Amendment0001.pdf

SEE SCHEDULE AA1-00191-8

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is the follow ing:

1)To include as Attachment # 8 the Preliminary Safety and coordiantion Plan consisting of 20 sheets dated 23 May 2016.

2) To change the delivery information of the tw o CLINS

3) To revise Section H, Special Contract Requirements, add the paragraph entitled "ADDITIONAL REQUIREMENTS FOR INVOICES AND

PAYMENTS."

1. CONTRACT ID CODE PAGE OF PAGES

J 1 14

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 06-Jun-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912PF-16-R-0011

X 9B. DATED (SEE ITEM 11)

13-May-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

06-Jun-2016

CODE

414TH CSB RCO ITALY SUBOFFICE LIVORNO

VIA AURELIA, EDIFICIO 5131

ZONA DEPOSITO

56128 TIRRENIA (PISA)

W912PF 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912PF-16-R-0011

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION F - DELIVERIES OR PERFORMANCE

The following Delivery Schedule Item has been deleted from CLIN 0001:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC

POP 10-OCT-2016 TO

19-SEP-2018

N/A W6LF USAG USA GARRISON LIVORNO

W6LF USAG USA GARRISON LIVORNO

UNIT 31301

APO AE 09613

049-631-413-8182 FOB: Destination

W582TM

The following Delivery Schedule item has been added to CLIN 0001:

444 dys. ADC 1 LIVORNO

LIVORNO

APO AE 09613

The following Delivery Schedule Item has been deleted from CLIN 0002:

POP 10-OCT-2016 TO

19-AUG-2018

N/A W6LF USAG USA GARRISON LIVORNO

W6LF USAG USA GARRISON LIVORNO

UNIT 31301

APO AE 09613

049-631-413-8182

The following Delivery Schedule item has been added to CLIN 0002:

444 dys. ADC 1 LIVORNO

LIVORNO

APO AE 09613

SECTION H - SPECIAL CONTRACT REQUIREMENTS

The following have been modified:

CONTRACTING OFFICER AUTHORITY

CONTRACTING OFFICER AUTHORITY

In no event shall any understanding or agreement between the Contractor and any Government employee, other than the Contracting Officer on any contract, modification, change order, letter of verbal direction to the Contractor be effective or binding upon the Government. All such actions must be formalized by a proper contractual document executed by an appointed Contracting Officer. The Contractor is hereby put on notice that in the event a Government employee, other than the Contracting Officer, directs a change in the work to be performed, or increases the scope of work to be performed, it is the Contractor's responsibility to make inquiry of the Contracting Officer before making the deviation. Payments will not be made without being authorized by an appointed Contracting Officer with the legal authority to bind the Government.

CONTRACT MANAGER

1. The contractor shall provide a contract manager who shall be responsible for the performance of work. The name of this person and an alternate(s) who shall act for the contractor when the manager is absent shall be designated in writing to the Contracting Officer or designee prior to start performance .

2. The contract manager or alternate shall have full authority to act for the contractor on all contract matters relating to daily operation of this contract.

3. The contract manager or alternate shall be available during normal duty hours within sixty (60) minutes to meet at the job site with the Contracting Officer or designee to discuss problem areas. The contractor shall provide to the Contracting Officer or designee the telephone number of the person(s) to call should the need arise.

4. The contract manager or alternate shall be capable of explaining the work operations and receiving instructions in the English language. The Contracting Officer shall have the right to determine without appeal of such decision, whether the proposed representative has sufficient technical and lingual capabilities and the Contractor shall immediately replace any individual not acceptable to the Contracting Officer.

ENTRY PASSES

1. Within 10 working days after contract award, the Contractor shall submit, to the COR, completed Applications for USAREUR Installation Pass forms for each person that will be employed for the performance of this contract. The forms will be issued at the pre-performance meeting. The forms must be supported by the following documentation.

a. 2 photocopies of the personal identification document;

b. 1 passport size picture;

c. 1 certificato del casellario giudiziale or 1 certificato dei carichi pendenti.

2. Failure to obtain entry approval shall not affect the contract price and/or time of completion.

SCHEDULE (PROGRESS CHART)

Reference to FAR Clause 52.236-15 entitled "SCHEDULES FOR CONSTRUCTION CONTRACTS" incorporated under this contract. The contractor shall submit the required schedule (progress chart) at the pre-construction conference.

PERFORMANCE COORDINATION

Before starting performance, the Contractor SHALL coordinate the operation with the COR.

SUBSTITUTION OF PROPOSED FIRM(S)

If the award is made to a Permanent Pool of Firms (Consorzio Stabile), the Contractor shall make no substitution of the firm(s) that it has proposed to perform the work during the evaluation phase unless the firm(s) goes/go out of business. In this case, the Permanent Pool of Firms shall provide to the Contracting Officer the names of at least five (5) proposed substitutions with comparable or better qualification, past performance, and technical competence to the firm being replaced, and any additional information requested by the Contracting Officer. The Contracting Officer will notify the Contractor within ten (10) calendar days after receipt of all required information of the decision on substitution.

SUBCONTRACTING

The Contractor shall submit requests to subcontract any portion of work to be performed under this contract to the Contracting Officer for approval. The following documents shall be submitted for subcontract consent.

1. Description of Work to be subcontracted

2. Name(s) of the Subcontractor(s)

CONTRACTOR RESPONSIBILITY

1. Contractor Supervision. Pursuant to FAR 52.236-6 Clause “SUPERINTENDENCE BY THE CONTRACTOR

(APRIL 1984)”, Contractor shall supervise his/her employees to ensure compliance with contract standards.

Contractor or his/her representative shall be present at all times during work performance at contract site.

2. Host Nation Safety Requirements. In addition to the safety requirements set forth in FAR 52.236-13 Clause

“ACCIDENT PREVENTION (NOV 1991)”, Contractor shall comply with Host Nation Safety Regulations. If a prime contractor subcontracts work, the prime contractor will be responsible to verify the professional technical capabilities of its subcontractors in accordance with attachment XVII of Italian DLGS 81/2008. In case of conflict between Host Nation and US Standards, the more stringent standards shall govern.

3. Fire Protection and Prevention. The Contractor shall comply with fire protection and prevention regulation and fire defense plan prescribed for buildings in which work is to be performed. A copy of the regulation and plan is on file with the Contracting Officer or Contracting Officer Representative (COR).

4. NOTE: UNDER NO CIRCUMSTANCES SHALL CONTRACTOR STORE FLAMMABLE MATERIAL

WITHIN GOVERNMENT BUILDINGS.

5. Lost Articles. Contractor shall be responsible in the event of theft by his personnel of Government property or personal property of Government personnel, civilian or military. All lost or misplaced articles found by his/her employees shall be turned in to the COR.

6. Protective Measures. In addition to FAR 52.236-9 “PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS (APRIL 1984)”, Contractor shall provide barricades and precaution signs in both English and the Host Nation language for the safety of inhabitants and passers-by. Contractor shall be responsible for removal of furnishings and equipment as required for preparation of work sites as well as for reinstallation thereof. Contractor shall replace any furnishings and equipment at their original locations upon completion of contract work.

7. Building Security. Contractor employees shall assure that all equipment is de-energized and stored in designated storage areas together with supplies upon completion of work. When buildings are unoccupied – lights, water outlets, and blowers shall be turned off and windows closed and locked on a floor-to-floor basis as work progresses, followed by locking of all exterior doors upon completion of work. Keys to buildings shall be deposited with the COR. Contractor shall be responsible for any losses or damages arising from failure to secure buildings during and after working hours by his/her personnel.

8. Clean Up. In accordance with Contract Clause FAR 52.236-12 “CLEANING UP (APRIL 1984)”, Contractor shall be responsible for cleaning up. Accumulated dirt and debris shall be hauled off, and disposed of in accordance with Host Nation Law, at least once a week by the Contractor. Stairwells used by the Contractor during execution of work shall be cleaned daily. Cloths, mops, and brushes containing combustible materials shall be disposed of or stored outside of the buildings in tight, covered, metal containers. Paints and thinners shall not be poured into inlets of the interior or exterior sewage system. Paints, stains, and other residues on adjacent surfaces or fixtures caused by the Contractor shall be carefully removed and cleaned to original finish.

Upon completion of the work, the Contractor shall remove all construction equipment, materials, and debris resulting from contract work. The entire work site and the area used by the Contractor personnel shall be left clean.

9. Turn-in Salvage Material. The Contractor shall be responsible for salvage. All dismantled materials indicated for turn-in by the specification or as directed by the COR shall be enumerated in a roster prepared by the Contractor and turned in to Government disposal office/yard selected by COR. Contractor shall obtain a hand receipt for the materials turned in and attach the hand receipt to his final invoice. Turn-in times shall be as directed by the COR.

AS-BUILT DRAWINGS

The Contractor shall include as-built drawings as an element of work in its progress schedule.

The Contractor shall maintain at the job site one set of full-size prints of the contract drawings, accurately marked in red with adequate dimensions, to show all variations between the construction performed by the Contractor and those that are indicated or specified in the contract documents, including buried or concealed construction.

Special attention shall be given to recording the horizontal and vertical location of all buried utilities that differ from the contract drawings. Existing utility lines and features revealed during the course of construction shall also be accurately located and dimensioned. Variations in the interior utility systems shall be clearly defined and dimensioned; and coordinated with exterior utility connections at the building five-foot line, where applicable.

Existing topographic features which differ from those shown on the contract drawings shall also be accurately located and recorded. Where a choice of materials or methods is permitted herein, or where variations in scope or character of methods is permitted herein, or where variations in scope or character of work from that of the original contract are authorized, the drawings shall be marked to define the construction actually provided. The representations of such changes shall conform to standard drafting practice and shall include such supplementary notes, legends, and details as necessary to clearly portray the as-built construction.

The Contractor’s as-built drawings shall be available for review by the Contracting Officer, Contracting Officer Representative (COR) and Government Inspector at all times.

Upon completion of the work, the as-builts shall be certified and signed by the Contractor as being accurate, and delivered to the COR for approval and acceptance. Within 14 calendar days from receipt, the COR will review the as-builts and return, with comments, to the Contractor. The as-builts will be returned to the Contractor with an electronic copy of the original contract drawings in the CAD version. The Contractor shall update the original drawings as recorded during the construction phase and shall provide the following documentation.

a. One CAD electronic copy of the entire project in the as-built version certified by the Contractor as as-builts.

b. One PDF electronic copy of the entire project in the as-built version, certified by the Contractor as as-builts.

c. One printed copy on reproducible support (polyester) of the entire project, limited to the copies on which some modifications were made, to be provided with the same characteristics and format of the originals (certified by the Contractor as as-builts).

Requests for partial payments will not be approved if as-builts are not kept current

Requests for final payment will not be approved until the final corrected as-builts are delivered to the COR for final acceptance. The COR will review and perform final acceptance of the as-builts within 7 calendar days from receipt.

ENVIRONMENTAL PROTECTION

1. General: The Contractor shall be responsible for providing a plan for the prevention of environmental pollution during and as a result of construction operations under this contract. During the Pre-Construction Conference, the Contractor will meet with representatives of the Contracting Officer to develop an understanding of the environmental pollution control program.

2. Protection of Land Resources: The land resources outside the limits of permanent work shall be preserved in its present condition, or restored to its original condition, after completion of construction. The Contractor shall confine his construction activities to areas defined by the plans or specifications.

3. Prevention of Landscape Defacement: Except in areas shown on plans or specified to be cleared, the Contractor shall not deface, injure or destroy trees or shrubs, nor remove or cut them, without the written authorization from the Contracting Officer. Survey monuments or markers shall be protected before operations in the vicinity of the survey markers.

4. Restoration of Landscape Damage: Any landscape feature damaged by the Contractor’s operation shall be restored to its original condition at the Contractor’s expense. The Contracting Officer will decide what method of restoration shall be used.

5. Temporary Excavation and Embankments: If the Contractor proposes to construct temporary roads or embankments and excavations for plant and/or work areas, the Contractor shall submit for approval at least seven (7) calendar days prior to scheduled start of such temporary work:

a. A layout of all temporary roads, excavations and embankments to be constructed within the work area.

b. Details of the completed borrow excavations.

6. Post-Construction Cleanup: The Contractor shall remove all signs of temporary construction such as haul roads, work areas, structures, foundations of temporary structures, and stockpiles of materials.

7. Protection of Water Resources: The Contractor shall not pollute streams or drainage courses with fuels, oils, bitumen, calcium chloride, acids, construction wastes, or other harmful materials. The Contractor is responsible for investigating and complying with all applicable local laws and directives concerning pollution. All work shall be performed so that objectionable conditions will not be created.

8. Erosion Control: Prior to the start of construction, the Contractor shall submit a plan for approval of the

Contracting Officer showing his methods for controlling erosion and disposing of wastes. Fills and waste areas shall be constructed by selective placement to eliminate silts or clays on the surface that will erode and contaminate adjacent streams and reservoirs.

9. Spillage: Special measures shall be taken to prevent chemicals, fuels, oils, greases, bituminous materials, waste washings, herbicides and insecticides, cement and other contaminants from contaminating the soil and ground water, or from entering streams.

10. Disposal: Disposal of any materials, wastes, effluents, trash, garbage, oil, grease, chemicals, etc., shall be subject to the approval of the Contracting Officer. Ground which has been contaminated by Contractor activities shall be excavated and disposed of as directed by the Contracting Officer, and replaced with suitable fill material, compacted and finished with top soil, at the Contractor’s expense.

ACCIDENT PREVENTION

1. In accordance with clause 52.236-13 "Accident Prevention," the U.S. Army Corps of Engineers Safety and

Health Requirements Manual, EM 385-1-1 can be accessed at: http://www.usace.army.mil/inet/usace-docs/eng-manuals/em385-1-1/toc.htm

2. The Contractor will maintain an accurate record of, and will report to the Contracting Officer in the manner and on the forms prescribed by the Contracting Officer, all accidents resulting in death, traumatic injury, occupational disease, and damage to property, materials, supplies and equipment incident to work performed under this contract.

3. Compliance with the provisions of this article by subcontractors will be the responsibility of the Contractor.

4. Prior to commencement of the work, the Contractor may be required to;

a. submit in writing his proposals for effectuating provision for accident prevention;

b. meet in conference with representatives of the Contracting Office to discuss and develop mutual understandings relative to administration of the overall safety program.

HOT WORK PERMIT

The Contractor shall be responsible for coordinating with the Contracting Officer Representative (COR) to obtain a Hot Work Permit from the Directorate of Public Works (DPW) Fire Department before starting any work with an open flame.

UTILITY OUTAGES

The Contractor shall obtain the COR approval in ordre to perform any utility outage under this contract. Utility outages requests shall be submitted in writing to the COR at least 15 calendar days before any desired utility outage.

ASBESTOS

If the Contractor encounters material suspected of containing asbestos, the project manager shall note those materials and inform the COR on a daily basis. The Contractor shall treat suspected materials as if they contain asbestos until an analysis is possible. The Government will provide the analysis.

GOVERNMENT-FURNISHED UTILITIES

1. Utilities. Water and electrical power required for the execution of this project will be made available to the

Contractor without charge, in accordance with the contract clause “AVAILABILITY AND USE OF UTILITY SERVICES (APRIL 1984), FAR 52.236-14. Necessary connections to lines shall be made by the Contractor without additional cost to the Government. Electrical connections or temporary installations shall be made in accordance with VDE 0100. No other material, equipment, or services shall be furnished by the Government unless expressly stated elsewhere herein.

2. Telephones. Telephone facilities shall be made available without charge at a location designated by the Contracting Officer to make calls within the military reservation areas only. Use of telephones in family quarters by the Contractor or his/her employees or Sub-Contractors is strictly prohibited.

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1. This requirement specifies the procedure for determining time extensions for unusually severe weather, in accordance with the Contract Clause FAR 52.249-10 – DEFAULT (FIXED PRICE CONSTRUCTION). In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control, and without the fault and negligence, of the Contractor.

2. The following schedule of monthly anticipated adverse weather delays for the project location is based on the

Italian Weather Agency (Bollettino Meteorologico) and will constitute the base line for monthly weather time evaluations. The Contractor’s progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

Monthly Anticipated Adverse Weather (Calendar Days)

Jan Feb Mar Apr May Jun Jul Aug Sep Oct Nov Dec 8 7 10 8 5 3 3 3 5 10 10 8

3. Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor shall record on the daily Contractor Quality Control (CQC) report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the Contractor’s scheduled work day.

4. The number of actual adverse weather delay days shall include days impacted by actual adverse weather, even if the adverse weather occurred in the previous month, be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph 2 above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a modification for time, in accordance with the FAR 52.249-10 – DEFAULT (FIXED PRICE CONSTRUCTION).

PRE FINAL AND FINAL INSPECTION

1. Prior to the final inspection, the Contracting Officer has the right to schedule one, or more than one, pre-final inspection if he/she determines it necessary. The pre-final inspection(s) will be conducted jointly among the Contractor, the COR, and appropriate Government personnel. Any discrepancies noted shall be corrected prior to any final inspection.

2. When the project is ready for final inspection, the Contractor shall request final inspection in writing to the

Contracting Officer at least two (2) calendar days before the desired date of inspection.

ADDITIONAL REQUIREMENTS FOR INVOICES AND PAYMENTS

All requests for progress payments and final payment shall include the following supporting documentation:

Proof of subcontractors’ payment ("fatture quietanzate”).

1. Be supported with a COPY CERTIFIED (COPIA AUTENTICATA) and NOT older than 120 days at the time of the request for payment of the Contractor's DURC (Documento Unico di Regolarita Contributiva). Self-certifications (autocertiftcazioni) are NOT allowed. The document MUST include the following statement: "Con il presente documento si dichiara che l'impresa RISULTAREGOLARE ai fini del DURC".

2. The documents stated above shall be uploaded in Wide Area Workflow (WAWF) in accordance with 252.232-7006 Wide Area WorkFlow Payment Instructions.

SECTION I - CONTRACT CLAUSES

The following have been added by full text:

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

Construction Payment

(Contracting Officer: Insert applicable document type(s). Note: If a “Combo” document type is identified but not supportable by the Contractor's business systems, an “Invoice” (stand-alone) and “Receiving Report” (stand-alone) document type may be used instead.)

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

W582TM

(Contracting Officer: Insert inspection and acceptance locations or “Not applicable”.)

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC W56FJW Issue By DoDAAC W912PF Admin DoDAAC W912PF Inspect By DoDAAC W582TM Ship To Code N/A Ship From Code N/A Mark For Code N/A Service Approver (DoDAAC) N/A Service Acceptor (DoDAAC) W582TM Accept at Other DoDAAC N/A LPO DoDAAC N/A DCAA Auditor DoDAAC N/A Other DoDAAC(s) N/A

(*Contracting Officer: Insert applicable DoDAAC information or “See schedule” if multiple ship to/acceptance locations apply, or “Not applicable.”)

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

Paolo.Serraglini2.ln@mail.mil for DESIGN PHASE Gianna.buonanni2.ln@mail.mil for CONSTRUCTION PHASE

(Contracting Officer: Insert applicable email addresses or “Not applicable.”)

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

USARMY.VICENZA.266-FMC.MBX.266FMC-IFO-CVS-WAWF-OFFICIAL@MAIL.MIL

(Contracting Officer: Insert applicable information or “Not applicable.”)

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

(End of clause)

The following have been deleted:

252.232-7006 Wide Area WorkFlow Payment Instructions MAY 2013

The following were previously included by reference and are now included by full text:

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

(a) Payment of price. The Government shall pay the Contractor the contract price as provided in this contract.

(b) Progress payments. The Government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the Contracting Officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the Contracting Officer.

(1) The Contractor's request for progress payments shall include the following substantiation:

(i) An itemization of the amounts requested, related to the various elements of work required by the contract covered by the payment requested.

(ii) A listing of the amount included for work performed by each subcontractor under the contract.

(iii) A listing of the total amount of each subcontract under the contract.

(iv) A listing of the amounts previously paid to each such subcontractor under the contract.

(v) Additional supporting data in a form and detail required by the Contracting Officer.

(2) In the preparation of estimates, the Contracting Officer may authorize material delivered on the site and preparatory work done to be taken into consideration. Material delivered to the Contractor at locations other than the site also may be taken into consideration if--

(i) Consideration is specifically authorized by this contract; and

(ii) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract.

(c) Contractor certification. Along with each request for progress payments, the Contractor shall furnish the following certification, or payment shall not be made: (However, if the Contractor elects to delete paragraph (c)(4) from the certification, the certification is still acceptable.)

I hereby certify, to the best of my knowledge and belief, that--

(1) The amounts requested are only for performance in accordance with the specifications, terms, and conditions of the contract;

(2) All payments due to subcontractors and suppliers from previous payments received under the contract have been made, and timely payments will be made from the proceeds of the payment covered by this certification, in accordance with subcontract agreements and the requirements of chapter 39 of Title 31, United States Code;

(3) This request for progress payments does not include any amounts which the prime contractor intends to withhold or retain from a subcontractor or supplier in accordance with the terms and conditions of the subcontract; and

(4) This certification is not to be construed as final acceptance of a subcontractor's performance.

(Name)

(Title)

(Date)

(d) Refund of unearned amounts. If the Contractor, after making a certified request for progress payments, discovers that a portion or all of such request constitutes a payment for performance by the Contractor that fails to conform to the specifications, terms, and conditions of this contract (hereinafter referred to as the "unearned amount"), the Contractor shall--

(1) Notify the Contracting Officer of such performance deficiency; and

(2) Be obligated to pay the Government an amount (computed by the Contracting Officer in the manner provided in paragraph (j) of this clause) equal to interest on the unearned amount from the 8th day after the date of receipt of the unearned amount until--

(i) The date the Contractor notifies the Contracting Officer that the performance deficiency has been corrected; or

(ii) The date the Contractor reduces the amount of any subsequent certified request for progress payments by an amount equal to the unearned amount.

(e) Retainage. If the Contracting Officer finds that satisfactory progress was achieved during any period for which a progress payment is to be made, the Contracting Officer shall authorize payment to be made in full. However, if satisfactory progress has not been made, the Contracting Officer may retain a maximum of 10 percent of the amount of the payment until satisfactory progress is achieved. When the work is substantially complete, the Contracting Officer may retain from previously withheld funds and future progress payments that amount the Contracting Officer considers adequate for protection of the Government and shall release to the Contractor all the remaining withheld funds. Also, on completion and acceptance of each separate building, public work, or other division of the contract, for which the price is stated separately in the contract, payment shall be made for the completed work without retention of a percentage.

(f) Title, liability, and reservation of rights. All material and work covered by progress payments made shall, at the time of payment, become the sole property of the Government, but this shall not be construed as--

(1) Relieving the Contractor from the sole responsibility for all material and work upon which payments have been made or the restoration of any damaged work; or

(2) Waiving the right of the Government to require the fulfillment of all of the terms of the contract.

(g) Reimbursement for bond premiums. In making these progress payments, the Government shall, upon request, reimburse the Contractor for the amount of premiums paid for performance and payment bonds (including coinsurance and reinsurance agreements, when applicable) after the Contractor has furnished evidence of full payment to the surety. The retainage provisions in paragraph (e) of this clause shall not apply to that portion of progress payments attributable to bond premiums.

(h) Final payment. The Government shall pay the amount due the Contractor under this contract after--

(1) Completion and acceptance of all work;

(2) Presentation of a properly executed voucher; and

(3) Presentation of release of all claims against the Government arising by virtue of this contract, other than claims, in stated amounts, that the Contractor has specifically excepted from the operation of the release. A release may also be required of the assignee if the Contractor's claim to amounts payable under this contract has been assigned under the Assignment of Claims Act of 1940 (31 U.S.C. 3727 and 41 U.S.C. 6305).

(i) Limitation because of undefinitized work. Notwithstanding any provision of this contract, progress payments shall not exceed 80 percent on work accomplished on undefinitized contract actions. A "contract action" is any action resulting in a contract, as defined in FAR Subpart 2.1, including contract modifications for additional supplies or services, but not including contract modifications that are within the scope and under the terms of the contract, such as contract modifications issued pursuant to the Changes clause, or funding and other administrative changes.

(j) Interest computation on unearned amounts. In accordance with 31 U.S.C. 3903(c)(1), the amount payable under subparagraph (d)(2) of this clause shall be--

(1) Computed at the rate of average bond equivalent rates of 91-day Treasury bills auctioned at the most recent auction of such bills prior to the date the Contractor receives the unearned amount; and

(2) Deducted from the next available payment to the Contractor.

(End of clause)

SECTION J - LIST OF DOCUMENTS, EXHIBITS AND OTHER ATTACHMENTS

The following have been modified:

ATTACHMENTS

The following documents are incorporated into the solicitation:

1. Attachment # 1 - Scope of Work/Performance Work Schedule consisting of 12 pages and 5 enclosures dated 11 April 2016 and Attachment #1 to the Scope of Work entitled " Minimum Ammunition Storage Area Safety/security requirements" consisting of two pages dated 24 June 2015;

2. Attachment #2- Technical specifications consisting 19 pages;

3. Attachment # 3- Design Past Experience consisting of 1 page;

4. Attachment # 4-Construction Past Experience consisting of 1 page;

5.Attachment # 5- Past Performance Questionnaire consisting of 1 page;

6. Attachment # 6-Dichiarazione del possesso dei requisiti generali (Statement of possession of General requirements) consisting of 2 pages;

7. Attachment # 7-Dichiarazione del possesso dei requisiti generali bis (Statement of posssession of General requirements-Additional Information) consisting of 1 page;

8. Attachment # 8- Preliminary safety and Coordination Plan dated 23 May 2016 consisting of 20 sheets

(End of Summary of Changes)