W912P825B0050 Solicitation Package.pdf

ED 04-014

W912P825B0050

US Army Corps of Engineers New Orleans District

Flood Control, Amite River and Tributaries, Comite River Diversion Project

Brooks Lake Closure Structure and Guide Levee

East Baton Rouge Parish, Louisiana

Construction Solicitation and Specifications

18 August 2025

DEPARTMENT OF THE ARMY

U.S. ARMY CORPS OF ENGINEERS, NEW ORLEANS DISTRICT

7400 LEAKE AVENUE

NEW ORLEANS, LA 70118-3651

ED 04-014

SOLICITATION: W912P825B0050 18 August 2025

FOR: Flood Control, Amite River and Tributaries, Comite River Diversion Project, Brooks Lake Closure Structure and Guide Levee, East Baton Rouge Parish, Louisiana

TO OPEN:

Prospective contractors must register in the System for Award Management (SAM). See FAR Clause 52.204-7 for required information. The website for SAM is https://www.sam.gov. As of April 4, 2022, the Federal Government has stopped using the DUNS Number as a unique identifier for entities and switched to a Unique Entity ID generated by SAM.gov. In addition, entities with DUNS Numbers but no SAM.gov registration have been able to get Unique Entity IDs without registering in SAM.gov since October 2021. NOTE: The DUNS Number is no longer used in SAM.gov, eSRS, FSRS, FPDS, CPARS, or FAPIIS.

BIDDERS MUST PROVIDE FULL, ACCURATE AND COMPLETE INFORMATION AS REQUIRED BY THIS

SOLICITATION AND ITS ATTACHMENTS. THE PENALTY FOR MAKING FALSE STATEMENTS IN BIDS

IS PRESCRIBED IN 18 U.S.C. 1001. (FAR 52.214-4 APR 1984)

DESCRIPTION AND MAGNITUDE OF WORK: The work consists of constructing a guide levee, access ramp, a closure structure, which includes a 54” pipe, headwall, and flap gate, turf establishment, and improving an existing access road off of West Irene Road tying into a proposed access road running south to the project site.

CAUTION TO BIDDERS: In delivery of hand-carried bids, bidders are cautioned to allow sufficient time for delays which may be encountered as a result of frequent trains which are subject to block all access roads to place of bid opening for various lengths of time and for visitor background checks by MVN security when entering the installation at place of bid opening. Such delays DO NOT permit acceptance or consideration of late bids.

NOTE: ALL WORK UNDER THESE SPECIFICATIONS SHALL BE PERFORMED IN ACCORDANCE WITH

THE PROVISIONS OF EM 385-1-1 "SAFETY AND OCCUPATIONAL HEALTH REQUIREMENTS” DATED

15 MARCH 2024.

ATTENTION: Contractors must complete, and submit with their bid, the provisions located in Section 00600. A bidder may also submit, in lieu of the completed Section 00600, a complete copy of their Online Representations and Certifications from SAM.gov with an expiration date on or after the date of award.

ALL INQUIRIES REGARDING THIS SOLICITATION

SHOULD BE MADE TO THE FOLLOWING:

FRANCESCA E. DEBOER

CONTRACT SPECIALIST

KAREN D. HARGRAVE

CONTRACTING OFFICER

U.S. ARMY CORPS OF ENGINEERS, NEW ORLEANS DISTRICT

E‐MAILS: FRANCESCA.E.DEBOER@USACE.ARMY.MIL

PHONE: (504) 862‐1604

AND/OR

KAREN.D.HARGRAVE@USACE.ARMY.MIL

PHONE: (504) 862‐1561

COLLECT CALLS NOT ACCEPTED

NOTE: FOR THE MOST PROMPT REPSONSE, PLEASE SEND ALL QUESTIONS VIA

E‐MAIL.

PTC-i ED 04-014

PROJECT TABLE OF CONTENTS

Division 00 – PROCUREMENT AND CONTRACT REQUIREMENTS

Solicitation, Offer and Award SF-1442 00010 Bidding Schedule 00100 Instructions, To Bidders 00600 Representations and Certifications 00700 Contract Clauses

Division 01 - GENERAL REQUIREMENTS

01100 General Provisions 01 32 01.00 12 Project Schedule 01 33 00 Submittal Procedures 01 35 26 Governmental Safety Requirements 01 42 00 Sources for Reference Publications 01 45 00.15 10 Resident Management System Contractor Mode (RMS CM) 01 45 04.00 10 Contractor Quality Control 01 50 00 Traffic Control and Coordination 01 53 00.02 12 Temporary Retaining Structures 01 57 20.00 12 Environmental Protection 01 57 23.00 12 Storm Water Pollution Prevention Plan 01 57 23.01 12 Truck Wash-Down Racks 01 78 02.00 10 Closeout Submittals

Division 31 – EARTHWORK

31 05 19 Geotextiles 31 11 00.00 12 Clearing and Grubbing 31 23 00.00 12 Excavation 31 23 19.00 12 Dewatering 31 24 00.00 12 Embankment

Division 32 – EXTERIOR IMPROVEMENTS

32 15 00.00 12 Surfacing (Granular) 32 31 13 Chain Link Fences and Gates 32 92 19.04 12 Turf Establishment and Maintenance

Division 33 – UTILITIES

33 40 00 Storm Drainage Utilities 33 40 01.00 12 Culverts

Division 35 – WATERWAY AND MARINE CONSTRUCTION

35 20 18 Flap Gate and Appurtenances 35 31 19.04 12 Riprap and Bedding Construction

Flood Control, Amite River and Tributaries, Comite River Diversion Project Brooks Lake Closure Structure and Guide Levee, East Baton Rouge, Parish, Louisiana

This procurement is set aside f or 100% Historically Underutilized Business Zone (HUBZone) small businesses only.

The w ork consists of constructing a guide levee, access ramp, a closure structure, w hich includes a 54” pipe, headw all, and f lap gate, turf establishment, and improving an existing access road of f of West Irene Road tying into a proposed access road running south to the project site. The estimated time of completion is 455 calendar days, af ter receipt of notice to proceed.

The Rough Order of Magnitude (ROM) of construction is betw een $5,000,000.00 and $10,000,000.00.

X

FRANCESCA E DEBOER

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

18-Aug-2025

(RFP)

(IFB)

CALL:

Comite Diversion Brooks Lake

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________455 calendar days after receiving aw ard, X notice to proceed. This performance period is X mandatory, negotiable. (See _________________________FAR 52.211-10

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________17 Sep 2025 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______60 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USACE, CONTRACTING DIVISION

ATTN: CEMVN-CT, ROOM 172

7400 LEAKE AVE.

NEW ORLEANS LA 70118-3651

W912P8

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

10:00 AM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

ED-04-014

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W912P825B0050 78

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

SECTION 00010 - BIDDING SCHEDULE

00010-3 ED 04-014

Flood Control, Amite River and Tributaries, Comite River Diversion

Project, Brooks Lake Closure Structure and Guide Levee

Item

DESCRIPTION

Estimated Quantity

Unit

Unit Price

Estimated Amount

Mobilization and Demobilization 1 JOB

0002 Safety Fence 1 JOB

0003 Video and Photographic Documentation 1 JOB

0004 Traffic Control 1 JOB

0005 Temporary Retaining Structures 1 JOB

0006 Silt Fence

0006AA First 6,400 LF 6,400 LF

0006AB All Over 6,400 LF 7,600 LF

0007 Truck Wash-Down Rack 1 JOB

0008 Geotextile Separator 22,000 SY

0009 Clearing and Grubbing 1 JOB

0010 Stockpile Development 1 JOB

0011 Construction Dewatering 1 JOB

0012 Embankment, Compacted Fill 80,200 CY

0013 Excavation, Access Road 16,200 CY

0014 Surfacing 2,500 CY

0015 Chain Link Fencing and Gates 1 JOB

0016 Seeding and Mulching 31 AC

0017 Fertilizer

0017AA First 1,000 LBS 1,000 LBS

0017AB All Over 1,000 LBS 1,000 LBS

0018++ Lime Soil Amendment 33.27 TON

00010-4 ED 04-014

0019++ Sulfur Soil Amendment 16.64 TON

0020 Culvert, 54” CMP 228 LF

0021 Flowable Fill 1,100 CY

0022 Culvert, 15” HDPE 728 LF

0023 Culvert, 30” HDPE 500 LF

0024 Flap Gate 1 JOB

0025 Headwall 1 JOB

0026 Riprap, 1’ Thick 40 TON

0027 Riprap, 3’ Thick 60 TON

0028 Bedding Material 465 TON

TOTAL: $

++Items not subject to the requirements of FAR 52.211-18 VARIATION IN ESTIMATED QUANTITY.

**The unit "JOB" as used in this Bidding Schedule is synonymous with the term "Lump Sum" used elsewhere within these plans and specifications.

Award will be made as a whole to one bidder.

NOTE 1: Bidders shall furnish unit prices for each item listed in the Schedule requiring a unit price. If the bidder fails to insert a unit price in the appropriate blank for required item(s), but does furnish an extended total, or an estimated amount for such item(s), the Government shall deem the unit price to be the quotient obtained by dividing the extended amount for that line item by the quantity. IF A BIDDER OMITS BOTH THE

UNIT PRICE AND THE EXTENDED TOTAL OR ESTIMATED AMOUNT FOR ANY

ITEM, ITS BID SHALL BE DECLARED NON-RESPONSIVE AND THEREFORE

INELIGIBLE FOR AWARD.

NOTE 2: Any bid may be rejected if the Contracting Officer determines in writing that it is unreasonable as to price. Unreasonableness of price includes not only total price of bid, but the price for individual line items as well. Any bid may be rejected if the prices for any line items or sub line items are materially unbalanced (See FAR 14.404-2).

NOTE 3: THE NOTICE TO PROCEED (NTP): The successful bidder is advised that performance and payment bonds shall be submitted in accordance with the time frame in block 12B of SF 1442. The NTP will be issued immediately after verification of acceptable performance and payment bonds. Within seven (7) days after issuance of the NTP, the Contractor shall initiate a meeting to discuss the submittal process with the Area or Resident Engineer or his authorized representative. Physical work cannot start until the Accident Prevention Plan, Contractor Quality Control Plan, and other submittals which may be required, have been submitted and approved and all preliminary meetings called for under the contract, have been conducted.

00010-5 ED 04-014

NOTE 4: RAPID VENDOR PAYMENT: Web based instructions for the submission of invoices; https://www.mvn.usace.army.mil/Business-With-Us/Contracting/Rapid-Vendor- Payment/

EVALUATION OF SUBLINE ITEMS (Dec 2019 - AFARS 5152.211-9000).

Item Nos. 0006 and 0017 are subdivided into two or more estimated quantities and are to be separately priced. The Government will evaluate each of these items on the basis of total price of its subline items.

(End of Clause)

VARIATIONS IN ESTIMATED QUANTITIES - SUBLINE ITEMS (Dec 2019) - AFARS 5152.211-9001).

This variation in estimated quantities clause is applicable only to item Nos. 0006 and 0017.

(a) Variation from the estimated quantity in the actual work performed under any second or subsequent subline item or elimination of all work under such a second or subsequent subline item will not be the basis for an adjustment in contract unit price.

(b) Where the actual quantity of work performed for item Nos. 0006 and 0017 is less than 85% of the quantity of the first subline item listed under such item, the contractor will be paid at the contract unit price for that subline item for the actual quantity of work performed and, in addition, an equitable adjustment shall be made in accordance with the clause at Federal Acquisition Regulation (FAR) 52.211-18, VARIATION IN ESTIMATED QUANTITY.

(c) If the actual quantity of work performed under item Nos. 0006 and 0017 exceeds 115% or is less than 85% of the total estimated quantity of the subline item under that item and/or if the quantity of the work performed under the second subline item or any subsequent subline item under item Nos. NONE exceeds 115% or is less than 85% of the estimated quantity of any such subline item, and if such variation causes an increase or a decrease in the time required for performance of this contract the contract completion time will be adjusted in accordance with the clause FAR 52.211-18, VARIATION IN ESTIMATED QUANTITY.

(End of Clause) https://www.mvn.usace.army.mil/Business-With-Us/Contracting/Rapid-Vendor-Payment/ https://www.mvn.usace.army.mil/Business-With-Us/Contracting/Rapid-Vendor-Payment/

Bid Bond (See Instructions on Page 3)

Date Bond Executed (Must Not Be Later Than Bid Opening Date)

OMB Control Number: 9000-0001 Expiration Date: 1/31/2027

Principal (Legal Name And Business Address) Type Of Organization ("X" One)

State Of Incorporation

Surety(ies) (Name And Business Address)

Percent Of Bid Price

Penal Sum Of Bond Amount Not To Exceed Million(s) Thousand(s) Hundred(s) Cents

Bid Identification Bid Date Invitation Number

Authorized For Local Reproduction Previous Edition Is Not Usable

STANDARD FORM 24 (REV. 10/2023)

Prescribed by GSA - FAR (48 CFR) 53.228(a)

For (Construction, Supplies Or Services)

Obligation:

We, the Principal and Surety(ies) are firmly bound to the United States of America (hereinafter called the Government) in the above penal sum. For payment of the penal sum, we bind ourselves, our heirs, executors, administrators, and successors, jointly and severally. However, where the Sureties are corporations acting as co-sureties, we, the Sureties, bind ourselves in such sum "jointly and severally" as well as "severally" only for the purpose of allowing a joint action or actions against any or all of us. For all other purposes, each Surety binds itself, jointly and severally with the Principal, for the payment of the sum shown opposite the name of the Surety. If no limit of liability is indicated, the limit of liability is the full amount of the penal sum.

Conditions:

The Principal has submitted the bid identified above.

Therefore:

The above obligation is void if the Principal - (a) upon acceptance by the Government of the bid identified above, within the period specified therein for acceptance (sixty (60) days if no period is specified), executes the further contractual documents and gives the bond(s) required by the terms of the bid as accepted within the time specified (ten (10) days if no period is specified) after receipt of the forms by the Principal; or (b) in the event of failure to execute such further contractual documents and give such bonds, pays the Government for any cost of procuring the work which exceeds the amount of the bid.

Each Surety executing this instrument agrees that its obligation is not impaired by any extension(s) of the time for acceptance of the bid that the Principal may grant to the Government. Notice to the Surety(ies) of extension(s) is waived. However, waiver of the notice applies only to extensions aggregating not more than sixty (60) calendar days in addition to the period originally allowed for acceptance of the bid.

Other (Specify)

Individual Partnership Joint Venture

Corporation

2.

(Seal)2.(Seal) 1.

1.

1.

1. 3.2.

Name(s) (Typed)

Signature(s)

Individual Surety(ies)

Name(s) And Title(s) (Typed)

Corporate Seal

(Seal)

3.

(Seal)

2.

(Seal) Signature(s)

Principal

2.

State Of Incorporation Liability Limit ($)

2.

2.

1.Name(s) And Title(s) (Typed)

Signature(s)1. 2. Corporate Seal

Corporate Seal

Name And Address

Signature(s)

Name(s) And Title(s) (Typed)

1.

1.

2.

2.

State Of Incorporation Liability Limit ($)

Corporate Seal

Name(s) And Title(s) (Typed)

Signature(s)

Name And Address

1.

1.

2.

2.

State Of Incorporation Liability Limit ($)

Corporate Seal

Liability Limit ($)State Of Incorporation

1.

1.

Name And Address

Name(s) And Title(s) (Typed)

Signature(s)

Name And Address

Corporate Surety(ies)

Witness:

The Principal and Surety(ies) executed this bid bond and affixed their seals on the above date.

STANDARD FORM 24 (REV. 10/2023) PAGE 2

STANDARD FORM 24 (REV. 10/2023) PAGE 3

Corporate Seal

Name And Address

Signature(s)

Name(s) And Title(s) (Typed)

1.

1.

State Of Incorporation

2.

2.

Liability Limit ($)

Corporate Seal

Name(s) And Title(s) (Typed)

Signature(s)

Name And Address

1.

1.

2.

2.

State Of Incorporation Liability Limit ($)

Corporate Seal

State Of Incorporation Liability Limit ($)

2.

2.

1.

1.

Name And Address

Signature(s)

Name(s) And Title(s) (Typed)

Instructions

1. This form is authorized for use when a bid guaranty is required. Any deviation from this form will require the written approval of the Administrator of General Services.

2. Insert the full legal name and business address of the Principal in the space designated "Principal" on the face of the form. An authorized person shall sign the bond. Any person signing in a representative capacity (e.g., an attorney-in-fact) must furnish evidence of authority if that representative is not a member of the firm, partnership, or joint venture, or an officer of the corporation involved.

3. The bond may express penal sum as a percentage of the bid price. In these cases, the bond may state a maximum dollar limitation (e.g., 20% of the bid price but the amount not to exceed dollars).

4. (a) Corporations executing the bond as sureties must appear on the Department of the Treasury's list of approved sureties and must act within the limitations listed therein. The value put into the Liability

Limit block is the penal sum (i.e., the face value) of the bond, unless a co-surety arrangement is proposed.

(b) When multiple corporate sureties are involved, their names and addresses shall appear in the spaces (Surety A, Surety B, etc.) headed "Corporate Surety(ies)." In the space designated

"Surety(ies)" on the face of the form, insert only the letter identifier corresponding to each of the sureties. Moreover, when co-surety arrangements exist, the parties may allocate their respective limitations of liability under the bond, provided that the sum total of their liability equals 100% of the bond penal sum.

(c) When individual sureties are involved, a completed Affidavit of Individual Surety (Standard Form 28) for each individual surety, shall accompany the bond. The Government may require the surety to furnish additional substantiating information concerning its financial capability.

5. Corporations executing the bond shall affix their corporate seals. Individuals shall execute the bond opposite the word "Corporate Seal"; and shall affix an adhesive seal if executed in Maine, New

Hampshire, or any other jurisdiction requiring adhesive seals.

6. Type the name and title of each person signing this bond in the space provided.

7. In its application to negotiated contracts, the terms "bid" and "bidder" shall include "proposal" and

"offeror."

STANDARD FORM 24 (REV. 10/2023) PAGE 4

Paperwork Reduction Act Statement - This information collection meets the requirements of 44 USC §

3507, as amended by section 2 of the Paperwork Reduction Act of 1995. You do not need to answer these questions unless we display a valid Office of Management and Budget (OMB) control number. The OMB control number for this collection is 9000-0001. We estimate that it will take 1 hour to read the instructions, gather the facts, and answer the questions. Send only comments relating to our time estimate, including suggestions for reducing this burden, or any other aspects of this collection of information to: General

Services Administration, Regulatory Secretariat Division (MVCB), 1800 F Street, NW, Washington, DC

20405.

00010-20 ED 04-014

Section 00100 - Bidding Schedule/Instructions to Bidders

INSTRUCTIONS TO BIDDERS

INSTRUCTIONS TO BIDDERS

SOLICITATION NUMBER: W912P825B0050

NOTE: BIDDERS MAY SUBMIT BIDS BY ONLY ONE METHOD: A) ELECTRONIC COMMERCE

(EMAIL) OR BY B) PHYSICAL SUBMISSION. BIDDERS SHALL LIMIT THE BID SUBMITTAL TO ONE

OPTION OR THE OTHER, NOT BOTH.

Electronic Submission of Bids/Proposals (Email):

The New Orleans District utilizes electronic commerce (Email) for receipt of electronic bids under this IFB solicitation. To submit an electronic commerce (Email) bid please follow these steps:

1. Send an email containing your name, email address and bid/proposal to the following emails associated with the IFB (MUST include all emails):

Francesca.E.deBoer@usace.army.mil Karen.D.Hargrave@usace.army.mil

2. ALL BIDS SUBMITTED BY EMAIL MUST CONTAIN THE SOLICITATION NUMBER IN THE

SUBJECT LINE.

3. Once the agency receives your bid/proposal at the above email addresses, you will then receive a confirmation email stating your bid/proposal was received. If a bidder does not receive a reply acknowledging receipt electronically from the New Orleans District, it is incumbent upon the bidder to seek confirmation from the issuing Contracting office by phone.

Note: The size limit for incoming emails is 35MB. Any bid/proposal over this size may not be accepted by the server and will constitute the bid not being received timely. Please note that embedded links, URLs, and other html language included may interfere with the USACE server security, which may cause emails to be removed prior to being received by the contracting office. Bidders are advised to refrain from including external links, embedded links, URLs, and other html language not germane to the proposal/bid.

Please note it is a bidder’s responsibility, when transmitting its bid electronically, to ensure the receipt of its bid to the proper designee at the proper time. See FAR 14.304(b)(1)(i) regarding untimely electronic bids. Please note, MVN’s computer system firewall may cause a delay in receipt of emails, so be sure to allow ample time for possible delay. If your email would exceed 35MB you can use one of the following methods as a work-around:

Use .zip files as attachments. Combine multiple files into a .zip file to compress file size prior to adding as an email attachment.

Send multiple emails. Label each email with same subject line and indicate number of emails.

For example: Smith Construction W912P825BXXXX (1 of 2) Smith Construction

W912P825XXXX (2 5 2).

Physical Submission of Bids:

Bidders may submit their bids by hand carrying or express mail to the New Orleans District Contracting Office in Room 172. Bidders are advised to allow adequate time to ensure timely submission of its bid.

Traffic onto the New Orleans District campus may be delayed by trains blocking the entrance or security either at the gate and/or inside of the building. Express delivery may be utilized but it is incumbent upon the bidder to ensure bid delivery time and date is before the receipt of bid cutoff time. See FAR 14.304(b)(1)(ii) and (c).

Questions/Clarifications:

All questions are due no later than Friday, 22 August 2025 10:00AM CST/local time. A forthcoming amendment will provide responses to contractor questions.

Bid Opening:

The Bid Opening is scheduled for Wednesday, 17 September 2025 at 2:00PM CST/local time.

The contracting officer an contract specialist will begin downloading bids at 10:00AM local time, which is the bid submission cutoff time. All bids recevied after 10:00AM local time on Wednesday, 17 September 2025, will be considered late.

Audio Teleconference Bid Opening Information:

Microsoft Teams

Join the meeting now Meeting ID: 993 338 651 410 Passcode: n9e6Qg9K Dial in by phone +1 503-207-9433,,816591068# United States, Beaverton Find a local number Phone conference ID: 816 591 068#

CLAUSES INCORPORATED BY REFERENCE

52.204-6 Unique Entity Identifier OCT 2016 52.204-7 System for Award Management NOV 2024 52.204-22 Alternative Line Item Proposal JAN 2017 52.209-7 Information Regarding Responsibility Matters OCT 2018 52.209-13 Violation of Arms Control Treaties or Agreements --

Certification

NOV 2021

52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-12 Preparation Of Bids APR 1984 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-29 Order Of Precedence--Sealed Bidding JAN 1986 52.214-34 Submission Of Offers In The English Language APR 1991

52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.222-5 Construction Wage Rate Requirements--Secondary Site of the

Work

MAY 2014

52.225-10 Notice of Buy American Requirement--Construction Materials

MAY 2014

52.232-13 Notice Of Progress Payments APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.211-18 Variation in Estimated Quantity.

As prescribed in 11.703(c), insert the following clause in solicitations and contracts when a fixed-price construction contract is contemplated that authorizes a variation in the estimated quantity of unit-priced items:

Variation in Estimated Quantity (Apr 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgement of the Contracting Officer, is justified.

(End of clause)

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000.00, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of provision)

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Karen D. Hargrave, USACE-New Orleans District, 7400 Leake Avenue, New Orleans, LA 70118.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) Site visits may be arranged during normal duty hours by contacting:

Name: Richard Brousssard Address: 7400 Leake Avenue, New Orleans, LA 70118 Telephone: 504-862-2523

(End of provision)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

[Insert one or more Internet addresses]

(End of provision)

AFARS 5152.211-9000 Evaluation of Subline Items.

As prescribed in AFARS 5111.703(c)(i), insert the following provision:

EVALUATION OF SUB LINE ITEMS ( DEC 2019)

Item Nos. 0006 and 0017 are subdivided into two or more estimated quantities and are to be separately priced. The Government will evaluate each of these items on the basis of total price of its subline items.

(End of provision)

AFARS 5152.211-9001 Variations in Estimated Quantities—Subline Items.

As prescribed in AFARS 5111.703(c)(ii), insert the following clause:

VARIATIONS IN ESTIMATED QUANTITIES — SUB LINE ITEMS ( DEC 2019)

This variation in estimated quantities clause is applicable only to item Nos. 0006 and 0017.

(a) Variation from the estimated quantity in the actual work performed under any second or subsequent subline item or elimination of all work under such a second or subsequent subline item will not be the basis for an adjustment in contract unit price.

(b) Where the actual quantity of work performed for item Nos. 0006 and 0017 is less than 85% of the quantity of the first subline item listed under such item, the contractor will be paid at the contract unit price for that subline item for the actual quantity of work performed and, in addition, an equitable adjustment shall be made in accordance with the clause at Federal Acquisition Regulation (FAR) 52.211-18, Variation in Estimated Quantities.

(c) If the actual quantity of work performed under item Nos. 0006 and 0017 exceeds 115% or is less than 85% of the total estimated quantity of the subline item under that item and/or if the quantity of the work performed under the second subline item or any subsequent subline item under item Nos. 0006 and 0017 exceeds 115% or is less than 85% of the estimated quantity of any such subline item, and if such variation causes an increase or a decrease in the time required for performance of this contract the contract completion time will be adjusted in accordance with the clause FAR 52.211-18, Variation in Estimated Quantities.

(End of clause)

Section 00600 - Representations & Certifications

52.204-7 System for Award Management NOV 2024 52.204-16 Commercial and Government Entity Code Reporting AUG 2020 52.204-18 Commercial and Government Entity Code Maintenance AUG 2020 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.209-13 Violation of Arms Control Treaties or Agreements -- Certification

NOV 2021

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2025)

(a)(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $45,000,000.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519, if the acquisition--

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] Paragraph (d) applies.

[ ] Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c) (1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless—

(A) The acquisition is to be made under the simplified acquisition procedures in Part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements--Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that—

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services--Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations--Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance--Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of biobased products in USDA-designated product categories; or include the clause at 52.223-2, Reporting of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA- designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals--Representation. This provision applies to solicitations that include the provision at 52.204-7.

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $100,000, the provision with its Alternate II applies.

(C) If the acquisition value is $100,000 or more but is less than $102,280, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan--Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran—Representation and Certification. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

(i) 52.204-17, Ownership or Control of Offeror.

(ii) 52.204-20, Predecessor of Offeror.

(iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

(iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment--Certification.

(v) 52.222-52 Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services--Certification.

(vi) 52.227-6, Royalty Information.

(A) Basic.

(B) Alternate I.

(vii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The Offeror has completed the annual representations and certifications electronically in SAM accessed through https://www.sam.gov. After reviewing the SAM information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [ offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.209-12 CERTIFICATION REGARDING TAX MATTERS (OCT 2020)

(a) This provision implements section 523 of Division B of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts.

(b) If the Offeror is proposing a total contract price that will exceed $5.5 million (including options), the Offeror shall certify that, to the best of its knowledge and belief, it--

(1) Has [ ] filed all Federal tax returns required during the three years preceding the certification;

(2) Has not [ ] been convicted of a criminal offense under the Internal Revenue Code of 1986; and

(3) Has not [ ], more than 90 days prior to certification, been notified of any unpaid Federal tax assessment for which the liability remains unsatisfied, unless the assessment is the subject of an installment agreement or offer in compromise that has been approved by the Internal Revenue Service and is not in default, or the assessment is the subject of a non-frivolous administrative or judicial proceeding.

52.219-3 NOTICE OF HUBZONE SET-ASIDE OR SOLE-SOURCE AWARD (OCT 2022)

(a) Definition. "HUBZone small business concern,'' as used in this clause, means a small business concern, certified by the Small Business Administration (SBA), that appears on the List of Qualified HUBZone Small Business Concerns maintained by the SBA (13 CFR 126.103).

(b) Applicability. This clause applies only to--

(1) Contracts that have been set aside, or awarded on a sole-source basis to, HUBZone small business concerns;

(2) Part or parts of a multiple-award contract that have been set aside for HUBZone small business concerns;

(3) Orders set aside for HUBZone small business concerns under multiple-award contracts as described in 8.405-5 and 16.505(b)(2)(i)(F); and

(4) Orders issued directly to HUBZone small business concerns under multiple-award contracts as described in 19.504(c)(1)(ii).

(c) General.

(1) Offers are solicited only from HUBZone small business concerns. Offers received from concerns that are not HUBZone small business concerns will not be considered.

(2) Any award resulting from this solicitation will be made to a HUBZone small business concern.

(d) Joint venture. A joint venture may be considered a HUBZone concern if--

(1) At least one party to the joint venture is a HUBZone small business concern and complies with 13 CFR 126.616(c); and

(2) Each party to the joint venture qualifies as small under the size standard for the solicitation, or the protege is small under the…