W912PL20R0002_Amendment0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICAITON NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicble)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICIATION NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a)By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPIRATION DATA (If required)

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc. ) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION ( Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

1 13

0001 Nov 6, 2019

W912PL

USACE-LOS ANGELES DISTRICT

CONTRACTING DIVISION, WEST REGION BRANCH

915 WILSHIRE BLVD, SUITE 930

LOS ANGELES, CA 90017

W912PL20R0002

Oct 9, 2019

CONSTRUCT AIR TRAFFIC CONTROL TOWER, AIR FORCE PLANT 42, AIR FORCE TEST CENTER, PALMDALE, CA

SF 1442, Solicitation, Offer and Award;

Section 00 73 00, Contract Clause No. FAR 52.211-10, Commencement, Prosecution and Completion of Work.

Due date for receipt of proposals is extended to December 4th, 2019 at 2:00 PM local time.

Please Note: FBO is moving to beta.SAM.gov starting on November 8th, 2019.

INSTRUCTIONS

Instructions for items other than those that are self-explanatory, are as follows:

Item 1 (Contract ID Code) . Insert the contract type identification code that appears in the title block of the contract being modified.

Item 3 (Effective date) .

(1)

(2)

(3)

(4)

(5)

For a solicitation amendment, change order, or administrative change, the effective date shall be the issue date of the amendment, change order, or administrative change.

For a supplemental agreement, the effective date shall be the date agreed to by the contracting parties.

For a modification issued as an initial or confirming notice of termination for the convenience of the Government, the effective date and the modification number of the confirming notice shall be the same as the effective date and modification number of the initial notice.

For a modification converting a termination for default to a termination for the convenience of the Government, the effective date shall be the same as the effective date of the termination for default.

For a modification confirming the contacting officer's determination of the amount due in settlement of a contract termination, the effective date shall be the same as the effective date of the initial decision.

(a)

(b)

(c)

(d)

(e)

(f)

Item 6 (Issued By) . Insert the name and address of the issuing office. If applicable, insert the appropriate issuing office code in the code block.

Item 8 (Name and Address of Contractor) . For modifications to a contract or order, enter the contractor's name, address, and code as shown in the original contract or order, unless changed by this or a previous modification.

Item 9, (Amendment of Solicitation No. - Dated), and 10, (Modification of Contract/Order No. - Dated ). Check the appropriate box and in the corresponding blanks insert the number and date of the original solicitation, contract, or order.

Item 12 (Accounting and Appropriation Data) .

When appropriate, indicate the impact of the modification on each affected accounting classification by inserting one of the following entries.

(2) Accounting classification Net decrease $

Include subject matter or short title of solicitation/contract where feasible.

Item 16B . The contracting officer's signature is not required on solicitation amendments. The contracting offier's signature is normally affixed last on supplemental agreements.

(i)

NOTE: If there are changes to multiple accounting classifications that cannot be placed in block 12, insert an asterisk and the words "See continuation sheet".

Item 13 . Check the appropriate box to indicate the type of modification. Insert in the corresponding blank the authority under which the modification is issued. Check whether or not contractor must sign this document. (See FAR 43.103.)

Item 14 (Description of Amendment/Modification) .

Organize amendments or modifications under the appropriate Uniform Contract Format (UCF) section headings from the applicable solicitation or contract. The UCF table of contents, however, shall not be set forth in this document Indicate the impact of the modification on the overall total contract price by inserting one of the following entries:

Total contract price increased by $

Total contract price decreased by $

Total contract price unchanged.

State reason for modification.

When removing, reinstating, or adding funds, identify the contract items and accounting classifications.

When the SF 30 is used to reflect a determination by the contracting officer of the amount due in settlement of a contract terminated for the convenience of the Government, the entry in Item 14 of the modification may be limited to --

A reference to the letter determination; and

A statement of the net amount determined to be due in settlement of the contract.

(g)

(h)

(i)

(ii)

(1)

(2)

(3)

(4)

(5)

(6)

(i)

(ii)

(iii)

STANDARD FORM 30 (REV. 10-83) BACK

(1) Accounting classification Net increase $

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NUMBER 2. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

3. DATE ISSUED PAGE OF PAGES

IMPORTANT - The "offer" section on the reverse must be fully completed by the offeror.

4. CONTRACT NUMBER 5. REQUISITION/PURCHASE REQUEST NUMBER 6. PROJECT NUMBER

7. ISSUED BY CODE 8. ADDRESS OFFER TO

9. FOR INFORMATION CALL

A. NAME B. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

SOLICITATION

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date):

11. The Contractor shall begin performance within calendar days and complete it within calendar days after receiving award, notice to proceed. This performance period is mandatory, negotiable. (See .)

12A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

12B. CALENDAR DAYS

YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and copies to perform the work required are due at the place specified in Item 8 by (hour) local time (date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes containing offers shall be marked to show the offeror’s name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

NSN 7540-01-155-3212

Designed using Perform Pro, WHS/DIOR, Oct 96

1442-103 STANDARD FORM 1442 (REV. 4-85) (EG)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d)

W912PL20R0002

X

OCT 9, 2019 1 OF 2

USACE, Los Angeles District Contracting Division, West Region Branch 915 Wilshire Blvd, Suite 930 Los Angeles, CA 90017

See Item 7

Lucia A. Carvajal 213.452.3240

AIR TRAFFIC CONTROL TOWER, (ATCT) AF PLANT 42, AIR FORCE TEST CENTER,PALMDALE, CA.

Scope of Work includes but is not limited to a 160’ tower with: drilled shaft foundations, floor slabs, buckling-restrained brace frames, fire protection and detection, emergency power, Furniture Fixtures & Equipment (FF&E) for office spaces, FAA control cab with Slat-Wall Consoles, elevator, access control systems, HVAC, plumbing, parking lots, access driveways, fencing, and other supporting building systems and exterior infrastructure. The existing 93’ ATCT will also be demolished at the end of construction after commissioning of the new tower.

Offerors must submit both a technical proposal and a price proposal. The basis of award is best Value Trade-off, IAW FAR 15.101-1. This process permits trade-offs among cost or price and non-cost factors and allows the Government to accept other than the lowest priced proposal. In making this determination, all evaluation factors other than cost or price, when combined, are approximately equal to, cost or price.

The Government intends to evaluate proposals and award a contract without discussions with offerors. The Government reserves the right to conduct discussions if the Contracting Officer later determines them necessary. FAR 52.215-1(f)(4).

The magnitude of construction is $10,000,000.00 - $25,000,000.00 The Notice of Price Evaluation Preference for HUBZone Small Business Concerns will apply to this procurement. See Section 00 70 00, Contract Clause No. FAR 52.219-4.

10 * 00 73 00

X X *Section 00 73 00

X 10

6 2 PM

December 4th, 2019

X

OFFER (Must be fully completed by offeror)

STANDARD FORM 1442 BACK (REV. 4-85)

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code) 15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14)

CODE FACILITY CODE

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted by the Government in writing within calendar days after the date offers are due. (Insert any number equal or greater than the minimum requirement stated in 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGEMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation - give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print) 20B. SIGNATURE 20C. OFFER DATE

AWARD (To be completed by Government)

21. ITEMS ACCEPTED

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24.SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

ITEM 25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) ( ) 41 U.S.C. 253(c) ( )

26. ADMINISTERED BY 27. PAYMENT WILL BE MADE BYCODE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return copies to the issuing office.) Contractor agrees to furnish and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and

(c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

29. AWARD. (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN

(Type or print)

30B. SIGNATURE 30C. DATE

31A. NAME OF CONTRACTING OFFICER (Type or print)

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

DUNS NO.: TAX ID NO.:

CAGE CODE NO.:

( ) - ; FAX ( ) -

See Section 00 10 00 Solicitation Contract Line Item Number (CLIN) Schedule

USACE Los Angeles District Edwards AFB Resident Office 222 N. Rosamond Blvd, Building 3759 Edwards AFB, CA 93524-8501

USACE, Finance Center

ATTN: CEFCO-AO-D

5722 Integrity Drive Millington, TN 38054-5005

Construct Air Traffic Control Tower, Air Force Plant 42 W912PL20R0002 Air Force Test Center, Palmdale

00 73 00 - 1 Amendment 0001

Section 00 73 00 - Supplementary Conditions

Table of Contents

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236-4 PHYSICAL DATA (APR 1984)

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

CONTRACT ADMINISTRATION DATA

PROCURING CONTRACTING OFFICER

NOTICE TO CONTRACTOR

SAFETY REQUIREMENTS

CONTRACTOR PERFORMANCE EVALUATIONS

UDG 5115.404-73-1 ALTERNATE STRUCTURED APPROACH - CONSTRUCTION CONTRACTS (USACE

ACQUISITION INSTRUCTION (UAI) 5115.404-73

UAI 5122.1302-100 VETERANS EMPLOYMENT EMPHASIS FOR U. S. ARMY CORPS OF ENGINEERS

CONTRACTS

ER 415-1-15 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 89)

INVOICES (AUG 1991)

AS-BUILT DRAWINGS (PROGRESS PAYMENT) (OCT 1998)

INSURANCE REQUIRED

00 73 00 - 2

Section 00 73 00 - Supplementary Conditions

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within ten (10) calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 730 calendar days after the date the contractor receives the Notice to Proceed.

Beneficial Occupancy of the New Control Tower 480 calendar days after the contractor receives the Notice to Proceed. The successful contractor grants the option items listed in the Pricing Schedule to the Government. The Option Item may be exercised any time up to 90 calendar days after receipt of notice of award. Exercise of an option item occurs upon mailing of written notice to the Contractor. Exercise of the option item(s) will be made by the Contracting Officer. The price for exercise of the option item(s) includes all work and effort associated with the scope of that item. No additional time for contract completion will be allowed when an option is exercised. The given contract completion time was formulated to include time necessary to perform all option work. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,685.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least twenty percent (20%) of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site

00 73 00 - 3 investigations by surveys.

(b) Weather conditions. The contractor shall make his/her own investigations as to weather conditions at the site.

(c) Transportation facilities. The contractor shall make his/her own investigations as to transportation facilities.

Access ways shall be investigated by the contractor to satisfy himself/herself as to their existence and allowable use.

(d) Other pertinent information. None.

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

(a) The Government will provide to the Contractor, without charge, one set of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

(b) The Contractor shall--

(1) Check all drawings furnished immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph (b); and

(5) Reproduce and print contract drawings and specifications as needed.

(c) In general--

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

(d) Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such details as if fully and correctly set forth and described in the drawings and specifications.

(e) The work shall conform to the specifications and the contract drawings identified on the following index of drawings:

Refer to Index of Contract Drawings.

CONTRACT ADMINISTRATION DATA

The Contract Administration Office for this contract subsequent to award is:

00 73 00 - 4

Department of the Army Los Angeles District, Corps of Engineers Edwards AFB Resident Office P.O. Box 326, Building 3760 Edwards AFB, CA 93523-0326 ATTN: Doug Delaney Telephone No: 661.277.9921

Payment will be made by:

USACE Finance Center

ATTN: CEFC-AO-P

5270 Integrity Drive Millington, TN 38054-5005

Submit Invoices to:

Department of the Army Los Angeles District, Corps of Engineers Edwards AFB Resident Office P.O. Box 326, Building 3760 Edwards AFB, CA 93523-0326 ATTN: Doug Delaney Telephone No: 661.277.9921

(End of statement)

PROCURING CONTRACTING OFFICER

The Contracting Officer who signs this contract will be the Procuring Contacting Officer for this contract. However, any Contracting Officer assigned to the Los Angeles District, contracting within his or her authority may take formal action on this contract when a contract action needs to be taken and the Procuring Contracting Officer is unavailable.

NOTICE TO CONTRACTOR

Only a warranted Contracting Officer (either a Procuring Contracting officer (PCO), or an Administrative Contracting Officer (ACO)), acting within their delegated limits, has the authority to issue modifications or otherwise change the terms and conditions of this contract. If an individual other than the Contracting Officer attempts to make changes to the terms and conditions of this contract you shall not proceed with the change and shall immediately notify the Contracting Officer.

00 73 00 - 5

SAFETY REQUIREMENTS

If this contract is for construction or dismantling, demolition or removal of improvements with a Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U. S.

Army Corps of Engineers Safety and Health Requirements Manual EM 385-1-1, in effect on the date of the solicitation. The current version is dated 30 November 2014. This publication may be obtained online and is available for download at http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM 385-1-1.pdf Any other Safety and Occupational specific questions can be addressed to the US Army Engineer District, Los Angeles, ATTN: Safety Office, 915 Wilshire Blvd, Suite 930, Los Angeles, CA 90017.

CONTRACTOR PERFORMANCE EVALUATIONS

In accordance with the provisions of Subpart 36.201(Evaluation of Contractor Performance) of the Federal Acquisition Regulation (FAR), construction contractor’s performance shall be evaluated throughout the performance of the contract. The United States Army Corps of Engineers (USACE) follows the procedures outlined in Engineering Regulation 415-1-17 to fulfill this FAR requirement. For construction contracts awarded at or above $700,000.00, the USACE will evaluate contractor’s performance and prepare a performance report using the Construction Contractor Appraisal Support System (CPARS) which is now a web based system. After an evaluation (interim or final) is written up by the USACE, the contractor will have the ability to access, review and comment on the evaluation for a period of 60 days. The CPARS will notify the contractor with an electronic message when a completed performance evaluation is available for their retrieval from CPARS or the Past Performance Information Retrieval System (PPIRS) for finalized evaluation.

UDG 5115.404-73-1 ALTERNATE STRUCTURED APPROACH - CONSTRUCTION CONTRACTS

(USACE ACQUISITION INSTRUCTION (UAI) 5115.404-73

(1) The following alternate structured approach shall be used for all fixed-price construction in accordance with Defense Federal Acquisition Regulation Supplement (DFARS) 215.404-4(b)(1).

Factor Rate Weight Value

Degree of risk 20 Relative difficulty of work 15 Size of job 15 Period of performance 15 Contractor's investment 5 Assistance by Government 5 Subcontracting 25

Total 100%

(2) Based on the circumstances of the procurement action, each of the above factors shall be weighted from 0.03 to

0.12 as indicated below. "Value” shall be obtained by multiplying the rate by the weight. The value column when totaled indicates the fair and reasonable profit percentage under the circumstances of the particular procurement.

http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM%20385-1-1.pdf http://www.publications.usace.army.mil/Portals/76/Publications/EngineerManuals/EM%20385-1-1.pdf

00 73 00 - 6

(a) Degree of risk. Where the work involves no risk or the degree of risk is very small, the weighting should be 0.03; as the degree of risk increases, the weighting should be increased up to a maximum of 0.12. Lump sum items shall generally have a higher weight than unit price items. Consider the nature of subcontractors, amount and type of labor included in costs and whether the negotiation is before or after performance of work.

Modifications, settled before the fact, have a much greater risk than those settled after the fact. A weight of 0.03 is appropriate for after the fact equitable adjustments and/0r settlements.

(b) Relative difficulty of work: If the work is difficult and complex, the weight should be 0.12 and should be proportionately reduced to 0.03 on the simplest of jobs. This factor is tied, to some extent, to the degree of risk.

Other things to consider are the nature of the work, by whom it is to be done (i.e., subcontractors, consultants), etc.

(c) Size of job. Work estimated up to $100,000 shall be weighted at 0.12. Work estimated between $100,000 and $5,000,000 shall be proportionately weighted from 0.12 to 0.05. Work from $5,000,000 to $10,000,000 shall be weighted at 0.04. Work in excess of $10,000,000 shall be weighted at 0.03. It should be noted that the control of fixed expenses generally improves with increased job magnitude.

(d) Period of performance. Work not to exceed 1 month is to be weighted at 0.03. Durations between 1 and 24 months are to be proportionately weighted between 0.03 and 0.12. Work in excess of 24 months is to be weighted at 0.12.

(e) Contractor's investment. To be weighted from 0.03 to 0.12 on the basis of below average, average and above average. Consider the amount of subcontracting, Government-furnished property or data, such as surveys, methods of making progress payments, and any mobilization payment items.

(f) Assistance by government. To be weighted from 0.12 to 0.03 on the basis of average to above average.

Consider use of Government-owned property, equipment and facilities, expediting assistance, etc.

(g) Subcontracting. To be weighted inversely proportional to the amount of subcontracting. Where 80 percent of more of the work is to be subcontracted, use 0.03. The weighting should be increase proportionately to

0.12 where all the work is performed by the contractor’s own forces.

UAI 5122.1302-100 VETERANS EMPLOYMENT EMPHASIS FOR U. S. ARMY CORPS OF

ENGINEERS CONTRACTS

In addition to complying with the requirements outlined in FAR Part 22.13, FAR Provision 52.222-38, FAR Clause 52.222-35, FAR Clause 52.222-37, DFARS222.13 and Department of Labor regulations, U.S. Army Corps of Engineers(USACE) contractors and subcontractors at all tiers are encouraged to promote the training and employment of U.S. veterans while performing under a USACE contract. While no set-aside, evaluation preference, or incentive applies to the solicitation or performance under the resultant contract, USACE contractors are encouraged to seek out highly qualified veterans to perform services under this contract. The following resources are available to assist USACE contractors in their outreach efforts:

- U.S. Department of Labor Veterans’ Employment and Training Service (VETS): https://www.dol.gov/vets/

- Federal Veteran Employment Information: https://www.fedshirevets.gov/

- Veterans Opportunity to Work (VOW) Program: https://www.benefits.va.gov/vow/

- U.S. Army Warrior Transition Command Employment Index:

https://wct.army.mil/modules/employers/index.html

- Hiring Our Heroes: https://www.uschamberfoundation.org/hiring-our-heroes

00 73 00 - 7

ER 415-1-15 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 89)

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the contract clause entitled "Default: Fixed Price Construction)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar data for the project location and will constitute the base line for monthly weather time evaluations. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

PRECIPITATION OVER 0.10 INCHES

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

3 3 2 1 1 1 1 0 1 1 1 3

TEMPERATURE BELOW 32 DEG F.

19 10 5 1 0 0 0 0 0 1 6 17

SURFACE WINDS OVER 20MPH

1 1 1 3 3 1 1 0 1 1 1 1

Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work.

Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor’s schedule workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated listed above, the Contracting Officer will convert any qualifying delays to

00 73 00 - 8 calendar days, giving full consideration for equivalent fair weather work days, and issue a modification in accordance with the contract clause entitled “Default (Fixed Price Construction)”.

(End of Clause)

INVOICES (AUG 1991)

The Government shall pay the Contractor upon submission of proper invoices for supplies delivered and accepted or services rendered and accepted for the portion of work actually performed under this contract. Invoices will be submitted (one hard-copy/ink-signed copy) to the address in Block 26, SF1442, which will be completed at time of award. Invoices shall be submitted on ENG Form 93 which will be provided to the Contractor by the Government

AS-BUILT DRAWINGS (PROGRESS PAYMENT) (OCT 1998)

One-half of one percent of construction award money shall be withheld until the final as-built drawings and CADD files are accepted by the Government.

INSURANCE REQUIRED

In accordance with Section 00 70 00, Conditions of the Contract, Contract Clause No. 52.228-5, “Insurance- Work on a Government Installation,” the contractor shall procure the following minimum insurance:

Type Amount

Workmen's Compensation and Employer's Liability Insurance $100,000

General Liability Insurance $500,000 per occurrence

Automobile Liability Insurance $200,000 per person and Bodily injury $500,000 per occurrence

Property damage $ 20,000 per occurrence

00 73 00 - 9