Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas

The U.S. Army Corps of Engineers, Galveston District Office requires a contract for Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas.
Project Information: The work consists of repair of damages to the levee embankment and riprap. Replacement of pump station engine is no longer required and will be deleted from the final scope.

Completion Time: Schedule No. 1 - 90 calendar days.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages in an amount TBD to the Government for each calendar day of delay until the work is completed or accepted.

The contractor will be required to provide Performance and Payment Bonds within (5) calendar days after award. The contractor shall begin work within (24) calendar days after acknowledgement of the notice to Proceed.

The Solicitation issued will be Firm Fixed Price. The magnitude of this project is from $5,000,000.00 and $10,000,000.00.

The solicitation is advertised as "100% SMALL BUSINESS SET-ASIDE". The North American Industrial Classification System (NAICS) Code applicable to this project is 237990. The Small Business Size Standard is $36.5 Million.

The solicitation will be issued on or about 23 May 2019. Response date is 16 July2019 @ 2:00 PM. The estimated award date for this project is August 2019.
ATTENTION TO OFFEROR(s)/CONTRACTOR(s): EFFECTIVE MARCH 22, 2018, YOU MUST SUBMIT A NOTARIZED LETTER APPOINTING THE AUTHORIZED ENTITY ADMINISTRATOR BEFORE YOUR REGISTRATION WILL BE ACTIVATED. THIS REQUIREMENT NOW APPLIES TO BOTH NEW AND EXISTING ENTITIES. MAKE SURE YOUR SAM PROFILE INCLUDES "ALL AWARDS" AND NOT JUST "FEDERAL ASSISTANCE AWARDS" AS THIS OPTION IS ONLY FOR GRANTS AND COOPERATIVE AGREEMENTS. PLEASE VISIT WWW.SAM.GOV FOR MORE INFORMATION.

All offerors are encouraged to visit the Federal Business Opportunities website at https://www.fbo.gov to view and download the plans, specification and or any amendments for this procurement. Plans and specifications will not be available in paper format or on compact disc. To register as an "Interested Vendor", visit https://www.fbo.gov . Offerors must be registered with the Systems for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: https://www.sam.gov .
The Contract Specialist for this solicitation will be Ms. Lucille Smith, (409) 766-3845; E-mail: Lucille.r.smith@usace.army.mil . For technical information about this solicitation, please contact Mr. Josh Hutchinson at (409) 941-8518 or Ms. Terri Carlson at (409) 766-3176, between the hours of 8:00 AM to 4:00 PM, Monday through Friday, excluding Federal Holidays.

.

The U.S. Army Corps of Engineers, Galveston District Office requires a contract for Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas.
Project Information: The work consists of repair of damages to the levee embankment and riprap. Replacement of pump station engine is no longer required and will be deleted from the final scope.

Completion Time: Schedule No. 1 - 90 calendar days.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages in an amount TBD to the Government for each calendar day of delay until the work is completed or accepted.

The contractor will be required to provide Performance and Payment Bonds within (5) calendar days after award. The contractor shall begin work within (24) calendar days after acknowledgement of the notice to Proceed.

The Solicitation issued will be Firm Fixed Price. The magnitude of this project is from $5,000,000.00 and $10,000,000.00.

The solicitation is advertised as "100% SMALL BUSINESS SET-ASIDE". The North American Industrial Classification System (NAICS) Code applicable to this project is 237990. The Small Business Size Standard is $36.5 Million.

The solicitation will be issued on or about 23 May 2019. Response date is 2 July2019 @ 2:00 PM. The estimated award date for this project is August 2019.
ATTENTION TO OFFEROR(s)/CONTRACTOR(s): EFFECTIVE MARCH 22, 2018, YOU MUST SUBMIT A NOTARIZED LETTER APPOINTING THE AUTHORIZED ENTITY ADMINISTRATOR BEFORE YOUR REGISTRATION WILL BE ACTIVATED. THIS REQUIREMENT NOW APPLIES TO BOTH NEW AND EXISTING ENTITIES. MAKE SURE YOUR SAM PROFILE INCLUDES "ALL AWARDS" AND NOT JUST "FEDERAL ASSISTANCE AWARDS" AS THIS OPTION IS ONLY FOR GRANTS AND COOPERATIVE AGREEMENTS. PLEASE VISIT WWW.SAM.GOV FOR MORE INFORMATION.

All offerors are encouraged to visit the Federal Business Opportunities website at https://www.fbo.gov to view and download the plans, specification and or any amendments for this procurement. Plans and specifications will not be available in paper format or on compact disc. To register as an "Interested Vendor", visit https://www.fbo.gov . Offerors must be registered with the Systems for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: https://www.sam.gov .
The Contract Specialist for this solicitation will be Ms. Lucille Smith, (409) 766-3845; E-mail: Lucille.r.smith@usace.army.mil . For technical information about this solicitation, please contact Mr. Josh Hutchinson at (409) 941-8518 or Ms. Terri Carlson at (409) 766-3176, between the hours of 8:00 AM to 4:00 PM, Monday through Friday, excluding Federal Holidays.

.

TO ALL PROSPECTIVE CONTRACTORS: THERE WILL BE A GROUP SITE VISIT ON MONDAY, JUNE 17, 2019 @ 9:00 AM. ALL INTERESTED CONTRACTORS ARE TO MEET AT 915 STRATTON RIDGE ROAD, CLUTE, TEXAS 77531. THE CORPS POINT OF CONTACT FOR THIS SITE VISIT IS JANTZEN MILLER, CELL# 409-392-0233 AND JOSH HUTCHISON, CELL# 409-239-1480. .

The U.S. Army Corps of Engineers, Galveston District Office requires a contract for Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas.
Project Information: The work consists of repair of damages to the levee embankment and riprap. Replacement of pump station engine is no longer required and will be deleted from the final scope.

Completion Time: Schedule No. 1 - 90 calendar days.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages in an amount TBD to the Government for each calendar day of delay until the work is completed or accepted.

The contractor will be required to provide Performance and Payment Bonds within (5) calendar days after award. The contractor shall begin work within (24) calendar days after acknowledgement of the notice to Proceed.

The Solicitation issued will be Firm Fixed Price. The magnitude of this project is from $5,000,000.00 and $10,000,000.00.

The solicitation is advertised as "100% SMALL BUSINESS SET-ASIDE". The North American Industrial Classification System (NAICS) Code applicable to this project is 237990. The Small Business Size Standard is $36.5 Million.

The solicitation will be issued on or about 23 May 2019. Response date is 24 June 2019 @ 2:00 PM. The estimated award date for this project is July 2019.
ATTENTION TO OFFEROR(s)/CONTRACTOR(s): EFFECTIVE MARCH 22, 2018, YOU MUST SUBMIT A NOTARIZED LETTER APPOINTING THE AUTHORIZED ENTITY ADMINISTRATOR BEFORE YOUR REGISTRATION WILL BE ACTIVATED. THIS REQUIREMENT NOW APPLIES TO BOTH NEW AND EXISTING ENTITIES. MAKE SURE YOUR SAM PROFILE INCLUDES "ALL AWARDS" AND NOT JUST "FEDERAL ASSISTANCE AWARDS" AS THIS OPTION IS ONLY FOR GRANTS AND COOPERATIVE AGREEMENTS. PLEASE VISIT WWW.SAM.GOV FOR MORE INFORMATION.

All offerors are encouraged to visit the Federal Business Opportunities website at https://www.fbo.gov to view and download the plans, specification and or any amendments for this procurement. Plans and specifications will not be available in paper format or on compact disc. To register as an "Interested Vendor", visit https://www.fbo.gov . Offerors must be registered with the Systems for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: https://www.sam.gov .
The Contract Specialist for this solicitation will be Ms. Lucille Smith, (409) 766-3845; E-mail: Lucille.r.smith@usace.army.mil . For technical information about this solicitation, please contact Mr. Josh Hutchinson at (409) 941-8518 or Ms. Terri Carlson at (409) 766-3176, between the hours of 8:00 AM to 4:00 PM, Monday through Friday, excluding Federal Holidays.

.

The U.S. Army Corps of Engineers, Galveston District Office requires a contract for Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas.
Project Information: The work consists of repair of damages to the levee embankment and riprap. Replacement of pump station engine is no longer required and will be deleted from the final scope.

Completion Time: Schedule No. 1 - 90 calendar days.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages in an amount TBD to the Government for each calendar day of delay until the work is completed or accepted.

The contractor will be required to provide Performance and Payment Bonds within (5) calendar days after award. The contractor shall begin work within (24) calendar days after acknowledgement of the notice to Proceed.

The Solicitation issued will be Firm Fixed Price. The magnitude of this project is from $5,000,000.00 and $10,000,000.00.

The solicitation is advertised as "100% SMALL BUSINESS SET-ASIDE". The North American Industrial Classification System (NAICS) Code applicable to this project is 237990. The Small Business Size Standard is $36.5 Million.

The solicitation will be issued on or about 15 May 2019. Response date is 14 June 2019 @ 2:00 PM. The estimated award date for this project is July 2019.
ATTENTION TO OFFEROR(s)/CONTRACTOR(s): EFFECTIVE MARCH 22, 2018, YOU MUST SUBMIT A NOTARIZED LETTER APPOINTING THE AUTHORIZED ENTITY ADMINISTRATOR BEFORE YOUR REGISTRATION WILL BE ACTIVATED. THIS REQUIREMENT NOW APPLIES TO BOTH NEW AND EXISTING ENTITIES. MAKE SURE YOUR SAM PROFILE INCLUDES "ALL AWARDS" AND NOT JUST "FEDERAL ASSISTANCE AWARDS" AS THIS OPTION IS ONLY FOR GRANTS AND COOPERATIVE AGREEMENTS. PLEASE VISIT WWW.SAM.GOV FOR MORE INFORMATION.

All offerors are encouraged to visit the Federal Business Opportunities website at https://www.fbo.gov to view and download the plans, specification and or any amendments for this procurement. Plans and specifications will not be available in paper format or on compact disc. To register as an "Interested Vendor", visit https://www.fbo.gov . Offerors must be registered with the Systems for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: https://www.sam.gov .
The Contract Specialist for this solicitation will be Ms. Lucille Smith, (409) 766-3845; E-mail: Lucille.r.smith@usace.army.mil . For technical information about this solicitation, please contact Mr. Josh Hutchinson at (409) 941-8518 or Ms. Terri Carlson at (409) 766-3176, between the hours of 8:00 AM to 4:00 PM, Monday through Friday, excluding Federal Holidays.

.

The U.S. Army Corps of Engineers, Galveston District Office requires a contract for Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas.
Project Information: The work consists of repair of damages to the levee embankment and riprap. Replacement of pump station engine is no longer required and will be deleted from the final scope.

Completion Time: Schedule No. 1 - 90 calendar days.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages in an amount TBD to the Government for each calendar day of delay until the work is completed or accepted.

The contractor will be required to provide Performance and Payment Bonds within (5) calendar days after award. The contractor shall begin work within (24) calendar days after acknowledgement of the notice to Proceed.

The Solicitation issued will be Firm Fixed Price. The magnitude of this project is from $5,000,000.00 and $10,000,000.00.

The solicitation is advertised as "100% SMALL BUSINESS SET-ASIDE". The North American Industrial Classification System (NAICS) Code applicable to this project is 237990. The Small Business Size Standard is $36.5 Million.

The solicitation will be issued on or about 8 April 2019. Response date is 1 May 2019 @ 2:00 PM. The estimated award date for this project is June 2019.
ATTENTION TO OFFEROR(s)/CONTRACTOR(s): EFFECTIVE MARCH 22, 2018, YOU MUST SUBMIT A NOTARIZED LETTER APPOINTING THE AUTHORIZED ENTITY ADMINISTRATOR BEFORE YOUR REGISTRATION WILL BE ACTIVATED. THIS REQUIREMENT NOW APPLIES TO BOTH NEW AND EXISTING ENTITIES. MAKE SURE YOUR SAM PROFILE INCLUDES "ALL AWARDS" AND NOT JUST "FEDERAL ASSISTANCE AWARDS" AS THIS OPTION IS ONLY FOR GRANTS AND COOPERATIVE AGREEMENTS. PLEASE VISIT WWW.SAM.GOV FOR MORE INFORMATION.

All offerors are encouraged to visit the Federal Business Opportunities website at https://www.fbo.gov to view and download the plans, specification and or any amendments for this procurement. Plans and specifications will not be available in paper format or on compact disc. To register as an "Interested Vendor", visit https://www.fbo.gov . Offerors must be registered with the Systems for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: https://www.sam.gov .
The Contract Specialist for this solicitation will be Ms. Lucille Smith, (409) 766-3845; E-mail: Lucille.r.smith@usace.army.mil . For technical information about this solicitation, please contact Mr. Charles Wheeler at (409) 766-3128 or Ms. Terri Carlson at (409) 766-3176, between the hours of 8:00 AM to 4:00 PM, Monday through Friday, excluding Federal Holidays.

Added: Jan 30, 2019 3:55 pm Modified: Mar 04, 2019 3:23 pmTrack Changes ELECTRONIC BID SUBMISSION THROUGH FBO IS AUTHORIZED.  SEE SECTION 00 21 00 OF THE SPECIFICATION FOR FBO BID SUBMISSION INSTRUCTIONS.  THE CONTRACTING OFFICER IS CHANGED TO CURTIS COLE, JR..

ELECTRONIC BID SUBMISSION THROUGH FBO IS NOT AUTHORIZED. SEE SECTION 00 21 00 OF THE SPECIFICATION FOR BID SUBMISSION INSTRUCTIONS. THE CONTRACTING OFFICER IS CHANGED TO CURTIS COLE, JR..

The U.S. Army Corps of Engineers, Galveston District Office requires a contract for Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas.
Project Information: The work consists of repair of damages to the levee embankment and riprap. Replacement of pump station engine is no longer required and will be deleted from the final scope.

Completion Time: Schedule No. 1 - 90 calendar days.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages in an amount TBD to the Government for each calendar day of delay until the work is completed or accepted.

The contractor will be required to provide Performance and Payment Bonds within (5) calendar days after award. The contractor shall begin work within (24) calendar days after acknowledgement of the notice to Proceed.

The Solicitation issued will be Firm Fixed Price. The magnitude of this project is from $5,000,000.00 and $10,000,000.00.

The solicitation is advertised as "100% SMALL BUSINESS SET-ASIDE". The North American Industrial Classification System (NAICS) Code applicable to this project is 237990. The Small Business Size Standard is $36.5 Million.

The solicitation will be issued on or about 14 February 2019. Response date is 18 March 2019 @ 2:00 PM. The estimated award date for this project is April 2019.
ATTENTION TO OFFEROR(s)/CONTRACTOR(s): EFFECTIVE MARCH 22, 2018, YOU MUST SUBMIT A NOTARIZED LETTER APPOINTING THE AUTHORIZED ENTITY ADMINISTRATOR BEFORE YOUR REGISTRATION WILL BE ACTIVATED. THIS REQUIREMENT NOW APPLIES TO BOTH NEW AND EXISTING ENTITIES. MAKE SURE YOUR SAM PROFILE INCLUDES "ALL AWARDS" AND NOT JUST "FEDERAL ASSISTANCE AWARDS" AS THIS OPTION IS ONLY FOR GRANTS AND COOPERATIVE AGREEMENTS. PLEASE VISIT WWW.SAM.GOV FOR MORE INFORMATION.

All offerors are encouraged to visit the Federal Business Opportunities website at https://www.fbo.gov to view and download the plans, specification and or any amendments for this procurement. Plans and specifications will not be available in paper format or on compact disc. To register as an "Interested Vendor", visit https://www.fbo.gov . Offerors must be registered with the Systems for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: https://www.sam.gov .
The Contract Specialist for this solicitation will be Ms. Lucille Smith, (409) 766-3845; E-mail: Lucille.r.smith@usace.army.mil . For technical information about this solicitation, please contact Mr. Charles Wheeler at (409) 766-3128 or Ms. Terri Carlson at (409) 766-3176, between the hours of 8:00 AM to 4:00 PM, Monday through Friday, excluding Federal Holidays.

.

The U.S. Army Corps of Engineers, Galveston District Office requires a contract for Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas.
Project Information: The work consists of repair of damages to the levee embankment and riprap. Replacement of pump station engine is no longer required and will be deleted from the final scope.

Completion Time: Schedule No. 1 - 90 calendar days.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages in an amount TBD to the Government for each calendar day of delay until the work is completed or accepted.

The contractor will be required to provide Performance and Payment Bonds within (5) calendar days after award. The contractor shall begin work within (24) calendar days after acknowledgement of the notice to Proceed.

The Solicitation issued will be Firm Fixed Price. The magnitude of this project is from $5,000,000.00 and $10,000,000.00.

The solicitation is advertised as "100% SMALL BUSINESS SET-ASIDE". The North American Industrial Classification System (NAICS) Code applicable to this project is 237990. The Small Business Size Standard is $36.5 Million.

The solicitation will be issued on or about 3 January 2019. Response date is 4 February 2019 @ 2:00 PM. The estimated award date for this project is March 2019.
ATTENTION TO OFFEROR(s)/CONTRACTOR(s): EFFECTIVE MARCH 22, 2018, YOU MUST SUBMIT A NOTARIZED LETTER APPOINTING THE AUTHORIZED ENTITY ADMINISTRATOR BEFORE YOUR REGISTRATION WILL BE ACTIVATED. THIS REQUIREMENT NOW APPLIES TO BOTH NEW AND EXISTING ENTITIES. MAKE SURE YOUR SAM PROFILE INCLUDES "ALL AWARDS" AND NOT JUST "FEDERAL ASSISTANCE AWARDS" AS THIS OPTION IS ONLY FOR GRANTS AND COOPERATIVE AGREEMENTS. PLEASE VISIT WWW.SAM.GOV FOR MORE INFORMATION.

All offerors are encouraged to visit the Federal Business Opportunities website at https://www.fbo.gov to view and download the plans, specification and or any amendments for this procurement. Plans and specifications will not be available in paper format or on compact disc. To register as an "Interested Vendor", visit https://www.fbo.gov . Offerors must be registered with the Systems for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: https://www.sam.gov .
The Contract Specialist for this solicitation will be Ms. Lucille Smith, (409) 766-3845; E-mail: Lucille.r.smith@usace.army.mil . For technical information about this solicitation, please contact Mr. Charles Wheeler at (409) 766-3128 or Ms. Terri Carlson at (409) 766-3176, between the hours of 8:00 AM to 4:00 PM, Monday through Friday, excluding Federal Holidays.

.

The U.S. Army Corps of Engineers, Galveston District Office requires a contract for Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas.
Project Information: The work consists of repair of damages to the levee embankment and riprap. Replacement of pump station engine is no longer required and will be deleted from the final scope.

Completion Time: Schedule No. 1 - 90 calendar days.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages in an amount TBD to the Government for each calendar day of delay until the work is completed or accepted.

The contractor will be required to provide Performance and Payment Bonds within (5) calendar days after award. The contractor shall begin work within (24) calendar days after acknowledgement of the notice to Proceed.

The Solicitation issued will be Firm Fixed Price. The magnitude of this project is from $5,000,000.00 and $10,000,000.00.

The solicitation is advertised as "100% SMALL BUSINESS SET-ASIDE". The North American Industrial Classification System (NAICS) Code applicable to this project is 237990. The Small Business Size Standard is $36.5 Million.

The solicitation will be issued on or about 3 January 2019. Response date is 4 February 2019 @ 2:00 PM. The estimated award date for this project is February 2019.
ATTENTION TO OFFEROR(s)/CONTRACTOR(s): EFFECTIVE MARCH 22, 2018, YOU MUST SUBMIT A NOTARIZED LETTER APPOINTING THE AUTHORIZED ENTITY ADMINISTRATOR BEFORE YOUR REGISTRATION WILL BE ACTIVATED. THIS REQUIREMENT NOW APPLIES TO BOTH NEW AND EXISTING ENTITIES. MAKE SURE YOUR SAM PROFILE INCLUDES "ALL AWARDS" AND NOT JUST "FEDERAL ASSISTANCE AWARDS" AS THIS OPTION IS ONLY FOR GRANTS AND COOPERATIVE AGREEMENTS. PLEASE VISIT WWW.SAM.GOV FOR MORE INFORMATION.

All offerors are encouraged to visit the Federal Business Opportunities website at https://www.fbo.gov to view and download the plans, specification and or any amendments for this procurement. Plans and specifications will not be available in paper format or on compact disc. To register as an "Interested Vendor", visit https://www.fbo.gov . Offerors must be registered with the Systems for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: https://www.sam.gov .
The Contract Specialist for this solicitation will be Ms. Lucille Smith, (409) 766-3845; E-mail: Lucille.r.smith@usace.army.mil . For technical information about this solicitation, please contact Mr. Charles Wheeler at (409) 766-3128 or Ms. Terri Carlson at (409) 766-3176, between the hours of 8:00 AM to 4:00 PM, Monday through Friday, excluding Federal Holidays.

.

The U.S. Army Corps of Engineers, Galveston District Office requires a contract for Freeport Hurricane Flood Protection Project (HFPP) in Brazoria County, Texas.
Project Information: The work consists of repair of damages to the levee embankment, riprap, and replacement of pump station engine.

Completion Time: Schedule No. 1 - 90 calendar days.

If the contractor fails to complete the work within the time specified, the contractor shall pay liquidated damages in an amount TBD to the Government for each calendar day of delay until the work is completed or accepted.

The contractor will be required to provide Performance and Payment Bonds within (5) calendar days after award. The contractor shall begin work within (24) calendar days after acknowledgement of the notice to Proceed.

The Solicitation issued will be Firm Fixed Price. The magnitude of this project is over $10,000,000.00.

The solicitation is advertised as "100% SMALL BUSINESS SET-ASIDE". The North American Industrial Classification System (NAICS) Code applicable to this project is 237990. The Small Business Size Standard is $36.5 Million.

The solicitation will be issued on or about 17 December 2018. Response date is 16 January 2019 @ 2:00 PM. The estimated award date for this project is February 2019.
ATTENTION TO OFFEROR(s)/CONTRACTOR(s): EFFECTIVE MARCH 22, 2018, YOU MUST SUBMIT A NOTARIZED LETTER APPOINTING THE AUTHORIZED ENTITY ADMINISTRATOR BEFORE YOUR REGISTRATION WILL BE ACTIVATED. THIS REQUIREMENT NOW APPLIES TO BOTH NEW AND EXISTING ENTITIES. MAKE SURE YOUR SAM PROFILE INCLUDES "ALL AWARDS" AND NOT JUST "FEDERAL ASSISTANCE AWARDS" AS THIS OPTION IS ONLY FOR GRANTS AND COOPERATIVE AGREEMENTS. PLEASE VISIT WWW.SAM.GOV FOR MORE INFORMATION.

All offerors are encouraged to visit the Federal Business Opportunities website at https://www.fbo.gov to view and download the plans, specification and or any amendments for this procurement. Plans and specifications will not be available in paper format or on compact disc. To register as an "Interested Vendor", visit https://www.fbo.gov . Offerors must be registered with the Systems for Award Management (SAM), in order to receive a Government contract award. To register, the SAM Internet address is: https://www.sam.gov .
The Contract Specialist for this solicitation will be Ms. Lucille Smith, (409) 766-3845; E-mail: Lucille.r.smith@usace.army.mil . For technical information about this solicitation, please contact Mr. Charles Wheeler at (409) 766-3128 or Ms. Terri Carlson at (409) 766-3176, between the hours of 8:00 AM to 4:00 PM, Monday through Friday, excluding Federal Holidays.

.