A11_Amd_0001_Teton Canyon.pdf

226 KB Posted

Attached to
Teton Canyon Trail Bridge Replacements
Solicitation number
1240LN25R0007
Issued by

About this file

Written by GovTribe AI ·

This document is an amendment to a Request for Proposal (RFP) for the Teton Canyon Bridge project issued by the USDA Forest Service. The amendment, dated September 23, 2025, makes three key changes: 1) extends the response deadline to September 29, 2025, at 12:00 p.m. CDT, 2) updates the solicitation number from 1240LN25R0007 to 1240LN25R0008, and 3) adds a Liquidated Damages Clause (FAR 52.211-12). The liquidated damages provision specifies that the contractor will pay $160.00 for each calendar day of delay in completing the work, with damages continuing to accrue even if the government terminates the contractor's right to proceed.

View the file

Other files

File Type Posted
A11_Amd_0002_Teton Canyon.pdf PDF
A10_ RFP_Ques_Ans_Teton_Canyon_Bridge.xlsx XLSX spreadsheet
A10_Atch_3_Dwg_TreasureBridgePrefab_FINAL.pdf PDF
A10_Atch_3_TreasureBridgeSitePictures.docx DOCX document
A10_Atch_1_TetonBridges FSSS_3312025.pdf PDF
A10_Atch_3__Dwg_G-082 SHEEP BRIDGE TRAIL BRIDGE FINAL 5_23_23.pdf PDF
A10_RFP_Final_1240LN25R0008 (1).pdf PDF
A10_Atch_3_Dwg2_SheepTreasureProposalEvaluationCriteria.pdf PDF
A10_Atch_2_Schedule_Of_Items.xlsx XLSX spreadsheet
A10_Atch_3_SheepBridgePhotos.pdf PDF
A10_Atch_4_WD.pdf PDF
Show all 11

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file
Try for free Login

Text version

The file's text, extracted by GovTribe without its formatting.

United States Forest USDA Forest Service 1400 Independence Avenue, Department of Service PPS-Intermountain Branch Mailstop 1138

Agriculture

Washington, DC 20250

September 23, 2025

USDA Forest Service

Crystal Amos, Contracting Officer

PPS-Intermountain

1400 Independence Avenue, Mailstop 1138

Washington, DC 20250

Subject: Request for Proposal, 1240LN25R0008_0001, Teton Canyon Bridge

The purpose of this amendment is to:

1. Change the response date to 29 September 2025, 12:00 p.m. CDT

2. Change Box 1, SF1442, from 1240LN25R0007 to 1240LN25R0008

3. Add Liquidated Damages Clause, 52.211-12, Liquidated Damages-Construction (See Atch 1)

All other terms and conditions of this solicitation remain the same.

Sincerely, CRYSTAL AMOS

Contracting Officer

Attachments:

1. 52.211-12, Liquidated Damages

FAR 52.211-12 LIQUIDATED DAMAGES-CONSTRUCTION (SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $160.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor’s right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the

Termination clause.

(End of clause)

Caring for the Land and Serving People Printed on Recycled Paper

File details come from the government source that posted it. Updated .