am6_W912PL-12-R-0001.pdf

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment your desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT 1. CONTRACT ID CODE

2. AMENDMENT/MODIFICATION NO. 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO. (If applicable)

7. ADMINISTERED BY (If other than Item 6) CODE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA FAR (48 CFR) 53.243

FACILITY CODE

9A. AMENDMENT OF SOLICITATION

NO.

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NO.

10B. DATED (SEE ITEM 13)

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended, is not extended.

12. ACCOUNTING AND APPROPRIATION DATA (If required) copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

13. THIS ITEM ONLY APPLIES TO MODIFICATION OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER NO.

IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15C. DATE SIGNED

15A. NAME AND TITLE OF SIGNER (Type or print)

16C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

PAGE OF PAGES

6. ISSUED BY CODE

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code) (X)

CODE

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

NSN 7540-01-152-8070

Previous edition unusable

Design-Build Communications Network Control Center Nellis Air Force Base, Clark County, Nevada

1. Revised Page: 00800-5 - clause 52.211-10 Commencement, Prosecution, and Completion of Work

LOS ANGELES DISTRICT , COECESPL-CT-EAST REGION

BRANCH P.O. BOX 532711LOS ANGELES, CALIFORNIA

90053-2325

LOS ANGELES DISTRICT , COECESPL-CT-EAST REGION

BRANCH P.O. BOX 532711LOS ANGELES, CALIFORNIA

90053-2325

N/A

W912PL-12-R-0001

N/A

1 1

01/13/2012

11/17/2011

N/A

W912PL-12-R-0001

52.0000-4001 UNAUTHORIZED INSTRUCTIONS FROM GOVERNMENT OR OTHER PERSONNEL

(MAY 2000)

Authorities/Technical Direction: The Contractor shall take no direction from any Government employee or any other person other than the Government contracting Officer that changes the terms and conditions of this contract action, the scope, or any change that impacts the cost, price, or schedule.

Changes authorized by the Contracting Officer will be in the form of a written, official, signed modification to the contract action received by the Contract before the Contractor will act upon those changes. The Contract will comply with the Changes clause of this contract when the contractor believes direction has been given from persons other than the Government Contracting Office that equate to a change by notifying the Contracting Officer as directed by the clause. Any direction given by any Government employee or any other person outside their authority must be reported to the Contracting Officer. Contracting Officer Representative (CORs) are limited to the authorities stated in the COR appointment letters. If a COR is appointed under this contract, they will be appointed by written letter from the Contracting Officer to the Contractor and COR specific to this contract only. COR appointment letters from previous contract at this installation are not valid for this contract

(End of Clause)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to

(a) commence work under this contract within 10 calendar days after the date the Contractor receives the Notice to Proceed,

(b) prosecute the work diligently, and

(c) complete the entire Base Bid work and options # 2, 3, 4, 5, 6, 7 and 8 ready for use not later than 540 calendar days after receipt of Notice to Proceed (NTP).

(d) If Option #1 is exercised, the Contracting Officer will issue a separate NTP for that option. The Contracting Officer will not issue the NTP for work under Option #1 until 7 days after he/she determines that the work under the base contract and any other options, if exercised, is substantially complete. The contractor shall be required to complete Option #1 ready for use not later than 183 days after receipt of the Option #1 Notice to Proceed.

(e) The 540‐day contract completion duration was formulated to include time necessary to perform all option work except Option One. No additional time for contract completion will be allowed when an option item is exercised, with the exception of Option One, Demolition of B‐589, which will extend the contract completion date by 190 days. If Option One is exercised, the Contracting Officer will issue a separate NTP for that option. The Contracting Officer will not issue the NTP for work under Option One until 7 days after he/she determines that the work under the base contract and any other options, if exercised, is substantially complete, and the contractor shall be required to complete Option #1 ready for use not later than 183 days after receipt of the Option #1 NTP.

The time slated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,322 for each calendar day of delay until the work is completed or accepted.

SECTION 00800 – 5 Amend. 0006