W912WJ19B0011_0002.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this Amendment is to answ er Contractor Requests for Information, incorporate XYZ files “HAM_20181010_CS_2018_058_03avg” and “HAM_20181010_CS_2018_058_20min”, update Permit No. NAE-2019-01376, and amend specifications. All other terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912WJ19B0011

X 9B. DATED (SEE ITEM 11)

02-Jul-2019

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

U0002

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

29-Jul-2019

CODE

U S ARMY ENGR DISTRICT, NEW ENGLAND

696 VIRGINIA RD

CONCORD MA 01742-2751

W912WJ 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912WJ19B0011

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION CONTRACT FORM

The following have been added by full text:

AMENDMENT 0002

Solicitation W912WJ19B0011

Hampton Harbor Maintenance Dredging Hampton and Seabrook, New Hampshire

SPECIFICATION CHANGES

Section 01 11 00 of the Specifications is amended as follows:

1.1.1 No Dredge Seasons

(a) Operational Restrictions:

To avoid impacts to local environmental resources and due to environmental restrictions, environmental windows of permitted dredging, placement of dredged material, and all other work shall be as follows:

(1) Dredging of the Inner Harbor: 15 October 2019 through 15 January 2020.

(2) Dredging of the Federal Entrance Channel: 15 October 2019 through 1 March 2020.

(3) All other work and work on receiving beaches: 1 October 2019 through 1 March 2020.

"All other work" shall include, but not be limited to, preparation of and work on receiving beaches, pipeline installation and removal, sand fence installation, placement of dredged material within the West Bulkhead, and placement and grading of beachfill.

Amend Section 01 57 20 “ENVIRONMENTAL PROTECTION” as follows:

Under the permits attached at the end of this section, remove the Department of the Army permit (dated June 20, 2019) in its entirety and replace it with the version (2019-01376) attached to this amendment.

PLAN CHANGES

W912WJ19B0011

No changes.

All other Specifications and Plans not listed in this amendment will remain unchanged.

REQUESTS FOR INFORMATION

1) In the spec’s section 1.1.1 No Dredge Seasons states the following: To avoid impacts to local environmental resources and due to environmental restrictions, the work required under this contract will only be permitted between 1 October 2019 and 15 March 2020. However, in section 1.1.1a,1 and 2 reference March 1 as the cut‐off. Additionally, are the dates listed in Section 1.1.1a 1‐2 the required work start and completion dates for the respected areas?

RESPONSE: Please see amended Specification Section 01 11 00.

ALL WORK MUST BE COMPLETED WITHIN THE ENVIRONMENTAL WINDOWS STATED IN AMENDED SECTION 01 11 00 (SCOPE OF WORK) FOR THE RESPECTIVE PARTS OF THE PROJECT. ALSO REFER TO RESPONSES TO QUESTIONS

2 ‐ 4 FOR ADDITIONAL INFORMATION PERTAINING TO REQUIRED COMPLETION DATES.

2) Is there the ability or willingness of the USACE to extend the dredge and work season to March 31, 2020?

RESPONSE: IF, DURING CONSTRUCTION, THE CONTRACTOR CANNOT COMPLETE PERFORMANCE WITHIN THE DATES IN AMENDED SECTION 01 11 00 REFERENCED ABOVE, THE GOVERNMENT WILL EVALUATE A REQUEST FOR EXTENSION OF TIME BUT IN NO EVENT WILL THE COMPLETION DATE(S) BE EXTENDED BEYOND THE ENVIRONMENTAL WINDOWS IN THE PERMITS. THE GOVERNMENT HAS NO ABILITY TO EXTEND BEYOND THE

ENVIRONMENTAL PERMIT DATES.

3) In section 1.1.1(a)(1) it states: (1) Dredging of the Inner Harbor: 15 October 2019 through 15 January 2020. Is there a reason for the dredging window to end on January 15th? Can this be extended to the full length of the contract?

RESPONSE: PLEASE SEE RESPONSE TO QUESTION 2.

4) Due to the current dredging industry workload, we would like to see if the project dredging window could be extended to March 31 or even to April 10th with provisions for appropriate wildlife monitoring.

RESPONSE: DREDGING, PLACEMENT OF DREDGED MATERIAL, AND ALL OTHER WORK WILL NOT BE EXTENDED BEYOND THE DATES SHOWN IN AMENDED SECTION 01 11 00. PLEASE SEE RESPONSE TO QUESTION 2.

5. Can provide us with the XYZ data for the "before dredge" survey of the areas to be dredged.

RESPONSE: BEFORE DREDGE XYZ FILES HAVE BEEN PROVIDED AND ARE ATTACHED TO THIS AMENDMENT.

(End of Summary of Changes)