Solicitation 1202SC21Q0004 A005 022125.pdf

OFFEROR’S COPY

(Ref. 48 CFR 1) Issuing Office:

U.S. Forest Service, Contracting National Interagency Fire Center 3833 S Development Ave, MS 1100 Boise, ID 83705-5354

This solicitation can be downloaded from the following Internet site: https://www.sam.gov

Offers Are Solicited For: Retardant On-Demand (ROD) Solicitation No:

1202SC21Q0004

Amendment 001 Amendment 002 Amendment 003 Amendment 004 Amendment 005

Issued Date:

3/11/2022 6/15/2022

12/22/2022 12/5/2023 1/5/2024

2/21/2025

IMPORTANT – NOTICE TO OFFEROR

Offers are due on 3/3/2025 @ 1430 Mountain Time. Quotes may be submitted at any time prior to the due date and the Government reserves the right to award Blanket Purchase Agreements at any time, provided the Offeror is determined to meet all requirements specified and pricing is determined to be considered fair and reasonable.

New Offerors shall submit the following items via email in response to this solicitation:

a. SF-1449, block 17a and blocks 30a-30c: Complete, date, and sign;

b. Fill in the appropriate information requested for Section B;

c. Provide quotation in the format required by Section E.3 of the solicitation;

d. Provide your responses to Section E.6 of the solicitation and FAR 52.223-1 Biobased Product

Certification (MAY 2024);

e. Solicitation package shall be EMAILED only in the following format:

i. To: Retardant On-Demand by email to: larry.robillard@usda.gov;

ii. Email Subject Line: Solicitation 1202SC21Q0004-Company Name-ROD-Submittal Date;

iii. File Name Configuration: Company Name–ROD-Business/Technical–Submittal Date.

Offerors w/ current BPAs shall submit the following items via email in response to this solicitation:

a. SF-1449, block 17a and blocks 30a-30c: Complete, date, and sign;

b. Fill in the appropriate information requested for Schedule of Items in Section B;

c. Provide your responses to Section E.6 of the solicitation and FAR 52.223-1 Biobased Product

Certification (MAY 2024).

Offerors may contact Larry Robillard for information about this solicitation at larry.robillard@usda.gov or 208-407- 6003.

“The policy of the United States Department of Agriculture Forest Service prohibits discrimination on the basis of race, color, national origin, age, religion, sex, disability, family status, and/or political affiliation.” Persons believing they have been discriminated against in any Forest Service related activity should write to: Chief, Forest Service, USDA, P. O. Box 96090, Washington, DC 20090-6090.

Previous editions of this form are obsolete. FS-6300-44 (11/79) https://www.sam.gov/ mailto:larry.robillard@usda.gov mailto:larry.robillard@usda.gov

Solicitation No. 1202SC21Q0004 A005 USDA Forest Service Retardant On-Demand National Office

TABLE OF CONTENTS

i

SECTION A - SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

STANDARD FORM SF-1449

SECTION B – SCHEDULE OF SUPPLIES/SERVICES

B.1 GENERAL INFORMATION

B.2 SCHEDULE OF ITEMS – PRICING

SECTION C – CONTRACT CLAUSES

C.1 52.212-4 - CONTRACT TERMS AND CONDITIONS - COMMERCIAL PRODUCT AND COMMERCIAL

SERVICES (DEVIATION 2017-1) (NOV 2023)

C.2 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS -- COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (JAN 2025) ... 11

C.3 CONTRACT CLAUSES INCORPORATED BY REFERENCE (FAR 52.252-2) (FEB 1998)

C.4 AUTHORIZED DEVIATIONS IN CLAUSES (FAR 52.252-6) (NOV 2020)

C.5 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR EMPLOYEES

C.6 PERMITS AND RESPONSIBILITIES (FAR 52.236-7) (NOV 1991)

C.7 CONFIDENTIALITY OF INFORMATION

C.8 INSURANCE COVERAGE

C.9 USE OF PREMISES

C.10 INSPECTION AND ACCEPTANCE

C.11 AGREEMENT PERIOD

C.12 AGREEMENT CANCELLATION

C.13 CLAIM SETTLEMENT AUTHORITY

C.14 EXTENT OF OBLIGATION

C.15 GOVERNMENT LIABILITY

C.16 FOREST SERVICE HARASSMENT FREE WORKPLACE POLICY

C.17 INCIDENT BEHAVIOR

C.18 PERSONNEL CONDUCT

C.19 NOTICE OF CONTRACTOR PERFORMANCE ASSESSMENT REPORTING SYSTEM

C.20 DELIVERY TICKETS

C.21 ORDERING, RELOCATING, REDUCING, RELEASING, REASSIGNING, AND CANCELLING. THE

FOLLOWING IS ADDED:

C.22 Addenda to 52-212-4 - PAYMENT AND INVOICES

C.23 CONTRACTOR EVALUATIONS

C.24 PRE-USE INSPECTION OF EQUIPMENT

C.25 Addenda to 52-212-4 - INSPECTIONS DURING USE

C.26 SMALL BUSINESS SUBCONTRACTING PLAN

SECTION D - LIST OF EXHIBITS

EXHIBIT D.1: RETARDANT ON DEMAND SPECIFICATIONS

EXHIBIT D.2: RETARDANT ON DEMAND (ROD) REQUEST FORM

EXHIBIT D.3: INSPECTION FORM

EXHIBIT D.4: RETARDANT ON DEMAND PERFORMANCE EVALUATION

EXHIBIT D.5: ROD DAILY PERFORMANCE SHEET

EXHIBIT D.6: LAQA SAMPLE FORM (DATED 03/01/2014)

SECTION E – SOLICITATION PROVISIONS

E.1 GENERAL INFORMATION

E.2 SIZE STANDARD AND NAICS CODE INFORMATION (AGAR 452.219-70) (SEP 2001)

E.3 52.212-1 INSTRUCTIONS TO OFFERORS – COMMERCIAL ITEMS (SEP 2023) (TAILORED)

E.4 EVALUATION – COMMERCIAL ITEMS (FAR 52.212-2) (NOV 2021)

E.5 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FAR 52.252-1) (FEB 1998)

E.6 52.212-3 - OFFEROR REPRESENTATIONS AND CERTIFICATIONS -- COMMERCIAL PRODUCTS

AND COMMERCIAL SERVICES (MAY 2024)

SOLICITATION/CONTRACT/ORDER FOR COMMERCIAL ITEMS

OFFEROR TO COMPLETE BLOCKS 12, 17, 23, 24, & 30

1. REQUISITION NUMBER

2. CONTRACT NO.

3. AWARD/EFFECTIVE

DATE

4. ORDER NUMBER

5. SOLICITATION NUMBER

1202SC21Q0004

6. SOLICITATION ISSUE

DATE

2/21/2025

7. FOR SOLICITATION

INFORMATION CALL:

a. NAME

LARRY J. ROBILLARD

b. TELEPHONE NUMBER (No collect calls)

(208) 407-6003

8. OFFER DUE DATE/

LOCAL TIME

3/3/2025 @ 1430 MT

9. ISSUED BY CODE 10. THIS ACQUISITION IS UNRESTRICTED OR SET ASIDE: 100% FOR:

U.S. FOREST SERVICE, CONTRACTING

NATIONAL INTERAGENCY FIRE CENTER

OWYHEE BUILDING – MS 1100

3833 S DEVELOPMENT AVE

BOISE, ID 83705-5354

SMALL BUSINESS

WOMEN-OWNED SMALL BUSINESS

(WOSB) ELIGIBLE UNDER THE WOMEN-OWNED

SMALL BUSINESS PROGRAM

HUBZONE SMALL

BUSINESS

ECONOMICALLY DISADVANTAGED

WOMEN-OWNED SMALL BUSINESS

(EDWOSB)

NAICS: 325998 (fire retardant chemical preparations mfg.)

SERVICE-DISABLED

VETERAN-OWNED

SMALL BUSINESS

8 (A)

SIZE STANDARD:

500 employees

11. DELIVERY FOR FOB DESTINA-

TON UNLESS BLOCK IS

MARKED

SEE SCHEDULE

12. DISCOUNT TERMS

13a. THIS CONTRACT IS A

RATED ORDER UNDER

DPAS (15 CFR 700)

13b. RATING

14. METHOD OF SOLICITATION

RFQ IFB RFP

15. DELIVER TO CODE 16. ADMINISTERED BY CODE

See Block 9

17a. CONTRACTOR/ CODE FACILITY 18a. PAYMENT WILL BE MADE BY CODE

OFFEROR CODE

See Section C.22 PAYMENT AND INVOICES

TELEPHONE NO. NINE-DIGIT DUNS NO. .

17b CHECK IF REMITTANCE IS DIFFERENT AND PUT SUCH ADDRESS IN

OFFER

18b. SUBMIT INVOICES TO ADDRESS SHOWN IN BLOCK 18a UNLESS BLOCK BELOW

IS CHECKED

SEE ADDENDUM

19.

ITEM NO.

20.

SCHEDULE OF SUPPLIES/SERVICES

21.

QUANTITY

22.

UNIT

23.

UNIT PRICE

24.

AMOUNT

SEE SECTION B (ATTACHED)

RETARDANT ON-DEMAND

ALL PRODUCTS

25. ACCOUNTING AND APPROPRIATION DATA

26. TOTAL AWARD AMOUNT (For Govt. Use Only)

27a. SOLICITATION INCORPORATES BY REFERENCE FAR 52.212-1, 52.212-4. FAR 52.212-3 AND 52.212-5 ARE ATTACHED. ADDENDA ARE ARE NOT ATTACHED

27b. CONTRACT/PURCHASE ORDER INCORPORATES BY REFERENCE FAR 52.212-4. FAR 52.212-5 IS ATTACHED. ADDENDA ARE ARE NOT ATTACHED

28. CONTRACTOR IS REQUIRED TO SIGN THIS DOCUMENT AND RETURN 1 .

COPIES TO ISSUING OFFICE. CONTRACTOR AGREES TO FURNISH AND

DELIVER ALL ITEMS SET FORTH OR OTHERWISE IDENTIFIED ABOVE AND ON ANY

ADDITIONAL SHEETS SUBJECT TO THE TERMS AND CONDITIONS SPECIFIED

HEREIN.

29. AWARD OF CONTRACT: REF. _________________ __ OFFER

DATED _______________ . YOUR OFFER ON SOLICITATION (BLOCK

5), INCLUDING ANY ADDITIONS OR CHANGES WHICH ARE SET

FORTH HEREIN, IS ACCEPTED AS TO ITEMS:

30a. SIGNATURE OF OFFEROR/CONTRACTOR 31a. UNITED STATES OF AMERICA (SIGNATURE OF CONTRACTING OFFICER)

30b. NAME AND TITLE OF SIGNED (Type or print) 30c. DATE SIGNED 31b. NAME OF CONTRACTING OFFICER (Type or print) 31c. DATE SIGNED

AUTHORIZED FOR LOCAL REPRODUCTION

PREVIOUS EDITION NOT USABLE STANDARD FORM 1449 (REV. 2/2012)

Prescribed by GSA - FAR (48 CFR) 53.212

SECTION B – SCHEDULE OF SUPPLIES/SERVICES

B.1 GENERAL INFORMATION

(a) This solicitation and resultant Blanket Purchase Agreements (BPAs) for Retardant On- Demand, enables the Forest Service (FS), State & Private Forestry (S&PF), Fire and Aviation Management Program to acquire fully qualified aerial Long-Term Fire Retardant (LTFR) products on an as-needed basis to temporary locations throughout the United States including onsite mixing and loading of LTFR products onto aircraft and helicopters. Additionally, ground application of pretreatment/ground application fully qualified LTFR products are supplied pre-mixed, ready-to-use and may require additional local environmental permits prior to use. Please see the Specifications in Section D.1 and the Qualified Products List (QPL) for complete details.

(b) This acquisition will result in commercial, multiple award, BPAs, under the authority of Federal Acquisition Regulations (FAR), part 12, Acquisition of Commercial Items in conjunction with FAR part 13, Simplified Acquisition Procedures. The dollar limitation for any individual order is the Simplified Acquisition Threshold (SAT) ($7.5M IAW Agency procedure). Since the needs of the Government and availability of Contractor's resources during an emergency cannot be determined in advance, it is mutually agreed that, upon request of the Government, the Contractor shall furnish fully qualified LTFR product/products including onsite mixing and loading capability to the extent the Contractor is willing and able at the time of order. Due to the sporadic occurrence of Incident activity, the placement of any orders IS NOT GUARANTEED.

(c) This acquisition is being solicited as full and open competition.

(d) Suppliers must quote only fully qualified aerial Long-Term Fire Retardants in accordance with US Department of Agriculture Forest Service Specification 5100-304d, Interim Amendment 1 (or latest version) Long-Term Retardant, Wildland Firefighting and currently on the Long-Term Retardant for Wildland Fire Management QPL located at https://www.fs.usda.gov/rm/fire/wfcs/documents/2024-1205_qpl_ret_.pdf .

(e) Offerors shall complete the Section B.2 - Schedule of Items - Pricing for the 2025 Calendar Year, for all fully qualified LTFR products and miscellaneous items they propose to offer. The successful Contractor(s) is/are responsible for furnishing all LTFR product(s) and equipment, materials, supplies, trained/certified personnel, laborers, transportation and lodging necessary to meet the agreement specifications as identified in Exhibit D.1. Updates for establishing an annual BPA including annual pricing updates, will be requested through an updated solicitation posted to Sam.gov and a solicitation amendment will be published around the end of the current year with quotations and prices due around the middle of January.

Performance extending beyond the calendar year will continue to utilize the current BPA pricing until such time that new prices are updated.

(f) The effective period of the resultant BPAs will be from date of establishment through 31 December 2031 with annual reviews happening around the end of the current year.

(g) This acquisition is being solicited in conjunction with FAR Part 13, Simplified Acquisition Procedures and any reference to contract shall be considered synonymous with agreement, Offeror shall be considered synonymous with Vendor or Quoter, and proposal shall be considered synonymous with quotation.

https://www.fs.usda.gov/rm/fire/wfcs/documents/2024-1205_qpl_ret_.pdf

B.2 SCHEDULE OF ITEMS – PRICING

Calendar Year 2025 (Date of Award - December 31, 2025 or until next year prices are established)

Company: _________________________________________

24 Hour Contact: _________________________________________

A. CLIN 0100 - Qualified LTFR Product(s) (CY 2025)

Note: Yield Mixed Retardant = equivalent of mixed LTFR in gallons from 1 Ton of concentrate.

ITEM

(Sub-

CLIN) DESCRIPTION

UNIT OF

MEASURE

PRICE PER

UNIT

01XX LTFR Product Freight (per truckload) per Shipment Cost Reimbursed

(Sub-

CLIN) PRODUCT LOT NO. PRICE/TON

YIELD

MIXED

RETARDANT

(GAL/TON)

PRICE/MIXED

GALLON

01XX

01XX

01XX

01XX

Calendar Year 2025 (Date of Award - December 31, 2025 or until next year prices are established)

B. CLIN 0200 - Support Services (CY 2025)

(Sub-

CLIN) DESCRIPTION

UNIT OF

MEASURE

PRICE PER

UNIT

0201 Daily Rate: MRB-VLAT (Very Large Air Tanker) per Day

0202 Daily Rate: MRB-AT (Air Tanker) per Day

0203 Daily Rate: MRB-SEAT (Singe Engine Air Tanker) per Day

0204 Daily Rate: MRB-H (Helicopter) per Day

0205 Daily Rate: MRB-GAU (Ground Applied Unit w/ 2 person crew) per Day

0206 Daily Rate: MRB-GT (Ground Tender w/ 2 person crew) per Day

0207 Put-Through Rate: Retardant & Water per Gallon

0208 Extended Standby (per person, for additional hours worked) per Hour

0209 Additional Person (per person, ordered on an existing incident) per Day

0210 Mileage Rate for Equipment to Site (incl personnel) per Mile

0211 Relocation Fee for Equipment on Incident per Event

0212 Crew Change-Out (per person, once every 14 days on an incident) per Person

02XX

C. CLIN 0300 - Optional Items (CY 2025)

ITEM

(Sub-

CLIN) DESCRIPTION

UNIT OF

MEASURE

PRICE PER

UNIT

0301 Water Tender per Day

0302 Water Storage (Pumpkin – min 2,500 gallons) per Day

0303 Additional Dip Tank (min 5,000 gallons) per Day

0304 Additional Water/Retardant Pump Station per Day

0305 Additional Loading System per Day

0306 Additional 500’ Lay-Flat Discharge Hose (min 2.5” dia.) per Day

0307 Mixing Unit for GAU per Day

03XX

SECTION C – CONTRACT CLAUSES

C.1 52.212-4 - CONTRACT TERMS AND CONDITIONS - COMMERCIAL PRODUCT AND

COMMERCIAL SERVICES (DEVIATION 2017-1) (NOV 2023)

(a) Inspection/Acceptance. The Contractor shall only tender for acceptance those items that conform to the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post-acceptance rights-

(1) Within a reasonable time after the defect was discovered or should have been discovered; and

(2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item.

(b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act ( 31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the Governmentwide commercial purchase card), the Contractor may not assign its rights to receive payment under this contract.

(c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties.

(d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at Federal Acquisition Regulation (FAR) 52.233-1, Disputes, which is incorporated herein by reference. The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract.

(e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference.

(f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence.

(g) Invoice.

(1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include --

(i) Name and address of the Contractor;

(ii) Invoice date and number;

(iii) Contract number, line item number and, if applicable, the order number;

(iv) Description, quantity, unit of measure, unit price and extended price of the items delivered;

(v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading;

(vi) Terms of any discount for prompt payment offered;

(vii) Name and address of official to whom payment is to be sent;

(viii) Name, title, and phone number of person to notify in event of defective invoice; and

(ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the invoice only if required elsewhere in this contract.

(x) Electronic funds transfer (EFT) banking information.

(A) The Contractor shall include EFT banking information on the invoice only if required elsewhere in this contract.

(B) If EFT banking information is not required to be on the invoice, in order for the invoice to be a proper invoice, the Contractor shall have submitted correct EFT banking information in accordance with the applicable solicitation provision, contract clause (e.g., 52.232-33, Payment by Electronic Funds Transfer-System for Award Management, or 52.232-34, Payment by Electronic Funds Transfer-Other Than System for Award Management), or applicable agency procedures.

(C) EFT banking information is not required if the Government waived the requirement to pay by EFT.

(2) Invoices will be handled in accordance with the Prompt Payment Act ( 31 U.S.C.3903) and Office of Management and Budget (OMB) prompt payment regulations at 5 CFR Part 1315.

(h) Patent indemnity. The Contractor shall indemnify the Government and its officers, employees and agents against liability, including costs, for actual or alleged direct or contributory infringement of, or inducement to infringe, any United States or foreign patent, trademark or copyright, arising out of the performance of this contract, provided the Contractor is reasonably notified of such claims and proceedings.

(i) Payment.

(1) Items accepted. Payment shall be made for items accepted by the Government that have been delivered to the delivery destinations set forth in this contract.

(2) Prompt Payment. The Government will make payment in accordance with the Prompt Payment Act ( 31 U.S.C.3903) and prompt payment regulations at 5 CFR Part 1315.

(3) Electronic Funds Transfer (EFT). If the Government makes payment by EFT, see 52.212-5(b) for the appropriate EFT clause.

(4) Discount. In connection with any discount offered for early payment, time shall be computed from the date of the invoice. For the purpose of computing the discount earned, payment shall be considered to have been made on the date which appears on the payment check or the specified payment date if an electronic funds transfer payment is made.

(5) Overpayments. If the Contractor becomes aware of a duplicate contract financing or invoice payment or that the Government has otherwise overpaid on a contract financing or invoice payment, the Contractor shall-

(i) Remit the overpayment amount to the payment office cited in the contract along with a description of the overpayment including the—

(A) Circumstances of the overpayment (e.g., duplicate payment, erroneous payment, liquidation errors, date(s) of overpayment);

(B) Affected contract number and delivery order number, if applicable;

(C) Affected line item or subline item, if applicable; and

(D) Contractor point of contact.

(ii) Provide a copy of the remittance and supporting documentation to the Contracting Officer.

(6) Interest.

(i) All amounts that become payable by the Contractor to the Government under this contract shall bear simple interest from the date due until paid unless paid within 30 days of becoming due. The interest rate shall be the interest rate established by the Secretary of the Treasury as provided in 41 U.S.C. 7109, which is applicable to the period in which the amount becomes due, as provided in (i)(6)(v) of this clause, and then at the rate applicable for each six-month period as fixed by the Secretary until the amount is paid.

(ii) The Government may issue a demand for payment to the Contractor upon finding a debt is due under the contract.

(iii) Final decisions. The Contracting Officer will issue a final decision as required by 33.211 if—

(A) The Contracting Officer and the Contractor are unable to reach agreement on the existence or amount of a debt within 30 days;

(B) The Contractor fails to liquidate a debt previously demanded by the Contracting Officer within the timeline specified in the demand for payment unless the amounts were not repaid because the Contractor has requested an installment payment agreement; or

(C) The Contractor requests a deferment of collection on a debt previously demanded by the Contracting Officer (see 32.607-2).

(iv) If a demand for payment was previously issued for the debt, the demand for payment included in the final decision shall identify the same due date as the original demand for payment.

(v) Amounts shall be due at the earliest of the following dates:

(A) The date fixed under this contract.

(B) The date of the first written demand for payment, including any demand for payment resulting from a default termination.

(vi) The interest charge shall be computed for the actual number of calendar days involved beginning on the due date and ending on—

(A) The date on which the designated office receives payment from the Contractor;

(B) The date of issuance of a Government check to the Contractor from which an amount otherwise payable has been withheld as a credit against the contract debt; or

(C) The date on which an amount withheld and applied to the contract debt would otherwise have become payable to the Contractor.

(vii) The interest charge made under this clause may be reduced under the procedures prescribed in FAR 32.608-2 in effect on the date of this contract.

(j) Risk of loss. Unless the contract specifically provides otherwise, risk of loss or damage to the supplies provided under this contract shall remain with the Contractor until, and shall pass to the Government upon:

(1) Delivery of the supplies to a carrier, if transportation is f.o.b. origin; or

(2) Delivery of the supplies to the Government at the destination specified in the contract, if transportation is f.o.b. destination.

(k) Taxes. The contract price includes all applicable Federal, State, and local taxes and duties.

(l) Termination for the Government’s convenience. The Government reserves the right to terminate this contract, or any part hereof, for its sole convenience. In the event of such termination, the Contractor shall immediately stop all work hereunder and shall immediately cause any and all of its suppliers and subcontractors to cease work. Subject to the terms of this contract, the Contractor shall be paid a percentage of the contract price reflecting the percentage of the work performed prior to the notice of termination, plus reasonable charges the Contractor can demonstrate to the satisfaction of the Government using its standard record keeping system, have resulted from the termination. The Contractor shall not be required to comply with the cost accounting standards or contract cost principles for this purpose. This paragraph does not give the Government any right to audit the Contractor’s records. The Contractor shall not be paid for any work performed or costs incurred which reasonably could have been avoided.

(m) Termination for cause. The Government may terminate this contract, or any part hereof, for cause in the event of any default by the Contractor, or if the Contractor fails to comply with any contract terms and conditions, or fails to provide the Government, upon request, with adequate assurances of future performance. In the event of termination for cause, the Government shall not be liable to the Contractor for any amount for supplies or services not accepted, and the Contractor shall be liable to the Government for any and all rights and remedies provided by law. If it is determined that the Government improperly terminated this contract for default, such termination shall be deemed a termination for convenience.

(n) Title. Unless specified elsewhere in this contract, title to items furnished under this contract shall pass to the Government upon acceptance, regardless of when or where the Government takes physical possession.

(o) Warranty. The Contractor warrants and implies that the items delivered hereunder are merchantable and fit for use for the particular purpose described in this contract.

(p) Limitation of liability. Except as otherwise provided by an express warranty, the Contractor will not be liable to the Government for consequential damages resulting from any defect or deficiencies in accepted items.

(q) Other compliances. The Contractor shall comply with all applicable Federal, State and local laws, executive orders, rules and regulations applicable to its performance under this contract.

(r) Compliance with laws unique to Government contracts. The Contractor agrees to comply with 31 U.S.C. 1352 relating to limitations on the use of appropriated funds to influence certain Federal contracts; 18 U.S.C. 431 relating to officials not to benefit; 40 U.S.C. chapter 37, Contract Work Hours and Safety Standards; 41 U.S.C. chapter 87, Kickbacks; 49 U.S.C. 40118, Fly American; and 41 U.S.C. chapter 21 relating to procurement integrity.

(s) Order of precedence. Any inconsistencies in this solicitation or contract shall be resolved by giving precedence in the following order:

(1) The schedule of supplies/services.

(2) The Assignments, Disputes, Payments, Invoice, Other Compliances, Compliance with Laws Unique to Government Contracts, and Unauthorized Obligations paragraphs of this clause.

(3) The clause at 52.212-5.

(4) Addenda to this solicitation or contract, including any license agreements for computer software.

(5) Solicitation provisions if this is a solicitation.

(6) Other paragraphs of this clause.

(7) The Standard Form 1449.

(8) Other documents, exhibits, and attachments.

(9) The specification.

(t) Reserved

(u) Unauthorized Obligations.

(1) Except as stated in paragraph (u)(2) of this clause, when any supply or service acquired under this contract is subject to any End User License Agreement (EULA), Terms of Service (TOS), or similar legal instrument or agreement, that includes any clause requiring the Government to indemnify the Contractor or any person or entity for damages, costs, fees, or any other loss or liability that would create an Anti-Deficiency Act violation (31 U.S.C. 1341), the following shall govern:

(i) Any such clause is unenforceable against the Government.

(ii) Neither the Government nor any Government authorized end user shall be deemed to have agreed to such clause by virtue of it appearing in the EULA, TOS, or similar legal instrument or agreement. If the EULA, TOS, or similar legal instrument or agreement is invoked through an "I agree" click box or other comparable mechanism (e.g., "click-wrap" or "browse-wrap" agreements), execution does not bind the Government or any Government authorized end user to such clause.

(iii) Any such clause is deemed to be stricken from the EULA, TOS, or similar legal instrument or agreement.

(2) Paragraph (u)(1) of this clause does not apply to indemnification by the Government that is expressly authorized by statute and specifically authorized under applicable agency regulations and procedures.

(v) Incorporation by reference. The Contractor’s representations and certifications, including those completed electronically via the System for Award Management (SAM), are incorporated by reference into the contract.

C.2 52.212-5 CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR

EXECUTIVE ORDERS -- COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (JAN

2025)

(a) The Contractor shall comply with the following Federal Acquisition Regulation (FAR) clauses, which are incorporated in this contract by reference, to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

(1) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91).

(3) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115- 232).

(4) 52.209-10, Prohibition on Contracting with Inverted Domestic Corporations (Nov 2015).

(5) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) (31 U.S.C.3903 and 10 U.S.C. 3801).

(6) 52.233-3, Protest After Award (Aug 1996) (31 U.S.C. 3553).

(7) 52.233-4, Applicable Law for Breach of Contract Claim (Oct 2004) (Public Laws 108- 77 and 108-78 (19 U.S.C. 3805note)).

(b) The Contractor shall comply with the FAR clauses in this paragraph (b) that the contracting officer has indicated as being incorporated in this contract by reference to implement provisions of law or Executive orders applicable to acquisitions of commercial products and commercial services:

[Contracting Officer check as appropriate.]

☒ (1) 52.203-6, Restrictions on Subcontractor Sales to the Government (Jun 2020), with Alternate I (Nov 2021) (41 U.S.C. 4704 and 10 U.S.C. 4655).

☒ (2) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509)).

☐ (3) 52.203-15, Whistleblower Protections under the American Recovery and Reinvestment Act of 2009 (Jun 2010) (Section 1553 of Pub. L. 111-5). (Applies to contracts funded by the American Recovery and Reinvestment Act of 2009.)

☐ (4) 52.203-17, Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights (NOV 2023) (41 U.S.C. 4712) ); this clause does not apply to contracts of DoD, NASA, the Coast Guard, or applicable elements of the intelligence community—see FAR 3.900(a).

☒ (5) 52.204-10, Reporting Executive Compensation and First-Tier Subcontract Awards (Jun 2020) (Pub. L. 109-282) (31 U.S.C. 6101 note).

☐ (6) [Reserved].

☐ (7) 52.204-14, Service Contract Reporting Requirements (Oct 2016) (Pub. L. 111- 117, section 743 of Div. C).

☐ (8) 52.204-15, Service Contract Reporting Requirements for Indefinite-Delivery Contracts (Oct 2016) (Pub. L. 111-117, section 743 of Div. C).

☒ (9) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328).

☐ (10) 52.204–28, Federal Acquisition Supply Chain Security Act Orders—Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts.

(Dec 2023) ( Pub. L. 115–390, title II).

☐ (11) (i) 52.204–30, Federal Acquisition Supply Chain Security Act Orders— Prohibition. (Dec 2023) ( Pub. L. 115–390, title II).

☐ (ii) Alternate I (Dec 2023) of 52.204-30.

☒ (12) 52.209-6, Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded.

(Jan 2025) (31 U.S.C. 6101 note).

☒ (13) 52.209-9, Updates of Publicly Available Information Regarding Responsibility Matters (Oct 2018) (41 U.S.C. 2313).

☐ (14) [Reserved].

☐ (15) 52.219-3, Notice of HUBZone Set-Aside or Sole-Source Award (Oct 2022) (15 U.S.C. 657a).

☐ (16) 52.219-4, Notice of Price Evaluation Preference for HUBZone Small Business Concerns (Oct 2022) (if the offeror elects to waive the preference, it shall so indicate in its offer) (15 U.S.C. 657a).

☐ (17) [Reserved].

☐ (18) (i) 52.219-6, Notice of Total Small Business Aside (Nov 2020) (15 U.S.C. 644).

☐ (ii) Alternate I (Mar 2020) of 52.219-4.

☐ (19) (i) 52.219-7, Notice of Partial Small Business Set-Aside (Nov 2020) (15 U.S.C.

644).

☐ (ii) Alternate I (Mar 2020) of 52.219-7.

☒ (20) 52.219-8, Utilization of Small Business Concerns (Jan 2025) (15 U.S.C. 637(d)(2) and (3)).

☐ (21) (i) 52.219-9, Small Business Subcontracting Plan (Jan 2025) (15 U.S.C.

637(d)(4)).

☐ (ii) Alternate I (NOV 2016) of 52.219-9.

☒ (iii) Alternate II (NOV 2016) of 52.219-9.

☐ (iv) Alternate III (Jun 2020) of 52.219-9.

☐ (v) Alternate IV (Jan 2025) of 52.219-9.

☐ (22) 52.219-13, Notice of Set-Aside of Orders (Mar 2020) (15 U.S.C. 644(r)).

☐ (ii) Alternate I (Mar 2020) of 52.219-13.

☐ (23) 52.219-14, Limitations on Subcontracting (Oct 2022) (15 U.S.C. 657s).

☒ (24) 52.219-16, Liquidated Damages—Subcontracting Plan (Sep 2021) (15 U.S.C.

637(d)(4)(F)(i)).

☐ (25) 52.219-27, Notice of Set-Aside for, or Sole-Source Award to, Service-Disabled Veteran-Owned Small Business (SDVOSB) Concerns Eligible Under the SDVOSB Program (Feb 2024) (15 U.S.C. 657f).

☒ (26) (i) 52.219-28, Postaward Small Business Program Rerepresentation (Jan 2025) (15 U.S.C. 632(a)(2)).

☐ (ii) Alternate I (Mar 2020) of 52.219-28.

☐ (27) 52.219-29, Notice of Set-Aside for, or Sole Source Award to, Economically Disadvantaged Women-Owned Small Business Concerns (Oct 2022)(15 U.S.C.

637(m)).

☐ (28) 52.219-30, Notice of Set-Aside for, or Sole Source Award to, Women-Owned Small Business Concerns Eligible Under the Women-Owned Small Business Program (Oct 2022) (15 U.S.C. 637(m)).

☐ (29) 52.219-32, Orders Issued Directly Under Small Business Reserves (Mar 2020) (15 U.S.C. 644(r)).

☐ (30) 52.219-33, Nonmanufacturer Rule (Sep 2021) (15U.S.C. 637(a)(17)).

☒ (31) 52.222-3, Convict Labor (June 2003) (E.O. 11755).

☒ (32) 52.222-19, Child Labor—Cooperation with Authorities and Remedies (Jan 2025) (E.O. 13126).

☒ (33) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

☒ (34) (i) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

☐ (ii) Alternate I (Feb 1999) of 52.222-26.

☒ (35) (i) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

☐ (ii) Alternate I (July 2014) of 52.222-35.

☒ (36) (i) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C. 793).

☐ (ii) Alternate I (July 2014) of 52.222-36.

☒ (37) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

☒ (38) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496).

☒ (39) (i) 52.222-50, Combating Trafficking in Persons (Nov 2021) (22 U.S.C. chapter 78 and E.O. 13627).

☐ (ii) Alternate I (Mar 2015) of 52.222-50, (22 U.S.C. chapter 78 and E.O.

13627).

☐ (40) 52.222-54, Employment Eligibility Verification (Jan 2025) (Executive Order 12989). (Not applicable to the acquisition of commercially available off-the-shelf items or certain other types of commercial products or commercial services as prescribed in FAR 22.1803).

☐ (41) (i) 52.223-9, Estimate of Percentage of Recovered Material Content for EPA- Designated Items (May 2008) (42 U.S.C. 6962(c)(3)(A)(ii)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

☐ (ii) Alternate I (May 2008) of 52.223-9 (42 U.S.C. 6962(i)(2)(C)). (Not applicable to the acquisition of commercially available off-the-shelf items.)

☐ (42) 52.223-11, Ozone-Depleting Substances and High Global Warming Potential Hydrofluorocarbons (May 2024) (42 U.S.C. 7671, et seq.)

☐ (43) 52.223-12, , Maintenance, Service, Repair, or Disposal of Refrigeration Equipment and Air Conditioners (May 2024) (42 U.S.C. 7671, et seq.).

☐ (44) 52.223-20, Aerosols (May 2024) (42 U.S.C. 7671, et seq.).

☐ (45) 52.223-21, Foams (May 2024) (42 U.S.C. 7671, et seq.).

☒ (46) 52.223-23, Sustainable Products and Services (May 2024) (E.O. 14057, 7 U.S.C.

8102, 42 U.S.C. 6962, 42 U.S.C. 8259b, and 42 U.S.C. 7671l).

☒ (47) (i) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

☐ (ii) Alternate I (Jan 2017) of 52.224-3.

☒ (48) 52.225-1, Buy American--Supplies (Oct 2022) (41 U.S.C. chapter 83).

☐ (iii) Alternate I (Oct 2022) of 52.225-1.

☐ (49) (i) 52.225-3, Buy American-Free Trade Agreements-Israeli Trade Act (Nov 2023) (19 U.S.C. 3301 note, 19 U.S.C. 2112 note, 19 U.S.C. 3805 note, 19 U.S.C. 4001 note, 19 U.S.C. chapter 29 (sections 4501-4732), Public Law 103-182, 108-77, 108-78, 108- 286, 108-302, 109-53, 109-169, 109-283, 110-138, 112-41, 112-42, and 112-43.

☐ (ii) Alternate I [Reserved].

☐(iii) Alternate II (Jan 2025) of 52.225-3.

☐(iv) Alternate III (Feb 2024) of 52.225-3.

☐(v) Alternate IV (Oct 2022) of 52.225-3.

☐ (50) 52.225-5, Trade Agreements (Nov 2023) (19 U.S.C. 2501, et seq., 19 U.S.C.

3301 note).

☒ (51) 52.225-13, Restrictions on Certain Foreign Purchases (Feb 2021) (E.O.’s, proclamations, and statutes administered by the Office of Foreign Assets Control of the Department of the Treasury).

☐ (52) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

☐ (53) 52.226-4, Notice of Disaster or Emergency Area Set-Aside (Nov 2007) (42 U.S.C.

5150).

☐ (54) 52.226-5, Restrictions on Subcontracting Outside Disaster or Emergency Area (Nov 2007) (42 U.S.C. 5150).

☒ (55) 52.226-8, Encouraging Contractor Policies to Ban Text Messaging While Driving (May 2024) ( E.O. 13513).

☐ (56) 52.229-12, Tax on Certain Foreign Procurements (Feb 2021).

☐ (57) 52.232-29, Terms for Financing of Purchases of Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505), 10 U.S.C. 2307(f)).

☐ (58) 52.232-30, Installment Payments for Commercial Products and Commercial Services (Nov 2021) (41 U.S.C. 4505, 10 U.S.C. 2307(f)).

☒ (59) 52.232-33, Payment by Electronic Funds Transfer--System for Award Management (Oct 2018) (31 U.S.C. 3332).

☐ (60) 52.232-34, Payment by Electronic Funds Transfer—Other Than System for Award Management (Jul 2013) (31 U.S.C. 3332).

☐ (61) 52.232-36, Payment by Third Party (May 2014) (31 U.S.C. 3332).

☐ (62) 52.239-1, Privacy or Security Safeguards (Aug 1996) (5 U.S.C. 552a).

☒ (63) 52.240-1, Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act-Covered Foreign Entities (Nov 2024) (Sections 1821-1826, Pub. L. 118-31, 41 U.S.C. 3901 note prec.).

☐ (64) 52.242-5, Payments to Small Business Subcontractors (Jan 2017) (15 U.S.C.

637(d)(13)).

☐ (65) (i) 52.247-64, Preference for Privately Owned U.S.-Flag Commercial Vessels (NOV 2021) (46 U.S.C. 55305) and 10 U.S.C. 2631).

☐ (ii) Alternate I (Apr 2003) of 52.247-64.

☐ (iii) Alternate II (Nov 2021) of 52.247-64.

(c) The Contractor shall comply with the FAR clauses in this paragraph (c), applicable to commercial services, that the Contracting Officer has indicated as being incorporated in this contract by reference to implement provisions of law or executive orders applicable to acquisitions of commercial products and commercial services:

☐ (1) 52.222-41, Service Contract Labor Standards (Aug 2018) (41 U.S.C. chapter 67.).

☐ (2) 52.222-42, Statement of Equivalent Rates for Federal Hires (May 2014) (29 U.S.C.

206 and 41 U.S.C. chapter 67).

☐ (3) 52.222-43, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (Multiple Year and Option Contracts) (Aug 2018) (29 U.S.C.206 and 41 U.S.C. chapter 67).

☐ (4) 52.222-44, Fair Labor Standards Act and Service Contract Labor Standards -- Price Adjustment (May 2014) (29 U.S.C. 206 and 41 U.S.C. chapter 67).

☐ (5) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67).

☒ (6) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C. chapter 67).

☐ (7) 52.222-55, Minimum Wages Under Executive Order 13658 (Jan 2022) (E.O.

13658).

☐ (8) 52.222-62, Paid Sick Leave Under Executive Order 13706 (Jan 2022) (E.O.

13706).

☐ (9) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Jun 2020) (42 U.S.C. 1792).

☐ (10) 52.247-69, Reporting Requirement for U.S.-Flag Air Carriers Regarding Training to Prevent Human Trafficking (Jan 2025) ( 49 U.S.C. 40118(g)).

(d) Comptroller General Examination of Record Comptroller General Examination of Record. The Contractor shall comply with the provisions of this paragraph (d) if this contract was awarded using other than sealed bid, is in excess of the simplified acquisition threshold, as defined in FAR 2.101, on the date of award of this contract, and does not contain the clause at 52.215-2, Audit and Records-Negotiation.

(1) The Comptroller General of the United States, or an authorized representative of the Comptroller General, shall have access to and right to examine any of the Contractor’s directly pertinent records involving transactions related to this contract.

(2) The Contractor shall make available at its offices at all reasonable times the records, materials, and other evidence for examination, audit, or reproduction, until 3 years after final payment under this contract or for any shorter period specified in FAR subpart 4.7, Contractor Records Retention, of the other clauses of this contract. If this contract is completely or partially terminated, the records relating to the work terminated shall be made available for 3 years after any resulting final termination settlement. Records relating to appeals under the disputes clause or to litigation or the settlement of claims arising under or relating to this contract shall be made available until such appeals, litigation, or claims are finally resolved.

(3) As used in this clause, records include books, documents, accounting procedures and practices, and other data, regardless of type and regardless of form. This does not require the Contractor to create or maintain any record that the Contractor does not maintain in the ordinary course of business or pursuant to a provision of law.

(e)

(1) Notwithstanding the requirements of the clauses in paragraphs (a), (b), (c) and (d) of this clause, the Contractor is not required to flow down any FAR clause, other than those in this paragraph (e)(1) in a subcontract for commercial products and commercial services.

Unless otherwise indicated below, the extent of the flow down shall be as required by the clause—

(i) 52.203-13, Contractor Code of Business Ethics and Conduct (Nov 2021) (41 U.S.C. 3509).

(ii) 52.203-17, Contractor Employee Whistleblower Rights (Nov 2023) ( 41 U.S.C.

4712).

(iii) 52.203-19, Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements (Jan 2017) (section 743 of Division E, Title VII, of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)).

(iv) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by KasperskyLab Covered Entities (Dec 2023) (Section 1634 of Pub. L. 115-91)

(v) 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment. (Nov 2021) (Section 889(a)(1)(A) of Pub. L. 115-232).

(vi) 52.204-27, Prohibition on a ByteDance Covered Application (Jun 2023) (Section 102 of Division R of Pub. L. 117-328).

(vii) (A) 52.204–30, Federal Acquisition Supply Chain Security Act Orders— Prohibition. (Dec 2023) ( Pub. L. 115–390, title II).

(B) Alternate I (Dec 2023) of 52.204–30.

(viii) 52.219-8, Utilization of Small Business Concerns (Jan 2025) (15 U.S.C.

637(d)(2) and (3)), in all subcontracts that offer further subcontracting opportunities. If the subcontract (except subcontracts to small business concerns) exceeds the applicable threshold specified in FAR 19.702(a) on the date of subcontract award, the subcontractor must include 52.219-8 in lower tier subcontracts that offer subcontracting opportunities.

(ix) 52.222-21, Prohibition of Segregated Facilities (Apr 2015).

(x) 52.222-26, Equal Opportunity (Sep 2016) (E.O. 11246).

(xi) 52.222-35, Equal Opportunity for Veterans (Jun 2020) (38 U.S.C. 4212).

(xii) 52.222-36, Equal Opportunity for Workers with Disabilities (Jun 2020) (29 U.S.C. 793).

(xiii) 52.222-37, Employment Reports on Veterans (Jun 2020) (38 U.S.C. 4212).

(xiv) 52.222-40, Notification of Employee Rights Under the National Labor Relations Act (Dec 2010) (E.O. 13496). Flow down required in accordance with paragraph (f) of FAR clause 52.222-40.

(xv) 52.222-41, Service Contract Labor Standards (Aug 2018), (41 U.S.C. chapter 67).

(xvi) (A) 52.222-50, Combating Trafficking in Persons (NOV 2021) (22 U.S.C.

chapter 78 and E.O. 13627).

(B) Alternate I (Mar 2015) of 52.222-50 (22 U.S.C. chapter 78 E.O. 13627).

(xvii) 52.222-51, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Requirements (May 2014) (41 U.S.C. chapter 67.)

(xviii) 52.222-53, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Requirements (May 2014) (41 U.S.C.

chapter 67)

(xix) 52.222-54, Employment Eligibility Verification (Jan 2025) ( E.O. 12989).

(xx) 52.222-55, Minimum Wages Under Executive Order 14026 (Jan 2022).

(xxi) 52.222-62, Paid sick Leave Under Executive Order 13706 (Jan 2022) (E.O.

13706).

(xxii) (A) 52.224-3, Privacy Training (Jan 2017) (5 U.S.C. 552a).

(B) Alternate I (Jan 2017) of 52.224-3.

(xxiii) 52.225-26, Contractors Performing Private Security Functions Outside the United States (Oct 2016) (Section 862, as amended, of the National Defense Authorization Act for Fiscal Year 2008; 10 U.S.C. 2302 Note).

(xxiv) 52.226-6, Promoting Excess Food Donation to Nonprofit Organizations. (Jun 2020) (42 U.S.C. 1792). Flow down required in accordance with paragraph (e) of FAR clause 52.226-6.

(xxv) 52.232-40, Providing Accelerated Payments to Small Business Subcontractors (Mar 2023) ( 31 U.S.C. 3903 and 10 U.S.C. 3801). Flow down required in accordance with paragraph (c) of 52.232-40.

(xxvi) 52.240-1, Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act-Covered Foreign Entities (Nov 2024) (Sections 1821-1826, Pub. L. 118-31, 41 U.S.C. 3901 note prec.).

(xxvii) 52.247-64, Preference for Privately-Owned U.S. Flag Commercial Vessels (Nov 2021) (46 U.S.C. 55305 and 10 U.S.C. 2631). Flow down required in accordance with paragraph (d) of FAR clause 52.247-64.

(2) While not required, the Contractor may include in its subcontracts for commercial items a minimal number of additional clauses necessary to satisfy its contractual obligations.

C.3 CONTRACT CLAUSES INCORPORATED BY REFERENCE (FAR 52.252-2) (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make the full text available. Also, the full text of a clause may be accessed electronically at this/these address(es): www.arnet.gov/far/ www.usda.gov/procurement/policy/agar.html

FEDERAL ACQUISITION REGULATION (48 CFR CHAPTER 1) CLAUSES

52.204-13 System for Award Management Maintenance. (OCT 2018) 52.204-18 Commercial and Government Entity Code Maintenance (AUG 2020) 52.228-5 Insurance - Work on a Government Installation (JAN 1997) 52.245-1 Alt 1 Government Property (APR 2012)

C.4 AUTHORIZED DEVIATIONS IN CLAUSES (FAR 52.252-6) (NOV 2020)

(a) The use in this solicitation or contract of any Federal Acquisition Regulation (48 CFR Chapter 1) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the date of the clause.

(b) The use in this solicitation or contract of any Agriculture Acquisition Regulation (48 CFR 4) clause with an authorized deviation is indicated by the addition of “(DEVIATION)” after the name of the regulation.

C.5 PERSONAL IDENTITY VERIFICATION OF CONTRACTOR EMPLOYEES

(a) The Contractor shall comply with the personal identity verification (PIV) policies and procedures established by the Department of Agriculture (USDA) Directives 4620-002 series.

(b) Should the results of the PIV process require the exclusion of a Contractor's employee; the Contracting Officer will notify the Contractor in writing.

(c) The Contractor must appoint a representative to manage compliance with the PIV policies established by the USDA Directives 4620-002 series and to maintain a list of employees eligible for a USDA LincPass required for performance of the work.

(d) The responsibility of maintaining a sufficient workforce remains with the Contractor.

Contractor employees may be barred by the Government from performance of work should they be found ineligible or to have lost eligibility for a USDA LincPass. Failure to maintain a sufficient http://www.arnet.gov/far/ http://www.usda.gov/procurement/policy/agar.html workforce of employees eligible for a USDA LincPass may be grounds for termination of the contract.

(e) The Contractor shall insert this clause in all subcontracts when the subcontractor is required to have routine unaccompanied physical access to a Federally-controlled facility and/or routine unaccompanied access to a Federally-controlled information system.

(f) The PIV Sponsor for this contract is a designated program point of contact, which in most cases is the COR, unless otherwise specified in this contract.