General Requirements.pdf

Project 07-457957 01 March 2010

GENERAL REQUIREMENTS

Solicitation Number: 07-457957

Specification Number: 07-457957

Drawing Number: A07457957G001 (Sheet 1 through 13) (Attachment 2)

Title: Homeporting Fast Response Cutter (FRC) USCG Base

Location of the work: Miami, FL

Estimated Cost Range: $1,000,000 and $5,000,000.

Description of the work: Design and construct new and modified existing infrastructure required for Homeporting new Fast Response Cutters (FRC) at US Coast Guard Base Support Unit (BSU) Miami, Miami Beach, Florida. The scope of work includes, but is not limited to, modifications to existing and provision of new electrical, telecommunications, water, compressed air and sewer shore-tie services and provisions of new bollards and fendering based on the vessel berthing plan shown on the RFP drawings. Do the work according to this specification and as shown on the Government-approved, Contractor-originated drawings.

Time for completion: Phase I: 12/17/2010

Phase IB: 01/11/2011 Phase II: 02/25/2011 Phase IIB: 04/08/2011 Phase III: 05/13/2011

Wage Determination: FL080267 with Modification No. 1 dated 02/12/2010

Liquidated Damages/Insurance/Bonds: Liquidated damages of $830.00 per day will be assessed, if necessary, in accordance with Section H.11 of the contract. Liquidated Damages will be assessed based on the project’s final completion date. Please review Section H.7 of the contract for insurance requirements and Section L.1 of the contract for performance and payment bond requirements.

Utilities: Government Furnished Property: Not Applicable.

Price Proposal: Submit attached Price Proposal Form along with a complete cost breakdown (labor, materials, equipment, subcontractor cost breakdowns, and mark-ups).

Proposal Acceptance Period: 30 Days from proposal due date.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) ALTERNATE I (FEB

1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed and

(b) Attend a mandatory pre-proposal meeting at FDCC on March 15, 2010 at 10:00 am.

(c) Attend a pre-proposal mandatory site visit which will be scheduled during the March 15, 2010 pre-proposal meeting at FDCC.

Authorized Representatives of the Contracting Officer

___Eric Tipping_____ is the representative of the Contracting Officer during the Design Phase for the purpose of monitoring the contractor's performance to ensure that all of the technical requirements under the contract are met by the delivery date or within the period of performance, and at the price or within the estimated cost stipulated in the contract.

___Steve Allen__ is the Contracting Officer's Technical Representative for the purpose of day to day technical administration/inspection of all work under the contract. This includes, but is not limited to, administration of progress, approval of submittals, final inspection and providing technical assistance when required. The contractor is cautioned that in no instance is the above named person authorized to approve any changes which will involve the quantity, quality, price or performance of the contract.

__** To be determined **___ is the representative of the Contracting Officer for the purpose of inspection of work under the contract. The Contractor is cautioned that in no instance is the above named person authorized to approve any changes, which will involve the quantity, quality, price, or performance of the contract.

__Sarah Rall_________ of the Contracting Division, U.S. Coast Guard, Facilities Design & Construction Center, 5505 Robin Hood Road, Suite K, Norfolk, VA 23513-2431, telephone number (757) 852-3407 , is the Contracting Officer's Administrator/Negotiator for this contract. All matters related to performance of this contract shall be coordinated through her.

1. BASE BID ITEM

Provide all services and materials necessary to design and construct new and modified existing infrastructure required for Homeporting new Fast Response Cutters (FRC) at U.S. Coast Guard Base Support Unit (BSU) Miami, Miami Beach, Florida. All work shall be performed in accordance with Specification No. 07-457957 and Drawing No. A07457957G001, Sheets 1 through 13.

ONE JOB $

AMENDMENTS ACKNOWLEDGED:

Amendment No. Date Amendment No. Date

Offeror:

Address:

Phone:

Fax:

Email:

Name:

Signed:

Date: