WBV083-11-H-0023.pdf

Task Order for HubZone MATOC

West Bank and Vicinity, Hurricane Protection Project, East and West of Algiers Canal, Orleans Parish, Louisiana, WBV-83 - N.O. Sewerage & Water Board (S&WB) 42" Sewer Force Main & 12" Waterline; ED 12-064

This is a HubZone MATOC LOW PRICE procurement.

The work consists of construction of temporary retaining structure/temporary flood protection (TRS/TFP), clearing and grubbing, embankment placement, degrading of the existing levee, structural excavation and backfill, construction of concrete T-walls, driving of steel sheet pile and H-piles, modification to existing utilities, turf establishment and maintenance, concrete slope paving, and other incidental work thereto.

The deadline for submitting questions regarding the subject solicitation is November 28, 2012, 2:00 PM CST. Any questions received after this deadline will not be considered.

WBV083-11-H-0023

21 November 2012 1

ED-12-064

U.S. ARMY ENGINEER DISTRICT, NEW ORLEANS

7400 LEAKE AVE.

NEW ORLEANS, LA 70118-3651

U.S. ARMY ENGINEER DISTRICT, NEW ORLEANS

ATTN: CEMVN-CT-E Rachel Spears 7400 LEAKE AVE, Room 155A

NEW ORLEANS, LA 70118-3651

W912P8

Rachel W. Spears (504) 862-1561

10 150

1 1400 December 7, 2012

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying no., date):

1. SOLICITATION NO. 3. DATE ISSUED PAGE OF PAGES

4. CONTRACT NO. 5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

7. ISSUED BY 8. ADDRESS OFFER TO

A. NAME B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

12B. CALENDAR DAYS 12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

13. ADDITIONAL SOLICITATION REQUIREMENTS:

(If "YES," indicate within how may calendar days after award in Item 12B.)

A. Sealed offers in original and (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

2. TYPE OF SOLICITATION

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

CODE

9. FOR INFORMATION

CALL:

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

11. The Contractor shall begin performance within

SEALED BID (IFB)

NEGOTIATED (RFP)

award, notice to proceed. This performance period is mandatory, negotiable. (See

YES NO

is, is not required.

NSN 7540-01-155-3212

STANDARD FORM 1442 (REV. APR 1985)

Prescribed by GSA APD PE v1.00 FAR (48 CFR) 53.236-1 (d) calendar days and complete it within calendar days after receiving copies to perform the work required are due at the place specified in Item 8 by calendar days for Government acceptance after the date offers are due will not be considered and

CAGE CODE NO. DUNS NO.

WEST BANK AREA OFFICE

U.S. ARMY CORPS OF ENGINEERS

5750 BAYOU ESTATES BLVD

MARRERO, LA 70073

USAED NEW ORLEANS

C/O USACE, FINANCE CENTER (UFC)

ATTN: CEFC-AO-P

5720 INTEGRITY DRIVE

MILLINGTON, TN 38054-5005

21. ITEMS ACCEPTED:

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NO. (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

FACILITY CODE CODE

20B. SIGNATURE 20C. OFFER DATE

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BY

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30B. SIGNATURE 30C. DATE

BY

29. AWARD (Contractor is not required to sign this document.) Your offer28. NEGOTIATED AGREEMENT Contractor is required to sign this

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

document and return Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

OFFER (Must be fully completed by offeror) on this solicitation is hereby accepted as to the items listed. This award con-summates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

AWARD (To be completed by Government)

TO SIGN (Type or print)

DATE

(Type or print)

The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within (Insert any number equal to or greater than the minimum require-ment stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.

17.

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

AMENDMENT NO.

22. AMOUNT

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 Copies unless otherwise specified)

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

CODE

31B. UNITED STATES OF AMERICA 31C. AWARD

10 U.S.C 2304(c) ( ) 41 U.S.C 253(c) ( )

STANDARD FORM 1442 BACK (REV. APR 1985)

APD PE v1.00

DATE

calendar days after the date offers are due.

copies to issuing office.)

General Decision Number: LA120007 09/28/2012 LA7

Superseded General Decision Number: LA20100008

State: Louisiana

Construction Type: Heavy

Counties: Jefferson, Orleans, Plaquemines, St Bernard, St Charles, St James, St John the Baptist and St Tammany Counties in Louisiana.

HEAVY CONSTRUCTION PROJECTS (Includes flood control, water & sewer lines, and water wells. Also includes elevated storage tanks in all listed parishes except Plaquemines and St. James.

Excludes industrial construction-chemical processing, power plants, and refineries.)

Modification Number Publication Date 0 01/06/2012 1 03/09/2012 2 04/13/2012 3 06/01/2012 4 06/15/2012 5 07/06/2012 6 07/27/2012 7 08/03/2012 8 09/28/2012

* CARP0729-001 07/01/2012

Rates Fringes

MILLWRIGHT.......................$ 25.80 9.50

CARP1846-006 07/01/2012

Rates Fringes

CARPENTER

(formbuilding/formsetting and Piledrivers).....................$ 22.21 7.75

ELEC0130-005 06/01/2012

JEFFERSON, ORLEANS, PLAQUEMINES, ST. BERNARD, ST. CHARLES, ST.

JAMES, AND ST. JOHN THE BAPTIST PARISHES

Rates Fringes

ELECTRICIAN (including low voltage wiring)..................$ 27.85 9.22

* ELEC1077-002 09/01/2012

ST. TAMMANY PARISH

ELECTRICIAN (including low voltage wiring)..................$ 22.50 7.17

ENGI0406-018 07/01/2009

Rates Fringes

OPERATOR: Power Equipment Bulldozer...................$ 21.26 6.70 Mechanic....................$ 23.31 6.70

PLAS0567-003 07/01/2012

JEFFERSON, ORLEANS, PLAQUEMINES, ST. BERNARD, ST. CHARLES, ST.

JOHN THE BAPTIST, and ST. TAMMANY PARISHES

Cement Mason/Concrete Finisher...$ 20.58 5.69

PLAS0812-003 06/01/2004

ST. JAMES PARISH

Rates Fringes

Cement Mason/Concrete Finisher...$ 21.85 0.00

PLUM0060-002 06/04/2012

JEFFERSON, ORLEANS, PLAQUEMINES, ST. BERNARD, ST. CHARLES, ST.

JAMES (Southeastern Portion), ST. JOHN THE BAPTIST, and ST.

TAMMANY PARISHES

Plumbers (excluding pipe laying)..........................$ 26.88 10.42

PLUM0198-005 07/01/2012

ST. JAMES PARISH (Northwestern Portion)

Rates Fringes

PLUMBER (excluding pipe laying)..........................$ 24.54 10.38

SULA2004-007 05/13/2004

Rates Fringes

CARPENTER (all other work).......$ 13.75 2.60

Laborers:

Common/Landscape............$ 9.88 0.00

Fence.......................$ 11.24 0.00 Flagger.....................$ 8.58 0.00 Mason Tender................$ 7.25 0.00 Pipelayer...................$ 9.84 0.00

PIPEFITTER (excluding pipelaying)......................$ 17.52 4.51

Power equipment operators:

Backhoe/Excavator...........$ 14.42 0.00 Crane.......................$ 16.34 3.30 Dragline....................$ 16.50 0.00 Front End Loader............$ 13.89 0.00 Oiler.......................$ 10.03 0.00

Truck drivers:

Dump........................$ 11.01 0.00 Pickup......................$ 12.25 0.00

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is union or non-union.

Union Identifiers

An identifier enclosed in dotted lines beginning with characters other than "SU" denotes that the union classification and rate have found to be prevailing for that classification. Example: PLUM0198-005 07/01/2011. The first four letters , PLUM, indicate the international union and the four-digit number, 0198, that follows indicates the local union number or district council number where applicable , i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. The date, 07/01/2011, following these characters is the effective date of the most current negotiated rate/collective bargaining agreement which would be July 1, 2011 in the above example.

Union prevailing wage rates will be updated to reflect any changes in the collective bargaining agreements governing the rate.

0000/9999: weighted union wage rates will be published annually each January.

Non-Union Identifiers

Classifications listed under an "SU" identifier were derived from survey data by computing average rates and are not union rates; however, the data used in computing these rates may include both union and non-union data. Example: SULA2004-007 5/13/2010. SU indicates the rates are not union rates, LA indicates the State of Louisiana; 2004 is the year of the survey; and 007 is an internal number used in producing the wage determination. A 1993 or later date, 5/13/2010, indicates the classifications and rates under that identifier were issued as a General Wage Determination on that date.

Survey wage rates will remain in effect and will not change until a new survey is conducted.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

NOTICE TO CONTRACTOR

This solicitation contains two sets of goals for minority participation in construction crafts on this contract. They are the New Orleans Hometown Plan and the New Orleans Standard Metropolitan Statistical Area (SMSA).

Contractor will determine the goals applicable to him by the following:

Hometown Plan applies only to those contractors who are signatory to the Hometown Plan and utilizing crafts signatory to the plan.

New Orleans Standard Metropolitan Statistical Area (SMSA) applies to all contractors in the New Orleans SMSA area not signatory to the Hometown Plan, or utilizing crafts not signatory to the plan.

Federal Register/Vol. 45, No. 194/Friday, October 3, 1980

SOLICITATION PROVISION

NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION

TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY

The Bidder’s attention is called to “EQUAL OPPORTUNITY” and “LOCAL AFFIRMATIVE ACTION PLAN” clauses of the contract.

The acceptable ranges of minority manpower utilization, expressed in percentage terms, are as follows:

Goals for Minority Goals for Female Timetables Participation for Participation in

Each Trade______ Each Trade_____

Indefinitely 20% - 23 % 6.9%

The Bidder shall, within 5 days after a request therefor by the Contracting Officer of his duly authorized representative, submit the following information.

(a) A list of the construction trades he intends to use, either directly or through subcontractors at any tier, in the performance of work covered by this solicitation;

(b) A list of the labor organizations with which he has collective bargaining agreements and which are signatories to the Hometown Plan with respect to trades for which specific commitments to goals of minority manpower utilization are set forth in the Hometown Plan;

(c) A list of the labor organizations with which he has collective bargaining agreements and which are not signatories to the Hometown Plan or which are signatories thereto but with respect to trades for which no specific commitments to goals of minority manpower utilization are set forth in the Hometown Plan, and

(d) A list of all current construction work or contracts to which he is a party in any capacity in the covered area.

As used in this NOTICE and the contract to result from this solicitation:

(a) “Hometown Plan” or “Plan” means the NEW ORLEANS Plan, consisting of “An Agreement for Implementation of Employment of Minorities in the New Orleans Building Construction Industry.”

(b) “The covered area” means Orleans, Jefferson, St. Bernard, St.

Tammany, St. Charles, St. John, Lafourche, Plaquemines, Washington, Terrebonne, Tangipahoa*, Livingston** and St.

James*** Parishes, Louisiana.

(c) “Director, OFCC” means the Director, Office of Federal Contract Compliance, United States Department of Labor, or any person to whom he delegates authority; and

(d) “Minority” means Negro, Spanish-surnamed American, Oriental, and American Indian, and includes both men and women.

* Area covered is east of the Illinois Central Railroad.

** Area covered is southeast of the line from a point of the Livingston &

Tangipahoa Parish line adjacent from New Orleans and Baton Rouge.

*** Area covered is southeast of a line drawn from the town of Gramercy to the point of intersection of St. James, Lafourche and Assumption Parishes.

NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE

EQUAL EMPLOYMENT OPPORTUNITY (APRIL 1984)

(a) The offeror’s attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor’s aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for Minority Participation Goals for Female Participation for Each Trade for Each Trade

SMSA Counties MS 19.2% 6.9% SMSA Counties LA 31.0% 6.9% Non-SMSA Counties 27.7% 6.9%

These goals are applicable to all the Contractor’s construction work performed in the covered area. If the Contractor performs construction work in the geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed.

Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Program office.

(c) The Contractor’s compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled “Affirmative Action Compliance Requirements for Construction,” and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects.

The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor’s goals shall be a violation of the contract. Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Director, Office of Federal Contract Compliance Programs, within 10 working days following award of a construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notifications shall list the –

(1) Name, address, and telephone number of the subcontractor;

(i) Employer identification number of the subcontractor;

(2) Estimated dollar amount of the subcontract;

(3) Estimated starting and completion dates of the subcontract;

and

(4) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the “covered area” is (FAR 52.222-23) Economic Area 113, New Orleans, LA as follows:

Standard Metropolitan Statistical Area

(SMSA) Counties:

0920 Biloxi – Gulfport, MS - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - 19.2% MS Hancock; MS Harrison; MS Stone

5560 New Orleans, LA - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - 31.0% LA Jefferson; LA Orleans; LA St. Bernard; LA St. Tammany

Non-Standard Metropolitan Statistical Area

(Non-SMSA) Counties - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - 27.7% LA Assumption; LA Lafourche; LA Plaquemines; LA St. Charles;

LA St. James; LA St. John the Baptist; LA Tangipahoa;

LA Terrebonne; LA Washington; MS Forrest; MS Lamar; MS Marion;

MS Pearl River; MS Perry; MS Pike; MS Walthall

ED 12-064

WBV083-11-H-0023

US Army Corps Of Engineers

New Orleans District

West Bank & Vicinity, Hurricane Protection Project, East & West of Algiers Canal, Orleans Parish, Louisiana

WBV-83 N.O. Sewerage & Water Board (S&WB) 42” Sewer Force Main & 12” Waterline

Construction Solicitation And Specifications

September 2012

ED 12-064

DEPARTMENT OF THE ARMY

NEW ORLEANS DISTRICT, CORPS OF ENGINEERS

P.O. BOX 60267

NEW ORLEANS, LOUISIANA 70160-0267

REPLY TO November 21, 2012

ATTENTION OF:

SOLICITATION: Task Order for HubZone MATOC WBV083-11-H-0023

FOR: West Bank & Vicinity, Hurricane Protection Project, East & West of Algiers Canal, Orleans Parish, Louisiana, WBV-83 N.O. Sewerage & Water Board (S&WB) 42” Sewer Force Main & 12” Waterline

TO OPEN: Proposals are due by December 7, 2012 at 2:00 PM, Local Time and Place, New Orleans, LA

I. NOTE THE AFFIRMATIVE ACTION PROGRAM REQUIREMENT OF THE EQUAL

OPPORTUNITY CLAUSE WHICH MAY APPLY TO THE CONTRACT RESULTING FROM

THIS SOLICITATION.

II. NOTE THE CERTIFICATION OF NONSEGREGATED FACILITIES IN THIS SOLICITATION.

Bidders, offerors and applicants are cautioned to note the "Certification of Non-segregated Facilities" in the solicitation. Failure of a bidder or offeror to agree to the certification will render his bid or offer non-responsive to the terms of solicitations involving awards of contracts exceeding $10,000 which are not exempt from the provisions of the Equal Opportunity clause.

III. Prospective contractors must be registered in the System for Award Management (SAM). See

FAR Clause 52.204-99 for required information. The website for SAM is https://www.sam.gov.

SAM registration replaces some of the Representations and Certifications normally found in Section 00600. You will be required to provide your company’s Dun and Bradstreet number. If you do not already have a D&B number, one can be obtained simply by calling Dun and Bradstreet at (800) 333-0505.

BIDDERS MUST PROVIDE FULL, ACCURATE AND COMPLETE INFORMATION AS REQUIRED BY

THIS SOLICITATION AND ITS ATTACHMENTS. THE PENALTY FOR MAKING FALSE STATEMENTS

IN BIDS IS PRESCRIBED IN 18 U.S.C. 1001. (FAR 52.214-4 APR 1984)

DESCRIPTION AND MAGNITUDE OF WORK: This project includes construction of temporary retaining structure/ temporary flood protection (TRS/TFP), clearing and grubbing, embankment placement, degrading of the existing levee, structural excavation and backfill, construction of steel A-frame floodwalls, driving of sheet pile and H-piles, modification to existing utilities, turf establishment and maintenance, concrete slope paving, and other incidental work.

CAUTION TO BIDDERS: In delivery of hand-carried bids, bidders are cautioned to allow sufficient time for delays which may be encountered as a result of frequent trains which are subject to block all access roads to place of bid opening for various lengths of time. Such delays DO NOT permit acceptance or consideration of late bids.

NOTE: ALL WORK UNDER THESE SPECIFICATIONS SHALL BE PERFORMED IN ACCORDANCE

WITH THE PROVISIONS OF EM 385-1-1 "CORPS OF ENGINEERS SAFETY AND HEALTH

REQUIREMENTS MANUAL", DATED September 2008.

http://www.ccr.gov/

PTC-i ED 12-064

PROJECT TABLE OF CONTENTS

Division 00 – PROCUREMENT AND CONTRACTING REQUIREMENTS

00010 Solicitation, Offer and Award (SF-1442) Bidding Schedule 00700 Contract Clauses

Division 01 - GENERAL REQUIREMENTS

01100 General Provisions 01 32 16.00 20 Construction Progress Documentation 01 33 00 Submittal Procedures 01 42 00 Sources for Reference Publications 01 45 02.00 10 Quality Control System (QCS) 01 45 04.00 10 Contractor Quality Control 01 53 00.02 12 Temporary Retaining Structures 01 57 20.00 12 Environmental Protection 01 57 23.00 12 Storm Water Pollution Prevention Plan 01 57 23.01 12 Truck Wash-Down Racks 01 78 02.00 10 Closeout Submittals

Division 03 – CONCRETE

03 15 13.00 12 Waterstops

Division 05 – METALS

05 50 03.00 12 Metalwork Fabrication, Machine Work, and Miscellaneous

Provisions

Division 09 – FINISHES

09 97 02 03 12 Painting: Coal Tar Epoxy Systems

Division 31 – EARTHWORK

31 11 00.00 12 Clearing and Grubbing 31 23 00.00 12 Excavation 31 23 16.16 12 Structural Excavation and Backfill 31 23 19.00 12 Dewatering

PTC-ii ED 12-064

31 24 00.00 12 Embankment 31 41 16.00 12 Steel Sheet Piling 31 62 16.00 12 Steel H-Piles

Division 32 – EXTERIOR IMPROVEMENTS

32 92 19.04 12 Turf Establishment and Maintenance

Division 33 – UTILITIES

33 05 00.00 12 Modifications to Existing Utilities 33 11 00 Water Distribution Systems

Division 35 – WATERWAY AND MARINE CONSTRUCTION

35 43 38.00 12 Concrete Scour Protection

00010-3 Ed 12-064

SECTION 00010 – BIDDING SCHEDULE

West Bank & Vicinity, Hurricane Protection Project, East & West of Algiers Canal, Orleans Parish, Louisiana, WBV-83 N.O. Sewerage & Water Board (S&WB) 42” Sewer Force Main & 12” Waterline

Item DESCRIPTION Estimated Quantity Unit Unit Price Estimated Amount

BASE WORK

0001 Mobilization and Demobilization 1 LS

Temporary Retaining Structures/Temporary Flood Protection

1 LS

0003 Silt Fences 2,000 LF

0004 Truck Wash-Down Racks 1 LS

0005 Clearing and Grubbing 1 LS

0006 Structural Excavation 1 LS

0007 Structural Backfill 1 LS

0008 Construction Dewatering 1 LS

009 Embankment, Compacted Fill 1,154 CY

0010 Sheet Piling, Steel, Type PZ-27 8,910 SF

00011 Steel H-Piling HP 14 X 73 1,756 LF

0012 Seeding and Mulching 2 AC

0013++ Lime Soil Amendment 2 TON

0014++ Sulfur Soil Amendment 1 TON

0015 Fertilizer

0015AA First 120 LBS 120 LBS

0015AB All Over 120 LBS 100 LBS

0016 Modifications to Existing Utilities

(42" SFM) 1 LS

0017 12" Waterline 1 LS

0018 Concrete Scour Protection 1,740 SY

TOTAL BASE WORK: $

00010-4 Ed 12-064

OPTION WORK

(WBV-47.1 Side @ 12” Waterline)

0019 Mobilization and Demobilization 1 LS

0020 Silt Fences 1,000 LF

0021 Clearing and Grubbing 1 LS

0022 Structural Excavation 1 LS

0023 Structural Backfill 1 LS

0024 Embankment, Compacted Fill 2,460 CY

0025 Seeding and Mulching 1 AC

0026++ Lime Soil Amendment 1 TON

0027++ Sulfur Soil Amendment 0.5 TON

0028 Fertilizer

0028AA First 60 LBS 60 LBS

0028AB All Over 60 LBS 50 LBS

0029 12" Waterline 1 LS

TOTAL OPTION WORK $

TOTAL BASE WORK+OPTION WORK $

++Items not subject to the requirements of FAR 52.211-18 VARIATION IN ESTIMATED QUANTITY.

Award will be made as a whole to one bidder.

NOTE 1: Bidders shall furnish unit prices for each item listed in the Schedule requiring a unit price. If the bidder fails to insert a unit price in the appropriate blank for required item(s), but does furnish an extended total, or an estimated amount for such item(s), the Government shall deem the unit price to be the quotient obtained by dividing the extended amount for that line item by the quantity. IF A BIDDER OMITS BOTH THE UNIT PRICE AND THE EXTENDED

TOTAL OR ESTIMATED AMOUNT FOR ANY ITEM, ITS BID SHALL BE

DECLARED NON-RESPONSIVE AND THEREFORE INELIGIBLE FOR

AWARD.

NOTE 2: Any bid may be rejected if the Contracting Officer determines in writing that it is unreasonable as to price. Unreasonableness of price includes not only total price of bid, but the price for individual line items as well. Any bid may be rejected if the prices for any line items or sub line items are materially unbalanced (See FAR 14.404-2).

00010-5 Ed 12-064

NOTE 3: THE NOTICE TO PROCEED (NTP): The successful bidder is advised that performance and payment bonds shall be submitted in accordance with the time frame in block 12B of SF 1442. The NTP will be issued immediately after verification of acceptable performance and payment bonds. Within seven (7) days after issuance of the NTP, the Contractor shall initiate a meeting to discuss the submittal process with the Area or Resident Engineer or his authorized representative. Physical work cannot start until the Accident Prevention Program, Contractor Quality Control Plan, and other submittals which may be required, have been submitted and approved and all preliminary meetings called for under the contract, have been conducted.

NOTE 4: OPTION WORK ITEMS. The Government may require the delivery of the numbered line item(s), identified in the schedule as OPTION WORK Items, in the quantities and prices stated in the schedule. The Contracting Officer may exercise the OPTION WORK Items by written notice to the Contractor. Bidders shall bid on all items including OPTION WORK Items (see “Evaluation of Options” FAR 52.217-5). Failure to bid on all items will result in a non-responsive bid.

NOTE 5: TIME ADJUSTMENT IN THE EVENT OF THE EXERCISE OF OPTION

WORK. In the event that the OPTION WORK item is exercised under the terms of the contract, the time required for completion of the contract will not be adjusted from the original contract duration of 150 calendar days since the optional work can be done concurrently NOTE 6 EVALUATION OF OPTIONS (FAR 52.217-5 JUL 1990). The Government will evaluate offers for award purposes by adding the total price for all options to the total price for this basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

NOTE 7: RAPID VENDOR PAYMENT: Web based instructions for the submission of invoices;

http://www.mvn.usace.army.mil/ebs/rapid_vendor_payment.asp http://www.mvn.usace.army.mil/ebs/rapid_vendor_payment.asp

00010-6 Ed 12-064

EVALUATION OF SUBDIVIDED ITEMS. (EFARS 52.211-5000 - MAR 95).

Item Nos. 0015 and 0028 is subdivided into two or more estimated quantities and are to be separately priced. The Government will evaluate each of these items on the basis of total price of its sub-items.

(End of Clause)

VARIATIONS IN ESTIMATED QUANTITIES - SUBDIVIDED ITEMS. (EFARS

52.211-5001 - MAR 95).

The Variations in Estimated Quantities Subdivided Items clause is applicable only in Item Nos. 0015 and 0028.

a. Variations from the estimated quantity in the actual work performed under any second or subsequent sub-item or elimination of all work under such a second or subsequent sub-item will not be the basis for an adjustment in contract unit price.

b. Where the actual quantity of work performed for Item Nos. 0015 and 0028 is less than 85% of the quantity of the first sub-item listed under such items, the Contractor will be paid at the contract unit price for that sub-item for the actual quantity of work performed and, in addition, an equitable adjustment in contract price shall be made in accordance with the clause FAR 52.211-18, Variation in Estimated Quantity .

c. If the quantity of work performed under Item Nos. 0015 and 0028 exceeds 115% or is less than 85% of the total estimated quantity of the sub-items under that item, and/or if the quantity of work performed under the second sub-item or any subsequent sub-item under Item No. NONE exceeds 115% or is less than 85% of the estimated quantity of any such sub-item, and if such variation causes an increase or a decrease in the time required for performance of this contract, the contract completion time will be adjusted in accordance with the clause FAR 52.211-18, Variation in Estimated Quantity.

00700-a ED 12-064

Section Table of Contents

SECTION 00700 – CONTRACT CLAUSES

1. COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK 1

2. LIQUIDATED DAMAGES 1

3. CONTRACT DRAWINGS AND SPECIFICATIONS 1

4. EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE 3

5. PHYSICAL DATA 4

6. LAYOUT OF WORK 5

7. QUANTITY SURVEYS 5

8. PAYMENT FOR MOBILIZATION AND DEMOBILIZATION 6

9. PERFORMANCE OF WORK BY THE CONTRACTOR 6

10 SCHEDULES FOR CONSTRUCTION CONTRACTS 6

11. OBSTRUCTION OF NAVIGABLE WATERWAYS 7

00700-1 ED 12-064

SECTION 00700 – CONTRACT CLAUSES

1. COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

(FAR 52.211-10 - APR 1984)

The Contractor shall be required to

(a) Commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed,

(b) Prosecute the work diligently, and

(c) Complete the entire work ready for use not later than 150 calendar days after the date of receipt by him of notice to proceed. The time stated for completion shall include final cleanup of the premises.

NOTE. The Contractor is hereby informed that time allowed for completion of work has been established as the shortest reasonable duration and that he/she shall make any and all provisions necessary (multiple crews, overtime, concurrent operations, etc.) to accomplish the work within the available time period.

2. LIQUIDATED DAMAGES - CONSTRUCTION (FAR 52.211-12 – SEPT 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,655.00 per day for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

3. CONTRACT DRAWINGS AND SPECIFICATIONS (DFARS 252.236-7001 –

AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall --

00700-2 ED 12-064

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general --

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

Project Title File Name Drawing No(s).

West Bank & Vicinity, H-4-47692 G-001 thru G-006, B-001 Hurricane Protection Project, thru B-040, C-001, C-002, East & West of Algiers Canal, C-101, C-101A, C-102, Orleans Parish, Louisiana, C-201 thru C-204, WBV-83 N.O. Sewerage & Water Board C-301 thru C-310, C-501, (S&WB) 42” Sewer Force Main & 12” Waterline C-502, S-501 thru S-506

NOTE: PLAN DRAWING SIGNATURES: The plan drawings accompanying this solicitation have been submitted and approved by the individuals shown in the title blocks on the plans. The actual signatures of the individuals shown on the plans are on file and are available for inspection at U.S. Army Engineer District, 00700-3 ED 12-064

New Orleans, Corps of Engineers, Attn: CEMVN-ED, P.O. Box 60267, New Orleans, Louisiana 70160-0267, and access thereto may be had upon request.

4. EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (EFARS

52.231-5000 - MAR 95)

(a) This clause does not apply to terminations. See EFARS 52.249-5000, Basis For Settlement of Proposals, and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable condition, owned or controlled and furnished by a Contractor or Subcontractor at any tier shall be based on actual cost data for each piece of equipment or groups of similar serial and series for which the Government can determine both ownership and operating costs from the Contractor's accounting records. When both ownership and operating costs cannot be determined for any piece of equipment or groups of similar serial or series equipment from the Contractor's accounting records, costs for that equipment shall be based upon the applicable provisions of EP 1110-1-8, "Construction Equipment Ownership and Operating Expense Schedule," Region III. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the Contracting Officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply. For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d) (ii) and FAR 31.205-36. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established practice of leasing the same or similar equipment to unaffiliated lessees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the small purchase threshold, the Contracting Officer shall request the Contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

(End Of Clause)

NOTE1: Costs for repairs or overhauling are not allowed.

00700-4 ED 12-064

NOTE 2: A copy of the "EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE CD can be obtained from the Government Printing Office (GPO) by calling (202)512-1800 or through the Internet site www.gpoaccess.gov.

Also any references in the paragraph to the manual should be changed to reference the CD.

5. PHYSICAL DATA (FAR 52.236-4 - APR 1984)

Data and information furnished or referred to below is for the Contractor's information.

The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by surveys and borings. Field notes, graphic boring logs, field and laboratory test results, and other data on which this information is based are available at U.S. Army Engineer District, New Orleans, Corps of Engineers, Attn: CEMVN-ED, P.O. Box 60267, New Orleans, Louisiana 70160-0267, and access thereto may be had upon request.

(b) Weather Conditions. Data on weather conditions may be obtained from the National Weather Service.

(c) Transportation Facilities.

1. Primary access to and from the site shall be via General Degaulle, Tullis Drive, and Woodlawn Hwy (La Hwy 407). Alternate access shall be Tall Spruce Drive. Barge access shall be via Algiers Canal and the Mississippi River. Access to both project sites will also be via the existing levee crown.

2. The Contractor shall take (1) pre- and post construction photographs to document existing conditions and restoration thereof; (2) take pre- and post-construction levee cross sections at 25 foot intervals to document restoration thereof; (3) fully restore the levee embankment sections to as shown in the plans; and (4) perform full turf establishment on all existing levees, access roads, and staging, storage and office trailer areas.

(d) The Contractor is responsible for keeping streets free of mud, tracking, spillage and/or other surface pollution from his equipment and operations.

Contractor shall take whatever means required (i.e., street cleaners, manual labor, water trucks with sprayers) as often as needed to maintain clean streets near the work site. All debris resulting from street cleaning operations shall be hauled off-site and disposed of properly.

(e) Estimates of quantities involved in certain items of work for which bids are being solicited on a lump sum or job basis have been made for the use of the

00700-5 ED 12-064

Government. Copies of these quantity estimates may be viewed/obtained by contacting Thomas Murphy, Chief Cost Engineering and Specifications, same address as stated in subparagraph (a) above. It is expressly understood that the accuracy of these estimates is in no way warranted and that the furnishing of this information to a bidder will not relieve him of his responsibility to estimate the quantities involved.

6. LAYOUT OF WORK (FAR 52.236-17 - APR 1984)

The Contractor shall lay out its work from Government-established base lines and benchmarks indicated on the drawings, and shall be responsible for all measurements in connection with the layout. The Contractor shall furnish, at its own expense, all stakes, templates, platforms, equipment, tools, materials, and labor required to lay out any part of the work. The Contractor shall be responsible for executing the work to the lines and grades that may be established or indicated by the Contracting Officer.

The Contractor shall also be responsible for maintaining and preserving all stakes and other marks established by the Contracting Officer until authorized to remove them. If such marks are destroyed by the Contractor or through its negligence before their removal is authorized, the Contracting Officer may replace them and deduct the expense of the replacement from any amounts due or to become due to the Contractor.

7. QUANTITY SURVEYS (FAR 52.236-16 - APR 1984)

(a) Quantity surveys will be conducted, and the data derived from these surveys shall be used in computing the quantities of work performed and the actual construction completed and in place.

(b) The Government shall conduct the original and final surveys and make the computations based on them. The Contractor shall conduct the surveys for any periods for which progress payments are requested and shall make the computations based on these surveys. All surveys conducted by the Contractor shall be conducted under the direction of a representative of the Contracting Officer, unless the Contracting Officer waives this requirement in a specific instance.

(c) Promptly upon completing a survey, the Contractor shall furnish the originals of all field notes and all other records relating to the survey or to the layout of the work to the Contracting Officer, who shall use them as necessary to determine the amount of progress payments. The Contractor shall retain copies of all such material furnished to the Contracting Officer.

00700-6 ED 12-064

8. PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (DFARS 252.236-

7004 - DEC 1991)

(a) The Government will pay all costs for the mobilization and demobilization of all of the Contractor's plant and equipment at the contract lump sum price for this item.

(1) Sixty percent (60%) of the lump sum price upon completion of the Contractor's mobilization at the work site.

(2) The remaining forty percent (40%) upon completion of demobilization.

(b) The Contracting Officer may require the Contractor to furnish cost data to justify this portion of the bid if the Contracting Officer believes that the percentages in paragraphs (a)(1) and (a)(2) of this clause do not bear a reasonable relation to the cost of the work in this contract.

(1) Failure to justify such price to the satisfaction of the Contracting Officer will result in payment, as determined by the Contracting Officer, of-

(i) Actual mobilization costs at completion of mobilization;

(ii) Actual demobilization costs at completion of demobilization; and

(iii) The remainder of this item in the final payment under this contract.

(2) The Contracting Officer's determination of the actual costs in paragraph (b)(1) of this clause is not subject to appeal.

9. PERFORMANCE OF WORK BY THE CONTRACTOR (FAR 52.236-1 - APR

1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least twenty percent (20%) of the total amount of the work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract, if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

10. SCHEDULES FOR CONSTRUCTION CONTRACTS (FAR 52.236-15 - APR

1984)

(a) The Contractor shall, within five days after the work commences on the contract or another period of time determined by the Contracting Officer, prepare and submit to the Contracting Officer for approval three copies of a practicable schedule showing the order in which the Contractor proposes to perform the

00700-7 ED 12-064

work, and the dates on which the Contractor contemplates starting and completing the several salient features of the work (including acquiring materials, plant, and equipment). The schedule shall be in the form of a progress chart of suitable scale to indicate appropriately the percentage of work scheduled for completion by any given date during the period. If the Contractor fails to submit a schedule within the time prescribed, the Contracting Officer may withhold approval of progress payments until the Contractor submits the required schedule.

(b) The Contractor shall enter the actual progress on the chart as directed by the Contracting Officer, and upon doing so shall immediately deliver three copies of the annotated schedule to the Contracting Officer. If, in the opinion of the Contracting Officer, the Contractor falls behind the approved schedule, the Contractor shall take steps necessary to improve its progress, including those that may be required by the Contracting Officer, without additional cost to the Government. In this circumstance, the Contracting Officer may require the Contractor to increase the number of shifts, overtime operations, days of work, and/or the amount of construction plant, and to submit for approval any supplementary schedule or schedules in chart form as the Contracting Officer deems necessary to demonstrate how the approved rate of progress will be regained.

(c) Failure of the Contractor to comply with the requirements of the Contracting Officer under this clause shall be grounds for a determination by the Contracting Officer that the Contractor is not prosecuting the work with sufficient diligence to ensure completion within the time specified in the contract. Upon making this determination, the Contracting Officer may terminate the Contractor’s right to proceed with the work, or any separable part of it, in accordance with the default terms of this contract.

End of Clause

NOTE: See Section 01 32 16.00 20 “CONSTRUCTION PROGRESS DOCUMENTATION” for additional construction schedule requirements.

11. OBSTRUCTION OF NAVIGABLE WATERWAYS (DFARS 252.236-7002 - DEC

91)

(a) The Contractor shall:

(1) Promptly recover and remove any material, plant, machinery, or appliance which the Contractor loses, dumps, throws overboard, sinks, or misplaces, and which, in the opinion of the Contracting Officer, may be dangerous to or obstruct navigation;

(2) Give immediate notice, with description and locations of any such

00700-8 ED 12-064

obstructions, to the Contracting Officer; and

(3) When required by the Contracting Officer, mark or buoy such obstructions until the same are removed.

(b) The Contracting Officer may:

(1) Remove the obstructions by contract or otherwise should the Contractor refuse, neglect, or delay compliance with paragraph (a) of this clause; and

(2) Deduct the cost of removal from any monies due or to become due to the Contractor; or

(3) Recover the cost of removal under the Contractor's bond.

(c) The Contractor's liability for the removal of a vessel wrecked or sunk without fault or negligence is limited to that provided in Sections 15, 19, and 20 of the River and Harbor Act of March 3, 1899 (33 U.S.C.410 et.seq.).

01100-a Ed 12-064

Section Table of Contents

SECTION 01100 - GENERAL PROVISIONS

1. TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER 1

2. DAMAGE TO WORK 2

3. SAFETY PROVISIONS 2

4. INSPECTOR'S FIELD OFFICE 7

5. PROJECT SIGN 8

6. RIGHTS-OF-WAY 9

7. CERTIFICATES OF COMPLIANCE 10

8. ENVIRONMENTAL LITIGATION 10

9. UTILITIES AND IMPROVEMENTS 11

10. PERMISSIBLE HOURS OF WORK 14

11. VIBRATION MONITORING 14

12. AGGREGATE SOURCES 15

13. STONE SOURCES 17

14. CLAY SOURCES 19

15. FORMAT OF SURVEYS 22

16. PROJECT BENCHMARKS 23

17. COMMERCIAL WARRANTY 23

18. ACCESS PLAN 24

19. TEMPORARY FLOOD PROTECTION 24

20. FIELD VERIFICATION OF UTILITY LOCATIONS 24

21. SPECIAL WORK REQUIREMENTS (AT FACILITIES) 24

01100-1 Ed 12-064

SECTION 01100 - GENERAL PROVISIONS

1. TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

(a) This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance with the Contract Clause in Section 00700, entitled Default (Fixed Price Construction) (FAR 52.249-10). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied.

(1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

(2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

(b) The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) for temperature, precipitation and wet ground conditions or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities. Also considered in the chart below was wind, fog, high or low tides, etc.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORK DAYS

BASED ON (5) DAY WORK WEEK

Jan

Feb

Mar

Apr

May

Jun

Jul

Aug

Sep

Oct

Nov

Dec

(c) Upon receipt of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor shall record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor's scheduled work day.

(d) The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), and shall be calculated chronologically from the first to the last day of each month, and shall…