Fish and Wildlife Service to sign as owner, except that the Government will prepare and sign a separate Notice of Intent (NOI) to discharge for the Contractor to include with the permit application. The Contractor is solely responsible for executing the terms and conditions of the permit as issued by the EPA. The Contractor shall submit to the Contracting Officer a copy of all permit applications and a copy of all approvals from the

COMPLEX VISITOR CENTER APRIL 30, 2020

SUMMARY 011000 - 6

EPA. Allow the Government 10 days for review of the application package prior to submission.

2. During construction, the Contractor shall comply with all applicable Federal, State, and local laws and regulations concerning the control and abatement of water pollution.

3. The Contractor's construction activities shall be performed by methods that will prevent entrance or accidental spillage of solid matter, contaminants, debris, and other objectionable pollutants and wastes into streams, flowing or dry water-courses, lakes, ponds, and underground water sources. The Contractor shall dispose of all pollutants such as petroleum products, rubbish, cement, concrete, etc., and objectionable material at a jurisdictionally accepted waste management facility.

4. Sanitary facilities, such as chemical toilets shall be located far enough from wells, live streams, or ponds to prevent pollution of the water.

5. Dewatering work for structure foundations or earthwork operations adjacent to or encroaching on streams or watercourses shall be conducted in a manner that prevents muddy water and eroded materials from entering streams or watercourses. This shall be accomplished by construction of intercepting ditches, bypass channels, barriers, settling ponds, or other approved means. Excavated material shall not be placed in or adjacent to watercourses where it can be washed away by high water or storm runoff.

E. Prevention of site contamination

1. The purpose of this section is to prevent invasive species from being introduced to the project work sites. This includes both plant and animal species. Invasive species can have long last detrimental effects at project sites at US Fish and Wildlife Service lands.

2. Prior to entrance to the work site, all equipment brought on site will be thor-oughly washed to remove dirt, seeds, and plant parts. Any equipment that has been any body of water within the past 30 days will be thoroughly cleaned with hot water greater than 140 degree F (typically the temperature found at commer-cial truck washes) and dried for a minimum of five days before being used at this project site. In addition, before transporting equipment from the project site all visible mud, plants and fish/animals will be removed, all water will be elimi-nated, and the equipment will be thoroughly cleaned. Anything that came in con-tact with water will be cleaned and dried following the above procedure.

F. Environmental Litigation: Time lost due to work stoppage because of failure of the Contractor to comply with these requirements may not be the subject of a claim for extension of time, for additional costs, or damages.

END OF SECTION 011000

COMPLEX VISITOR CENTER APRIL 30, 2020

PAYMENT PROCEDURES 012900 - 1

SECTION 012900 – PAYMENT PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements necessary to prepare and process Applications for Payment.

1.2 SCHEDULE OF VALUES

A. Coordination: Coordinate preparation of the schedule of values with preparation of Contractor's construction schedule.

1. Submit the schedule of values to Contracting Officer at earliest possible date but no later than seven days before the date scheduled for submittal of initial Applications for Payment.

1.3 APPLICATIONS FOR PAYMENT

A. Each Application for Payment shall be consistent with previous applications and payments as certified by Contracting Officer.

B. Payment Application Times: The date for each progress payment is indicated in the Agreement between Government and Contractor.

C. Initial Application for Payment: Administrative actions and submittals that must precede or coincide with submittal of first Application for Payment include the following:

1. Schedule of values.

2. Contractor's construction schedule (preliminary if not final).

3. Submittal schedule (preliminary if not final).

D. Final Payment Application: After completing Project closeout requirements, submit final Application for Payment with releases and supporting documentation not previously submitted and accepted, including, but not limited, to the following:

1. Evidence of completion of Project closeout requirements.

2. Written guarantees, warranties, and certificates.

3. Record (As-Built) Drawings

4. All test reports.

END OF SECTION 012900

COMPLEX VISITOR CENTER APRIL 30, 2020

PROJECT MANAGEMENT AND COORDINATION 013100 - 1

SECTION 013100 - PROJECT MANAGEMENT AND COORDINATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative provisions for coordinating construction operations on Project including, but not limited to, the following:

1. Requests for Information (RFIs).

2. Project meetings.

1.2 DEFINITIONS

A. RFI: Request from Government, Owner, Construction Manager, Architect, or Contractor seeking information required by or clarifications of the Contract Documents.

1.3 INFORMATIONAL SUBMITTALS

A. Subcontract List: Prepare a written summary identifying individuals or firms proposed for each portion of the Work, including those who are to furnish products or equipment fabricated to a special design. Include the following information in tabular form:

1. Name, address, and telephone number of entity performing subcontract or supplying products.

2. Number and title of related Specification Section(s) covered by subcontract.

3. Drawing number and detail references, as appropriate, covered by subcontract.

1.4 GENERAL COORDINATION PROCEDURES

A. Coordination: Coordinate construction operations included in different Sections of the Specifications to ensure efficient and orderly installation of each part of the Work. Coordinate construction operations, included in different Sections, which depend on each other for proper installation, connection, and operation.

1. Provide a construction schedule noting demolition activities, construction activities, deliveries, payments, etc., as needed to convey coordination information to the Contacting Officer, Contacting Officer’s Representative (COR), Government Inspector as well as local staff.

2. Schedule construction operations in sequence required to obtain the best results where installation of one part of the Work depends on installation of other components, before or after its own installation.

3. Coordinate installation of different components to ensure maximum performance and accessibility for required maintenance, service, and repair.

COMPLEX VISITOR CENTER APRIL 30, 2020

PROJECT MANAGEMENT AND COORDINATION 013100 - 2

4. Make adequate provisions to accommodate items scheduled for later installation.

B. Prepare memoranda for distribution to each party involved, outlining special procedures required for coordination. Include such items as required notices, reports, and list of attendees at meetings.

1. Prepare similar memoranda for Owner and separate contractors if coordination of their Work is required.

C. Administrative Procedures: Coordinate scheduling and timing of required administrative procedures with other construction activities as well as any activities of other contractors to avoid conflicts and to ensure orderly progress of the Work. Such administrative activities include, but are not limited to, the following:

1. Preparation of Contractor's construction schedule.

2. Preparation of the Schedule Of Values.

3. Installation and removal of temporary facilities and controls.

4. Delivery and processing of submittals.

5. Progress meetings.

6. Pre-installation conferences.

7. Project closeout activities.

8. Startup and adjustment of systems.

1.5 REQUESTS FOR INFORMATION (RFIs)

A. General: Immediately on discovery of the need for additional information or interpretation of the Contract Documents, Contractor shall prepare and submit an RFI in the form specified.

1. The Government will return RFIs as submitted to the Government by other entities controlled by Contractor with no response. RFI’s must come directly from the Contractor.

2. Coordinate and submit RFIs in a prompt manner so as to avoid delays in Contractor's work or work of subcontractors.

B. Content of the RFI: Include a detailed, legible description of item needing information or interpretation and the following:

1. Project name.

2. Project number.

3. Date.

4. Name of Contractor.

5. RFI number, numbered sequentially.

6. RFI subject.

7. Specification Section number and title and related paragraphs, as appropriate.

8. Drawing number and detail references, as appropriate.

9. Field dimensions and conditions, as appropriate.

10. Contractor's suggested resolution. If Contractor's solution(s) impacts the Contract Time or the Contract Sum, Contractor shall state impact in the RFI.

11. Contractor's signature.

COMPLEX VISITOR CENTER APRIL 30, 2020

PROJECT MANAGEMENT AND COORDINATION 013100 - 3

12. Attachments: Include sketches, descriptions, measurements, photos, Product Data, Shop Drawings, coordination drawings, and other information necessary to fully describe items needing interpretation.

C. RFI Forms: AIA Document G716, or Software-generated form with substantially the same content as indicated above, acceptable to the Government.

D. The Governments Action: The Government will review each RFI, determine action required, and respond. Allow seven working days for the Government’s response for each RFI. RFIs received after 1:00 p.m. will be considered as received the following working day.

1. The following RFIs will be returned without action:

a. Requests for approval of submittals.

b. Requests for approval of substitutions.

c. Requests for coordination information already indicated in the Contract Documents.

d. Requests for adjustments in the Contract Time or the Contract Sum.

e. Requests for interpretation of Architect's actions on submittals.

f. Incomplete RFIs or inaccurately prepared RFIs.

g. Request For Information submitted by a sub-contractor to the Contractor.

2. The Government’s action may include a request for additional information, in which case the time for response will date from time of receipt of additional information.

3. The Government’s action on RFIs that may result in a change to the Contract Time or the Contract Sum may be eligible for Contractor to submit Change Proposal.

a. If Contractor believes the RFI response warrants change in the Contract Time or the Contract Sum, notify Contacting Officer and COR in writing within 10 days of receipt of the RFI response.

E. RFI Log: Prepare, maintain, and submit a tabular log of RFIs organized by the RFI number.

Submit log weekly with not less than the following information:

1. Project name.

2. Name and address of Contractor.

3. Name and address of Contacting Officer and COR.

4. RFI number including RFIs that were dropped and not submitted.

5. RFI description.

6. Date the RFI was submitted.

7. Date the Contacting Officer’s response was received.

F. On receipt of the Government’s action, update the RFI log and immediately distribute the RFI response to affected parties. Review response and notify the Government within seven days if Contractor disagrees with response.

1. Identification of related Minor Change in the Work, Construction Change Directive, and Proposal Request, as appropriate.

2. Identification of related Field Order, Work Change Directive, and Proposal Request, as appropriate.

COMPLEX VISITOR CENTER APRIL 30, 2020

PROJECT MANAGEMENT AND COORDINATION 013100 - 4

1.6 PROJECT MEETINGS

A. General: Schedule and conduct meetings and conferences at Project site unless otherwise indicated.

1. Attendees: Inform participants and others involved, and individuals whose presence is required, of date and time of each meeting. Notify the Facility Director, the Contracting officer and the COR of scheduled meeting dates and times.

2. Agenda: Prepare the meeting agenda. Distribute the agenda to all invited attendees.

3. Minutes: Entity responsible for conducting meeting will record significant discussions and agreements achieved. Distribute the meeting minutes to everyone concerned, including the Contracting Officer and the COR, Construction Manager, and Architect, within three days of the meeting.

B. Preconstruction Conference: The Contracting Officer will schedule a preconstruction conference before starting construction, at a time convenient to the Contracting Officer, COR, Facility Director, On-Site Government Inspector and Contractor.

1. Attendees: Authorized representatives of the Contracting Officer, Government Project Manager, Owner's Commissioning Authority, Construction Manager, Architect, and their consultants; Contractor and its superintendent; major subcontractors; suppliers; and other concerned parties shall attend the conference. Participants at the conference shall be familiar with Project and authorized to conclude matters relating to the Work.

2. Agenda: Discuss items of significance that could affect progress, including the following:

a. Tentative construction schedule.

b. Phasing.

c. Critical work sequencing and long-lead items.

d. Designation of key personnel and their duties.

e. Procedures for processing field decisions and Change Orders.

f. Procedures for RFIs.

g. Procedures for testing and inspecting.

h. Procedures for processing Applications for Payment.

i. Distribution of the Contract Documents.

j. Submittal procedures.

k. Preparation of record documents.

l. Use of the premises and existing building.

m. Work restrictions.

n. Working hours.

o. Owner's occupancy requirements.

p. Responsibility for temporary facilities and controls.

q. Procedures for moisture and mold control.

r. Procedures for disruptions and shutdowns.

s. Construction waste management and recycling.

t. Parking availability.

u. Office, work, and storage areas.

v. Equipment deliveries and priorities.

COMPLEX VISITOR CENTER APRIL 30, 2020

PROJECT MANAGEMENT AND COORDINATION 013100 - 5

w. First aid.

x. Security.

y. Progress cleaning.

3. Minutes: Entity responsible for conducting meeting will record and distribute meeting minutes.

C. Progress Meetings: Conduct progress meetings at regular intervals as directed by the Contracting officer and/or the COR.

1. Attendees: In addition to representatives of the Government, Construction Manager, and Architect (as applicable), each contractor, subcontractor, supplier, and other entity concerned with current progress or involved in planning, coordination, or performance of future activities shall be represented at these meetings. All participants at the meeting shall be familiar with Project and authorized to conclude matters relating to the Work.

2. Agenda: Review and correct or approve minutes of previous progress meeting. Review other items of significance that could affect progress. Include topics for discussion as appropriate to status of Project.

a. Contractor's Construction Schedule: Review progress since the last meeting.

Determine whether each activity is on time, ahead of schedule, or behind schedule, in relation to Contractor's construction schedule. Determine how construction behind schedule will be expedited; secure commitments from parties involved to do

so. Discuss whether schedule revisions are required to ensure that current and subsequent activities will be completed within the Contract Time.

1) Review schedule for next period.

b. Review present and future needs of each entity present, including the following:

1) Interface requirements.

2) Sequence of operations.

3) Status of submittals.

4) Deliveries.

5) Off-site fabrication.

6) Access.

7) Site utilization.

8) Temporary facilities and controls.

9) Progress cleaning.

10) Quality and work standards.

11) Status of correction of deficient items.

12) Field observations.

13) Status of RFIs.

14) Status of proposal requests.

15) Pending changes.

16) Status of Change Orders.

17) Pending claims and disputes.

18) Documentation of information for payment requests.

COMPLEX VISITOR CENTER APRIL 30, 2020

PROJECT MANAGEMENT AND COORDINATION 013100 - 6

3. Minutes: Entity responsible for conducting the meeting will record and distribute the meeting minutes to each party present and to parties requiring information.

a. Schedule Updating: Revise Contractor's construction schedule after each progress meeting where revisions to the schedule have been made or recognized. Issue revised schedule concurrently with the report of each meeting.

END OF SECTION 013100

COMPLEX VISITOR CENTER APRIL 30, 2020

CONSTRUCTION PROGRESS DOCUMENTATION 013200 - 1

SECTION 013200 – CONSTRUCTION PROGRESS DOCUMENTATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements for documenting the progress of construction during performance of the Work, including the following:

1. Contractor's construction schedule.

2. Construction schedule updating reports.

3. Daily construction reports.

4. Site condition reports.

1.2 DEFINITIONS

A. Activity: A discrete part of a project that can be identified for planning, scheduling, monitoring, and controlling the construction project. Activities included in a construction schedule consume time and resources.

1. Critical Activity: An activity on the critical path that must start and finish on the planned early start and finish times.

2. Predecessor Activity: An activity that precedes another activity in the network.

3. Successor Activity: An activity that follows another activity in the network.

1.3 INFORMATIONAL SUBMITTALS

A. Contractor's Construction Schedule: Initial schedule, of size required to display entire schedule for entire construction period.

1. Submit a working electronic copy of schedule, using software indicated, and labeled to comply with requirements for submittals. Include type of schedule (initial or updated) and date on label.

B. Construction Schedule Updating Reports: Submit with Applications for Payment.

1.4 COORDINATION

A. Coordinate Contractor's construction schedule with the schedule of values, submittal schedule, progress reports, payment requests, and other required schedules and reports.

1. Secure time commitments for performing critical elements of the Work from entities involved.

2. Coordinate each construction activity in the network with other activities and schedule them in proper sequence.

COMPLEX VISITOR CENTER APRIL 30, 2020

CONSTRUCTION PROGRESS DOCUMENTATION 013200 - 2

PART 2 - PRODUCTS

2.1 CONTRACTOR'S CONSTRUCTION SCHEDULE, GENERAL

A. Time Frame: Extend schedule from date established from the Notice to Proceed to the date of completion.

B. Activities: Treat each story or separate area as a separate numbered activity for each main element of the Work. Comply with the following:

1. Activity Duration

2. Procurement Activities

3. Submittal Review Time

4. Punch List and Final Completion: Include not more than 15 days for completion of punch list items and final completion.

C. Constraints: Include constraints and work restrictions indicated in the Contract Documents and as follows in schedule, and show how the sequence of the Work is affected.

1. Phasing: Arrange list of activities on schedule by phase.

2. Work under More Than One Contract: Include a separate activity for each contract.

3. Work by Owner: Include a separate activity for each portion of the Work performed by

Owner.

4. Work Restrictions: Show the effect of the following items on the schedule:

a. Coordination with existing construction.

b. Limitations of continued occupancies.

c. Uninterruptible services.

d. Partial occupancy before Substantial Completion.

e. Use of premises restrictions.

f. Provisions for future construction.

g. Seasonal variations.

h. Environmental control.

5. Work Stages: Indicate important stages of construction for each major portion of the Work.

6. Other Constraints

D. Milestones: Include milestones indicated in the Contract Documents in schedule, including, but not limited to, the Notice to Proceed, Substantial Completion, and final completion and the following interim milestones.

1. Insert milestones not indicated elsewhere.

END OF SECTION 013200

COMPLEX VISITOR CENTER APRIL 30, 2020

PHOTOGRAPHIC DOCUMENTATION 013233 - 1

SECTION 013233 - PHOTOGRAPHIC DOCUMENTATION

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes administrative and procedural requirements for the following:

1. Preconstruction photographs.

2. Periodic construction photographs.

B. Related Requirements:

1. Section 017700 "Closeout Procedures" for submitting photographic documentation as Project Record Documents at Project closeout.

1.2 INFORMATIONAL SUBMITTALS

A. Key Plan: Submit key plan of Project site and building with notation of vantage points marked for location and direction of each photograph. Indicate elevation or story of construction.

Include same information as corresponding photographic documentation.

B. Digital Photographs: Submit unaltered, original, full-size image files within 5 days of taking photographs.

1. Digital Camera: Minimum sensor resolution of 8 megapixels.

2. Digital photographs to be submitted in the order in which they were taken with the photograph “name” as given by the device used to take to photo.

3. Identification: Provide the following information with each image description in file metadata tag:

a. Date and time photograph was taken

b. Unique photograph number

1.3 QUALITY ASSURANCE

A. Photographs to be clear, focused, level, have proper exposure settings (not over exposed or under exposed), and clearly show and document the subject matter. Detail photographs (close-ups) to be preceded by a larger overall view of the area being documented.

1.4 USAGE RIGHTS

A. If a professional photographer is used for this requirement, obtain and transfer copyright usage rights from photographer to Owner for unlimited reproduction of photographic documentation.

COMPLEX VISITOR CENTER APRIL 30, 2020

PHOTOGRAPHIC DOCUMENTATION 013233 - 2

PART 2 - PRODUCTS

2.1 PHOTOGRAPHIC MEDIA

A. Digital Images: Provide images in JPG format, with minimum size of 8 megapixels.

PART 3 - EXECUTION

3.1 CONSTRUCTION PHOTOGRAPHS

A. Photographer: Engage a qualified photographer to take construction photographs. Photographer need not be a professional photographer, but an individual familiar with and able to produce clear, focused photographs of the subject area with good reference points.

B. General: Take photographs using the maximum range of depth of field, and that are in focus, to clearly show the Work. Photographs with blurry or out-of-focus areas will not be accepted.

1. Maintain key plan with each set of construction photographs that identifies each photographic location.

C. Digital Images: Submit digital images exactly as originally recorded in the digital camera, without alteration, manipulation, editing, or modifications using image-editing software.

1. Date and Time: Include date and time in file name for each image.

2. Field Office Images: Maintain one set of images accessible in the field office at Project site, available at all times for reference. Identify images in the same manner as those submitted to the Government.

D. Preconstruction Photographs: Before commencement of excavation, commencement of demolition and starting construction, take photographs of Project site and surrounding properties, including existing items to remain during construction, from different vantage points, as directed by Government.

1. Flag excavation areas before taking construction photographs.

2. Take minimum of 10 photographs, or as needed, to show existing conditions adjacent to property before starting the Work.

3. Take minimum of 10 photographs, or as needed, of existing buildings either on or adjoining property to accurately record physical conditions at start of construction.

E. Periodic Construction Photographs: Take photographs as needed to fully document the construction progress. Select vantage points to show status of construction and progress since last photographs were taken. Try to retake progress photos from the same vantage points when possible so as to show relative construction progress.

F. Final Completion Construction Photographs: Take color photographs after date of Substantial Completion for submission as Project Record Documents. The Government will inform photographer of desired vantage points.

COMPLEX VISITOR CENTER APRIL 30, 2020

PHOTOGRAPHIC DOCUMENTATION 013233 - 3

G. Additional Photographs: The Government may request photographs in addition to periodic photographs specified as needed to verify progress or to verify work completion accuracy.

1. Three days' notice will be given, where feasible.

2. In emergency situations, take additional photographs within 24 hours of request.

3. Circumstances that could require additional photographs include, but are not limited to, the following:

a. Special events planned at Project site.

b. Immediate follow-up when on-site events result in construction damage or losses.

c. Photographs to be taken at fabrication locations away from Project site. These photographs are not subject to unit prices or unit-cost allowances.

d. Substantial Completion of a major phase or component of the Work.

e. Extra record photographs at time of final acceptance.

f. Owner's request for special publicity photographs.

END OF SECTION 013233

COMPLEX VISITOR CENTER APRIL 30, 2020

SUBMITTAL PROCEDURES 013300 - 1

SECTION 013300 – SUBMITTAL PROCEDURES

PART 1 - GENERAL

1.1 SUMMARY

A. Section includes requirements for the submittal schedule and administrative and procedural requirements for submitting Shop Drawings, Product Data, Samples, and other submittals.

1.2 DEFINITIONS

A. Action Submittals: Written and graphic information and physical samples that require Architect's Contracting Officer responsive action.

B. Informational Submittals: Written and graphic information and physical samples that do not require Architect's Contracting Officer responsive action. Submittals may be rejected for not complying with requirements.

1.3 ACTION SUBMITTALS

A. Submittal Schedule: Submit a schedule of submittals, arranged in chronological order by dates required by construction schedule. Include time required for review, ordering, manufacturing, fabrication, and delivery when establishing dates. Include additional time required for making corrections or revisions to submittals noted by Architect Contracting Officer and additional time for handling and reviewing submittals required by those corrections.

1.4 SUBMITTAL ADMINISTRATIVE REQUIREMENTS

A. Coordination: Coordinate preparation and processing of submittals with performance of construction activities.

1. Coordinate each submittal with fabrication, purchasing, testing, delivery, other submittals, and related activities that require sequential activity.

2. Coordinate transmittal of different types of submittals for related parts of the Work so processing will not be delayed because of need to review submittals concurrently for coordination.

a. Contracting Officer reserves the right to withhold action on a submittal requiring coordination with other submittals until related submittals are received.

B. Processing Time: Allow time for submittal review, including time for resubmittals, as follows.

Time for review shall commence on Contracting Officer receipt of submittal. No extension of the Contract Time will be authorized because of failure to transmit submittals enough in advance of the Work to permit processing, including resubmittals. Submittals received after 1:00 PM will be considered to having arrived the following day.

COMPLEX VISITOR CENTER APRIL 30, 2020

SUBMITTAL PROCEDURES 013300 - 2

1. Initial Review: Allow 10 days for initial review of each submittal. Allow additional time if coordination with subsequent submittals is required. Contracting Officer will advise Contractor when a submittal being processed must be delayed for coordination.

2. Intermediate Review: If intermediate submittal is necessary, process it in same manner as initial submittal.

3. Resubmittal Review: Allow 10 days for review of each resubmittal.

C. Paper Submittals: Place a permanent label or title block on each submittal item for identification.

1. Transmittal for Paper Submittals: Assemble each submittal individually and appropriately for transmittal and handling. Transmit each submittal using a transmittal form.

a. Transmittal Form for Paper Submittals: Use FWS transmittal form.

D. Electronic Submittals: Identify and incorporate information in each electronic submittal file as follows:

1. Name file with submittal number or other unique identifier, including revision identifier.

a. File name shall use a sequential submittal number followed by station initials and Specification Section number (Submittal 001-GVPNFH-061000). Resubmittals shall include a numeric suffix after the submittal number (e.g., Submittal 001-R1-

GVPNFH-061000).

2. Transmittal Form for Electronic Submittals: Use electronic form provided by Contracting Officer.

E. Options: Identify options requiring selection by the Government. Clearly mark options selected by the Contractor from the options on the manufacturer’s product data sheet.

F. Deviations: Identify deviations from the Contract Documents on submittals.

G. Resubmittals: Make resubmittals in same form and number of copies as initial submittal.

1. Note date and content of previous submittal.

2. Note date and content of revision in label or title block and clearly indicate extent of revision.

3. Resubmit submittals until they are marked with approval notation from Contracting

Officer’s action stamp.

4. The contractor is allowed (2) resubmittals for any one item or group of related items for a total of (3) reviews of any given item or group of items. If at that time the contractor has not provided the required, requested information, the Government shall be allowed a credit for additional review time and associated costs.

H. Distribution: Furnish copies of final submittals to manufacturers, subcontractors, suppliers, fabricators, installers, authorities having jurisdiction, and others as necessary for performance of construction activities. Show distribution on transmittal forms.

I. Use for Construction: Retain complete copies of submittals on Project site. Use only final action submittals that are marked with approval notation from Contracting Officer’s action stamp.

COMPLEX VISITOR CENTER APRIL 30, 2020

SUBMITTAL PROCEDURES 013300 - 3

PART 2 - PRODUCTS

2.1 SUBMITTAL PROCEDURES

A. General Electronic Submittal Procedure Requirements:

1. Submit electronic submittals via email as PDF electronic files.

2. Contracting Officer’s Representative, through the Contracting Officer, will return annotated file by e-mail and/or standard mail. Annotate and retain one copy of file as an electronic Project record document file.

B. General Paper Submittal Procedure Requirements:

1. Action Submittals: Submit four (4) paper copies of each submittal unless otherwise indicated. Contracting Officer’s Representative through the Contracting Officer will return three (3) copies.

2. Informational Submittals: Submit three (3) paper copies of each submittal unless otherwise indicated. Contracting Officer will not return copies.

3. Certificates and Certifications Submittals: Provide a statement that includes signature of entity responsible for preparing certification. Certificates and certifications shall be signed by an officer or other individual authorized to sign documents on behalf of that entity.

a. Provide a digital signature with digital certificate on electronically-submitted certificates and certifications where indicated.

b. Provide a notarized statement on original paper copy certificates and certifications where indicated.

C. Product Data: Collect information into a single submittal for each element of construction and type of product or equipment.

1. If information must be specially prepared for submittal because standard published data are not suitable for use, submit as Shop Drawings, not as Product Data.

2. Mark each copy of each submittal to show which products and options are applicable.

3. Include the following information, as applicable:

a. Manufacturer's catalog cuts.

b. Manufacturer's product specifications.

c. Standard color charts.

d. Statement of compliance with specified referenced standards.

e. Testing by recognized testing agency.

f. Application of testing agency labels and seals.

g. Notation of coordination requirements.

h. Availability and delivery time information.

4. For equipment, include the following in addition to the above, as applicable:

a. Wiring diagrams showing factory-installed wiring.

b. Printed performance curves.

c. Operational range diagrams.

COMPLEX VISITOR CENTER APRIL 30, 2020

SUBMITTAL PROCEDURES 013300 - 4

d. Clearances required to other construction, if not indicated on accompanying Shop Drawings.

5. Submit Product Data before or concurrent with Samples.

6. Submit Product Data in the following…