Retardant On-Demand

February 21, 2025 - Amendment 005 (Update to CY 2025 Annual Amendment) - Attached

Amendment 005 is issued to the Retardant On-Demand solicitation, updating the solicitation and relevant clauses and provisions for the calendar year 2025. All Offerors must submit a completed and signed SF-1449, completed Section B Schedule of Items, and provide responses to Section E.7. Quotation format is specified in Section E Solicitation Provisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A005 022125.pdf including the revised due date of the solicitation to 03/03/2025 @ 1430 MT.

Quotations may be submitted at any time prior to the due date and the Government reserves the right to award Blanket Purchase Agreements at any time, provided the Offeror meets all requirements specified and pricing is determined to be considered fair and reasonable. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2025. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any Offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

+++++++++++++++++++++++++++++++++++++++++++++++++

January 5, 2024 - Amendment 004 (Update to CY 2024 Annual Amendment) - Issued

Amendment 004 is issued to the Retardant On-Demand solicitation, updating the due date of the solicitation to 01/15/2024 @ 1430 MT. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A004 010524.pdf.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

+++++++++++++++++++++++++++++++++++++++++++++++++

December 6, 2023 - Amendment 003 (CY 2024 Annual Amendment) - Issued

Amendment 003 is issued to the Retardant On-Demand solicitation, updating the solicitation and relevant clauses and provisions for the calendar year 2024. All Offerors must submit a completed and signed SF-1449, completed Section B Schedule of Items, and provide responses to Section E.7. Quotation format is specified in Section E Solicitation Provisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A003 120523.pdf.

Quotations may be submitted at any time prior to the due date and the Government reserves the right to award Blanket Purchase Agreements at any time, provided the Offeror meets all requirements specified and pricing is determined to be considered fair and reasonable. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2024. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any Offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++

December 29, 2022 - Amendment 002 (CY 2023 Annual Amendment) - Issued

Amendment 002 is issued to the Retardant On-Demand solicitation, updating the solicitation and relevant clauses and provisions for the calendar year 2023. All Offerors must submit a completed and signed SF-1449, completed Section B Schedule of Items, and provide responses to Section E.7. Quotation format is specified in Section E Solicitation Provisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A002 122222.pdf.

Quotations may be submitted at any time prior to the due date and the Government reserves the right to award Blanket Purchase Agreements at any time, provided the Offeror meets all requirements specified and pricing is determined to be considered fair and reasonable. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2023. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any Offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++

June 15, 2022 - Amendment 001 - Issued

Amendment 001 is issued to the Retardant On-Demand solicitation that revises the specification to address the addition of the Ground Applied Unit requirement in Exhibit D.1. Minor updates to Schedule B address these revisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A001 061522.pdf.
Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++

Combined synopsis and solicitation in accordance with FAR 13.105 (b).

The USDA Forest Service continues to have a need to obtain Long-Term Fire Retardant (LTFR) products and the ancillary on-site services to store, mix and load LTFR products onto Government supplied fixed wing airtankers (AT), very large airtankers (VLAT), single engine airtankers (SEAT), helicopters (H) and ground tenders (GT) at various locations throughout the U.S. This procurement is for all Offerors capable of supplying fully qualified Long-Term Fire Retardants in accordance with US Department of Agriculture Forest Service Specification 5100-304d Long-Term Retardant, Wildland Firefighting and currently on the Long-Term Retardant for Wildland Fire Management Qualified Products List (QPL) located at https://www.fs.fed.us/rm/fire/wfcs/documents/2021-1005_qpl_ret.pdf.

This acquisition is a follow-on acquisition from the previous FOB Origin Long-Term Fire Retardant contract and the Mobile Retardant Bases agreements and is being solicited as a Small Business set-aside, limited to companies that meet the small business size standard set forth by the North American Industry Classification System (NAICS) code 325998 (fire retardant chemical preparations manufacturing) with a size standard of 500 employees. This acquisition intends to establish Blanket Purchase Agreements (BPA) for the 2022 Calendar Year period of supply and performance. BPAs established will be commercial, multiple award, under the authority of Federal Acquisition Regulations (FAR), part 12, Acquisition of Commercial Items in conjunction with FAR part 13, Simplified Acquisition Procedures. The dollar limitation for any individual order is the Simplified Acquisition Threshold (SAT) ($7.5M IAW Agency procedure). This procurement is available to any existing or new Offerors proposing for the first time. In this manner, existing Contractors will be provided the annual opportunity to update their pricing and new Offerors will be allowed to provide their offer for consideration.

All Offerors must provide their offers as directed in Section E of the solicitation and pricing in the 2022 Schedule of Items in Section B. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2022. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard – larry.robillard@usda.gov) with any questions you may have.

January 5, 2024 - Amendment 004 (Update to CY 2024 Annual Amendment) - Issued

Amendment 004 is issued to the Retardant On-Demand solicitation, updating the due date of the solicitation to 01/15/2024 @ 1430 MT. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A004 010524.pdf.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

+++++++++++++++++++++++++++++++++++++++++++++++++

December 6, 2023 - Amendment 003 (CY 2024 Annual Amendment) - Issued

Amendment 003 is issued to the Retardant On-Demand solicitation, updating the solicitation and relevant clauses and provisions for the calendar year 2024. All Offerors must submit a completed and signed SF-1449, completed Section B Schedule of Items, and provide responses to Section E.7. Quotation format is specified in Section E Solicitation Provisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A003 120523.pdf.

Quotations may be submitted at any time prior to the due date and the Government reserves the right to award Blanket Purchase Agreements at any time, provided the Offeror meets all requirements specified and pricing is determined to be considered fair and reasonable. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2024. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any Offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++

December 29, 2022 - Amendment 002 (CY 2023 Annual Amendment) - Issued

Amendment 002 is issued to the Retardant On-Demand solicitation, updating the solicitation and relevant clauses and provisions for the calendar year 2023. All Offerors must submit a completed and signed SF-1449, completed Section B Schedule of Items, and provide responses to Section E.7. Quotation format is specified in Section E Solicitation Provisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A002 122222.pdf.

Quotations may be submitted at any time prior to the due date and the Government reserves the right to award Blanket Purchase Agreements at any time, provided the Offeror meets all requirements specified and pricing is determined to be considered fair and reasonable. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2023. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any Offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++

June 15, 2022 - Amendment 001 - Issued

Amendment 001 is issued to the Retardant On-Demand solicitation that revises the specification to address the addition of the Ground Applied Unit requirement in Exhibit D.1. Minor updates to Schedule B address these revisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A001 061522.pdf.
Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++

Combined synopsis and solicitation in accordance with FAR 13.105 (b).

The USDA Forest Service continues to have a need to obtain Long-Term Fire Retardant (LTFR) products and the ancillary on-site services to store, mix and load LTFR products onto Government supplied fixed wing airtankers (AT), very large airtankers (VLAT), single engine airtankers (SEAT), helicopters (H) and ground tenders (GT) at various locations throughout the U.S. This procurement is for all Offerors capable of supplying fully qualified Long-Term Fire Retardants in accordance with US Department of Agriculture Forest Service Specification 5100-304d Long-Term Retardant, Wildland Firefighting and currently on the Long-Term Retardant for Wildland Fire Management Qualified Products List (QPL) located at https://www.fs.fed.us/rm/fire/wfcs/documents/2021-1005_qpl_ret.pdf.

This acquisition is a follow-on acquisition from the previous FOB Origin Long-Term Fire Retardant contract and the Mobile Retardant Bases agreements and is being solicited as a Small Business set-aside, limited to companies that meet the small business size standard set forth by the North American Industry Classification System (NAICS) code 325998 (fire retardant chemical preparations manufacturing) with a size standard of 500 employees. This acquisition intends to establish Blanket Purchase Agreements (BPA) for the 2022 Calendar Year period of supply and performance. BPAs established will be commercial, multiple award, under the authority of Federal Acquisition Regulations (FAR), part 12, Acquisition of Commercial Items in conjunction with FAR part 13, Simplified Acquisition Procedures. The dollar limitation for any individual order is the Simplified Acquisition Threshold (SAT) ($7.5M IAW Agency procedure). This procurement is available to any existing or new Offerors proposing for the first time. In this manner, existing Contractors will be provided the annual opportunity to update their pricing and new Offerors will be allowed to provide their offer for consideration.

All Offerors must provide their offers as directed in Section E of the solicitation and pricing in the 2022 Schedule of Items in Section B. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2022. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard – larry.robillard@usda.gov) with any questions you may have.

December 6, 2023 - Amendment 003 (CY 2024 Annual Amendment) - Issued

Amendment 003 is issued to the Retardant On-Demand solicitation, updating the solicitation and relevant clauses and provisions for the calendar year 2024. All Offerors must submit a completed and signed SF-1449, completed Section B Schedule of Items, and provide responses to Section E.7. Quotation format is specified in Section E Solicitation Provisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A003 120523.pdf.

Quotations may be submitted at any time prior to the due date and the Government reserves the right to award Blanket Purchase Agreements at any time, provided the Offeror meets all requirements specified and pricing is determined to be considered fair and reasonable. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2024. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any Offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++

December 29, 2022 - Amendment 002 (CY 2023 Annual Amendment) - Issued

Amendment 002 is issued to the Retardant On-Demand solicitation, updating the solicitation and relevant clauses and provisions for the calendar year 2023. All Offerors must submit a completed and signed SF-1449, completed Section B Schedule of Items, and provide responses to Section E.7. Quotation format is specified in Section E Solicitation Provisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A002 122222.pdf.

Quotations may be submitted at any time prior to the due date and the Government reserves the right to award Blanket Purchase Agreements at any time, provided the Offeror meets all requirements specified and pricing is determined to be considered fair and reasonable. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2023. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any Offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++

June 15, 2022 - Amendment 001 - Issued

Amendment 001 is issued to the Retardant On-Demand solicitation that revises the specification to address the addition of the Ground Applied Unit requirement in Exhibit D.1. Minor updates to Schedule B address these revisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A001 061522.pdf.
Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++

Combined synopsis and solicitation in accordance with FAR 13.105 (b).

The USDA Forest Service continues to have a need to obtain Long-Term Fire Retardant (LTFR) products and the ancillary on-site services to store, mix and load LTFR products onto Government supplied fixed wing airtankers (AT), very large airtankers (VLAT), single engine airtankers (SEAT), helicopters (H) and ground tenders (GT) at various locations throughout the U.S. This procurement is for all Offerors capable of supplying fully qualified Long-Term Fire Retardants in accordance with US Department of Agriculture Forest Service Specification 5100-304d Long-Term Retardant, Wildland Firefighting and currently on the Long-Term Retardant for Wildland Fire Management Qualified Products List (QPL) located at https://www.fs.fed.us/rm/fire/wfcs/documents/2021-1005_qpl_ret.pdf.

This acquisition is a follow-on acquisition from the previous FOB Origin Long-Term Fire Retardant contract and the Mobile Retardant Bases agreements and is being solicited as a Small Business set-aside, limited to companies that meet the small business size standard set forth by the North American Industry Classification System (NAICS) code 325998 (fire retardant chemical preparations manufacturing) with a size standard of 500 employees. This acquisition intends to establish Blanket Purchase Agreements (BPA) for the 2022 Calendar Year period of supply and performance. BPAs established will be commercial, multiple award, under the authority of Federal Acquisition Regulations (FAR), part 12, Acquisition of Commercial Items in conjunction with FAR part 13, Simplified Acquisition Procedures. The dollar limitation for any individual order is the Simplified Acquisition Threshold (SAT) ($7.5M IAW Agency procedure). This procurement is available to any existing or new Offerors proposing for the first time. In this manner, existing Contractors will be provided the annual opportunity to update their pricing and new Offerors will be allowed to provide their offer for consideration.

All Offerors must provide their offers as directed in Section E of the solicitation and pricing in the 2022 Schedule of Items in Section B. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2022. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard – larry.robillard@usda.gov) with any questions you may have.

December 29, 2022 - Amendment 002 (CY 2023 Annual Amendment) - Issued

Amendment 002 is issued to the Retardant On-Demand solicitation, updating the solicitation and relevant clauses and provisions for the calendar year 2023. All Offerors must submit a completed and signed SF-1449, completed Section B Schedule of Items, and provide responses to Section E.7. Quotation format is specified in Section E Solicitation Provisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A002 122222.pdf.

Quotations may be submitted at any time prior to the due date and the Government reserves the right to award Blanket Purchase Agreements at any time, provided the Offeror meets all requirements specified and pricing is determined to be considered fair and reasonable. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2023. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any Offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++

June 15, 2022 - Amendment 001 - Issued

Amendment 001 is issued to the Retardant On-Demand solicitation that revises the specification to address the addition of the Ground Applied Unit requirement in Exhibit D.1. Minor updates to Schedule B address these revisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A001 061522.pdf.
Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++

Combined synopsis and solicitation in accordance with FAR 13.105 (b).

The USDA Forest Service continues to have a need to obtain Long-Term Fire Retardant (LTFR) products and the ancillary on-site services to store, mix and load LTFR products onto Government supplied fixed wing airtankers (AT), very large airtankers (VLAT), single engine airtankers (SEAT), helicopters (H) and ground tenders (GT) at various locations throughout the U.S. This procurement is for all Offerors capable of supplying fully qualified Long-Term Fire Retardants in accordance with US Department of Agriculture Forest Service Specification 5100-304d Long-Term Retardant, Wildland Firefighting and currently on the Long-Term Retardant for Wildland Fire Management Qualified Products List (QPL) located at https://www.fs.fed.us/rm/fire/wfcs/documents/2021-1005_qpl_ret.pdf.

This acquisition is a follow-on acquisition from the previous FOB Origin Long-Term Fire Retardant contract and the Mobile Retardant Bases agreements and is being solicited as a Small Business set-aside, limited to companies that meet the small business size standard set forth by the North American Industry Classification System (NAICS) code 325998 (fire retardant chemical preparations manufacturing) with a size standard of 500 employees. This acquisition intends to establish Blanket Purchase Agreements (BPA) for the 2022 Calendar Year period of supply and performance. BPAs established will be commercial, multiple award, under the authority of Federal Acquisition Regulations (FAR), part 12, Acquisition of Commercial Items in conjunction with FAR part 13, Simplified Acquisition Procedures. The dollar limitation for any individual order is the Simplified Acquisition Threshold (SAT) ($7.5M IAW Agency procedure). This procurement is available to any existing or new Offerors proposing for the first time. In this manner, existing Contractors will be provided the annual opportunity to update their pricing and new Offerors will be allowed to provide their offer for consideration.

All Offerors must provide their offers as directed in Section E of the solicitation and pricing in the 2022 Schedule of Items in Section B. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2022. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard – larry.robillard@usda.gov) with any questions you may have.

June 15, 2022 - Amendment 001 - Issued

Amendment 001 is issued to the Retardant On-Demand solicitation that revises the specification to address the addition of the Ground Applied Unit requirement in Exhibit D.1. Minor updates to Schedule B address these revisions. Please see the attached amended solicitation - Solicitation 1202SC21Q0004 A001 061522.pdf.
Please email the Contracting Officer (Larry Robillard - larry.robillard@usda.gov) with any questions you may have.

++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++++

Combined synopsis and solicitation in accordance with FAR 13.105 (b).

The USDA Forest Service continues to have a need to obtain Long-Term Fire Retardant (LTFR) products and the ancillary on-site services to store, mix and load LTFR products onto Government supplied fixed wing airtankers (AT), very large airtankers (VLAT), single engine airtankers (SEAT), helicopters (H) and ground tenders (GT) at various locations throughout the U.S. This procurement is for all Offerors capable of supplying fully qualified Long-Term Fire Retardants in accordance with US Department of Agriculture Forest Service Specification 5100-304d Long-Term Retardant, Wildland Firefighting and currently on the Long-Term Retardant for Wildland Fire Management Qualified Products List (QPL) located at https://www.fs.fed.us/rm/fire/wfcs/documents/2021-1005_qpl_ret.pdf.

This acquisition is a follow-on acquisition from the previous FOB Origin Long-Term Fire Retardant contract and the Mobile Retardant Bases agreements and is being solicited as a Small Business set-aside, limited to companies that meet the small business size standard set forth by the North American Industry Classification System (NAICS) code 325998 (fire retardant chemical preparations manufacturing) with a size standard of 500 employees. This acquisition intends to establish Blanket Purchase Agreements (BPA) for the 2022 Calendar Year period of supply and performance. BPAs established will be commercial, multiple award, under the authority of Federal Acquisition Regulations (FAR), part 12, Acquisition of Commercial Items in conjunction with FAR part 13, Simplified Acquisition Procedures. The dollar limitation for any individual order is the Simplified Acquisition Threshold (SAT) ($7.5M IAW Agency procedure). This procurement is available to any existing or new Offerors proposing for the first time. In this manner, existing Contractors will be provided the annual opportunity to update their pricing and new Offerors will be allowed to provide their offer for consideration.

All Offerors must provide their offers as directed in Section E of the solicitation and pricing in the 2022 Schedule of Items in Section B. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2022. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard – larry.robillard@usda.gov) with any questions you may have.

Combined synopsis and solicitation in accordance with FAR 13.105 (b).

The USDA Forest Service continues to have a need to obtain Long-Term Fire Retardant (LTFR) products and the ancillary on-site services to store, mix and load LTFR products onto Government supplied fixed wing airtankers (AT), very large airtankers (VLAT), single engine airtankers (SEAT), helicopters (H) and ground tenders (GT) at various locations throughout the U.S. This procurement is for all Offerors capable of supplying fully qualified Long-Term Fire Retardants in accordance with US Department of Agriculture Forest Service Specification 5100-304d Long-Term Retardant, Wildland Firefighting and currently on the Long-Term Retardant for Wildland Fire Management Qualified Products List (QPL) located at https://www.fs.fed.us/rm/fire/wfcs/documents/2021-1005_qpl_ret.pdf.

This acquisition is a follow-on acquisition from the previous FOB Origin Long-Term Fire Retardant contract and the Mobile Retardant Bases agreements and is being solicited as a Small Business set-aside, limited to companies that meet the small business size standard set forth by the North American Industry Classification System (NAICS) code 325998 (fire retardant chemical preparations manufacturing) with a size standard of 500 employees. This acquisition intends to establish Blanket Purchase Agreements (BPA) for the 2022 Calendar Year period of supply and performance. BPAs established will be commercial, multiple award, under the authority of Federal Acquisition Regulations (FAR), part 12, Acquisition of Commercial Items in conjunction with FAR part 13, Simplified Acquisition Procedures. The dollar limitation for any individual order is the Simplified Acquisition Threshold (SAT) ($7.5M IAW Agency procedure). This procurement is available to any existing or new Offerors proposing for the first time. In this manner, existing Contractors will be provided the annual opportunity to update their pricing and new Offerors will be allowed to provide their offer for consideration.

All Offerors must provide their offers as directed in Section E of the solicitation and pricing in the 2022 Schedule of Items in Section B. The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of each current year. The BPA period of performance will be from date of established BPA to 31 December 2022. All responsible Offerors and suitable offers will be considered by the USDA Forest Service. All Offerors must have an active registration in SAM.GOV at the time of submission in order to be considered. Any offeror that does not have an active SAM.GOV registration will be rejected as non-responsive.

Please email the Contracting Officer (Larry Robillard – larry.robillard@usda.gov) with any questions you may have.