12435H18R0007_SF-1442.pdf

OMB APPROVAL NO. 2700-0042

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

12435H18R0007

2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED

11 July 2018

PAGE OF PAGES

IMPORTANT - The “offer” section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

5. REQUISITION/PURCHASE REQUEST NO.

6. PROJECT NO.

7. ISSUED BY CODE 8. ADDRESS OFFER TO

USDA FOREST SERVICE-EAZ ACQUISITION MANAGEMENT

1775 CLEVELAND HWY

GAINESVILLE, GA 30501

Same as Block 7

9. FOR INFORMATION

CALL:

A. NAME

FRANCOIES MORMAN

fmorman@fs.fed.us

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

770-297-3072

SOLICITATION

NOTE: In sealed bid solicitations “offer” and “offeror” mean “bid” and “bidder.”

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

This solicitation is a 100% SMALL BUSINESS SET ASIDE.

NAICS Code: 237310 Size Standard: $36.5 Million

MULKY GAP & DIXON CREEK CULVERT REPLACEMENTS

Price Range: The Government's estimate less than $500,000.00.

BONDS ARE REQUIRED. PROPOSALS MAY BE EMAILED TO FMORMAN@FS.FED.US.

DUNS # ______________ CAGE # ____________________ Tax ID# _____________________

NOTE: Offeror must be ACTIVE in the System for Award Management (www.SAM.gov) at the time solicitations are due. Those contractors not active in SAM at the time solicitations are due will be rejected and not considered for award.

A PRE-BID SITE VISIT IS SCHEDULED. INFORMATION FOUND IN SECTION L.

11. The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 27 March 2018.

The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer. See FAR 52.211-10, Alternate 1

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If “YES,” indicate within how many calendar days after award in Item 12B.)

YES NO

12B. CALENDAR DAYS

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and 1 copies to perform the work required are due at the place specified in Item 8 by 1200 p.m. EST (hour) local time 13 AUGUST 2018. If this is a sealed bid solicitation, offers must be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror’s name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than 120 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Computer Generated

MULKY GAP & DIXON CREEK CULVERT REPLACEMENTS

12435H18R0007

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

CODE FACILITY CODE

17. The offeror agrees to perform the work at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government within calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER

(Type or print)

20B. SIGNATURE

20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT

23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( 5)

26. ADMINISTERED BY CODE 27. PAYMENT WILL BE MADE BY

See Block 7 INVOICE PROCESSING PLATFORM - IPP

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return __1__ copies to issuing office.) Contractor agrees to furnish and deliver all items or perform all work, requisitions identified on this form and any continuation sheets for the consideration slated in this contract.

The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications or incorporated by reference in or attached to this contract.

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED

TO SIGN (Type or print)

31A. NAME OF CONTRACTING OFFICER (Type or print)

EDUARDO SAVORY

30B. SIGNATURE

30C. DATE

31B. UNITED STATES OF AMERICA

BY

31C. AWARD DATE

11 JULY 2018

Computer Generated STANDARD FORM 1442 BACK (REV. 4-85)