D2 - Solicitation Amendment - W912PM26RA0040005 CCopy Final.pdf

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Section 00 00 00 - Procurement and Contracting Requirements

Philpott Dam Anchors and Instrumentation ConstructionInstrument Name:

SOLICITATION W912PM26RA004 - Philpott Dam Anchors and Instrumentation Construction THE MAGNITUDE OF CONSTRUCTION FOR THIS PROJECT IS BETWEEN $5,000,000.00 and $10,000,000.00. ------------------------------- UNRESTRICTED-------------------------------------------------------- HAND CARRIED PROPOSALS AND

OTHER FORMS OF ELECTRONIC SUBMISSION, TO INCLUDE (CD-ROM) DISCS AND

FACSIMILE TRANSMISSIONS, ARE NOT AUTHORIZED. ALL PROPOSALS MUST BE

SUBMITTED ELECTRONICALLY PER ENCLOSURE 3: INSTRUCTIONS TO OFFERORS.

RETURN SECTION 00 45 00 REPRESENTATIONS AND CERTIFICATIONS WITH PROPOSAL.

VERBAL AND WRITTEN REQUESTS FOR INFORMATION MUST BE DIRECTED TO THE

PERSON LISTED ABOVE. INQUIRIES AND REQUESTS THAT ARE DIRECTED TO ANY

OTHER PERSON MAY NOT BE RELAYED TO THE PROPER PERSON AND, THEREFORE,

MAY NOT BE ANSWERED. SOLICITATION/TECHNICAL INQUIRIES VIA PROJNET IN

SECTION 00 21 13.

W912PM26RA0040005

Section 00 01 15 - List of Drawing Sheets

The attachments listed in this Section are incorporated by reference and made part of this contract with the same force and effect as if included in full text.

A21 - Specifications

A21 - Unlocked Drawings

A21 - Locked Drawings

A19 - DBA_WD_Virginia_VA20260025_Mod._No._0_Rev._Date_01.02.26

A19 - DBA_WD_VA2026001 01Jan2026

B9 - Enclosure 3 - Instructions to Offerors

B9 - Attachment 1 - Proposal Data Sheet

*** END OF NARRATIVE ***

Section 00 10 00 - Solicitation, Contract Line Item Number (CLIN) Schedule

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price

Amount

0001 Mobilization in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

1 Job

0002 Inclinometer core drilling and casing installation in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

382 Linear Foot

0003 Inclinometer Sensor installation in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

184 Each

0004 Vibrating Wire Piezometer in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

13 Each

0005 Pneumatic Piezometer Conversion in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

4 Each

0006 Automated Crack Meter Installation in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

22 Each

0007 6 Each

Anchor Vibrating Wire Load Cell Installation in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

0008 Anchor Electromagnetic Sensor Installation in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

6 Each

0009 Electrical Panelboard Installation in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

2 Each

0010 RMU Installation in accordance with the specification Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

1 Each

0011 RIO Cabinet Installation Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

3 Each

0012 Drilling in Concrete for Spillway Anchors Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

816 Linear Foot

0013 Spillway Anchors Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

786 Linear Foot

0014 Performance Test Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

12 Each

0015 Water Tightness Test 12 Each

Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

0016 Regrout for Anchors Pricing Arrangement: Firm Fixed Price

200 Cubic Feet

0017 Redrill Grout Holes Pricing Arrangement: Firm Fixed Price

522 Linear Foot

0018 Demobilization Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

1 Job

0019 Performance and Payment Bonds Product Service Code: Y1KA Pricing Arrangement: Firm Fixed Price

1 Job

Section 00 21 00 - Instructions

TOTAL AMOUNTS

TOTAL OF ALL LINE ITEM 0001 - 0019 ____________

NOTICE TO OFFERORS

NOTE 1: PLEASE BE SURE TO INCLUDE UNIT PRICES ROUNDED TO TWO (2) DECIMAL

PLACES.

NOTE 2: Proposal will be evaluated in accordance with Enclosure 3 - Instruction to offerors.

(End of Notice)

Information to all Contractors

System for Award Management (SAM)and Electronic Funds Transfer (EFT)

1. All contractors must register in the System for Award Management (SAM) database before they can be awarded a contract. You may register at http://www.sam.gov. SAM information or help is also available by calling 866-606-8220.

2. Public Law 104-134 requires the use of Electronic Funds Transfer (EFT) for all Federal payments. EFT information will be pulled from your SAM by the USACE FINANCE CENTER, 5720 INTEGRITY DRIVE, MILLINGTON, TN 38054-5005 for contractor payments.

(End)

Pre-Award Information

1. Contracts shall be awarded to responsible prospective contractors only. Before award, to be determined responsible, a prospective contractor must:

a. Have adequate financial resources to perform the contract, or the ability to obtain them;

b. Be able to comply with the required or proposed delivery or performance schedule, taking into consideration all existing commercial and government business commitments;

c. Have a satisfactory performance record;

d. Have a satisfactory record of integrity and business ethics;

e. Have the necessary organization, experience, accounting and operational controls, and technical skills, or the ability to obtain them;

f. Have the necessary production, construction, and technical equipment and facilities, or the ability to obtain them; and

g. Be otherwise qualified and eligible to receive an award under applicable laws and regulations.

2. Before award, to be determined responsible, a prospective contractor must submit the following information within three (3) days of request:

a. Current Financial Statement

b. Furnish a completed Small Business Subcontracting Plan (LARGE BUSINESS ONLY)

(End of Paragraph)

*** END OF NARRATIVE ***

FAR Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.204-7 System for Award Management- Registration. (Deviation)

2026-02

52.204-22 Alternative Line Item Proposal. 2017-01

52.215-1 Instructions to Offerors- Competitive Acquisition.

(Deviation)

2026-02

52.215-20 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data. (Deviation)

2026-02

52.222-5 Construction Wage Rate Requirements-Secondary Site of the Work. (Deviation)

2026-02

52.225-10 Notice of Buy American Requirement-Construction Materials.

2014-05

52.232-13 Notice of Progress Payments. 1984-04

52.233-2 Service of Protest. (Deviation) 2026-02

DFARS Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements.

2023-11

FAR Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.216-1 Type of Contract. (Deviation) 2026-02

Type of Contract (Feb 2026) (Deviation)

The Government contemplates award of a contract resulting from this Firm Fixed Price solicitation.

(End of provision)

52.228-1 Bid Guarantee. 1996-09

Bid Guarantee (Sept 1996)

Failure to furnish a bid guarantee on the SF 24 and include the amount, by the time set for (a) opening of bids, may be cause for rejection of the bid.

The bidder shall furnish a bid guarantee in the form of a firm commitment, bid bond (b) e.g., supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

To unsuccessful bidders as soon as practicable after the opening of bids; and(1)

To the successful bidder upon execution of contractual documents and bonds (including any (2) necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

The amount of the bid guarantee shall be percent of the bid price or $ , (c) 20% 3,000,000.00 whichever is less.

If the successful bidder, upon acceptance of its bid by the Government within the period (d) specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

In the event the contract is terminated for default, the bidder is liable for any cost of (e) acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of clause)

52.252-1 Solicitation Provisions Incorporated by Reference.

1998-02

Solicitation Provisions Incorporated by Reference (Feb 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

www.acquisition.gov

(End of provision)

52.252-5 Authorized Deviations in Provisions.

2020-11

Authorized Deviations in Provisions (Nov 2020)

The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) (a) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

The use in this solicitation of any (48 CFR Chapter ) provision with an (b) FAR and DFARS 1 & 2 authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of provision)

DFARS Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

252.215-7008 Only One Offer. 2022-12

ONLY ONE OFFER (DEC 2022)

(a) Cost or pricing data requirements. After initial submission of offers, if the Contracting Officer notifies the Offeror that only one offer was received, the Offeror agrees to-

(1) Submit any additional cost or pricing data that is required in order to determine whether the price is fair and reasonable (10 U.S.C. 3705) or to comply with the statutory requirement for certified cost or pricing data (10 U.S.C. 3702 and FAR 15.403-3); and

(2) Except as provided in paragraph (b) of this provision, if the acquisition exceeds the certified cost or pricing data threshold and an exception to the requirement for certified cost or pricing data at FAR 15.403-1(b)(2) through (5) does not apply, certify all cost or pricing data in accordance with paragraph (c) of DFARS provision 252.215-7010, Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data, of this solicitation.

(b) Canadian Commercial Corporation. If the Offeror is the Canadian Commercial Corporation, certified cost or pricing data are not required. If the Contracting Officer notifies the Canadian Commercial Corporation that additional data other than certified cost or pricing data are required in accordance with DFARS 225.870-4(c), the Canadian Commercial Corporation shall obtain and provide the following:

(1) Profit rate or fee (as applicable).

(2) Analysis provided by Public Works and Government Services Canada to the Canadian Commercial Corporation to determine a fair and reasonable price (comparable to the analysis required at FAR 15.404-1).

(3) Data other than certified cost or pricing data necessary to permit a determination by the U.

S. Contracting Officer that the proposed price is fair and reasonable ____[U.S. Contracting Officer to provide description of the data required in accordance with FAR 15.403-3(a)(1) with the notification].

(4) As specified in FAR 15.403-3(a)(4), an offeror who does not comply with a requirement to submit data that the U.S. Contracting Officer has deemed necessary to determine price reasonableness or cost realism is ineligible for award unless the head of the contracting activity determines that it is in the best interest of the Government to make the award to that offeror.

(c) Subcontracts. Unless the Offeror is the Canadian Commercial Corporation, the Offeror shall insert the substance of this provision, including this paragraph (c), in all subcontracts exceeding the simplified acquisition threshold defined in FAR part 2.

252.215-7012 Requirements for Submission of Proposals via Electronic Media.

2018-01

REQUIREMENTS FOR SUBMISSION OF PROPOSALS VIA ELECTRONIC MEDIA (JAN

2018)

The Offeror shall submit the cost portion of the proposal via the following electronic media: per enclosure 3 instructions.

Section 00 21 16 - Instructions to Proposers

Disclosure of Magnitude

Disclosure of Magnitude of Construction (FAR 36.204 and DFARS 236.204)

The estimated price range for this project is between $5,000,000.00 and $10,000,000.00.

Solicitation/Technical Inquiries via ProjNet

1. Solicitation/Technical Inquiries

a. Inquiries to be submitted via the Bidder Inquiry at the ProjNet website at https://www.projnet.org

b. If you have technical problems accessing the Bidder Inquiry via the ProjNet website. contact the ProjNet Help Desk at 1-800-428-4357 (HELP).

This number is for technical issues accessing the website only.

2. Any prospective bidder/offeror desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request in writing via the Bidder Inquiry in ProjNet within no less that then ten (10) calendar days prior to receipt of proposals. The Government reserves the right to decline addressing questions received less than ten calendar days to prior to receipt of proposals.

3. ProjNet - Bidder Inquiry module

a. To submit and review bid inqury items offerors will need to be a current registered user or self-register into system. To access Bidder Inquiry, go to the ProjNet web page at http://www.projnet.

org and clink the "Quick" add link. Once at the Quick add screen, select agency USCAE, enter Bidder Inquiry Key for this solicitation listed below, and offeror's email address, then click login. If this is offeror's first-time logging in they will be taken to the Bidder Inquiry Create Account screen to self-register. Fill in all required information and click create user. Verify that information on the next screen in correct and click continue. Please remember your Secret Questions Answer and email address used for future access to this website.

b. From this page you may view all offeror inquiries under Reports or post a new inquiry under Submit.

c. Offerors will receive an acknowledgement of their question via email, followed by another notification that an answer to their question has been posted after it has been reviewed by our technical team and responded by a Contracting Officer.

d. Offerors are responsible for checking bid inquiry items.

W912PM26RA0040005

https://www.projnet.org

e. Offerors are requested to review the specifications in its entirety, review the Bidder Inquiry System for answers to questions prior to submission of a new inquiry. The name of the submitter or firm is not published for the public on the report of all Bidder Inquiries. Offerors are on notice of, and assumed to be aware of, all inquiries, responses, and information posted in the Bidder Inquiry System up to the date of proposal submission, whether the inquiry was generated by the Offeror themselves or another potential Offeror. Offerors are responsible for incorporating all such information into their proposal, or for requesting further clarification.

4. Solicitation Information: RFP No: W912PM26RA004

Bidder Inquiry Key: 3359F6-8VVZJS

Site Visit:

An organized site visit has been scheduled for:

Tuesday, 5 May 2026: 8:00 AM EST

Philpott Dam Visitors Center

1058 Philpott Dam Rd

Bassett, VA 24055

Point of contact for the site visit:

Walter Haven: 910-251-4495

If you plan to attend the site visit, please RSVP to jenifer.m.garland@usace.army.mil and troy.d.

small@usace.army.mil. If no RSVPs are received the site visit will be cancelled.

The solicitation can only be changed by formal written amendment issued by the Contracting Officer.

Please RSVP for the site visit no later than 1 May 2026 by 4:00 PM EST to jenifer.m.

garland@usace.army.mil and troy.d.small@usace.army.mil.

*** END OF NARRATIVE ***

Section 00 45 00 - Representations and Certifications

Offer Identification

Offeror is requested to furnish the following information:

Name/Address:____________________________________________________________

Telephone No.____________________________________________________________

UEI: ________________________ CAGE: _______________________

CORPRATE CERTIFICATE:

The offeror shall execute and affix seal on attached Corporate Certificate if the company is incorporated. Company name on the seal should always be the same as company name on Page A-1 of the solicitation. If a proposal is signed by an officer of the company, the certificate shall be certified by another officer of the company. If the proposal is signed by someone other than an officer of the company, the proposal must be accompanied by: (1) a Corporate Resolution that individual signing the contract has authority to bind the company; or (2) a Corporate Resolution stating that an officer of the company may appoint individuals to sign proposals and bind the company.

NOTE: Contractor, if a corporation, should cause the following certificate to be executed under its corporate seal, provided that the same officer shall not execute both the contract and the certificate.

CERTIFICATE

I,________________________________________________ , certify that I am ____________________________________________of the corporation named Contractor herein, that _____________________________________________signed this contract on behalf of the Contractor, was then______________ of said corporation; that said contract was duly signed for and in of said corporation by authority of its governing body and is within the scope of its corporate powers.

____________________________________ (CORPORATE SEAL)

(Signature)

(End of provision)

Taxpayer Identification

Taxpayer Identification Number (TIN)," as used in this provision, means the number required by the Internal Revenue Service (IRS) to be used by the offeror in reporting income tax and other returns. The TIN may be either a Social Security Number or an Employer Identification Number.

(a) Taxpayer Identification Number (TIN).

___ TIN:.___________________________

___ TIN has been applied for.

__ TIN is not required because:

___ Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States;

___ Offeror is an agency or instrumentality of a foreign government;

___ Offeror is an agency or instrumentality of the Federal Government.

(b) Type of organization.

___ Sole proprietorship;

___ Partnership;

___ Corporate entity (not tax-exempt);

___ Corporate entity (tax-exempt);

___ Government entity (Federal, State, or local);

___ Foreign government;

___ International organization per 26 CFR1.6049-4;

___ Other ______________________________

(c) Common parent.

___ Offeror is not owned or controlled by a common parent

___ Name and TIN of common parent:

Name _________________________________

TIN___________________________________

(End of provision)

*** END OF NARRATIVE ***

FAR Provisions Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.229-12 Tax on Certain Foreign Procurements.

2021-02

DFARS Provisions Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.203-7005 Representation Relating to Compensation of Former DoD Officials.

2022-09

252.204-7008 Compliance with Safeguarding Covered Defense Information Controls.

2016-10

252.204-7016 Covered Defense Telecommunications Equipment or Services-Representation.

2019-12

252.204-7017 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services-Representation.

2021-05

252.225-7057 Preaward Disclosure of Employment of Individuals Who Work in the People's Republic of China.

2022-08

FAR Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.204-5 Women-Owned Business (Other Than Small Business).

2014-10

Women-Owned Business (Other Than Small Business) (Oct 2014)

(a) Definition."Women-owned business concern," as used in this provision, means a concern that is at least 51 percent owned by one or more women; or in the case of any publicly owned business, at least 51 percent of its stock is owned by one or more women; and whose management and daily business operations are controlled by one or more women.

(b) Representation. [Complete only if the offeror is a women-owned business concern and has not represented itself as a small business concern in paragraph (c)(1) of FAR 52.219-1, Small Business Program Representations, of this solicitation.] The offeror represents that it [ ] is a women-owned business concern.

52.209-7 Information Regarding Responsibility Matters.

(Deviation)

2026-02

Information Regarding Responsibility Matters (Feb 2026) (Deviation)

(a) Definitions. As used in this provision-

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means-

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager;

head of a division or business segment; and similar positions).

(b) The offeror [ ] has [ ] does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked "has" in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in-

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for

Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

DFARS Provisions Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

252.204-7007 Alternate A, Annual Representations and Certifications.

2025-10 Alternate A

2025-10

ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2025)

Substitute the following paragraphs (b), (d), and (e) for paragraphs (b) and (d) of the provision at FAR 52.204-8:

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (e) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (e) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (e) applies.

[ ] (ii) Paragraph (e) does not apply and the Offeror has completed the individual representations and certifications in the solicitation.

(d)(1) The following representations or certifications in the SAM database are applicable to this solicitation as indicated:

(i) 252.204-7016, Covered Defense Telecommunications Equipment or Services- Representation. Applies to all solicitations.

(ii) 252.216-7008, Economic Price Adjustment-Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $200,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)-Representation. Applies to solicitations and contracts when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)-Representation. Applies to solicitations and contracts when contract performance will be in Spain.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

[ ](i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

[ ](ii) 252.225-7000, Buy American-Balance of Payments Program Certificate.

[ ](iii) 252.225-7020, Trade Agreements Certificate.

[ ] Use with Alternate I.

[ ](iv) 252.225-7031, Secondary Arab Boycott of Israel.

[ ](v) 252.225-7035, Buy American-Free Trade Agreements-Balance of Payments Program Certificate.

[ ] Use with Alternate I.

[ ] Use with Alternate II.

[ ] Use with Alternate III.

[ ] Use with Alternate IV.

[ ] Use with Alternate V.

[ ](vi) 252.226-7002, Representation for Demonstration Project for Contractors Employing Persons with Disabilities.

[ ](vii) 252.232-7015, Performance-Based Payments-Representation.

(e) The Offeror has completed the annual representations and certifications electronically via the SAM website at https://www.sam.gov. After reviewing the SAM database information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [Offeror to insert changes, identifying change by provision number, title, date].

These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Provision # Title Date Change Any changes provided by the Offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

(End of provision)

Section 00 70 00 - Conditions of the Contract

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.222-3 Convict Labor. (Deviation) 2026-02

52.222-7 Withholding of Funds. (Deviation) 2026-02

52.228-11 Pledges of Assets (DEVIATION 2020-O0016)

2021-02 Deviation 2020- O0016

2020-04

52.240-1 Prohibition on Unmanned Aircraft Systems Manufactured or Assembled by American Security Drone Act-Covered Foreign Entities.

2024-11

52.240-90 Security Prohibitions and Exclusions Representations and Certifications. (Deviation)

2026-02

52.240-91 Security Prohibitions and Exclusions. (Deviation)

DFARS Clauses Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.225-7972 Prohibition on the Procurement of Foreign-Made Unmanned Aircraft Systems. (DEVIATION

2024-08 Deviation 2024- O0014

2024-08

2024-O0014)

252.225-7973 Prohibition on the Procurement of Foreign-Made Unmanned Aircraft Systems###Representation.

(DEVIATION 2024-O0014)

2024-08 Deviation 2024- O0014

2024-08

FAR Clauses Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.228-15 Performance and Payment Bonds-Construction (Deviation 2020-O0016)

2020-06 Deviation 2020- O0016

2020-04

PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (APR 2020) (DEVIATION 2020-

O0016)

(a) Definitions. As used in this clause-

Original contract price means the award price of the contract; or, for requirements contracts, the price payable for the estimated total quantity; or, for indefinite-quantity contracts, the price payable for the specified minimum quantity. Original contract price does not include the price of any options, except those options exercised at the time of contract award.

(b) Amount of required bonds. Unless the resulting contract price is $150,000 or less, the successful offeror shall furnish performance and payment bonds to the Contracting Officer as follows:

(1) Performance bonds (Standard Form 25, except that no seal is required). The penal amount of performance bonds at the time of contract award shall be 100 percent of the original contract price.

(2) Payment bonds (Standard Form 25A, except that no seal is required). The penal amount of payment bonds at the time of contract award shall be 100 percent of the original contract price.

(3) Additional bond protection.

(i) The Government may require additional performance and payment bond protection if the contract price is increased. The increase in protection generally will equal 100 percent of the increase in contract price.

(ii) The Government may secure the additional protection by directing the Contractor to increase the penal amount of the existing bond or to obtain an additional bond.

(c) Furnishing executed bonds. The Contractor shall furnish all executed bonds, including any necessary reinsurance agreements, to the Contracting Officer, within the time period specified in the Bid Guarantee provision of the solicitation, or otherwise specified by the Contracting Officer, but in any event, before starting work.

(d) Surety or other security for bonds. The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register or may be obtained from the U.S. Department of the Treasury, Financial Management Service, Surety Bond Branch, 3700 East West Highway, Room 6F01, Hyattsville, MD 20782. Or via the internet at http://www.fms.treas.gov/c570/.

(e) Notice of subcontractor waiver of protection (40 U.S.C. 3133(c)). Any waiver of the right to sue on the payment bond is void unless it is in writing, signed by the person whose right is waived, and executed after such person has first furnished labor or material for use in the performance of the contract.

(End of clause)

Section 00 72 00 - General Conditions

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate Deviation

Variation Effective Date

52.202-1 Definitions. 2020-06

52.203-3 Gratuities. 1984-04

52.203-5 Covenant Against Contingent Fees.

2014-05

52.203-6 Restrictions on Subcontractor Sales to the Government.

2020-06

52.203-7 Anti-Kickback Procedures. 2020-06

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity.

2014-05

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity.

2014-05

52.203-12 Limitation on Payments to Influence Certain Federal Transactions.

2020-06

52.203-13 Contractor Code of Business Ethics and Conduct.

2021-11

52.203-19 Prohibition on Requiring Certain Internal Confidentiality Agreements or Statements.

2017-01

52.204-9 Personal Identity Verification of Contractor Personnel.

2011-01

52.204-10 Reporting Executive Compensation and First-Tier Subcontract Awards. (Deviation)

2026-02

52.204-13 System for Award Management- Maintenance. (Deviation)

2026-02

52.204-19 Incorporation by Reference of Representations and Certifications.

2014-12

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded. (Deviation)

2026-02

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters.

(Deviation)

2026-02

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations.

(Deviation)

2026-02

52.210-1 Market Research. (Deviation) 2026-02

52.211-13 Time Extensions. 2000-09

52.215-10 Price Reduction for Defective Certified Cost or Pricing Data.

2011-08

52.215-11 Price Reduction for Defective Certified Cost or Pricing Data- Modifications. (Deviation)

2026-02

52.215-12 Subcontractor Certified Cost or 2026-02

Pricing Data. (Deviation)

52.215-13 Subcontractor Certified Cost or Pricing Data-Modifications.

(Deviation)

2026-02

52.215-15 Pension Adjustments and Asset Reversions. (Deviation)

2026-02

52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits (PRB) Other Than Pensions.

(Deviation)

2026-02

52.215-19 Notification of Ownership Changes. (Deviation)

2026-02

52.215-21 Requirements for Certified Cost or Pricing Data and Data Other Than Certified Cost or Pricing Data-Modifications. (Deviation)

2026-02

52.219-8 Utilization of Small Business Concerns. (Deviation)

2026-02

52.219-16 Liquidated Damages- Subcontracting Plan.

2021-09

52.222-1 Notice to the Government of Labor Disputes. (Deviation)

2026-02

52.222-4 Contract Work Hours and Safety Standards-Overtime Compensation. (Deviation)

2026-02

52.222-6 Construction Wage Rate Requirements. (Deviation)

2026-02

52.222-8 Payrolls and Basic Records.

(Deviation)

2026-02

52.222-9 Apprentices and Trainees.

2026-02

52.222-10 Compliance with Copeland Act Requirements. (Deviation)

2026-02

52.222-11 Subcontracts (Labor Standards).

(Deviation)

2026-02

52.222-12 Contract Termination-Debarment. 2014-05

52.222-13 Compliance with Construction Wage Rate Requirements and Related Regulations.

2014-05

52.222-14 Disputes Concerning Labor Standards. (Deviation)

2026-02

52.222-15 Certification of Eligibility. 2014-05

52.222-35 Equal Opportunity for Veterans.

(Deviation)

2026-02

52.222-36 Equal Opportunity for Workers with Disabilities. (Deviation)

2026-02

52.222-37 Employment Reports on Veterans. (Deviation)

2026-02

52.222-40 Notification of Employee Rights Under the National Labor Relations Act. (Deviation)

2026-02

52.222-50 Combating Trafficking in Persons. (Deviation)

2026-02

52.222-54 Employment Eligibility Verification. (Deviation)

2026-02

52.222-55 Minimum Wages for Contractor 2026-02

Workers Under Executive Order 14026. (Deviation)

52.222-62 Paid Sick Leave Under Executive Order 13706. (Deviation)

2026-02

52.222-90 Addressing DEI Discrimination by Federal Contractors.

(Deviation 2026-O0040, Revision 1)

2026-04

52.223-2 Reporting of Biobased Products Under Service and Construction Contracts. (Deviation)

2026-02

52.223-5 Pollution Prevention and Right-to- Know Information.

2024-05

52.225-13 Restrictions on Certain Foreign Purchases.

2021-02

52.226-1 Utilization of Indian Organizations and Indian-Owned Economic Enterprises.

(Deviation)

2026-02

52.226-7 Drug-Free Workplace. 2024-05

52.226-8 Encouraging Contractor Policies to Ban Text Messaging While Driving.

2024-05

52.227-1 Authorization and Consent. 2020-06

52.227-2 Notice and Assistance Regarding Patent and Copyright Infringement.

2020-06

52.227-4 Patent Indemnity-Construction Contracts.

2007-12

52.228-2 Additional Bond Security. 1997-10

52.228-12 Prospective Subcontractor Requests for Bonds.

2022-12

52.228-14 Irrevocable Letter of Credit. 2014-11

52.229-3 Federal, State, and Local Taxes. 2013-02

52.229-11 Tax on Certain Foreign Procurements-Notice and Representation.

2020-06

52.232-17 Interest. 2014-05

52.232-23 Assignment of Claims. 2014-05

52.232-27 Prompt Payment for Construction Contracts.

2017-01

52.232-33 Payment by Electronic Funds Transfer-System for Award Management.

2018-10

52.232-39 Unenforceability of Unauthorized Obligations.

2013-06

52.232-40 Providing Accelerated Payments to Small Business Subcontractors.

2023-03

52.233-1 Disputes. (Deviation) 2026-02

52.233-3 Protest after Award. (Deviation) 2026-02

52.233-4 Applicable Law for Breach of Contract Claim. (Deviation)

2026-02

52.236-2 Differing Site Conditions.

(Deviation)

2026-02

52.236-3 Site Investigation and Conditions Affecting the Work. (Deviation)

2026-02

52.236-5 Material and Workmanship.

(Deviation)

2026-02

52.236-6 Superintendence by the Contractor. (Deviation)

2026-02

52.236-7 Permits and Responsibilities.

(Deviation)

2026-02

52.236-8 Other Contracts. (Deviation) 2026-02

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements. (Deviation)

2026-02

52.236-10 Operations and Storage Areas.

(Deviation)

2026-02

52.236-11 Use and Possession Prior to Completion. (Deviation)

2026-02

52.236-12 Cleaning Up. (Deviation) 2026-02

52.236-13 Accident Prevention. (Deviation) 2026-02

52.236-15 Schedules for Construction Contracts. (Deviation)

2026-02

52.236-16 Quantity Surveys. (Deviation) 2026-02

52.236-17 Layout of Work. (Deviation) 2026-02

52.236-21 Specifications and Drawings for Construction. (Deviation)

2026-02

52.242-5 Payments to Small Business Subcontractors.

2017-01

52.242-13 Bankruptcy. 1995-07

52.242-14 Suspension of Work. 1984-04

52.243-4 Changes. (Deviation) 2026-02

52.244-6 Subcontracts for Commercial Products and Commercial Services. (Deviation)

2026-02

52.246-12 Inspection of Construction. 1996-08

52.246-21 Warranty of Construction. 1994-03

52.247-64 Preference for Privately Owned U.S.-Flag Commercial Vessels.

(Deviation)

2026-02

52.249-2 Termination for Convenience of the Government (Fixed-Price).

(Alternate I)

2012-04 Alternate I 1996-09

52.249-10 Default (Fixed-Price Construction).

1984-04

52.253-1 Computer Generated Forms.

DFARS Clauses Incorporated by Reference

Date

Alternate Deviation

Variation Effective Date

252.201-7000 Contracting Officer's Representative.

1991-12

252.203-7000 Requirements Relating to Compensation of Former DoD Officials.

2011-09

252.203-7001 Prohibition on Persons Convicted of Fraud or Other Defense- Contract-Related Felonies.

2023-01

252.203-7002 Requirement to Inform Employees of Whistleblower Rights.

2022-12

252.203-7003 Agency Office of the Inspector General.

2019-08

252.203-7004 Display of Hotline Posters. 2023-01

252.204-7000 Disclosure of Information. 2016-10

252.204-7003 Control of Government Personnel Work Product.

1992-04

252.204-7012 Safeguarding Covered Defense Information and Cyber Incident Reporting.

2024-05

252.204-7018 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services.

2023-01

252.204-7020 NIST SP 800-171 DoD Assessment Requirements.

2023-11

252.205-7000 Provision of Information to Cooperative Agreement Holders.

2024-10

252.209-7004 Subcontracting with Firms that are Owned or Controlled by the Government of a Country that is

2019-05 a State Sponsor of Terrorism.

252.219-7003 Small Business Subcontracting Plan (DoD Contracts).

2019-12

252.222-7006 Restrictions on the Use of Mandatory Arbitration Agreements.

2023-01

252.223-7006 Prohibition on Storage, Treatment, and Disposal of Toxic or Hazardous Materials.

2014-09

252.223-7008 Prohibition of Hexavalent Chromium.

2023-01

252.225-7012 Preference for Certain Domestic Commodities.

2022-04

252.225-7048 Export-Controlled Items. 2013-06

252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime.

2023-01

252.225-7058 Postaward Disclosure of Employment of Individuals Who Work in the People's Republic of China.

2023-01

252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region.

2023-06

252.227-7033 Rights in Shop Drawings. 1966-04

252.231-7000 Supplemental Cost Principles 1991-12

252.232-7003 Electronic Submission of Payment Requests and

2018-12

Receiving Reports.

252.232-7010 Levies on Contract Payments. 2006-12

252.236-7000 Modification Proposals--Price Breakdown.

1991-12

252.236-7002 Obstruction of Navigable Waterways.

1991-12

252.236-7008 Contract Prices--Bidding Schedules.

1991-12

252.243-7001 Pricing of Contract Modifications. 1991-12

252.243-7002 Requests for Equitable Adjustment.

2022-12

252.244-7000 Subcontracts for Commercial Products or Commercial Services.

2023-11

252.247-7023 Transportation of Supplies by Sea.

2024-10

FAR Clauses Incorporated by Full Text

Date

Alternate Deviation

Variation Effective Date

52.211-10 Commencement, Prosecution, and Completion of Work.

1984-04

Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within calendar 10 days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 365 .* The calendar days time stated for completion shall include final cleanup of the premises.

* The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

(End of clause)

52.211-12 Liquidated Damages- Construction.

2000-09

Liquidated Damages-Construction (Sept 2000)

If the Contractor fails to complete the work within the time specified in the contract, the (a) Contractor shall pay liquidated damages to the Government in the amount of for $1,482.00 each calendar day of delay until the work is completed or accepted.

If the Government terminates the Contractor's right to proceed, liquidated damages will (b) continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.219-4 Notice of Price Evaluation Preference for HUBZone Small Business Concerns. (Deviation)

Notice of Price Evaluation preference for HUBZone Small Business Concerns (Feb 2026)

(a) Evaluation preference.

(1) Offers will be evaluated by adding a factor of 10 percent to the price of all offers, except-

(i) Offers from HUBZone small business concerns that have not waived the evaluation preference; and

(ii) Otherwise successful offers from small business concerns.

(b) Waiver of evaluation preference. A HUBZone small business concern may choose to waive the evaluation preference. If the concern waives the preference, the factor will be added to its offer for evaluation purposes.

[ ] Offeror chooses to waive the evaluation preference.

(c) Joint venture. A HUBZone joint venture agrees that, in the performance of the contract, at least 40 percent of the aggregate work performed by the joint venture shall be completed by the HUBZone small business parties to the joint venture. Work performed by the HUBZone small business parties to the joint venture must be more than administrative functions.

52.219-28 Postaward Small Business Program Rerepresentation.

(Deviation)

2026-02

Postaward Small Business Program Rerepresentation (Feb 2026) (Deviation)

(a) . As used in this clause-Definitions

Long-term contract means a contract of more than five years in duration, including options.

However, the term does not include contracts that exceed five years in duration because the period of performance has…