Nokia Network Services Platform
Closed State & local contract opportunity Posted
- Solicitation number
- ITB-06854
- State
- Florida
- Responses due
Opportunity facts
- Jurisdiction
- UNSPSC code
Opportunity details come from vendor.myfloridamarketplace.com. Updated .
About this opportunity
The Florida Department of Transportation (FDOT) is seeking competitive sealed bids, proposals, or replies for the procurement of a Nokia Network Services Platform upgrade. The solicitation requires bidders to furnish and install new server hardware, operating system, and application software to replace end-of-life and end-of-support servers at two FDOT sites in Sanford and Plantation, Florida. The new servers must be capable of running the Nokia Services Platform (NSP) Release 23.4 in a virtualized environment. The contractor will be responsible for migrating existing data, configuring network interfaces, and implementing a workaround to support backup of certain network elements. Bids are due on November 16, 2023 by 9:00 AM local time, with a public bid opening at 11:00 AM the same day. The contract term is anticipated to begin upon execution and be effective for 12 months, with a 5-year hardware maintenance and software subscription plan.
Minority Business Enterprise (MBE) participation is encouraged but not required. Liquidated damages of $100 per day will be assessed for failure to complete the work by the designated completion date. The contractor will be required to maintain the new NSP servers under FDOT's existing maintenance and software subscription plan with Nokia. No pre-bid conference will be held, and bidders must be registered in the State of Florida's MyFloridaMarketplace system. The contract will be awarded to the successful bidder as a lump sum contract, with the successful bidder required to provide a performance bond in the full amount of the bid.
Opportunity text
Thursday, November 16, 2023 Addendum 2, Revised Timeline, Revised Scope of Services and Questions and Answers Part 3 posted.
*************************************************************************************************************************************************
Tuesday, November 14, 2023 Questions and Answers Part 2
*********************************************************************************************************************************************
Wednesday, November 8, 2023 - Addendum 1, Revised Timeline and Revised Scope of Services posted.
*********************************************************************************************************************************************
The Florida Department of Transportation requests competitive sealed bids, proposals, or replies (as indicated in the solicitation) for the procurement of:
Nokia Network Services Platform
All Bidders, Proposers, and Respondents must be registered in the State of Florida's MyFloridaMarketplace system. All prospective bidders, proposers, and respondents that are not registered, should go to https://vendor.myfloridamarketplace.com/ to complete on-line registration, or call 1-866-352-3776 for assisted registration.
NOTE: In accordance with section 287.057(23), Florida Statutes, respondentsto this solicitation or persons acting on their behalf may not contact, between the release of the solicitation and the end of the 72 hour period following the agency posting the notice of intended award, excluding Saturdays, Sundays, and state holidays, any employee or officer of the executive or legilative branch concerning any aspect of this solicitation, except in writing to the procurement officer or as provided in the solicitation documents. Violation of this provision may be grounds for rejecting a response.
Public Meeting Notices and Meeting Agendas: Notice of public meetings scheduled for this solicitation is provided in the timeline of the attached solicitation, with agendas for the public meetings.
INSPECTOR GENERAL: The contractor/consultant/vendor agrees to comply with s.20.055(5), Florida Statutes, and to incorporate in all subcontracts the obligation to comply with s.20.055(5), Florida Statutes.
For services contracts, all out-of-State corporations, out-of-State limited liability companies, and out-of-State limited partnerships must be authorized to do business in the State of Florida. For authorization, contact:
Florida Department of State
Tallahassee, Florida 32399
(850) 245-6051
Files
| File | Type | Posted |
|---|---|---|
| Addendum 2.pdf | ||
| 9034 Questions and Answers Part 2.pdf | ||
| Addendum 1.pdf | ||
| Solicitation Document 9034.pdf |
On GovTribe
Work this opportunity
- Track it in your pipeline
- Similar opportunities
- Ask GovTribe AI about this opportunity