W912QR-50297505_NRP08-0000.pdf

PDF 16 MB Posted

Attached to
Construction Services for the FY25 National Roofing Program (NRP) Project #8 - TX213, Bryan, TX
Solicitation number
W912QR-50297505
Issued by

About this file

This is a solicitation for construction services for the FY25 National Roofing Program (NRP) Project #8 located in Bryan, Texas, issued by the U.S. Army Corps of Engineers Louisville District. The solicitation is specifically for roof replacement services at two facilities: the USARC building (44,343 sq ft) and the AMSA building (two sections totaling 8,094 sq ft), with an estimated project cost between $1,000,000 and $5,000,000.

The contract is a design-build task order under a Multiple Award Task Order Contract (MATOC), requiring contractors to provide comprehensive roof replacement services including design analysis, site investigations, and construction. The existing roofs are modified bitumen systems installed in 2010, and the new roofs will be PVC membrane with ribs. Contractors must address multiple deficiencies identified in the site inspection report, including poor flashing, exposed reinforcement, granule loss, and drainage issues. Proposals are due by 2:00 PM ET on 23 June 2025, with the contract to be awarded on a best-value basis, considering past performance and pricing. The project includes replacement of exterior sealants and requires compliance with specific government standards and requirements.

View the file

Other files

File Type Posted
W912QR-50297505_NRP08-0002.pdf PDF
W912QR-50297505_NRP08-0001.pdf PDF

On GovTribe

Work with this file

  • Download the original file
  • Contacts named in this file
  • Similar government files
  • Ask GovTribe AI about this file

Text version

Solicitation For Army Reserve National Roofing Program FY25 Task Order #8

P2: 565479 Design-Build

Volume A – TX213 Bryan, TX

Certified Final

19 May 2025

W912QR-50297505

MATOC W912QR24D0054 thru 24D0063 All requirements of the base MATOC Volume 1 of 2 shall apply to this Task Order unless noted otherwise.

ARIMS: 200A

Disposition: Maintain for 15yrs after construction

W912QR-50297505_NRP08-0000

National Roofing Program (NRP) FY25

Project 08

P2 565479

TX213, Bryan, TX, US

Table of Contents

Version Certified Final

TABLE OF CONTENTS

VOLUME A: TX213, Bryan, TX

DIVISION 00 – PROCUREMENT AND CONTRACTING REQUIREMENTS

00 80 50.00 06 SPECIAL PROVISIONS FOR TASK ORDERS

00 80 50.00 06 Submittal Register

DIVISION 01 – GENERAL REQUIREMENTS

01 11 50.00 06 Task Order SCOPE OF WORK

ATTACHMENTS

ATTACHMENT A: Site Location

ATTACHMENT B: Building Layout

ATTACHMENT C: Site Inspection Report, 14 March

2025(For Information Only)

--End of Table of Contents--

NRP FY25 Project 08

TX213 Bryan, TX

25-Mar-25

SECTION 00 80 50.00 06

Version CERTIFIED FINAL

SECTION

00 80 50.00 06

SPECIAL PROVISIONS FOR TASK ORDERS

08/19

1. PART 1 GENERAL

1.1. SUBMITTALS

Government approval/acceptance is required for submittals with a "GOVT” designation; submittals not having a "GOVT" designation are for information only. When used, a designation following the "GOVT" designation identifies the office that will review the submittal for the

Government. The submittals listed in the Submittal Register at the end of this specification section shall be submitted in accordance with Section

01 33 00.00 06.

SD-01 Preconstruction Submittals

SD-02 Shop Drawings

SD-05 Design Data

SD-07 Certificates

SD-11 Closeout Submittals

1.2. NOT USED

1.3. COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK - Paragraph 1.37 of Section 00 80 00.00 06 is replaced with the following:

1.3.1 After approval of the required bonds, the Government will issue an Administrative Notice-to-Proceed (NTP) to allow for preconstruction activities to be initiated in accordance with the contract requirements. The contract period of performance specified in Contract

Clause 52.211-10 will begin upon issuance of Administrative NTP. No onsite demolition or construction work will be permitted during the

Administrative NTP period. All required preconstruction activities and submittals must be submitted and accepted by the Government, where applicable, within the Administrative NTP period. The Government will issue a Construction NTP to allow commencement of all other contract work after the Administrative NTP period, or after the contractor's completion of all work specified in the Administrative NTP. Failure to complete all required preconstruction activities may result in the contract being terminated for default in accordance with Contract

Clause 52.249-10 Default (Fixed-Price Construction)..

1.3.2 Refer to FAR 52.211-12 "LIQUIDATED DAMAGES" in Section 00 70 50 for the amount of Liquidated Damages for the Task order project.

1.3.3 Refer to FAR 52.211-10 "Commencement, Prosecution, and Completion of Work" in Section 00 70 50 for a notification of significant contract dates.

1.3.4 Additional Requirements/Clarifications of Work Included Within the Contract

The time stated in FAR 52.211-10 "Commencement, Prosecution, and

Completion of Work" in Section 00 70 50 for completion shall include as-built drawings, O&M manuals, operational tests/reports/training/instructions, and equipment lists.

1.4. TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER. ER 415-1-15

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the "Default

(Fixed-Price Construction)" as discussed in Section 00 70 00 of the base contract and Section 00 70 50 of this task order. In order for the

Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY WORKDAYS BASED ON (5) DAY WORK

WEEK

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

TX213 22 20 21 16 8 4 5 2 4 9 19 20

Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to

P2 565479

25-Mar-25

SECTION 00 80 50.00 06

Version CERTIFIED FINAL normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the

Contractor's scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated listed above, the

Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair-weather workdays, and issue a modification in accordance with the "Default (Fixed-Price

Construction)" in section 00 70 00 of the base contract, Volume 1 .

1.5. WAGE RATES

The decision of the Secretary of Labor, covering rates of wages, including fringe benefits to be paid laborers and mechanics performing work under this contract, is attached to this solicitation. The payment for all classes of laborers and mechanics actually employed to perform work under the contract will be specified in the following contract provisions: "Contract Work Hours and Safety Standards --

Overtime Compensation"; "Construction Wage Rate Requirements"; and

"Compliance with Copeland Act Requirements" in Section 00 70 00 of the base contract.

Wage decision included: TX20250234 Building

The work to be performed is located in Bryan, TX, Brazos County.

1.6. NOT USED

1.7. Antiterrorism (AT) and Operations Security (OPSEC)- Paragraph 1.7 of Section 00 80 00.00 06 is replaced with the following:

1.7.1 AT Level I training. This standard language is for contractor employees with an area of performance within an Army-controlled installation, facility, or area. All contractor employees, including subcontractor employees, requiring access to Army installations, facilities, and controlled access areas shall complete AT Level I awareness training within 30 calendar days after contract start date or effective date of incorporation of this requirement into the contract, whichever is applicable. The contractor shall submit certificates of completion for each affected contractor employee and subcontractor employee to the COR or to the contracting officer, if a COR is not assigned, within 30 calendar days after completion of training by all employees and subcontractor personnel. AT Level I awareness training is available at the following website: http://jko.jten.mil.

http://jko.jten.mil/

1.7.2 Access and general protection/security policy and procedures.

This standard language is for contractor employees with an area of performance within an Army-controlled installation, facility, or area.

Contractor and all associated subcontractor employees shall provide all information required for background checks to meet installation access requirements to be accomplished by the installation Provost Marshal

Office, Director of Emergency Services, or Security Office. Contractor workforce must comply with all personal identity verification requirements (CFR clause 52.204-9, Personal Identity Verification of

Contract Personnel) as directed by DoD, HQDA and/or local policy. In addition to the changes otherwise authorized by the changes clause of this contract, should the Force Protection Condition (FPCON) at any individual facility or installation change, the Government may require changes in contractor security matters or processes.

1.7.3 AT Awareness Training for Contractor Personnel Traveling

Overseas. This standard language requires U.S.-based contractor employees and associated subcontractor employees to make available and to receive Government-provided area of responsibility (AOR)–specific AT awareness training as directed by AR 525-13. Specific AOR training content is directed by the combatant commander, with the unit ATO being the local point of contact.

1.7.4 Army Training Certification Tracking System (ATCTS) registration for contractor employees who require access to Government information systems. All contractor employees with access to a Government info system must be registered in the ATCTS at commencement of services and must successfully complete the DoD Information Assurance Awareness prior to access to the information system and annually thereafter.

1.7.5 For contracts that require a formal OPSEC program. The contractor shall develop an OPSEC Standing Operating Procedure (SOP)/Plan within

90 calendar days of contract award, to be reviewed and approved by the responsible Government OPSEC officer. This plan will include a process to identify critical information, where it is located, who is responsible for it, how to protect it, and why it needs to be protected. The contractor shall implement OPSEC measures as ordered by the commander. In addition, the contractor shall have an identified certified Level II OPSEC coordinator per AR 530-1.

1.7.6 Controlled Unclassified Information (CUI). Include DFARS clause

252.204-7012, which requires the contractor to comply with NIST 800-

171. Also include DFARS provision 252.204-2019 into solicitations.

Acquisition officials should follow procedures outlined in DFARS 204.73 and verify vendors have an adequate NIST SP 800-171 summary assessment score within the Supplier Performance Risk System (within PIEE). If the score doesn’t show a medium- or high-level assessment with a score of

110 or better (as described in the “NIST SP 800-171 DoD Assessment

Methodology”), include clause252.204-7020 and obtain the vendor’s

P2 565479

25-Mar-25

SECTION 00 80 50.00 06

Version CERTIFIED FINAL

“system security plan” and “plan of action” for NIST SP 800-171 verification and assurance by Army security officials.

1.8. NOT USED

1.9. NOT USED

1.10. NOT USED

1.11. NOT USED

1.12. NOT USED

1.13. NOT USED

1.14. NOT USED

1.15. NOT USED

1.16. NOT USED

1.17. NOT USED

1.18. NOT USED

1.19. NOT USED

1.20. NOT USED

1.21. NOT USED

1.22. NOT USED

1.23. NOT USED

1.24. NOT USED

1.25. NOT USED

1.26. NOT USED

2. PART 2 PRODUCTS NOT USED

3. PART 3 EXECUTION NOT USED

Line

Act-ivity

Trans-mittal # Specification Section SD # SD Description Item Submitted

Paragraph

Classi-fication:

GA for

GOVT or

A/E Revwr Submit

Approval

Needed

By

Material

Needed

By

Action

Code

Date Of

Action

Date FWD to APPR /

Auth -

Date RCD

From

CONTR

Date

FWD To

Other

Revwr

Date

RCD

From

Other

Revwr

Action

Code

Date Of

Action

Mailed To

CONTR/

Date RCD

From

APPR

Authority Remarks

01 11 00.00 06 SD-01 Preconstruction Submittal Contractor’s Safety Program 3.7.2 GA

01 11 00.00 06 SD-01 Preconstruction Submittal Demolition Plan 4.2.1 GA

01 32 01.00 06 SD-01 Preconstruction Submittal Project Schedule 3.4 GA

01 35 26.00 06 SD-01 Preconstruction Submittal Scaffolding Erection Plan 3.4 GA

01 35 26.00 06 SD-01 Preconstruction Submittal Accident Prevention Plan (APP) 1.7 GA

01 35 26.00 06 SD-01 Preconstruction Submittal Accident Prevention Plan 1.8 GA

01 35 26.00 06 SD-01 Preconstruction Submittal Activity Hazard Analysis (AHA) 1.8 GA

01 35 26.00 06 SD-01 Preconstruction Submittal Site Safety & Health Officer Qualifications

(SSHO)

1.5.1 GA

01 45 04.10 06 SD-01 Preconstruction Submittal Design Quality Control Plan 3.2 GA

01 45 04.10 06 SD-01 Preconstruction Submittal Construction Quality Control Plan 3.3 GA

01 50 00 SD-01 Preconstruction Submittal Construction Site Plan 1.3 GA

01 57 19.00 06 SD-01 Preconstruction Submittal Environmental Protection Plan 1.7 GA

01 74 19 SD-01 Preconstruction Submittal Construction Waste Management Plan 1.7 GA

00 80 00.00 06 SD-05 Design Data Progress Photographs 1.45 GA

00 80 00.00 06 SD-07 Certificates No Asbestos - Containing Material (ACM)

Certification

1.14 GA

00 80 00.00 06 SD-07 Certificates Insurance 1.31 GA

00 80 00.00 06 SD-07 Certificates Warranties 1.15 GA

00 80 00.00 06 SD-08 Certificates Crane Certificate of Compliance 1.12.6 GA

00 80 00.00 06 SD-11 Closeout Submittals Records, Waste Generated/Diverted 1.10 GA

00 80 00.00 06 SD-11 Closeout Submittals Preliminary (Working) As-Built Drawings 3.4 GA

00 80 00.00 06 SD-11 Closeout Submittals Final As-Built Drawings 3.4 GA

TITLE: NRP FY25 Project 8

SUBMITTAL REGISTER

JOB NAME: TX213

LOCATION: Bryan, TX

CONTRACT NO:

CONTRACTOR:

SB MATOC

CONTRACTOR SCHEDULE

DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

FY25 NRR Project 08 TX213, Bryan, TX

SECTION 01 11 50.00 06

SECTION

01 11 50.00 06

Task Order SCOPE OF WORK Updated 6 Feb 2025

1. PROJECT INFORMATION

1.1. GENERAL

Design/Build: The Contractor shall provide all labor, equipment, supplies, and consultant services and all site investigations, surveys, analysis, sampling, testing and verification of existing field conditions as required for design and construction of the Roof Replacement Project at TX213 to result in a complete and useable Facility. Contractor shall provide complete design analysis incorporating all engineering computations, analysis, test, and survey results, building code (including fire protection, life safety, environmental and accessibility) review as it pertains/affects/relates to this project, equipment and material data and documentation of existing conditions.

1.2. SCOPE OF WORK

Unless specifically noted otherwise in this Specification Section or in the base MATOC contract Volume 1 of 2 itself, all requirements of the base MATOC contract Volume 1 of 2 shall apply to this Task Order. The work includes design and construction to replace the following roof systems located at TX213:

Building RFID (SF) Section(s) Existing Roof System

USARC (44,343) 1 MODIFIED BITUMEN

AMSA (3,869) 1 MODIFIED BITUMEN

AMSA (4,225) 2 MODIFIED BITUMEN

Design/Build: Design and construction shall comply with the requirements contained in this Task Order Request for Proposal (RFP). The design and technical criteria contained and cited in this RFP and the Unified Facilities Guide Specifications (UFGS) establish minimum standards for design and construction quality. The Designers of Record shall use the Unified Facilities Guide Specifications (UFGS) and the requirements contained in this RFP to fully develop the technical specifications and construction drawings. The objective of this solicitation is to obtain an energy efficient, durable, maintainable, and sustainable space.

Design/Build: The illustrations and exhibits included in this RFP illustrate the conceptual design of the project and are provided to define the scope of work and budget. The concepts provided shall be further developed by the Design/Build Contractor to comply with the customer’s functional needs.

All demolition required to construct the project is included as part of the work of this Contract.

1.3. SITE LOCATION

This project is located at Bryan, TX.

1.4. EXISTING SITE UTILITIES

1.4.1. The contractor shall verify the location of all utilities serving the building. Upgrading the existing utilities, (unless noted otherwise) outside the limits of construction, is not a part of this project.

1.5. BID OPTIONS

1.6. NOT USED

1.7. ATTACHMENTS

Design/Build: Information provided in the Attachments is intended to guide the completion of the design by establishing existing conditions, and the desired character, appearance, and function of the new construction. The following Attachments are included and shall be used and strictly adhered-to in completing the design and construction of the project.

a. ATTACHMENT A: Site Location

b. ATTACHMENT B: Building Layout Plans

c. ATTACHMENT C: Site Inspection Report, 14-Mar-25

1.8. NOT USED

1.9. NOT USED

1.10. NOT USED

1.11. NOT USED

1.12. NOT USED

1.13. NOT USED

1.14. PERSONNEL REQUIREMENTS AND QUALIFICATIONS

1.15. Registered Roof Consultant (RRC) (Designer of Record) shall have a degree in Architecture or Engineering and have at least ten (10) years of experience in roof repairs. The RRC must be currently licensed by the International Institute of Building Envelope Enclosures

(IIBEC).

1.16. NOT USED

P2 565479 25-Mar-25

SECTION 01 11 50.00 06

Version CERTIFIED FINAL

1.17. NOT USED

1.18. NOT USED

1.19. NOT USED

2. DESIGN REQUIREMENTS

2.1. GENERAL

The Contractor shall prepare complete construction documents for all work designed as required by the RFP. The construction documents to be prepared shall include, but are not limited to, construction drawings, specifications, submittals, and design analysis as required in Section 01 33 16.00 10 DESIGN DATA (DESIGN AFTER AWARD), Volume 1. Materials and equipment shall be limited to those specified except that where no specific material and equipment is specified or no basis of design is identified, the Contractor shall use materials and equipment accepted within the construction industry and in compliance with Design Criteria.

2.2. DESIGN

2.2.1. The Contractor shall prepare a 100% design for the project in accordance with the RFP using industry standard materials and efficient practices. The design of the materials selected shall be high quality, durable and easily maintained. The Contractor shall be responsible for the professional quality, code compliance, technical accuracy, and coordination of all designs, drawings, specifications, and other documents or publications upon which the design and construction are based. It shall be the responsibility of the Design/ Build Contractor to verify the accuracy of the documents provided.

2.2.2 CAD/BIM Requirement

The contractor will not be required to produce advanced modeling and design drawings will be limited to CAD files.

2.2.3 Design Submittal Requirements

The contractor will not be required to produce charette or interim design submittals. The contractor will submit a final design, a corrected final design, and a certified final design. The independent Registered Roof Observer (RRO) identified under Section 01 11 00.00 06 Paragraph 3.3..2.3 shall review the final design as part of the contractor design QC review team. The RRO shall attend the final design plan-in-hand review meeting.

2.1.4 Design Professionals

General Scope of work for most task orders will be for roof replacement and exterior water proofing with associated work. Roof replacement design will be certified by a RRC and have a professional engineer or architectural stamp. Structural analysis will only be required if there is a change in the dead load for the structural system or if called out in the task order scope of work. Electrical and mechanical design will be limited to relocating existing systems.

2.2.2. Design Milestone Schedule

Notice to Proceed (NTP) Day 0 Design Quality Control Plan (DQCP) NTP + 14 Days Design Kick-off (on site) NTP + 40 Days Charette Report (FIO no review) NTP + 60 Days Final Submittal NTP + 120 Days Final Plan in Hand Meeting (on-site) NTP + 138 Days Corrected Final Submittal NTP + 152 Days Certified Final Submittal NTP + 160 Days

2.3. REQUEST FOR PROPOSAL (RFP) INTENT

The intent of this RFP section is to describe the requirements for appearance, function, materials, and types of construction in sufficient detail to enable engineering and design to be completed by the Contractor.

2.4. Design Milestone Meetings

2.4.1. Charette / Kickoff Meeting

2.4.1.1. Shall be in person and on-site.

2.4.2. Final Design / Plan-in-hand Review Meeting

2.4.2.1. Shall be in person and on-site.

2.5. NOT USED

2.6. NOT USED

2.7. NOT USED

2.8. NOT USED

2.9. NOT USED

2.10. NOT USED

2.11. NOT USED

2.12. GOVERNMENT FURNISHED MATERIALS

2.12.1. GFM Handover

The GFM has been provided as part of the Solicitation package.

2.12.2. GFM File Formats

GFM are provided only in PDF format.

2.13. (See Paragraph 2.1 Section 01 11 00.00 06 )DESIGN SUBMITTAL

DISTRIBUTION MATRIX

Submittal Reviewers & Mailing Addresses

U.S. Army Corps of Engineers Ryan Fagan, PE

RYAN.A.FAGAN@USACE.ARMY.MIL

LRL-ED-MA Room 414 600 Doctor Martin Luther King Junior Place Louisville, KY 40202

Timothy M. McClellan, P.E., RRC Timothy.m.mcclellan@usace.army.mil LRL-ED-MA Room 414

Michael Brooks Michael.s.brooks@usace.army.mil

LRL-CDR

Jeffrey E. Bayers, P.E., P.M.P.

Jeffrey.e.bayers@usace.army.mil

LRL-PM-R

Steve Coffey, PE USARC G 3/5/7 Engineers - Desk 4N-4001-62 4700 Knox Street, Bldg 8-8108 Ft. Bragg, NC 28310 Phone: 910-570-8961 Email: steven.w.coffey3.civ@army.mil

Justin Reeder, PE, RRC, RRO, CDT USARC-ARIMD Engineering Branch / SAIN Engineering USAR National Roofing Program REM Phone: 843.813.2423

W912QR-50297505_NRP08-0000

mailto:Timothy.m.mcclellan@usace.army.mil mailto:Michael.s.brooks@usace.army.mil mailto:Jeffrey.e.bayers@usace.army.mil mailto:steven.w.coffey3.civ@army.mil

Email: justin.reeder@saineng.com

Jimmy Allgeier Construction Administration Section US Army Corps of Engineers 600 Dr. Martin Luther King, Jr Pl Louisville, Ky 40202 Phone:502-315-7428 Email: jamesjimmy.r.allgeier@usace.army.mil

3. GENERAL CONSTRUCTION REQUIREMENTS

3.1. SUMMARY

3.1.1. The requirements include:

a. Construction considerations and use of the premises.

b. Protection of personnel and Government property.

c. Construction facilities and job site standards.

d. The requirements of this section apply to the entire project including all amendments or modifications that may be issued to modify the contract documents.

3.2. GENERAL INFORMATION

3.2.1. NOT USED

3.2.2. NOT USED

3.2.3. Coordinate all construction activities with:

a. Contracting Officer’s Representative

b. Base Fire Department

c. Base Security/Police

d. Base Civil Engineer

e. Building Occupants

3.2.4. NOT USED

3.2.5. NOT USED

3.2.6. NOT USED

3.2.7. NOT USED

3.2.8. NOT USED

3.2.9. Project and Safety Signs. See 01 50 00, Paragraph 2.1.3.

3.3. DOCUMENTATION

3.3.1. NOT USED

mailto:justin.reeder@saineng.com

3.3.2. NOT USED

3.4. NOT USED

3.5. Work Schedule under Section 01 11 00.00 06 Paragraph 3.9.1.2 is changed to “Work S WORK SCHEDULE: The Contractor shall schedule the work between the hours of 7:00 a.m. and 4:30 p.m. Monday through Friday except Federal Holidays.

3.5.1. Permission to perform any work outside of these hours must be in writing and submitted five (5) calendar days in advance for approval by the Contracting Officer.

3.5.2. The Government may or may not grant such permission at its discretion.

3.6. Contractor Personal Vehicle Parking under Section 01 11 00.00 06 Paragraph 3.9.1.7 is changed to Contractor Personal Vehicle Parking:

The contractor may use a limited number of parking spaces in the existing lots for the contractor’s employee parking of personal vehicles. The Contractor shall coordinate with the Government on the exact number of available spaces, and shall make provisions to transport employees to the site should inadequate parking spaces be available on site. Parking in these areas is available on a first-come first served basis.

4. NOT USED

5. NOT USED

6. EXTERIOR EQUIPMENT

6.1. Properly secure rooftop equipment on AMSA, limited to one exhaust fan.

7. ARCHITECTURAL / BUILDING ENVELOPE

7.1. Approximately 1300 LF of exterior sealant to be replaced at

USARC. Approximately 700 LF of exterior sealant to be replaced at AMSA.

7.2. NOT USED

8. NOT USED

9. NOT USED

10. NOT USED

11. NOT USED

12. NOT USED

13. NOT USED

14. Roof System

Roof system installed shall comply with UFC 3-110-03 Roofing, with Change 5, or the latest version available. Where they do not existing contractor shall install roof access ladders from the ground to roof and between roof sections to allow access to all sections.

Contractors shall install new splash blocks at all downspout terminations.

Contractor bids shall include removal of 2-8 inches of insulation.

Existing roof systems may be multi-layered with differing roof system types below the surface membrane. Contractor is responsible for identifying all equipment mounted directly below the deck and to utilize a connection method that either avoids the deck or relocates equipment in a way that complies with current building codes.

Building RFID (SF) Section(s) New Roof System USARC (44,343) 1 PVC Membrane w/ Ribs AMSA (3,869) 1 PVC Membrane w/ Ribs AMSA (4,225) 2 PVC Membrane w/ Ribs

14.1. NOT USED

14.2 ROOF DECK REPAIR

Inspect the roof deck carefully. If there are roof deck areas which require repair or replacement, notify the Contracting Officer. Do not proceed with repair or replacement until directed by the Contracting Officer. Assume replacement up to 10% damaged decking and 50% wood nailers.

--End of Section --

TX

O

VE

R

AL

L

M

AP

U

SA

R C

BU

IL

D

IN

G

AM

SA

BU

IL

D

IN

G

SC Engineers COA #1906

ROOF ASSESSMENT REPORT

FOR

NATIONAL ROOFING PROGRAM (NRP)

FY23 1-N, TX213

2350 N HARVEY MITCHELL PARKWAY

BRYAN, TX 77801

March 14, 2025

REI PROJECT NO. 23CHS-020

TX213

ROOF ASSESSMENT REPORT

TABLE OF CONTENTS

I. OVERALL MAP

II. USARC BUILDING SITE OVERVIEW

III. USARC BUILDING SECTION 1

A. SECTION 1 COMPOSITION

B. SECTION 1 OBSERVATION

C. SECTION 1 DEFICIENCIES

D. SECTION 1 SUMMARY

IV. AMSA BUILDING SITE OVERVIEW

V. AMSA BUILDING SECTION 1

A. SECTION 1 COMPOSITION

B. SECTION 1 OBSERVATION

C. SECTION 1 DEFICIENCIES

D. SECTION 1 SUMMARY

VI. AMSA BUILDING SECTION 2

A. SECTION 2 COMPOSITION

B. SECTION 2 OBSERVATION

C. SECTION 2 DEFICIENCIES

D. SECTION 2 SUMMARY

VII. ROOF PLANS

A. USARC BUILDING

B. AMSA BUILDING

COVER
MATOC Letter
Offeror's Questions and Comments
00 10 00
Price Breakout Schedule
00 70 00
General Decision Number: TX20250234 05/16/2025
TOC
00 80 50.00 06
SUB REGISTER
01 11 50.00 06
ATTACHMENT A
ATTACHMENT B
ATTACHMENT C

File details come from the government source that posted it. Updated .