SF 30 W912PL21B0005 - Amendment 0003- Final.pdf

(SEE ITEM 13)

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

PAGE OF PAGES

IMPORTANT - The "offer" section on the reverse must be fully completed by the offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE

9. FOR INFORMATION CALL

B. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

11. The Contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory, negotiable. (See .)

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12B. CALENDAR DAYS

YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour)

B. An offer guarantee is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

NSN 7540-01-155-3212

Designed using Perform Pro, WHS/DIOR, Oct 96

1442-103 STANDARD FORM 1442 (REV. 4-85) (EG)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

W912PL21B0005 x

3. DATE ISSUED

7 May 2021 1 OF

U.S.Army Corps of Engineers, Los Angeles Dist Attn:Contracting Division CESPL-CT-W 915 Wilshire Boulevard, Suite 930 Los Angeles, California 90017-3401

A. NAME

Michael G Robinson 213-452-3311

10 see 00 73 00

X X *Section 00 73 00

X 10

1 Digital 1:00 PM

16 June 2021 If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror’s name and address, the solicitation number, and the date and time offers are due.

X

8. ADDRESS OFFER TO

Bids are to be submitted electronically, DoD Secure Access File Exchange (DoD Safe) at https://safe.apps.mil/ in accordance with Section 00 21 13, Instructions Pertaining to Submission of Electronic Bids (APR 2020).

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date):

Lower Norco Bluffs Toe Protection, Riverside County, CA

The project consists of an earth fill placed against the existing bluffs, approximately 7,330 feet in length, revetted with riprap slope protection and a launchable stone toe blanket. The project will tie into existing high ground at the upstream and downstream project extents. The embankment fill will raise the grade between 12 and 25 feet above existing grade to provide protection up to a 100-year flow event water surface elevation (WSE).

Total Period of Performance is 1095 Calendar Days. Completion of Bid Item’s 0001 through 0050, 0052 through 0055 and 1001 through 1002 shall be within the first 730 Calendar Days. Completion of Bid Item 0051 Landscape Establishment will be 365 Calendar Days and be completed prior to the end of the Total Period of Performance period.

The Estimate cost range for this procurement is $25,000,000 - $100,000,000

This procurement is a 100% total Small Business Set Aside. The NAICS Code is 237990 "Other Heavy and Civil Engineering Construction. The size Standard is $39,500,000.00.

Be advised this project may delayed, postponed, canceled or revised at any time prior to award.

OFFER (Must be fully completed by offeror)

STANDARD FORM 1442 BACK (REV. 4-85)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal or greater than the minimum requirement stated in 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24.SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BYCODE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to the issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and

(c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD. (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN

(Type or print)

30B. SIGNATURE 30C. DATE

31A. NAME OF CONTRACTING OFFICER (Type or print)

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

DUNS NO.: TAX ID NO.:

CAGE CODE NO.:

( ) - ; FAX ( ) -

See Section 00 10 00 Solicitation Contract Line Item Number (CLIN) Schedule

Santa Ana Dams Resident Office 2493 Pomona Riccon Rd.

Corona, CA 92880

USACE, Finance Center

ATTN: CEFCO-AO-D

5722 Integrity Drive Millington, TN 38054-5005

Lower Norco Bluffs Toe Protection W912PL21B0005 Riverside County, CA

RECEIPT OF SUBMISSIONS:

For the purposes of establishing whether a bid submission is considered timely, the government considers the date and time the submission is completely uploaded into the SAFE website. For bids larger than the 8GB capacity of the SAFE website and require multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the SAFE website. Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases.

The government will not be responsible for submissions delivered to any location or to anyone other than those designated to receive bids. Bidders are responsible for ensuring that bids are submitted so as to reach the designated recipient. Bidders are responsible for allowing sufficient time for the bid to be received in accordance with the instructions provided.

(End of statement)

VIRTUAL BID OPENING PROCEDURES AND INSTRUCTIONS FOR BIDDER’S PARTICIPATON

The electronic bids for this project are due on 16 June 2021 at 1:00 PM Local time.

In order to allow the bid opening officer sufficient time to download the bids after bids are due, the virtual bid opening will be held at 3:00 PM local time on 16 June 2021.

At the bid opening teleconference, bids and the Independent Government Estimate will be read aloud, just as in a traditional bid opening.

Following the bid opening a copy of the bid abstract and any bid can be made available for public inspection by interested persons by emailing a copy of the abstract and requested bids to those who participated in the virtual bid opening. In addition, in accordance with established practices, the Abstract of Bids will be available at beta.sam.gov for all interested parties.

To participate in the Virtual Bid Opening, the following information is provided:

1-844-800-2712 Access Code: 199 827 1077

(End of statement)

CONTRACTOR RESPONSIBILITY, PRE-AWARD SURVEY INFORMATION TO BE SUBMITTED

WITH BID

In order to determine a contractor's responsibility for purposes of contract award in accordance with FAR Part 9, a statement regarding previous experience in performing comparable work and information related to their business organization, financial resources, and/or plant to be used in

Amendment 0003 - Section 00 21 13

Lower Norco Bluffs Toe Protection W912PL21B0005 Riverside County, CA

Amendment 0003 - Section 00 73 00

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 1095** calendar Days from the notice to proceed. The time stated for completion shall include final cleanup of the premises.

*The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date.

** Total Period of Performance is 1095 Calendar Days. Completion of Bid Item’s 0001 through 0050, 0052 through 0055 and 1001 through 1002 will be within the first 730 Calendar Days. Completion of Bid Item 0051 Landscape Establishment will be 365 Calendar Days and be completed prior to the end of the Total Period of Performance period.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $2,405 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.211-13 TIME EXTENSIONS (SEP 2000)

Time extensions for contract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be extended only for those specific elements related to the changed work and that the remaining contract completion dates for all other portions of the work will not be altered. The change order also may provide an equitable readjustment of liquidated damages under the new completion schedule.

(End of clause)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

(a) The Contractor shall promptly, and before the conditions are disturbed, give a written notice to the Contracting Officer of

(1) subsurface or latent physical conditions at the site which differ materially from those indicated in this contract, or

(2) unknown physical conditions at the site, of an unusual nature, which differ materially from those ordinarily encountered and generally recognized as inhering in work of the character provided for in the contract.