W912QR21R0024_Specs-0002.pdf

PDF 1 MB Posted

Attached to
Construction of Target Structure at Ft. Knox Federal contract opportunity
Solicitation number
W912QR21R0024
Issued by
Department of the Army Corps of Engineers Engineering District Louisville

About this file

This document summarizes a federal contract solicitation for the construction of a training target structure at Fort Knox, Kentucky. The U.S. Army Corps of Engineers Louisville District will issue Request for Proposal W912QR20R0024 to construct the structure for specialized sustainment training. The project scope includes cast in place and blast resistant reinforced concrete walls, roofs, interior walls, support facilities for electric service, storm drainage, and site improvements. The contract duration is 720 calendar days from notice to proceed. The contract type is firm-fixed-price. The North American Industry Classification System code is 236220. This is a full and open acquisition with a best value tradeoff source selection evaluating past performance, technical, small business participation, and price factors. Discussions are not intended but may be conducted at the government's discretion. The construction magnitude is estimated between $10-25 million. Offerors must have active System for Award Management registration. The point of contact is the named contracting specialist.

View the file

Other files for this federal contract opportunity

Other files attached to Construction of Target Structure at Ft. Knox, newest first.
File Type Posted
W912QR21R0024Plans-0004.pdf PDF
W912QR21R0024Specs-0004.pdf PDF
W912QR21R0024_Plans-0003.pdf PDF
W912QR21R0024_Specs-0003.pdf PDF
W912QR21R0024_Photos-0002.pdf PDF
W912QR21R0024_Plans-0002.pdf PDF
W912QR21R0024-0001.pdf PDF
W912QR21R0024Specs-0000.pdf PDF
W912QR21R0024Plans-0000.pdf PDF

On GovTribe

Work with this file on GovTribe

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file

Text version

CIVIL/OPS/ENVIRONMENTAL BR

ATTN: MARCEL D HULL

600 DR M L KING JR PL RM 821

LOUISVILL KY 40202-2236

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

Solicitation W912QR21R0024 for the Construction of a Target Training Structure at Fort Knox, KY is hereby amended as follow s:

SEE ATTACHED SUMMARY OF CHANGES AMDT 0002

1. CONTRACT ID CODE PAGE OF PAGES

1 15

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912QR21R0024

X 9B. DATED (SEE ITEM 11)

24-Feb-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

18-Mar-2021

CODE

U. S. ARMY ENGINEER DISTRICT, LOUISVILLE

600 DR. MARTIN LUTHER KING, JR. PLACE

ROOM 821

LOUISVILLE KY 40202-2239

W912QR 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE 964860

FACILITY CODECODE

EMAIL:TEL:

W912QR21R0024Specs-0002

W912QR21R0024

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

SUMMARY OF CHANGES AMDT 0002

1. The following SPECIFICATION SECTIONS are hereby added in their entirety:

05 50 13 – Miscellaneous Metal Fabrications 05 51 33 – Metal Ladders

2. The following SPECIFICATION SECTIONS are hereby revised and replaced in their entirety:

01 50 00 – Temporary Construction Facilities and Controls 03 30 00 – Cast-in-Place Concrete 09 90 00 – Paints and Coatings 25 05 11 – Cybersecurity for Facility-Related Control Systems

3. The following DRAWINGS have been revised and replaced in their entirety:

CG101 – Grading Plan CG101A – Bid Option 004 Grading Plan CU102 – Utility Plan CU111 – Utility Plan S-001 – General Notes S-100 – Foundation Plan View S-101 – First Floor Plan View S-511 – Typical Sections and Details E-001 – Legend and Abbreviations E-101 – Power Plan 1st Floor E-102 – Power Plan 2nd and 3rd Floor E-601 – One Line Diagrams and Panel Schedule EU101 – Site Lighting Plan and Details EU503 – Electrical Utility Details TY101 – Plan View VSS F1 & F2 TY102 – Plan View VSS F3 & Roof TY103 – Plan View ACS Wiring F1 and F2 and Details TY104 – Plan View ACS Wiring F3 and Roof TY501 – VSS Details 1 TY503 – ACS Details TY601 – In-Plan/Out-Play VSS One-Line

4. Photographs of the haul road have been provided for clarity in lieu of site visit.

5. The proposal due date has been extended to 02 April 2021 at 1:00 PM Eastern Time (ET).

6. All other terms and conditions remain unchanged.

W912QR21R0024

SECTION 00 10 00 - SOLICITATION

The required response date/time has changed from 26-Mar-2021 01:00 PM to 02-Apr-2021 01:00 PM.

(End of Summary of Changes)

P2 477836 SOF Training Target Structure Ft Knox, KY

PROJECT TABLE OF CONTENTS

Amendment 0002

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 80 00.00 06 SPECIAL PROVISIONS

DIVISION 01 - GENERAL REQUIREMENTS

01 32 01.00 06 PROJECT SCHEDULE

01 33 00.00 06 SUBMITTAL PROCEDURES

01 33 29.00 06 SUSTAINABILITY REPORTING

01 35 26.00 06 GOVERNMENT SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE (RMS CM)

01 45 04.10 06 CONTRACTOR QUALITY CONTROL

01 45 35 SPECIAL INSPECTIONS

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 19.00 06 TEMPORARY ENVIRONMENTAL CONTROLS AND PERMITS

01 74 19 CONSTRUCTION WASTE MANAGEMENT AND DISPOSAL

01 78 23 OPERATION AND MAINTENANCE DATA

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 03 - CONCRETE

03 30 00 CAST-IN-PLACE CONCRETE

DIVISION 04 - MASONRY

04 20 00 UNIT MASONRY

DIVISION 05 - METALS

05 05 23.16 STRUCTURAL WELDING

05 12 00 STRUCTURAL STEEL

05 50 13 MISCELLANEOUS METAL FABRICATIONS

05 51 00 METAL STAIRS

05 51 33 METAL LADDERS

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

DIVISION 08 - OPENINGS

08 11 13 STEEL DOORS AND FRAMES

08 34 59 VAULT DOORS AND DAY GATES

08 39 54 BLAST RESISTANT DOORS

08 71 00 DOOR HARDWARE

DIVISION 09 - FINISHES

09 90 00 PAINTS AND COATINGS

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 03 00.00 20 BASIC MECHANICAL MATERIALS AND METHODS

PROJECT TABLE OF CONTENTS Page 1

AMENDMENT 0002

23 81 00 DECENTRALIZED UNITARY HVAC EQUIPMENT

DIVISION 25 - INTEGRATED AUTOMATION

25 05 11 CYBERSECURITY FOR FACILITY-RELATED CONTROL SYSTEMS

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 41 00 LIGHTNING PROTECTION SYSTEM

26 56 00 EXTERIOR LIGHTING

DIVISION 27 - COMMUNICATIONS

27 05 28.36 40 CABLE TRAYS FOR COMMUNICATIONS SYSTEMS

27 10 00 BUILDING TELECOMMUNICATIONS CABLING SYSTEM

27 13 23.00 40 COMMUNICATIONS OPTICAL BACKBONE CABLING

DIVISION 28 - ELECTRONIC SAFETY AND SECURITY

28 08 10 ELECTRONIC SECURITY SYSTEM ACCEPTANCE TESTING

28 10 05 ELECTRONIC SECURITY SYSTEMS (ESS)

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 11 00 CLEARING AND GRUBBING

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 05 33 LANDSCAPE ESTABLISHMENT

32 11 23 AGGREGATE BASE COURSES

32 15 00 AGGREGATE SURFACING

32 31 13 CHAIN LINK FENCES AND GATES

32 92 19 SEEDING

DIVISION 33 - UTILITIES

33 11 00 WATER UTILITY DISTRIBUTION PIPING

33 40 00 STORM DRAINAGE UTILITIES

33 71 02 UNDERGROUND ELECTRICAL DISTRIBUTION

33 82 00 TELECOMMUNICATIONS OUTSIDE PLANT (OSP)

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 2

SECTION 01 50 00

TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

05/18

Amendment 0002

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

NATIONAL FIRE PROTECTION ASSOCIATION (NFPA)

NFPA 70 (2017; ERTA 1-2 2017; TIA 17-1; TIA 17-2;

TIA 17-3; TIA 17-4; TIA 17-5; TIA 17-6;

TIA 17-7; TIA 17-8; TIA 17-9; TIA 17-10;

TIA 17-11; TIA 17-12; TIA 17-13; TIA

17-14; TIA 17-15; TIA 17-16; TIA 17-17 )

National Electrical Code

NFPA 241 (2019) Standard for Safeguarding Construction, Alteration, and Demolition Operations

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

U.S. FEDERAL AVIATION ADMINISTRATION (FAA)

FAA AC 70/7460-1 (2015; Rev L) Obstruction Marking and Lighting

U.S. FEDERAL HIGHWAY ADMINISTRATION (FHWA)

MUTCD (2015) Manual on Uniform Traffic Control Devices

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with Section 01 33 00.00 06 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Construction Site Plan; G

Traffic Control Plan; G

SECTION 01 50 00 Page 3

1.3 CONSTRUCTION SITE PLAN

Prior to the start of work, submit a site plan showing the locations and dimensions of temporary facilities (including layouts and details, equipment and material storage area (onsite and offsite), and access and haul routes, avenues of ingress/egress to the fenced area and details of the fence installation. Identify any areas which may have to be graveled to prevent the tracking of mud. Indicate if the use of a supplemental or other staging area is desired. Show locations of safety and construction fences, site trailers, construction entrances, trash dumpsters, temporary sanitary facilities, and worker parking areas.

PART 2 PRODUCTS

2.1 TEMPORARY SIGNAGE

2.1.1 Bulletin Board

Coordinate requirements with LRL Section 01 35 26.00 06 GOVERNMENTAL SAFETY

REQUIREMENTS.

2.1.2 Project Identification Signs - NOT USED

2.1.3 Warning Signs

Post temporary signs, tags, and labels to give workers and the public adequate warning and caution of construction hazards according to the EM 385-1-1 Section 04. Attach signs to the perimeter fencing every 150 feet warning the public of the presence of contruction hazards. Signs must require unauthorized persons to keep out of the construction site. Correct the data required by safety signs daily.

2.2 TEMPORARY TRAFFIC CONTROL

2.2.1 Haul Roads

Contractor shall utilize existing haul roads constructed at the project site. Contractor is responsible for maintenance of these haul roads including providing dust control measures and repair of roads damaged by Contractor vehicle access. Conractor shall abide by all traffic provisions established at the project site including maintaining a speed limit of 10 mph when travelling through the precast yard.

Material excavated from the project site may be utilized to maintain haul roads as appropriate. Any excess material can be stockpiled in the spoil area identified on G-004 of the contract drawings.

Amendment 0002*************************************************************

Any and all access to the Mt Eden gate must be coordinated in advance with Ft Knox Resident Office. A weight limit of 15 tons is enforced on this road and there is not an option to bond that roadway in order to increase that weight limit.

The Rodgers Hollow range area will not be accessible via the main entrance

SECTION 01 50 00 Page 4 during flooding/high water events. The road becomes inaccessible when the Ohio River McAlpine Lower gauge reaches approximately 48 ft. It is common for this situation to occur annually, and sometimes more often. The construction site would still be accessible to smaller vehicles via an alternate road but no deliveries, semis, etc. would be allowed. If this situation does occur, this period of time will be treated as an unusually severe weather event and the Contractor may be entitled to a Contract time extension in accordance with the paragraph titled "Time Extensions for Unusually Severe Weather" (ER-415-1-15) and FAR 52.249-10 "Default (Fixed Price Construction)"

************************************************************Amdendment 0002

2.2.2 Barricades

There are numerous existing barricades at the project site. If existing barricades do not adequately limit public access to hazardous areas, erect and maintain temporary barricades. Securely place barricades clearly visible with adequate illumination to provide sufficient visual warning of the hazard during both day and night.

2.3 FENCING

Provide fencing along the construction site and at all open excavations and tunnels to control access by unauthorized personnel. Safety fencing must be highly visible to be seen by pedestrians and vehicular traffic.

Specific fencing requirements are as described herein. All fencing will meet the requirements of EM 385-1-1.

2.3.1 Polyethylene Mesh Safety Fencing

Temporary safety fencing must be a high visibility orange colored, high density polyethylene grid, a minimum of 48 inches high and maximum mesh size of 2 inches. Fencing must extend from the grade to a minimum of 48 inches above the grade and be tightly secured to T-posts spaced as necessary to maintain a rigid and taut fence. Fencing must remain rigid and taut with a minimum of 200 pounds of force exerted on it from any direction with less than 4 inches of deflection.

2.3.2 Chain Link Panel Fencing

Temporary panel fencing must be galvanized steel chain link panels 6 feet high. Multiple fencing panels may be linked together at the bases to form long spans as needed. Each panel base must be weighted down using sand bags or other suitable materials in order for the fencing to withstand anticipated winds while remaining upright. Fencing must remain rigid and taut with a minimum of 200 pounds of force exerted on it from any direction with less than 4 inches of deflection.

2.4 TEMPORARY WIRING

Provide temporary wiring in accordance with EM 385-1-1 Section 11, NFPA 241 and NFPA 70. Include monthly inspection and testing of all equipment and apparatus.

SECTION 01 50 00 Page 5

PART 3 EXECUTION

3.1 EMPLOYEE PARKING

Construction contract employees will park privately owned vehicles in an area designated by the Contracting Officer. This area will be within reasonable walking distance of the construction site. Employee parking must not interfere with existing and established parking requirements of the overall project site.

3.2 TEMPORARY BULLETIN BOARD

Locate the bulletin board at the project site in a conspicuous place easily accessible to all employees, as approved by the Contracting Officer.

3.3 AVAILABILITY AND USE OF UTILITY SERVICES

3.3.1 Temporary Utilities

Provide temporary utilities required for construction. Materials may be new or used, must be adequate for the required usage, not create unsafe conditions, and not violate applicable codes and standards.

3.3.2 Sanitation

a. Provide and maintain within the construction area minimum field-type sanitary facilities approved by the Contracting Officer and periodically empty wastes into a municipal, district, or station sanitary sewage system, or remove waste to a commercial facility.

Obtain approval from the system owner prior to discharge into any municipal, district, or commercial sanitary sewer system. Any penalties or fines associated with improper discharge will be the responsibility of the Contractor. Coordinate with the Contracting Officer and follow station regulations and procedures when discharging into the station sanitary sewer system. Maintain these conveniences at all times. Include provisions for pest control and elimination of odors. Government toilet facilities will not be available to Contractor's personnel.

Amendment 0001****************************************************************

3.3.3 Telephone

Telephone service will not be provided by the Government and cellular service is extremely limited to non-existent in the general area. It is anticipated that 2-way radios will be necessary for the field personnel to communicate amongst one another. Additionally, a 2-way radio will be provided to Contractor personnel that will be able to contact range control in case of a medical emergency. Also, satellite internet service will likely be needed for communications in the contractor's trailer but is not required.

****************************************************************Amendment 0001

3.3.4 Obstruction Lighting of Cranes

Provide a minimum of 2 aviation red or high intensity white obstruction lights on temporary structures (including cranes) over 100 feet above ground level. Light construction and installation must comply with

SECTION 01 50 00 Page 6

FAA AC 70/7460-1. Lights must be operational during periods of reduced visibility, darkness, and as directed by the Contracting Officer.

3.3.5 Fire Protection

Provide temporary fire protection equipment for the protection of personnel and property during construction. Remove debris and flammable materials daily to minimize potential hazards.

3.4 TRAFFIC PROVISIONS

3.4.1 Maintenance of Traffic

a. Conduct operations in a manner that will not close any thoroughfare or interfere in any way with traffic on railways or highways except with written permission of the Contracting Officer at least 15 calendar days prior to the proposed modification date, and provide a Traffic Control Plan detailing the proposed controls to traffic movement for approval.

The plan must be in accordance with State and local regulations and the MUTCD, Part VI. Contractor may move oversized and slow-moving vehicles to the worksite provided requirements of the highway authority have been met.

b. Conduct work so as to minimize obstruction of traffic, and maintain traffic on at least half of the roadway width at all times. Obtain approval from the Contracting Officer prior to starting any activity that will obstruct traffic.

c. Provide, erect, and maintain, at contractors expense, lights, barriers, signals, passageways, detours, and other items, that may be required by the Life Safety Signage, overhead protection authority having jurisdiction.

3.4.2 Protection of Traffic

Maintain and protect traffic on all affected roads during the construction period except as otherwise specifically directed by the Contracting Officer. Measures for the protection and diversion of traffic, including the provision of watchmen and flagmen, erection of barricades, placing of lights around and in front of equipment the work, and the erection and maintenance of adequate warning, danger, and direction signs, will be as required by the State and local authorities having jurisdiction. Protect the traveling public from damage to person and property. Minimize the interference with public traffic on roads selected for hauling material to and from the site. Investigate the adequacy of existing roads and their allowable load limit. Contractor is responsible for the repair of any damage to roads caused by construction operations.

3.4.3 Dust Control

Dust control methods and procedures must be approved by the Contracting Officer. Coordinate dust control methods with LRL Section 01 57 19.00 06

TEMPORARY ENVIRONMENTAL CONTROLS AND PERMITS.

3.5 CONTRACTOR'S TEMPORARY FACILITIES

Contractor-owned or -leased trailers must be identified by Government assigned numbers. Apply the number to the trailer within 14 calendar days of notification, or sooner, if directed by the Government. Temporary

SECTION 01 50 00 Page 7 facilities will meet requirements as identified in EM 385-1-1 Section 04.

Amendment 0001****************************************************************

3.5.1 Administrative Field Offices

Provide and maintain administrative field office facilities at the location designated on the contract drawings. Government office and warehouse facilities will not be available to the Contractor's personnel.

3.5.2 Storage Area - NOT USED

3.5.3 Supplemental Storage Area - NOT USED

****************************************************************Amendment 0001

3.5.4 Appearance of Trailers

a. Trailers which are rusted, have peeling paint or are otherwise in need of repair will not be allowed on Installation property. Trailers must present a clean and neat exterior appearance and be in a state of good repair.

b. Paint using suitable paint and maintain the temporary facilities.

Failure to do so will be sufficient reason to require their removal.

3.5.5 Maintenance of Storage Area

a. Keep fencing in a state of good repair and proper alignment. Grassed or unpaved areas, which are not established roadways, and will be traversed with construction equipment or other vehicles, will be covered with a layer of gravel as necessary to prevent rutting and the tracking of mud onto paved or established roadways, should the Contractor elect to traverse them with construction equipment or other vehicles. Mow and maintain grass located within the boundaries of the construction site for the duration of the project. Grass and vegetation along fences, buildings, under trailers, and in areas not accessible to mowers will be edged or trimmed neatly.

3.5.6 Security Provisions

Provide adequate outside security lighting at the temporary facilities.

The Contractor will be responsible for the security of its own equipment.

3.5.7 Weather Protection of Temporary Facilities and Stored Materials

Take necessary precautions to ensure that roof openings and other critical openings in the building are monitored carefully. Take immediate actions required to seal off such openings when rain or other detrimental weather is imminent, and at the end of each workday. Ensure that the openings are completely sealed off to protect materials and equipment in the building from damage.

3.5.7.1 Building and Site Storm Protection

When a warning of gale force winds is issued, take precautions to minimize danger to persons, and protect the work and nearby Government property.

Precautions must include, but are not limited to, closing openings;

removing loose materials, tools and equipment from exposed locations; and

SECTION 01 50 00 Page 8 removing or securing scaffolding and other temporary work. Close openings in the work when storms of lesser intensity pose a threat to the work or any nearby Government property.

3.6 GOVERNMENT FIELD OFFICE

Amendment 0001****************************************************************

3.6.1 Resident Engineer's Office

Provide the Government Resident Engineer with an office, approximately 200 square feet in floor area, located inside the General Contractor's construction trailer and providing space heat, air conditioning, electric light and power, and toilet facilities (shared with the Contractor). Toilet facilities will consist of at least one lavatory and water closet complete with running hot water. Include a small plan table, 2 computer work spaces with a standard size office desks, chairs, and 1 bookcase. All furniture shall be "like new" condition.

Contractor shall empty trash, sweep floors, and clean Government facilities at least biweekly. The office must be lockable with minimum of two (2) keys provided to the Government. At completion of the project, the office will remain the property of the Contractor and be removed from the site.

Utilities will be connected and disconnected in accordance with local codes and to the satisfaction of the Contracting Officer. Compliance with safety and appearance requirements for temporary facilities stated in previous paragraphs is required.

****************************************************************Amendment 0001

3.7 PLANT COMMUNICATIONS

Whenever the individual elements of the plant are located so that operation by normal voice between these elements is not satisfactory, install a satisfactory means of communication, such as telephone or other suitable devices and make available for use by Government personnel.

3.8 TEMPORARY PROJECT SAFETY FENCING

As soon as practicable, but not later than 15 days after the date established for commencement of work, furnish and erect temporary project safety fencing at the work site. Maintain the safety fencing during the life of the contract and, upon completion and acceptance of the work, removefrom the work site.

3.9 CLEANUP

Remove construction debris, waste materials, packaging material and the like from the work site daily. Any dirt or mud which is tracked onto paved or surfaced roadways must be cleaned away. Store any salvageable materials resulting from demolition activities within the fenced area described above or at the supplemental storage area. Neatly stack stored materials not in trailers, whether new or salvaged.

3.10 RESTORATION OF STORAGE AREA

Upon completion of the project remove the bulletin board, signs, barricades and any other temporary products from the site. After removal of trailers, materials, and equipment from within the fenced area, remove the fence.

Restore areas used during the performance of the contract to the original

SECTION 01 50 00 Page 9 or better condition. Remove gravel used to traverse grassed areas and restore the area to its original condition, including top soil and seeding as necessary.

Amendment 0002***************************************************************

3.10.1 RANGE OPERATION RESTRICTIONS

Contractors shall be aware that live fire range operations will take precedence over construction operations in the Rodgers Hollow area.

Contractors shall anticipate up to 8 weeks (56 calendar days) per calendar year that personnel will not be allowed in the Rodgers Hollow area. The individual restrictions for down time could range from an hour up to 2 weeks. For any restrictions that will last 4 days or more, the Contractor will be given a 30 day notice. For restrictions that will last less 4 days, the Contractor will be given a 7 day notice.

***************************************************************Amendment 0002

-- End of Section --

SECTION 01 50 00 Page 10

SECTION 03 30 00

CAST-IN-PLACE CONCRETE

02/19

Amendment 0002

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to within the text by the basic designation only.

AMERICAN CONCRETE INSTITUTE (ACI)

ACI 117 (2010; Errata 2011) Specifications for Tolerances for Concrete Construction and Materials and Commentary

ACI 121R (2008) Guide for Concrete Construction Quality Systems in Conformance with ISO

ACI 213R (2014; E2017) Guide for Structural Lightweight-Aggregate Concrete

Amendment 0002*************************************************************

ACI 237 (2019) Self-Consolidating Concrete

*************************************************************Amendment 0002

ACI 301 (2016) Specifications for Structural Concrete

ACI 302.1R (2015) Guide for Concrete Floor and Slab Construction

ACI 304.2R (2017) Guide to Placing Concrete by Pumping Methods

ACI 304R (2000; R 2009) Guide for Measuring, Mixing, Transporting, and Placing Concrete

ACI 305.1 (2014) Specification for Hot Weather Concreting

ACI 305R (2010) Guide to Hot Weather Concreting

ACI 306.1 (1990; R 2002) Standard Specification for Cold Weather Concreting

ACI 306R (2016) Guide to Cold Weather Concreting

SECTION 03 30 00 Page 5

ACI 308.1 (2011) Specification for Curing Concrete

ACI 347R (2014; Errata 1 2017) Guide to Formwork for Concrete

ACI SP-2 (2007; Abstract: 10th Edition) ACI Manual of Concrete Inspection

ACI SP-15 (2011) Field Reference Manual: Standard Specifications for Structural Concrete ACI 301-05 with Selected ACI References

AMERICAN HARDBOARD ASSOCIATION (AHA)

AHA A135.4 (1995; R 2004) Basic Hardboard

AMERICAN WELDING SOCIETY (AWS)

AWS D1.4/D1.4M (2011) Structural Welding Code - Reinforcing Steel

ASTM INTERNATIONAL (ASTM)

ASTM A36/A36M (2014) Standard Specification for Carbon Structural Steel

ASTM A53/A53M (2018) Standard Specification for Pipe, Steel, Black and Hot-Dipped, Zinc-Coated, Welded and Seamless

ASTM A184/A184M (2019) Standard Specification for Welded Deformed Steel Bar Mats for Concrete Reinforcement

ASTM A615/A615M (2016) Standard Specification for Deformed and Plain Carbon-Steel Bars for Concrete Reinforcement

ASTM A706/A706M (2016) Standard Specification for Low-Alloy Steel Deformed and Plain Bars for Concrete Reinforcement

ASTM A767/A767M (2016) Standard Specification for Zinc-Coated (Galvanized) Steel Bars for Concrete Reinforcement

ASTM A775/A775M (2017) Standard Specification for Epoxy-Coated Steel Reinforcing Bars

ASTM A780/A780M (2009; R 2015) Standard Practice for Repair of Damaged and Uncoated Areas of Hot-Dip Galvanized Coatings

ASTM A820/A820M (2016) Standard Specification for Steel Fibers for Fiber-Reinforced Concrete

ASTM A884/A884M (2019) Standard Specification for Epoxy-Coated Steel Wire and Welded Wire Reinforcement

SECTION 03 30 00 Page 6

ASTM A934/A934M (2016) Standard Specification for Epoxy-Coated Prefabricated Steel Reinforcing Bars

ASTM A955/A955M (2018b) Standard Specification for Deformed and Plain Stainless-Steel Bars for Concrete Reinforcement

ASTM A970/A970M (2018) Standard Specification for Headed Steel Bars for Concrete Reinforcement

ASTM A996/A996M (2016) Standard Specification for Rail-Steel and Axle-Steel Deformed Bars for Concrete Reinforcement

ASTM A1022/A1022M (2016b) Standard Specification for Deformed and Plain Stainless Steel Wire and Welded Wire for Concrete Reinforcement

ASTM A1044/A1044M (2016a) Standard Specification for Steel Stud Assemblies for Shear Reinforcement of Concrete

ASTM A1055/A1055M (2016) Standard Specification for Zinc and Epoxy Dual Coated Steel Reinforcing Bars

ASTM A1060/A1060M (2016b) Standard Specification for Zinc-Coated (Galvanized) Steel Welded Wire Reinforcement, Plain and Deformed, for Concrete

ASTM A1064/A1064M (2017) Standard Specification for Carbon-Steel Wire and Welded Wire Reinforcement, Plain and Deformed, for Concrete

ASTM C31/C31M (2019) Standard Practice for Making and Curing Concrete Test Specimens in the Field

ASTM C33/C33M (2018) Standard Specification for Concrete Aggregates

ASTM C39/C39M (2018) Standard Test Method for Compressive Strength of Cylindrical Concrete Specimens

ASTM C42/C42M (2018a) Standard Test Method for Obtaining and Testing Drilled Cores and Sawed Beams of Concrete

ASTM C78/C78M (2018) Standard Test Method for Flexural Strength of Concrete (Using Simple Beam with Third-Point Loading)

ASTM C94/C94M (2018) Standard Specification for Ready-Mixed Concrete

ASTM C138/C138M (2017a) Standard Test Method for Density

SECTION 03 30 00 Page 7

(Unit Weight), Yield, and Air Content (Gravimetric) of Concrete

ASTM C143/C143M (2015) Standard Test Method for Slump of Hydraulic-Cement Concrete

ASTM C150/C150M (2018) Standard Specification for Portland Cement

ASTM C172/C172M (2017) Standard Practice for Sampling Freshly Mixed Concrete

ASTM C173/C173M (2016) Standard Test Method for Air Content of Freshly Mixed Concrete by the Volumetric Method

ASTM C231/C231M (2017a) Standard Test Method for Air Content of Freshly Mixed Concrete by the Pressure Method

ASTM C260/C260M (2010a; R 2016) Standard Specification for Air-Entraining Admixtures for Concrete

ASTM C311/C311M (2018) Standard Test Methods for Sampling and Testing Fly Ash or Natural Pozzolans for Use in Portland-Cement Concrete

ASTM C330/C330M (2017a) Standard Specification for Lightweight Aggregates for Structural Concrete

ASTM C494/C494M (2017) Standard Specification for Chemical Admixtures for Concrete

ASTM C552 (2017; E 2018) Standard Specification for Cellular Glass Thermal Insulation

ASTM C567/C567M (2014) Determining Density of Structural Lightweight Concrete

ASTM C578 (2018) Standard Specification for Rigid, Cellular Polystyrene Thermal Insulation

ASTM C591 (2019a) Standard Specification for Unfaced Preformed Rigid Cellular Polyisocyanurate Thermal Insulation

ASTM C595/C595M (2018) Standard Specification for Blended Hydraulic Cements

ASTM C618 (2019) Standard Specification for Coal Fly Ash and Raw or Calcined Natural Pozzolan for Use in Concrete

ASTM C803/C803M (2018) Standard Test Method for Penetration Resistance of Hardened Concrete

ASTM C845/C845M (2018) Standard Specification for Expansive Hydraulic Cement

SECTION 03 30 00 Page 8

ASTM C873/C873M (2015) Standard Test Method for Compressive Strength of Concrete Cylinders Cast in Place in Cylindrical Molds

ASTM C900 (2015) Standard Test Method for Pullout Strength of Hardened Concrete

ASTM C920 (2018) Standard Specification for Elastomeric Joint Sealants

ASTM C989/C989M (2018a) Standard Specification for Slag Cement for Use in Concrete and Mortars

ASTM C1012/C1012M (2018b) Standard Test Method for Length Change of Hydraulic-Cement Mortars Exposed to a Sulfate Solution

ASTM C1017/C1017M (2013; E 2015) Standard Specification for Chemical Admixtures for Use in Producing Flowing Concrete

ASTM C1074 (2011) Standard Practice for Estimating Concrete Strength by the Maturity Method

ASTM C1077 (2017) Standard Practice for Agencies Testing Concrete and Concrete Aggregates for Use in Construction and Criteria for Testing Agency Evaluation

ASTM C1107/C1107M (2017) Standard Specification for Packaged Dry, Hydraulic-Cement Grout (Nonshrink)

ASTM C1116/C1116M (2010a; R 2015) Standard Specification for Fiber-Reinforced Concrete

ASTM C1157/C1157M (2017) Standard Performance Specification for Hydraulic Cement

ASTM C1218/C1218M (2017) Standard Test Method for Water-Soluble Chloride in Mortar and Concrete

ASTM C1240 (2014) Standard Specification for Silica Fume Used in Cementitious Mixtures

ASTM C1260 (2014) Standard Test Method for Potential Alkali Reactivity of Aggregates (Mortar-Bar Method)

ASTM C1293 (2008; R 2015) Standard Test Method for Determination of Length Change of Concrete Due to Alkali-Silica Reaction

ASTM C1567 (2013) Standard Test Method for Potential Alkali-Silica Reactivity of Combinations of Cementitious Materials and Aggregate (Accelerated Mortar-Bar Method)

SECTION 03 30 00 Page 9

ASTM C1602/C1602M (2018) Standard Specification for Mixing Water Used in Production of Hydraulic Cement Concrete

Amendment 0002*************************************************************

ASTM C1611 (2018) Standard Test Method for Slump Flow of Self-Consolidating Concrete

*************************************************************Amendment 0002

ASTM C1778 (2016) Standard Guide for Reducing the Risk of Deleterious Alkali-Aggregate Reaction in Concrete

ASTM D412 (2016) Standard Test Methods for Vulcanized Rubber and Thermoplastic Elastomers - Tension

ASTM D471 (2016a) Standard Test Method for Rubber Property - Effect of Liquids

ASTM D1751 (2004; E 2013; R 2013) Standard Specification for Preformed Expansion Joint Filler for Concrete Paving and Structural Construction (Nonextruding and Resilient Bituminous Types)

ASTM D1752 (2018) Standard Specification for Preformed Sponge Rubber, Cork and Recycled PVC Expansion Joint Fillers for Concrete Paving and Structural Construction

ASTM D2628 (1991; R 2016) Standard Specification for Preformed Polychloroprene Elastomeric Joint Seals for Concrete Pavements

ASTM D2835 (1989; R 2017) Standard Specification for Lubricant for Installation of Preformed Compression Seals in Concrete Pavements

ASTM D3042 (2017) Standard Test Method for Insoluble Residue in Carbonate Aggregates

ASTM D5759 (2012) Characterization of Coal Fly Ash and Clean Coal Combustion Fly Ash for Potential Uses

ASTM D6690 (2015) Standard Specification for Joint and Crack Sealants, Hot Applied, for Concrete and Asphalt Pavements

ASTM E96/E96M (2016) Standard Test Methods for Water Vapor Transmission of Materials

ASTM E329 (2018) Standard Specification for Agencies Engaged in Construction Inspection, Testing, or Special Inspection

SECTION 03 30 00 Page 10

ASTM E1155 (2014) Standard Test Method for Determining Floor Flatness and Floor Levelness Numbers

ASTM E1643 (2018a) Standard Practice for Selection, Design, Installation, and Inspection of Water Vapor Retarders Used in Contact with Earth or Granular Fill Under Concrete Slabs

ASTM E1745 (2017) Standard Specification for Water Vapor Retarders Used in Contact with Soil or Granular Fill under Concrete Slabs

ASTM E1993/E1993M (1998; R 2013; E 2013) Standard Specification for Bituminous Water Vapor Retarders Used in Contact with Soil or Granular Fill Under Concrete Slabs

CONCRETE REINFORCING STEEL INSTITUTE (CRSI)

CRSI 10MSP (2009; 28th Ed; Errata) Manual of Standard Practice

CRSI RB4.1 (2016) Supports for Reinforcement Used in Concrete

FOREST STEWARDSHIP COUNCIL (FSC)

FSC STD 01 001 (2015) Principles and Criteria for Forest Stewardship

NATIONAL INSTITUTE OF STANDARDS AND TECHNOLOGY (NIST)

NIST PS 1 (2009) DOC Voluntary Product Standard PS 1-07, Structural Plywood

U.S. ARMY CORPS OF ENGINEERS (USACE)

COE CRD-C 513 (1974) Corps of Engineers Specifications for Rubber Waterstops

COE CRD-C 572 (1974) Corps of Engineers Specifications for Polyvinylchloride Waterstops

U.S. GENERAL SERVICES ADMINISTRATION (GSA)

FS SS-S-200 (Rev E; Am 1; Notice 1) Sealant, Joint, Two-Component, Jet-Blast-Resistant, Cold-Applied, for Portland Cement Concrete Pavement

1.2 DEFINITIONS

a. "Cementitious material" as used herein must include all portland cement, pozzolan, fly ash, and slag cement.

b. "Exposed to public view" means situated so that it can be seen from eye level from a public location after completion of the building. A public location is accessible to persons not responsible for operation

SECTION 03 30 00 Page 11 or maintenance of the building.

c. "Chemical admixtures" are materials in the form of powder or fluids that are added to the concrete to give it certain characteristics not obtainable with plain concrete mixes.

d. "Supplementary cementing materials" (SCM) include coal fly ash, , slag cement, natural or calcined pozzolans, and ultra-fine coal ash when used in such proportions to replace the portland cement that result in improvement to sustainability and durability and reduced cost.

e. "Design strength" (f'c) is the specified compressive strength of concrete at time(s) specified in this section to meet structural design criteria.

f. "Mass Concrete" is any concrete system that approaches a maximum temperature of 158 degrees F within the first 72 hours of placement.

In addition, it includes all concrete elements with a section thickness of 3 feet or more regardless of temperature.

g. "Mixture proportioning" is the process of designing concrete mixture proportions to enable it to meet the strength, service life and constructability requirements of the project while minimizing the initial and life-cycle cost.

h. "Mixture proportions" are the masses or volumes of individual ingredients used to make a unit measure (cubic meter or cubic yard) of concrete.

i. "Pozzolan" is a siliceous or siliceous and aluminous material, which in itself possesses little or no cementitious value but will, in finely divided form and in the presence of moisture, chemically react with calcium hydroxide at ordinary temperatures to form compounds possessing cementitious properties.

j. "Workability (or consistence)" is the ability of a fresh (plastic) concrete mix to fill the form/mould properly with the desired work (vibration) and without reducing the concrete's quality. Workability depends on water content, chemical admixtures, aggregate (shape and size distribution), cementitious content and age (level of hydration).

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for Contractor Quality Control approval. Submittals with an "S" are for inclusion in the Sustainability eNotebook, in conformance with Section 01 33 29 SUSTAINABILITY REPORTING.

Submit the following in accordance with Section 01 33 00 SUBMITTAL

PROCEDURES:

SD-01 Preconstruction Submittals

Concrete Curing Plan

Quality Control Plan; G

Quality Control Personnel Certifications; G

Quality Control Organizational Chart

SECTION 03 30 00 Page 12

Laboratory Accreditation; G

Form Removal Schedule; G

Maturity Method Data

SD-02 Shop Drawings

Formwork

Reinforcing Steel; G

SD-03 Product Data

Joint Sealants

Joint Filler

Formwork Materials

Recycled Aggregate Materials)

Cementitious Materials

Vapor Retarder

Concrete Curing Materials

Reinforcement

Liquid Chemical Floor Hardeners and Sealers

Admixtures

Waterstops

Local/Regional Materials

Pumping Concrete

Non-shrink Grout

SD-04 Samples

SD-05 Design Data

Concrete Mix Design; G

Formwork Calculations

SD-06 Test Reports

Concrete Mix Design; G

Fly Ash

SECTION 03 30 00 Page 13

Pozzolan

Slag Cement

Aggregates

Tolerance Report

Compressive Strength Tests; G

Unit Weight of Structural Concrete

Chloride Ion Concentration

Air Content

Slump Tests

Water

SD-07 Certificates

Reinforcing Bars

Welder Qualifications

Safety Data Sheets

Forest Stewardship Council (FSC) Certification

Field Testing Technician and Testing Agency

SD-08 Manufacturer's Instructions

Liquid Chemical Floor Hardeners and Sealers

Joint Sealants

Curing Compound

1.4 MODIFICATION OF REFERENCES

Accomplish work in accordance with ACI publications except as modified herein. Consider the advisory or recommended provisions to be mandatory.

Interpret reference to the "Building Official," the "Structural Engineer," and the "Architect/Engineer" to mean the Contracting Officer.

1.5 DELIVERY, STORAGE, AND HANDLING

Follow ACI 301, ACI 304R and ASTM A934/A934M requirements and recommendations. Do not deliver concrete until vapor retarder, forms, reinforcement, embedded items, and chamfer strips are in place and ready for concrete placement. Do not store concrete curing compounds or sealers with materials that have a high capacity to adsorb volatile organic compound (VOC) emissions. Do not store concrete curing compounds or sealers in occupied spaces.

SECTION 03 30 00 Page 14

1.5.1 Reinforcement

Store reinforcement of different sizes and shapes in separate piles or racks raised above the ground to avoid excessive rusting. Protect from contaminants such as grease, oil, and dirt. Ensure bar sizes can be accurately identified after bundles are broken and tags removed.

1.6 QUALITY ASSURANCE

1.6.1 Design Data

1.6.1.1 Formwork Calculations

ACI 347R. Include design calculations indicating arrangement of forms, sizes and grades of supports (lumber), panels, and related components.

Furnish drawings and calculations of shoring and re-shoring methods proposed for floor and roof slabs, spandrel beams, and other horizontal concrete members. Calculations must indicate concrete pressure with both live and dead loads, along with material types.

1.6.1.2 Concrete Mix Design

Sixty days minimum prior to concrete placement, submit a mix design for each strength and type of concrete. Submit a complete list of materials including type; brand; source and amount of cement, supplementary cementitious materials, and admixtures; and applicable reference specifications. Submit mill test and all other test for cement, supplementary cementitious materials, aggregates, and admixtures. Provide documentation of maximum nominal aggregate size, gradation analysis, percentage retained and passing sieve, and a graph of percentage retained verses sieve size. Provide mix proportion data using at least three different water-cementitious material ratios for each type of mixture, which produce a range of strength encompassing those required for each type of concrete required. If source material changes, resubmit mix proportion data using revised source material. Provide only materials that have been proven by trial mix studies to meet the requirements of this specification, unless otherwise approved in writing by the Contracting Officer. Indicate clearly in the submittal where each mix design is used when more than one mix design is submitted. Resubmit data on concrete components if the qualities or source of components changes. For previously approved concrete mix designs used within the past twelve months, the previous mix design may be re-submitted without further trial batch testing if accompanied by material test data conducted within the last six months.

Obtain mix design approval from the contracting officer prior to concrete placement.

1.6.2 Shop Drawings

1.6.2.1 Formwork

Drawings showing details of formwork including, but not limited to; joints, supports, studding and shoring, and sequence of form and shoring removal.

Indicate placement schedule, construction, location and method of forming control joints. Include locations of inserts, conduit, sleeves and other embedded items. Reproductions of contract drawings are unacceptable.

Submit form removal schedule indicating element and minimum length of time for form removal.

Design, fabricate, erect, support, brace, and maintain formwork so that it

SECTION 03 30 00 Page 15 is able to support, without failure, all vertical and lateral loads that may reasonably be anticipated to be applied to the formwork.

1.6.2.2 Reinforcing Steel

Indicate bending diagrams, assembly diagrams, splicing and laps of bars, shapes, dimensions, and details of bar reinforcing, accessories, and concrete cover. Do not scale dimensions from structural drawings to determine lengths of reinforcing bars. Reproductions of contract drawings are unacceptable.

1.6.3 Control Submittals

1.6.3.1 Concrete Curing Plan

Submit proposed materials, methods and duration for curing concrete elements in accordance with ACI 308.1.

1.6.3.2 Pumping Concrete

Submit proposed materials and methods for pumping concrete. Submittal must include mix designs, pumping equipment including type of pump and size and material for pipe, and maximum length and height concrete is to be pumped.

1.6.3.3 Safety Data Sheets

Submit Safety Data Sheets (SDS) for all materials that are regulated for hazardous health effects. SDS must be readily accessible during each work shift to employees when they are at the construction site.

1.6.4 Test Reports

1.6.4.1 Fly Ash and Pozzolan

Submit test results in accordance with ASTM C618 for fly ash and pozzolan.

Submit test results performed within 6 months of submittal date.

1.6.4.2 Slag Cement

Submit test results in accordance with ASTM C989/C989M for slag cement.

Submit test results performed within 6 months of submittal date.

1.6.4.3 Aggregates

Submit test results in accordance with ASTM C33/C33M, or ASTM C330/C330M for lightweight aggregate, and ASTM C1293 or ASTM C1567 as required in the paragraph titled ALKALI-AGGREGATE REACTION.

1.6.5 Quality Control Plan

Develop and submit for approval a concrete quality control program in accordance with the guidelines of ACI 121R and as specified herein. The plan must include approved laboratories. Provide direct oversight for the concrete qualification program inclusive of associated sampling and testing. All quality control reports must be provided to the Contracting Officer, Quality Manager and Concrete Supplier. Maintain a copy of ACI SP-15 and CRSI 10MSP at project site.

SECTION 03 30 00 Page 16

1.6.6 Quality Control Personnel Certifications

The Contractor must submit for approval the responsibilities of the various quality control personnel, including the names and qualifications of the individuals in those positions and a quality control organizational chart defining the quality control hierarchy and the responsibility of the various positions. Quality control personnel must be employed by the Contractor.

Submit American Concrete Institute certification for the following:

a. CQC personnel responsible for inspection of concrete operations.

b. Lead Foreman or Journeyman of the Concrete Placing, Finishing, and Curing Crews.

c. Field Testing Technicians: ACI Concrete Field Testing Technician, Grade I.

1.6.6.1 Quality Manager Qualifications

The quality manager must hold a current license as a professional engineer in a U.S. state or territory with experience on at least five similar projects. Evidence of extraordinary proven experience may be considered by the Contracting Officer as sufficient to act as the Quality Manager.

1.6.6.2 Field Testing Technician and Testing Agency

Submit data on qualifications of proposed testing agency and technicians for approval by the Contracting Officer prior to performing testing on concrete.

a. Work on concrete under this contract must be performed by an ACI Concrete Field Testing Technician Grade 1 qualified in accordance with ACI SP-2 or equivalent. Equivalent certification programs must include requirements for written and performance examinations as stipulated in

ACI SP-2.

b. Testing agencies that perform testing services on reinforcing steel must meet the requirements of ASTM E329.

c. Testing agencies that perform testing services on concrete materials must meet the requirements of ASTM C1077.

1.6.7 Laboratory Qualifications for Concrete Qualification Testing

The concrete testing laboratory must have the necessary equipment and experience to accomplish required testing. The laboratory must meet the requirements of ASTM C1077 and be Cement and Concrete Reference Laboratory (CCRL) inspected.

1.6.8 Laboratory Accreditation

Laboratory and testing facilities must be provided by and at the expense of the Contractor. The laboratories performing the tests must be accredited in accordance with ASTM C1077, including ASTM C78/C78M and ASTM C1260. The accreditation must be current and must include the required test methods, as specified. Furthermore, the testing must comply with the following requirements:

SECTION 03 30 00 Page 17

a. Aggregate Testing and Mix Proportioning: Aggregate testing and mixture proportioning studies must be performed by an accredited laboratory and under the direction of a registered professional engineer in a U.S.

state or territory competent in concrete materials and must sign all reports and designs.

b. Acceptance Testing: Furnish all materials, labor, and facilities required for molding, curing, testing, and protecting test specimens at the site and in the laboratory. Furnish and maintain boxes or other facilities suitable for storing and curing the specimens at the site while in the mold within the temperature range stipulated by

ASTM C31/C31M.

c. Contractor Quality Control: All sampling and testing must be performed by an approved, onsite, independent, accredited laboratory.

1.7 ENVIRONMENTAL REQUIREMENTS

Provide space…

This is the start of the file's text. The full file is on GovTribe.

File details come from the government source that posted it. Updated .