Two Step Design-Build for a 20, 000 square foot space related site at Vandenberg AFB

This project is a two-phase design-build solicitation. The solicitation criteria relies upon industry standards, where allowable, to afford the offeror a degree on design flexibility while meeting certain specific project requirements. The successful Contractor must design and construct complete and useable facilities, as described in the RFP documents. One solicitation will be issued covering both phases. Phase‐One is the pre‐selection phase (this phase does not include the submission of a price proposal). Evaluation factors under Phase‐One may consist of the following: Past Performance on projects of similar nature (similar or greater scope and complexity and technical sophistication) will be a major consideration; Specialized Experience; Capability to Perform; Technical Approach, Key Personnel, including AE and Construction members. Proposals will be evaluated in Phase‐One to determine which offerors will submit proposals for Phase‐ Two and an amendment will be issued to those selected offerors (maximum of five). The detailed project performance requirements for this project will be included in the Requests for Proposals (RFP) package (Phase‐Two). Evaluation factors for Phase‐Two may consist of the following: Design Narrative (Architectural; HVAC System; Structural); Ability to schedule/execute work on multiple projects/buildings simultaneously in an expedited timeframe and limited workspace; Environmental Compliance; Sustainable Design; Quality of Proposal Submittal; and a Price Proposal. Phase‐Two proposal ratings alone will be used to determine the most advantageous proposal to the Government. Basis of award is Best Value quote mark Trade‐off. quote mark Award of the Design‐Build contract will be made to one of the five firms, which, in the judgment of the Contracting Officer, provides the best combination of design features and cost/price reasonableness. In making this determination, all evaluation factors other than cost or price, when combined, are approximately equal to cost or price. The Government reserves the right to make award to other than the lowest price offeror, price and other factors considered.

The estimated cost range is $10,000,000.00 - $25,000,000.00

Period of performance is not to exceed 730 calendar days.

The solicitation will be available on or about February 12th, 2016. Plans and specifications will not be provided in hard paper copy. The solicitation and all amendments for this Request for Proposals will be posted on www.fbo.gov

All offerors are advised that this project may be delayed, cancelled or revised at any time during the solicitation,selection, evaluation, negotiation and/or final award process.

It is the responsibility of the contractor to check www.fbo.gov frequently for any amendments or changes to the solicitation. The Government is not responsible for any loss of internet connectivity or for an offerors inability to access the documents posted at the referenced website. No CDs or hard copies will be made available.

If you would like to list your firm so that others can see you are an interested vendor, you must click the Add Me to Interested Vendors button in the listing for this solicitation on www.fbo.gov

This project is a two-phase design-build solicitation. The solicitation criteria relies upon industry standards, where allowable, to afford the offeror a degree on design flexibility while meeting certain specific project requirements. The successful Contractor must design and construct complete and useable facilities, as described in the RFP documents. One solicitation will be issued covering both phases. Phase‐One is the pre‐selection phase (this phase does not include the submission of a price proposal). Evaluation factors under Phase‐One may consist of the following: Past Performance on projects of similar nature (similar or greater scope and complexity and technical sophistication) will be a major consideration; Specialized Experience; Capability to Perform; Technical Approach, Key Personnel, including AE and Construction members. Proposals will be evaluated in Phase‐One to determine which offerors will submit proposals for Phase‐ Two and an amendment will be issued to those selected offerors (maximum of five). The detailed project performance requirements for this project will be included in the Requests for Proposals (RFP) package (Phase‐Two). Evaluation factors for Phase‐Two may consist of the following: Design Narrative (Architectural; HVAC System; Structural); Ability to schedule/execute work on multiple projects/buildings simultaneously in an expedited timeframe and limited workspace; Environmental Compliance; Sustainable Design; Quality of Proposal Submittal; and a Price Proposal. Phase‐Two proposal ratings alone will be used to determine the most advantageous proposal to the Government. Basis of award is Best Value quote mark Trade‐off. quote mark Award of the Design‐Build contract will be made to one of the five firms, which, in the judgment of the Contracting Officer, provides the best combination of design features and cost/price reasonableness. In making this determination, all evaluation factors other than cost or price, when combined, are approximately equal to cost or price. The Government reserves the right to make award to other than the lowest price offeror, price and other factors considered.

The estimated cost range is $10,000,000.00 - $25,000,000.00

Period of performance is not to exceed 730 calendar days.

The solicitation will be available on or about January 15, 2015. Plans and specifications will not be provided in hard paper copy. The solicitation and all amendments for this Request for Proposals will be posted on www.fbo.gov

All offerors are advised that this project may be delayed, cancelled or revised at any time during the solicitation,selection, evaluation, negotiation and/or final award process.

It is the responsibility of the contractor to check www.fbo.gov frequently for any amendments or changes to the solicitation. The Government is not responsible for any loss of internet connectivity or for an offerors inability to access the documents posted at the referenced website. No CDs or hard copies will be made available.

If you would like to list your firm so that others can see you are an interested vendor, you must click the Add Me to Interested Vendors button in the listing for this solicitation on www.fbo.gov

This project is a two-phase design-build solicitation. The solicitation criteria relies upon industry standards, where allowable, to afford the offeror a degree on design flexibility while meeting certain specific project requirements. The successful Contractor must design and construct complete and useable facilities, as described in the RFP documents. One solicitation will be issued covering both phases. Phase‐One is the pre‐selection phase (this phase does not include the submission of a price proposal). Evaluation factors under Phase‐One may consist of the following: Past Performance on projects of similar nature (similar or greater scope and complexity and technical sophistication) will be a major consideration; Specialized Experience; Capability to Perform; Technical Approach, Key Personnel, including AE and Construction members. Proposals will be evaluated in Phase‐One to determine which offerors will submit proposals for Phase‐ Two and an amendment will be issued to those selected offerors (maximum of five). The detailed project performance requirements for this project will be included in the Requests for Proposals (RFP) package (Phase‐Two). Evaluation factors for Phase‐Two may consist of the following: Design Narrative (Architectural; HVAC System; Structural); Ability to schedule/execute work on multiple projects/buildings simultaneously in an expedited timeframe and limited workspace; Environmental Compliance; Sustainable Design; Quality of Proposal Submittal; and a Price Proposal. Phase‐Two proposal ratings alone will be used to determine the most advantageous proposal to the Government. Basis of award is Best Value quote mark Trade‐off. quote mark Award of the Design‐Build contract will be made to one of the five firms, which, in the judgment of the Contracting Officer, provides the best combination of design features and cost/price reasonableness. In making this determination, all evaluation factors other than cost or price, when combined, are approximately equal to cost or price. The Government reserves the right to make award to other than the lowest price offeror, price and other factors considered.

The estimated cost range is $10,000,000.00 - $30,000,000.00

Period of performance is not to exceed 730 calendar days.

The solicitation will be available on or about January 15, 2015. Plans and specifications will not be provided in hard paper copy. The solicitation and all amendments for this Request for Proposals will be posted on www.fbo.gov

All offerors are advised that this project may be delayed, cancelled or revised at any time during the solicitation,selection, evaluation, negotiation and/or final award process.

It is the responsibility of the contractor to check www.fbo.gov frequently for any amendments or changes to the solicitation. The Government is not responsible for any loss of internet connectivity or for an offerors inability to access the documents posted at the referenced website. No CDs or hard copies will be made available.

If you would like to list your firm so that others can see you are an interested vendor, you must click the Add Me to Interested Vendors button in the listing for this solicitation on www.fbo.gov