Purchase Aviation Life Support Equipment (ALSE) for Rotary Wing Aircraft

This is a combined synopsis/solicitation for commercial items prepared in accordance with (IAW) the format in Federal Acquisition Regulation (FAR) subpart 12.6 and part 13 as supplemented with additional information included in this notice.  This announcement constitutes the only solicitation; quotations are being requested and a written solicitation will not be issued.  Solicitation number 70Z03823QE0000062 is issued as a Request for Quotation (RFQ).  This solicitation document and incorporated provisions and clauses are those in effect through Federal Acquisition Circular Number 2023-05, effective 8 August 2023.

IAW FAR 6.302-1(a)(1), the United States Coast Guard (USCG). Aviation Logistics Center (ALC) plans to award one (1) purchase order and negotiate only with Lifesaving Systems LLC. (CAGE Code 64249) as the only known source of supply. All responsible sources may submit a capability statement, proposal, or quotation which shall be considered by the agency.

The applicable North American Industry Classification System (NAICS) code is 336413. The small business size standard is 1,250 employees. This is an unrestricted requirement.

It is anticipated that a firm-fixed price purchase order will be awarded on a sole source basis as a result of this solicitation for the following item:

SCHEDULE OF SUPPLIES

Line Item 1

Nomenclature:                           Triton II Molle System

Part Number:                             490-LOCG

National Stock Number:              8420-01-HS3-6194

Quantity:                                   fifteen (15) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 5 months after receipt of order (ARO­)

Line Item 2

Nomenclature:                           Triton II Molle System

Part Number:                             490-XLOCG

National Stock Number:              8420-01-HS3-6195

Quantity:                                   fifteen (15) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 5 months after receipt of order (ARO­)

Line Item 3

Nomenclature:                           Triton II Molle System

Part Number:                             490-XXOCG

National Stock Number:              8420-01-HS3-6196

Quantity:                                   five (5) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 5 months after receipt of order (ARO­)

Line Item 4

Nomenclature:                           Triton II Molle System

Part Number:                             490-MOCG

National Stock Number:              8420-01-HS3-6177

Quantity:                                   five (5) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 5 months after receipt of order (ARO­)

Line Item 5

Nomenclature:                           Molle EPIRB pocket

Part Number:                             745-P15-2

National Stock Number:              8420-01-HS3-6178

Quantity:                                   five (5) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 6 weeks after receipt of order (ARO­)

Line Item 6

Nomenclature:                           Molle Utility Pocket

Part Number:                             745-P2-2

National Stock Number:              8420-01-HS3-6197

Quantity:                                   five (5) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 6 weeks after receipt of order (ARO­)

Line Item 7

Nomenclature:                           Molle Utility Pocket

Part Number:                             745-P3-2

National Stock Number:              8420-01-HS3-6198

Quantity:                                   five (5) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 6 weeks after receipt of order (ARO­)

Line Item 8

Nomenclature:                           Molle Knife Pocket

Part Number:                             745-P11-2

National Stock Number:              8420-01-HS3-6200

Quantity:                                   five (5) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 6 weeks after receipt of order (ARO­)

Line Item 9

Nomenclature:                           Molle Chemlight Pocket

Part Number:                             745-P13-2

National Stock Number:              8420-01-HS3-6201

Quantity:                                   five (5) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 6 weeks after receipt of order (ARO­)

Line Item 10

Nomenclature:                           Litter Hoist Sling

Part Number:                             193-CG

National Stock Number:              1670-01-HS1-9803

Quantity:                                   forty (40) each

Optional Quantity:*                    up to thirty (30) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 6 weeks after receipt of order (ARO­)

Line Item 11

Nomenclature:                           Cover, Flotation

Part Number:                             103-2

National Stock Number:              4220-01-HS2-7447

Quantity:                                   ten (10) each

Optional Quantity:*                    up to twenty (20) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 6 weeks after receipt of order (ARO­)

Line Item 12

Nomenclature:                           Plastic Mesh Liner

Part Number:                             499-1

National Stock Number:              4240-01-493-9456

Quantity:                                   twenty (20) each

Optional Quantity:*                    up to twenty (20) each

Manufacturer CAGE Code:          64249

Required Delivery Date: 6 weeks after receipt of order (ARO­)

* 52.217-6         Option for Increased Quantity                                                                                  Mar 1989

At the time of award, the USCG will place an order for the purchase of the items at the quantities listed in the Schedule of Supplies. IAW with this addendum, the USCG may require the purchase of up to an additional thirty (30) each of Line Items 1-10 and twenty (20) each of Line Items 11 and 12 at the same price, terms, and conditions as specified in the original delivery order. The Contracting Officer may exercise this option by written notice to the Contractor through one (1) year after date of award (or other mutually agreed upon date). Delivery of any additional units shall be the same as called for in the order unless the parties otherwise agree.

Only the items requested in this solicitation will be considered for award.  All items shall have clear traceability to the Original Equipment Manufacturer (OEM), Lifesaving Systems LLC. (CAGE Code 64249). Traceability means a clear, complete, documented, and auditable paper trail that traces each step from an OEM or distributor to its current location.

The contractor shall furnish a Certificate of Conformance (COC) IAW FAR clause 52.246-15. The COC must be submitted in the format specified in the clause. Prospective vendors who are not the OEM must provide traceability for the offered product back to the OEM and will be required to submit a manufacturer's COC in addition to its own COC. 

NOTE: NO DRAWINGS, SPECIFICATIONS, OR SCHEMATICS ARE AVAILABLE FROM THE USCG.

Please carefully review this solicitation’s attachments for additional information and requirements such as applicable clauses and instructions to offerors:

1. Terms and Conditions
2. Justification and Approval for Other Than Full and Open Competition

The closing date and time for receipt of offers is 4 September 2023 at 4:30 p.m. Eastern Time.   Anticipated award date is on or about 11 September 2023.  Email quotations are preferred and may be sent to Rose.A.Bateman@uscg.mil. Please indicate 70Z03823QE0000062 in the subject line. 

NOTICE FOR FILING AGENCY PROTESTS

United States Coast Guard Ombudsman Program

It is the policy of the United States Coast Guard (USCG) to issue solicitations and make contract awards in a fair and timely manner. The Ombudsman Program for Agency Protests (OPAP) was established to investigate agency protest issues and resolve them without expensive and time- consuming litigation. OPAP is an independent reviewing authority that is empowered to grant a prevailing protester essentially the same relief as the Government Accountability Office (GAO).

Interested parties are encouraged to seek resolution of their concerns within the USCG as an Alternative Dispute Resolution (ADR) forum rather than filing a protest with the GAO or some external forum. Interested parties may seek resolution of their concerns informally or opt to file a formal agency protest with the Contracting Officer or Ombudsman.

Informal Forum with the Ombudsman. Interested parties who believe a specific USCG procurement is unfair or otherwise defective should first direct their concerns to the applicable Contracting Officer. If the Contracting Officer is unable to satisfy their concerns, interested parties are encouraged to contact the U.S. Coast Guard Ombudsman for Agency Protests. Under this informal process the agency is not required to suspend contract award performance.  Use of an informal forum does not suspend any time requirement for filing a protest with the agency or other forum. In order to ensure a timely response, interested parties should provide the following information to the Ombudsman: solicitation/contract number, contracting office, Contracting Officer, and solicitation closing date (if applicable).

Formal Agency Protest with the Ombudsman. Prior to submitting a formal agency protest, protesters must first use their best efforts to resolve their concerns with the Contracting Officer through open and frank discussions. If the protester’s concerns are unresolved, an Independent Review is available by the Ombudsman.  The protester may file a formal agency protest to either the Contracting Officer or as an alternative to that, the Ombudsman under the OPAP program.

Contract award or performance will be suspended during the protest period unless contract award or performance is justified, in writing, for urgent and compelling reasons or is determined in writing to be in the best interest of the Government.  The agency’s goal is to resolve protests in less than 35 calendar days from the date of filing. Protests shall include the information set forth in FAR 33.103(d) (2). If the protester fails to submit the required information, resolution of the protest may be delayed or the protest may be dismissed.  To be timely protests must be filed within the period specified in FAR 33.103(e).  Formal protests filed under the OPAP program should be submitted electronically to OPAP@uscg.mil and the Contracting Officer or by hand delivery to the Contracting Officer.

Election of Forum. After an interested party protests a Coast Guard procurement to the Contracting Officer or the Ombudsman, and while the protest is pending, the protester agrees not to file a protest with the GAO or other external forum. If the protest is filed with an external forum, the agency protest will be dismissed.