W91QV124R0121 Elevator Lighting.pdf

0012129161

B64 Elevator Lighting This is a non-personal services contract to repair the elevator lighting electrical issues at JBMHH Fort McNair Building 64. The Government shall not exercise any supervision or control over the contract service providers performing the services herein. Such contract service providers shall be accountable solely to the Contractor w ho, in turn is responsible to the Government. The contractor shall provide all personnel, equipment, supplies, facilities, transportation, tools, materials, supervision, and other items and non-personal services necessary to perform the elevator lighting repair as defined in this Performance Work Statement. The contractor shall perform to the standards in this contract

ROSALIE B HORTON (703) 806-8706

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

10-Jun-2024

(RFP)

(IFB)

X

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

X

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________70 calendar days after receiving aw ard, notice to proceed. This performance period is mandatory, negotiable. (See _________________________

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

YES X NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________ copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________ (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, X is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______10 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

MICC-FORT BELVOIR

9410 JACKSON LOOP

BLDG. 1425

FORT BELVOIR VA 22060-5116

W91QV1

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

(hour) Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: (703) 806-8706 TEL: FAX:

W91QV124R0121 36

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W91QV124R0121

Section 00 10 00 - Solicitation

PERFORMANCE WORK STATEMENT

PERFORMANCE WORK STATEMENT (PWS)

Fort McNair Building 64 Elevator Lighting Repair Part 1 General Information

1. GENERAL: This is a non-personal services contract to repair the elevator lighting electrical issues at Fort McNair Building 64. The Government shall not exercise any supervision or control over the contract service providers performing the services herein. Such contract service providers shall be accountable solely to the Contractor who, in turn is responsible to the Government.

1.1 Description of Services/Introduction: The contractor shall provide all personnel, equipment, supplies, facilities, transportation, tools, materials, supervision, and other items and non-personal services necessary to perform the elevator lighting repair as defined in this Performance Work Statement. The contractor shall perform to the standards in this contract.

1.2 Background: The Joint Base Myer Henderson Hall (JBMHH) consists of Fort Myer in Arlington, Virginia and adjacently located Henderson Hall and Ft McNair, Washington, DC.

Fort McNair is a ceremonial and administrative facility and is Headquarters for the Military District of Washington (MDW). Some of the tenants at Fort McNair include these senior colleges: The National War College, the Industrial College of the Armed Forces, the Information Resources Management College, and the Institute of National Strategic Studies, collectively known as National Defense University (NDU). Other organizations receiving support from Fort McNair are: A Company, 3rd US Infantry and the 67th Ordnance Detachment. The post also provides housing for general and flag officers assigned to various elements of the Department of Defense (DOD).

1.3 Objectives:

1.3.1 Provide a safe elevator interior lighting system that does not burn wiring or bulbs during operation for each passenger elevator in McNair building 64.

1.3.2 Work schedule is to be coordinated with the COR.

1.4 Scope: The work is to repair the elevator lighting system and provide a tested and certified operational interior lighting system to each of the elevators in McNair building 64 that will not burn out lights and transformers to the COR per this PWS.

1.5 Period of Performance: The period of performance shall be for 60 days.

1.6 General Information

1.6.1 Quality Control: Contractor Quality Control/Quality Assurance:

The Contractor's quality control plan is required to be submitted with his/her contractor evaluation proposal for this contract and to the Contracting Officer at the pre-work meeting.

The Contractor shall employee a Contractor Quality Manager (CQM) and establish and maintain a complete quality control program to assure the requirements of the contract are provided as specified in the Performance Work Statement. Four (4) copies of the Contractor's Quality Control program shall be provided to the Contracting Officer for approval at the Pre-Work conference and one copy shall be provided to the COR. One (1) approved copy shall be returned to the Contractor. Updated copies including all deficiencies and inspection reports must be provided within three (3) days to the Contracting Officer and the DPW

Environmental Division as schedules in a professional, workmanlike, and acceptable manner. The quality control program shall include, but not limited to the following:

An inspection system covering the services stated in SPECIFIC TASKS TO BE PERFORMED. The inspection system must specify areas to be inspected on scheduled or unscheduled basis and title of the individuals who will do the inspections. All inspection and deficiency reports shall be turned over to the Contracting Officer and the COR within three working days.

A record of all inspections conducted by the Contractor of any corrective actions taken shall be made available to the Government COR during the term of the Contract requested.

1.6.2 Quality Assurance: The government shall evaluate the contractor’s performance under this contract in accordance with the Quality Assurance Surveillance. This plan is primarily focused on what the Government must do to ensure that the contractor has performed in accordance with the performance standards. It defines how the performance standards will be applied, the frequency of surveillance, and the minimum acceptable defect rate(s).

1.6.3 Recognized Holidays:

New Year’s Day Labor Day Martin Luther King Jr.’s Birthday Columbus Day President’s Day Veteran’s Day Memorial Day Thanksgiving Day Juneteenth Christmas Day Independence Day

1.6.5 Hours of Operation: The contractor is responsible for conducting business during the hours of 7:00 a.m. and 4:30 p.m. Monday thru Friday except Federal holidays or when the Government facility is closed due to local or national emergencies, administrative closings, or similar Government directed facility closings. For other than firm fixed price contracts, the contractor will not be reimbursed when the government facility is closed for the above reasons. The Contractor must always maintain an adequate workforce for the uninterrupted performance of all tasks defined within this PWS when the Government facility is not closed for the above reasons. When hiring personnel, the Contractor shall keep in mind that the stability and continuity of the workforce are essential.

1.6.6 Place of Performance: The work to be performed under this contract will be performed at Fort McNair, District of Columbia.

1.6.6.1 The Contractor must be aware that Joint Base Myer-Henderson Hall (JBM-HH) is a controlled access installation and as a result, requires photographic identification and the potential of vehicle inspection to gain entrance onto the installation. Detention, delay and/or other challenges presented to the contract because of this fact are the sole responsibility of the contractor.

1.6.6.1.1 The Contractor and all associated subcontractor employees shall comply with applicable installation, facility and area commander installation and/or facility access and local security policies and procedures (provided by government representative). The contractor shall also provide all information required for background checks to meet installation access requirements to be accomplished by installation Provost Marshal Office, director of Emergency Services or Security Office. Contractor workforce must comply with all personal identity verification requirements as directed by DOD, HQDA and /or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

1.6.6.2 Access to Fort McNair will be at the 2nd Street Gate.

1.6.7 Type of Contract: The government will award a Firm Fixed Price contract.

1.6.8 Security Requirements:

1.6.8.1 Physical Security: The contractor shall be responsible for safeguarding all government equipment, information, and property if it is provided for contractor use. At the close of each work period, government facilities, equipment, and materials shall be secured.

1.6.9 Qualifications: The Contractor shall employ competent and skilled personnel who are proficient in performing maintenance on elevator systems using modern tools, methods, and techniques. Must be trained and certified to handle potentially hazardous and petroleum contaminated materials in compliance with all local, State, and Federal Regulations for the removal, handling, packaging, and transportation of petroleum and hazardous materials. Proof of certifications and training of the personnel shall be presented in the Contractor's Bid proposal evaluation package, within ten (10) days after the contract is awarded, and within five (5) business days after new personnel or subcontractors are hired.

Project Manager: The Contractor's Project Manager shall have a minimum of two (2) years’ experience repairing, inspecting, and otherwise maintaining such systems of the general type and rating specified herein. The Contractor shall provide a project manager who shall be responsible for the performance of the work, shall have full authority to always act for the Contractor during the requirements of this contract, shall act as the central point of contact with the Government, and shall be physically on site when work under this contract is being performed. Proof of certifications and training of the Project Manager shall be presented in the Contractor's Bid proposal evaluation package, to the contracting officer within ten (10) calendar days after the award is made, and within five (5) business days after new personnel or subcontractors are hired.

Elevator Repair System Technicians: Repair specialists and other persons employed to maintain and repair the elevator systems shall have as a minimum two (2) years’ experience repairing, inspecting and otherwise maintaining such systems of the general type and rating specified herein, except that helpers or apprentices may be permitted to work under the direct supervision of a responsible technician.

1.6.10 Post Award Conference/Periodic Progress Meetings: The Contractor agrees to attend any post award conference convened by the contracting activity or contract administration office in accordance with Federal Acquisition Regulation Subpart 42.5. The contracting officer, Contracting Officers Representative (COR), and other Government personnel, as appropriate, may meet periodically with the contractor to review the contractor's performance. At these meetings the contracting officer will apprise the contractor of how the government views the contractor's performance and the contractor will apprise the Government of problems, if any, being experienced.

Appropriate action shall be taken to resolve outstanding issues. These meetings shall be at no additional cost to the government.

1.6.11 Contracting Officer Representative (COR): The (COR) will be identified by separate letter. The COR monitors all technical aspects of the contract and assists in contract administration The COR is authorized to perform the following functions: assure that the Contractor performs the technical requirements of the contract:

perform inspections necessary in connection with contract performance: maintain written and oral communications with the Contractor concerning technical aspects of the contract: issue written interpretations of technical requirements, including Government drawings, designs, specifications: monitor Contractor's performance and notifies both the Contracting Officer and Contractor of any deficiencies; coordinate availability of government furnished property, and provide site entry of Contractor personnel. A letter of designation issued to the COR, a copy of which is sent to the Contractor, states the responsibilities and limitations of the COR, especially regarding changes in cost or price, estimates or changes in delivery dates. The COR is not authorized to change any of the terms and conditions of the resulting order.

1.6.12 Key Personnel: The follow personnel are considered key personnel by the government: Project Manager/Alternate Project Manager, Elevator System Repair Technicians. The contractor shall provide a contract manager who shall be responsible for the performance of the work. The name of this person and an alternate who shall act for the contractor when the manager is absent shall be designated in writing to the contracting officer. The contract manager or alternate shall have full authority to act for the contractor on all contract matters relating to daily operation of this contract and shall be able to converse, read and write

English. The contract manager or alternate shall be available until 4:30 p.m. Monday thru Friday except Federal holidays or when the government facility is closed for administrative reasons.

1.6.13 Organizational Conflict of Interest: Contractor and subcontractor personnel performing work under this contract may receive, have access to or participate in the development of proprietary or source selection information (e.g., cost or pricing information, budget information or analyses, specifications, or work statements, etc.) or perform evaluation services which may create a current or subsequent Organizational Conflict of Interests (OCI) as defined in FAR Subpart 9.5. The Contractor shall notify the Contracting Officer immediately whenever it becomes aware that such access or participation may result in any actual or potential OCI and shall promptly submit a plan to the Contracting Officer to avoid or mitigate any such OCI. The Contractor’s mitigation plan will be determined to be acceptable solely at the discretion of the Contracting Officer and in the event the Contracting Officer unilaterally determines that any such OCI cannot be satisfactorily avoided or mitigated, the Contracting Officer may affect other remedies as he or she deems necessary, including prohibiting the Contractor from participation in subsequent contracted requirements which may be affected by the OCI.

PART 2

DEFINITIONS & ACRONYMS

2. DEFINITIONS AND ACRONYMS:

2.1. DEFINITIONS:

2.1.1. CONTRACTOR. A supplier or vendor having a contract to provide specific supplies or service to the government. The term used in this contract refers to the prime.

2.1.2. CONTRACTING OFFICER. A person with authority to enter, administer, and/or terminate contracts, and make related determinations and findings on behalf of the government. Note: The only individual who can legally bind the government.

2.1.3. CONTRACTING OFFICER'S REPRESENTATIVE (COR). An employee of the U.S. Government appointed by the contracting officer to administer the contract. Such appointment shall be in writing and shall state the scope of authority and limitations. This individual has authority to provide technical direction to the Contractor as long as that direction is within the scope of the contract, does not constitute a change, and has no funding implications. This individual does NOT have authority to change the terms and conditions of the contract.

2.1.4. DEFECTIVE SERVICE. A service output that does not meet the standard of performance associated with the Performance Work Statement.

2.1.5. DELIVERABLE. Anything that can be physically delivered but may include non-physical things such as meeting minutes.

2.1.6. KEY PERSONNEL. Contractor personnel that are evaluated in a source selection process and that may be required to be used in the performance of a contract by the Key Personnel listed in the PWS. When key personnel are used as an evaluation factor in best value procurement, an offer can be rejected if it does not have a firm commitment from the persons that are listed in the proposal.

2.1.7. PHYSICAL SECURITY. Actions that prevent the loss or damage of Government property.

2.1.8. QUALITY ASSURANCE. The government procedures to verify that services being performed by the Contractor are performed according to acceptable standards.

2.1.9. QUALITY ASSURANCE Surveillance Plan (QASP). An organized written document specifying the surveillance methodology to be used for surveillance of contractor performance.

2.1.10. QUALITY CONTROL. All necessary measures taken by the Contractor to assure that the quality of a product or service shall meet contract requirements.

2.1.11. SUBCONTRACTOR. One that enters a contract with a prime contractor. The Government does not have privity of contract with the subcontractor.

2.1.12. WORKDAY. The number of hours per day the Contractor provides services in accordance with the contract.

2.1.12. WORK WEEK. Is defined as Monday through Friday, unless specified otherwise.

2.2. ACRONYMS:

ACOR Alternate Contracting Officer's Representative AFARS Army Federal Acquisition Regulation Supplement AR Army Regulation CCE Contracting Center of Excellence CFR Code of Federal Regulations CONUS Continental United States (excludes Alaska and Hawaii) COR Contracting Officer Representative COTR Contracting Officer's Technical Representative COTS Commercial Off the Shelf DA Department of the Army DD250 Department of Defense Form 250 (Receiving Report) DD254 Department of Defense Contract Security Requirement List DFARS Defense Federal Acquisition Regulation Supplement DMDC Defense Manpower Data Center DOD Department of Defense FAR Federal Acquisition Regulation HIPAA Health Insurance Portability and Accountability Act of 1996 KO Contracting Officer OCI Organizational Conflict of Interest OCONUS Outside Continental United States (includes Alaska and Hawaii) ODC Other Direct Costs PIPO Phase In/Phase Out POC Point of Contact PRS Performance Requirements Summary PWS Performance Work Statement QA Quality Assurance QAP Quality Assurance Program QASP Quality Assurance Surveillance Plan QC Quality Control QCP Quality Control Program TE Technical Exhibit

PART 3

GOVERNMENT FURNISHED PROPERTY, EQUIPMENT, AND SERVICES

3. GOVERNMENT FURNISHED ITEMS AND SERVICES:

3.1. Services: N/A

3.2. Facilities: N/A

3.3 Utilities: N/A

3.4 Equipment: N/A

3.5 Materials: N/A

PART 4

CONTRACTOR FURNISHED ITEMS AND SERVICES

4. CONTRACTOR FURNISHED ITEMS AND RESPONSIBILITIES:

4.1 General: The Contractor shall furnish all supplies, materials, equipment, facilities and services required to perform work under this contract that are not listed under Part 3 of this PWS.

4.2 Secret Facility Clearance: N/A

4.3. Materials: N/A

4.4. Equipment: The Contractor shall furnish all supplies, equipment, facilities and services required to perform work under this contract.

PART 5

SPECIFIC TASKS

5. Specific Tasks:

5.1. Basic Services.

5.2. Requirements.

5.2.1 The Contractor shall provide the necessary personnel, equipment, and materials to complete the tasks listed below:

5.2.1.1 Removal of all burnt wiring and lighting transformers from each passenger elevator.

5.2.1.2 Fabricate a box of sufficient size to accommodate three lighting transformers with associated wiring.

5.2.1.3 Install the fabricated box with transformers and wire into each elevator’s cab lights.

5.2.1.4 Perform lighting operations and safety test.

5.2.1.5 Perform work area cleanup and dispose of debris off-site.

5.3 Manpower Reporting Requirement:

5.3.1 N/A

5.4 Antiterrorism

5.4.1 AT Level I Training: This provision is for contractor employees with an area of performance within an Army controlled installation, facility or area. All contractor employees, to include subcontractor employees, requiring access to Army installations, facilities, and controlled access areas shall complete AT Level I awareness training within 30 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. The contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee to the COR or to the KO, if a COR is not assigned within 15 calendar days after completion of training by all employees and subcontractor personnel.

Additionally, the contractor and all associated sub-contractors shall brief all their employees on the local iWATCH program (training standards provided by the requiring activity ATO). This locally developed training will be used to inform employees of the types of behavior to watch for and instruct employees to report suspicious activity to the COR. This training shall be completed within 14 calendar days of contract award and within 5 calendar days of new employees commencing performance with the results reported to the COR NLT 15 calendar days after contract award.

PART 6

APPLICABLE PUBLICATIONS

6. APPLICABLE PUBLICATIONS (CURRENT EDITIONS)

6.1. The Contractor must abide by all applicable regulations, publications, manuals, and local policies and procedures.

Performance Requirements Summary

(PRS) Performance Objectives

Performance Standard Performance Threshold Acceptable Quality Level

(AQL)

Surveillance Methods

PWS#1. Remove all burnt wires and transformers.

PWS 5.2

The Contractor shall remove all burnt wires and transformers from all elevators and dispose of them off site.

Removed items are disposed of offsite.

100% Inspection

PWS#2. Box fabrication

PWS 5.2

The contractor shall fabricate box with three (3) transformers to support all cab lights for each elevator.

Boxes must be of sufficient size to accommodate the three transformers and associated wiring.

100% Inspection

PWS#3. Install fabricated box with three (3) transformers and wire into cab lights.

PWS 5.2

The Contractor shall install fabricated box containing three (3) transformers and wire into cab lights on all elevators.

All interior cab lights must be operational.

100% Inspection

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0010 1 Job CLIN 0001 B64 Elevator Lighting

FFP

CLIN 0001 B64 Elevator Lighting FOB: Destination

PURCHASE REQUEST NUMBER: 0012129161

PSC CD: S214

NET AMT

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0010 POP 28-AUG-2024 TO

28-OCT-2024

N/A W0UC USA JBM-HH

W0UC USA JBM-HH

DPW

204 ARLINGTON AVENUE

FORT MYER VA 22211-1199

210-466-1435 FOB: Destination

W80HUJ

CLAUSES INCORPORATED BY REFERENCE

52.202-1 Definitions JUN 2020 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-7 Anti-Kickback Procedures JUN 2020 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-13 Contractor Code of Business Ethics and Conduct NOV 2021 52.203-14 Display of Hotline Poster(s) NOV 2021 52.203-17 Contractor Employee Whistleblower Rights NOV 2023 52.203-19 Prohibition on Requiring Certain Internal Confidentiality

Agreements or Statements

JAN 2017

52.204-2 Security Requirements MAR 2021 52.204-2 Alt II Security Requirements (MAR 2021) - Alternate II APR 1984 52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.204-23 Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspersky Lab Covered Entities

DEC 2023

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.204-26 Covered Telecommunications Equipment or Services-- Representation.

OCT 2020

52.204-27 Prohibition on a ByteDance Covered Application JUN 2023 52.204-28 Federal Acquisition Supply Chain Security Act Orders--

Federal Supply Schedules, Governmentwide Acquisition Contracts, and Multi-Agency Contracts.

DEC 2023

52.204-29 Federal Acquisition Supply Chain Security Act Orders-- Representation and Disclosures.

DEC 2023

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.210-1 Market Research NOV 2021 52.211-10 Commencement, Prosecution, and Completion of Work APR 1984

52.211-10 Alt I Commencement, Prosecution, and Completion of Work (Apr 1984) - Alternate I

APR 1984

52.211-13 Time Extensions SEP 2000 52.212-4 Contract Terms and Conditions--Commercial Products and

Commercial Services

NOV 2023

52.216-24 Limitation Of Government Liability APR 1984 52.216-25 Contract Definitization OCT 2010 52.216-25 Alt I Contract Definitization (Oct 1997) - Alternate I APR 1984 52.219-8 Utilization of Small Business Concerns FEB 2024 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records JUL 2021 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-30 Construction Wage Rate Requirements--Price Adjustment (None or Separately Specified Method)

AUG 2018

52.222-31 Construction Wage Rate Requirements--Price Adjustment (Percentage Method)

AUG 2018

52.222-34 Project Labor Agreement JAN 2024 52.222-35 Equal Opportunity for Veterans JUN 2020 52.222-37 Employment Reports on Veterans JUN 2020 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons NOV 2021 52.222-50 Alt I Combating Trafficking in Persons (NOV 2021) Alternate I MAR 2015 52.222-54 Employment Eligibility Verification MAY 2022 52.222-55 Minimum Wages for Contractor Workers Under Executive

Order 14026

JAN 2022

52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2022 52.223-2 Reporting of Biobased Products Under Service and

Construction Contracts.

MAY 2024

52.223-3 Hazardous Material Identification And Material Safety Data FEB 2021 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2024 52.223-11 Ozone-Depleting Substances and High Global Warming

Potential Hydrofluorocarbons.

MAY 2024

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021 52.225-25 Prohibition on Contracting with Entities Engaging in Certain

Activities or Transactions Relating to Iran-- Representation and Certifications.

JUN 2020

52.227-1 Authorization and Consent JUN 2020 52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Individual Surety--Pledge of Assets FEB 2021 52.228-12 Prospective Subcontractor Requests for Bonds DEC 2022

52.228-15 Performance and Payment Bonds--Construction JUN 2020 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-16 Progress Payments NOV 2021 52.232-18 Availability Of Funds APR 1984 52.232-19 Availability Of Funds For The Next Fiscal Year APR 1984 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

MAR 2023

52.233-1 Disputes MAY 2014 52.233-1 Alt I Disputes (May 2014) - Alternate I DEC 1991 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-1 Performance of Work by the Contractor APR 1984 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-13 Alt I Accident Prevention (Nov 1991) - Alternate I NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-17 Layout of Work APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.236-27 Site Visit (Construction) FEB 1995 52.236-28 Preparation of Proposals--Construction OCT 1997 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.242-15 Stop-Work Order AUG 1989 52.243-4 Changes JUN 2007 52.243-5 Changes and Changed Conditions APR 1984 52.244-6 Subcontracts for Commercial Products and Commercial

Services

FEB 2024

52.246-12 Inspection of Construction AUG 1996 52.246-13 Inspection--Dismantling, Demolition, or Removal of

Improvements

AUG 1996

52.246-21 Warranty of Construction MAR 1994 52.246-23 Limitation Of Liability FEB 1997 52.248-3 Value Engineering-Construction OCT 2020 52.249-2 Termination For Convenience Of The Government (Fixed-

Price)

APR 2012

52.249-3 Termination for Convenience of the Government (Dismantling, Demolition, or Removal of Improvements)

APR 2012

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991

252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

JAN 2023

252.203-7002 Requirement to Inform Employees of Whistleblower Rights DEC 2022 252.203-7004 Display of Hotline Posters JAN 2023 252.204-7004 Antiterrorism Awareness Training for Contractors JAN 2023 252.204-7006 Billing Instructions--Cost Vouchers MAY 2023 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

JAN 2023

252.204-7015 Notice of Authorized Disclosure of Information for Litigation Support

JAN 2023

252.205-7000 Provision Of Information To Cooperative Agreement Holders JUN 2023 252.209-7004 Subcontracting With Firms That Are Owned or Controlled By

The Government of a Country that is a State Sponsor of Terrorism

MAY 2019

252.211-7003 Item Unique Identification and Valuation JAN 2023 252.223-7001 Hazard Warning Labels DEC 1991 252.223-7004 Drug Free Work Force SEP 1988 252.227-7033 Rights in Shop Drawings APR 1966 252.231-7000 Supplemental Cost Principles DEC 1991 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

DEC 2018

252.232-7004 DOD Progress Payment Rates OCT 2014 252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.243-7001 Pricing Of Contract Modifications DEC 1991 252.243-7002 Requests for Equitable Adjustment DEC 2022

CLAUSES INCORPORATED BY FULL TEXT

52.204-1 APPROVAL OF CONTRACT (DEC 1989)

This contract is subject to the written approval of MICC Fort Belvoir Contracting Officer and shall not be binding until so approved.

(End of clause)

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

The Offeror shall not complete the representation at paragraph (d)(1) of this provision if the Offeror has represented that it "does not provide covered telecommunications equipment or services as a part of its offered products or services to the Government in the performance of any contract, subcontract, or other contractual instrument" in paragraph (c)(1) in the provision at 52.204-26, Covered Telecommunications Equipment or Services-- Representation, or in paragraph (v)(2)(i) of the provision at 52.212-3, Offeror Representations and Certifications- Commercial Products and Commercial Services. The Offeror shall not complete the representation in paragraph (d)(2) of this provision if the Offeror has represented that it "does not use covered telecommunications equipment or services, or any equipment, system, or service that uses covered telecommunications equipment or services" in paragraph (c)(2) of the provision at 52.204-26, or in paragraph (v)(2)(ii) of the provision at 52.212-3.

(a) Definitions. As used in this provision-

Backhaul, covered telecommunications equipment or services, critical technology, interconnection arrangements, reasonable inquiry, roaming, and substantial or essential component have the meanings provided in the clause 52.204-25, Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract or extending or renewing a contract with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract. Nothing in the prohibition shall be construed to--

(i) Prohibit the head of an executive agency from procuring with an entity to provide a service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(ii) Cover telecommunications equipment that cannot route or redirect user data traffic or cannot permit visibility into any user data or packets that such equipment transmits or otherwise handles.

(c) Procedures. The Offeror shall review the list of excluded parties in the System for Award Management (SAM) (https://www.sam.gov) for entities excluded from receiving federal awards for "covered telecommunications equipment or services."

(d) Representations. The Offeror represents that--

(1) It [ ___ ] will, [ ___ ] will not provide covered telecommunications equipment or services to the Government in the performance of any contract, subcontract or other contractual instrument resulting from this solicitation. The Offeror shall provide the additional disclosure information required at paragraph (e)(1) of this section if the Offeror responds "will" in paragraph (d)(1) of this section; and

(2) After conducting a reasonable inquiry, for purposes of this representation, the Offeror represents that--

It [ ___ ] does, [ ___ ] does not use covered telecommunications equipment or services, or use any equipment, system, or service that uses covered telecommunications equipment or services. The Offeror shall provide the additional disclosure information required at paragraph (e)(2) of this section if the Offeror responds "does" in paragraph (d)(2) of this section.

(e) Disclosures.

(1) Disclosure for the representation in paragraph (d)(1) of this provision. If the Offeror has responded "will" in the representation in paragraph (d)(1) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the original equipment manufacturer (OEM) or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the Product Service Code (PSC) of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(1) of this provision.

(2) Disclosure for the representation in paragraph (d)(2) of this provision. If the Offeror has responded "does" in the representation in paragraph (d)(2) of this provision, the Offeror shall provide the following information as part of the offer:

(i) For covered equipment--

(A) The entity that produced the covered telecommunications equipment (include entity name, unique entity identifier, CAGE code, and whether the entity was the OEM or a distributor, if known);

(B) A description of all covered telecommunications equipment offered (include brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); and

(C) Explanation of the proposed use of covered telecommunications equipment and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(ii) For covered services--

(A) If the service is related to item maintenance: A description of all covered telecommunications services offered (include on the item being maintained: Brand; model number, such as OEM number, manufacturer part number, or wholesaler number; and item description, as applicable); or

(B) If not associated with maintenance, the PSC of the service being provided; and explanation of the proposed use of covered telecommunications services and any factors relevant to determining if such use would be permissible under the prohibition in paragraph (b)(2) of this provision.

(End of provision)

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO

SURVEILLANCE SERVICES OR EQUIPMENT (NOV 2021)

(a) Definitions. As used in this clause--

Backhaul means intermediate links between the core network, or backbone network, and the small subnetworks at the edge of the network (e.g., connecting cell phones/towers to the core telephone network). Backhaul can be wireless (e.g., microwave) or wired (e.g., fiber optic, coaxial cable, Ethernet).

Covered foreign country means The People's Republic of China.

Covered telecommunications equipment or services means--

(1) Telecommunications equipment produced by Huawei Technologies Company or ZTE Corporation (or any subsidiary or affiliate of such entities);

(2) For the purpose of public safety, security of Government facilities, physical security surveillance of critical infrastructure, and other national security purposes, video surveillance and telecommunications equipment produced by Hytera Communications Corporation, Hangzhou Hikvision Digital Technology Company, or Dahua Technology Company (or any subsidiary or affiliate of such entities);

(3) Telecommunications or video surveillance services provided by such entities or using such equipment; or

(4) Telecommunications or video surveillance equipment or services produced or provided by an entity that the Secretary of Defense, in consultation with the Director of National Intelligence or the Director of the Federal Bureau of Investigation, reasonably believes to be an entity owned or controlled by, or otherwise connected to, the government of a covered foreign country.

Critical technology means--

(1) Defense articles or defense services included on the United States Munitions List set forth in the International Traffic in Arms Regulations under subchapter M of chapter I of title 22, Code of Federal Regulations;

(2) Items included on the Commerce Control List set forth in Supplement No. 1 to part 774 of the Export Administration Regulations under subchapter C of chapter VII of title 15, Code of Federal Regulations, and controlled--

(i) Pursuant to multilateral regimes, including for reasons relating to national security, chemical and biological weapons proliferation, nuclear nonproliferation, or missile technology; or

(ii) For reasons relating to regional stability or surreptitious listening;

(3) Specially designed and prepared nuclear equipment, parts and components, materials, software, and technology covered by part 810 of title 10, Code of Federal Regulations (relating to assistance to foreign atomic energy activities);

(4) Nuclear facilities, equipment, and material covered by part 110 of title 10, Code of Federal Regulations (relating to export and import of nuclear equipment and material);

(5) Select agents and toxins covered by part 331 of title 7, Code of Federal Regulations, part 121 of title 9 of such Code, or part 73 of title 42 of such Code; or

(6) Emerging and foundational technologies controlled pursuant to section 1758 of the Export Control Reform Act of 2018 (50 U.S.C. 4817).

Interconnection arrangements means arrangements governing the physical connection of two or more networks to allow the use of another's network to hand off traffic where it is ultimately delivered (e.g., connection of a customer of telephone provider A to a customer of telephone company B) or sharing data and other information resources.

Reasonable inquiry means an inquiry designed to uncover any information in the entity's possession about the identity of the producer or provider of covered telecommunications equipment or services used by the entity that excludes the need to include an internal or third-party audit.

Roaming means cellular communications services (e.g., voice, video, data) received from a visited network when unable to connect to the facilities of the home network either because signal coverage is too weak or because traffic is too high.

Substantial or essential component means any component necessary for the proper function or performance of a piece of equipment, system, or service.

(b) Prohibition.

(1) Section 889(a)(1)(A) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2019, from procuring or obtaining, or extending or renewing a contract to procure or obtain, any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system. The Contractor is prohibited from providing to the Government any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104.

(2) Section 889(a)(1)(B) of the John S. McCain National Defense Authorization Act for Fiscal Year 2019 (Pub. L.

115-232) prohibits the head of an executive agency on or after August 13, 2020, from entering into a contract, or extending or renewing a contract, with an entity that uses any equipment, system, or service that uses covered telecommunications equipment or services as a substantial or essential component of any system, or as critical technology as part of any system, unless an exception at paragraph (c) of this clause applies or the covered telecommunication equipment or services are covered by a waiver described in FAR 4.2104. This prohibition applies to the use of covered telecommunications equipment or services, regardless of whether that use is in performance of work under a Federal contract.

(c) Exceptions. This clause does not prohibit contractors from providing--

(1) A service that connects to the facilities of a third-party, such as backhaul, roaming, or interconnection arrangements; or

(2) Telecommunications equipment that cannot route or…