W912P524R0004_Solicitation.pdf

CODE

(Hour)

PAGE(S)

until 02:00 PM local time 04 Dec 2024

X

A

X B

X C

D

EX

X

G

F 83 - 93

X H alison.t.abernathy@usace.army .mil

RATING PAGE OF PAGES

7. ISSUED BY

(Date)

IMPORTANT - Award will be made on this Form, or on Standard Form 26, or by other authorized official written notice.

Previous Edition is Unusable 33-134 STANDARD FORM 33 (REV. 9-97)

Prescribed by GSA

FAR (48 CFR) 53.214(c)

DO-C2 1 149

(If other than Item 7)

15A. NAME 16. NAME AND TITLE OF PERSON AUTHORIZED TO

AND

ADDRESS

SIGN OFFER (Type or print)

OF

OFFEROR

AMENDMENT NO. DATE

15B. TELEPHONE NO (Include area code) 17. SIGNATURE15C. CHECK IF REMITTANCE ADDRESS

IS DIFFERENT FROM ABOVE - ENTER

SUCH ADDRESS IN SCHEDULE.

18. OFFER DATE

1. THIS CONTRACT IS A RATED ORDER

UNDER DPAS (15 CFR 700)

2. CONTRACT NO.

W912P5 8. ADDRESS OFFER TO

See Item 7

9. Sealed offers in original and copies for furnishing the supplies or services in the Schedule will be received at the place specified in Item 8, or if handcarried, in the depository located in

CAUTION - LATE Submissions, Modifications, and Withdrawals: See Section L, Provision No. 52.214-7 or 52.215-1. All offers are subject to all terms and

PIEE.gov conditions contained in this solicitation.

10. FOR INFORMATION

CALL:

A. NAME (NO COLLECT CALLS)

ALISON T ABERNATHY (615)736-7921

11. TABLE OF CONTENTS

SOLICITATION/ CONTRACT FORM

SUPPLIES OR SERVICES AND PRICES/ COSTS

1 - 6

7 - 24

X I CONTRACT CLAUSES

DESCRIPTION/ SPECS./ WORK STATEMENT X

PACKAGING AND MARKING

25 J LIST OF ATTACHMENTS

INSPECTION AND ACCEPTANCE

DELIVERIES OR PERFORMANCE

26 - 27

28 - 31 X K

REPRESENTATIONS, CERTIFICATIONS AND

OTHER STATEMENTS OF OFFERORS

CONTRACT ADMINISTRATION DATA 32 X

SPECIAL CONTRACT REQUIREMENTS

OFFER (Must be fully completed by offeror) 33 - 35 M

L INSTRS., CONDS., AND NOTICES TO OFFERORS

EVALUATION FACTORS FOR AWARD

NOTE: Item 12 does not apply if the solicitation includes the provisions at 52.214-16, Minimum Bid Acceptance Period.

is inserted by the offeror) from the date for receipt of offers specified above, to furnish any or all items upon which prices are offered at the price set opposite each item, delivered at the designated point(s), within the time specified in the schedule.

13. DISCOUNT FOR PROMPT PAYMENT

(See Section I, Clause No. 52.232-8)

14. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments

AMENDMENT NO. DATE

to the SOLICITATION for offerors and related documents numbered and dated):

FACILITY

12. In compliance with the above, the undersigned agrees, if this offer is accepted within calendar days (60 calendar days unless a different period

SOLICITATION, OFFER AND AWARD

X

(X) SEC. DESCRIPTION (X) SEC. DESCRIPTION PAGE(S)

PART I - THE SCHEDULE

26. NAME OF CONTRACTING OFFICER (Type or print) 27. UNITED STATES OF AMERICA 28. AWARD DATE

EMAIL:TEL: (Signature of Contracting Officer)

CODE CODE

B. TELEPHONE (Include area code) C. E-MAIL ADDRESS

AWARD (To be completed by Government)

19. ACCEPTED AS TO ITEMS NUMBERED 20. AMOUNT 21. ACCOUNTING AND APPROPRIATION

22. AUTHORITY FOR USING OTHER THAN FULL AND OPEN COMPETITION:

10 U.S.C. 2304(c)( ) 41 U.S.C. 253(c)( ) (4 copies unless otherwise specified)

23. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

24. ADMINISTERED BY (If other than Item 7) CODE 25. PAYMENT WILL BE MADE BY CODE

PART IV - REPRESENTATIO NS AND INSTRUCTIO NS

PART III - LIST O F DO CUMENTS, EXHIBITS AND O THER ATTACHMENTS

36 - 81

PART II - CO NTRACT CLAUSES

CONTRACTING DIVISION

110 9TH AVE N

NASHVILLE TN 37203

615-736-7986

615-736-7124FAX:

TEL:

FAX:

TEL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

SOLICITATION

6. REQUISITION/PURCHASE NO.5. DATE ISSUED

06 Aug 2024

4. TYPE OF SOLICITATION

SEALED BID (IFB)

NEGOTIATED (RFP)

[ X ]

3. SOLICITATION NO.

W912P524R0004

Section 00900 - Wage Determinations

WAGE DETERMINATION

"General Decision Number: KY20240058 07/05/2024

Superseded General Decision Number: KY20230058

State: Kentucky

Construction Type: Heavy

Counties: Adair, Barren, Casey, Clinton, Cumberland, Green, Hart, Knox, Laurel, Logan, Marion, McCreary, Metcalfe, Pulaski, Russell, Simpson, Taylor, Wayne and Whitley Counties in Kentucky.

HEAVY CONSTRUCTION PROJECTS (including sewer/water construction).

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658. Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(1).

|If the contract is entered |. Executive Order 14026 |

|into on or after January 30, | generally applies to the |

|2022, or the contract is | contract. |

|renewed or extended (e.g., an |. The contractor must pay |

|option is exercised) on or | all covered workers at |

|after January 30, 2022: | least $17.20 per hour (or |

| | the applicable wage rate |

| | listed on this wage |

| | determination, if it is |

| | higher) for all hours |

| | spent performing on the |

| | contract in 2024. |

|If the contract was awarded on|. Executive Order 13658 |

|or between January 1, 2015 and| generally applies to the |

|January 29, 2022, and the | contract. |

|contract is not renewed or |. The contractor must pay all|

|extended on or after January | covered workers at least |

|30, 2022: | $12.90 per hour (or the |

| | applicable wage rate listed|

| | on this wage determination,|

| | if it is higher) for all |

| | hours spent performing on |

| | that contract in 2024. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at http://www.dol.gov/whd/govcontracts.

Modification Number Publication Date

0 01/05/2024

1 03/01/2024

2 05/31/2024

3 07/05/2024

CARP0064-007 04/01/2024

Rates Fringes

CARPENTER (Form Work Only).......$ 32.90 23.37

ELEC0369-004 09/04/2023

LINE CONSTRUCTION

Equipment Operator..........$ 38.76 23%+7.00

Groundman...................$ 25.51 23%+7.00

Lineman.....................$ 43.41 23%+7.00

* ENGI0181-010 07/01/2024

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 40.05 19.10

GROUP 2.....................$ 37.19 19.10

GROUP 4.....................$ 36.87 19.10

OPERATING ENGINEER CLASSIFICATIONS

GROUP 1 - Crane; Drill; Grader/Blade; Mechanic; Scraper

GROUP 2 - Bobcat/Skid Steer/Skid Loader; Forklift

GROUP 4 - Oiler

Operators on cranes with booms 150 feet and over (including jib) shall receive $1.00 above Group 1 rate; 250 feet and over including jib shall receive $1.50 above Class 1 rate.

Combination Rate: All crane operators operating cranes, where the length of the boom in combination with the length of the piling leads equal or exceeds 150 feet, shall receive $1.00 above the Group 1 rate.

Employees assigned to work below ground level are to be paid 10% above basic wage rate. This does not apply to open cut work.

IRON0782-010 08/01/2023

IRONWORKER (Reinforcing &

Structural)

Projects over

$20,000,000.00..............$ 34.75 25.52

Projects under

$20,000,000.00..............$ 33.01 25.52

LABO0189-014 07/01/2023

LABORER

Concrete Saw (Hand

Held/Walk Behind)...........$ 24.21 17.57

Concrete Worker.............$ 23.96 17.57

SUKY2011-014 06/25/2014

CEMENT MASON/CONCRETE FINISHER...$ 21.60 10.35

ELECTRICIAN......................$ 32.35 2.18

LABORER: Common or General......$ 20.60 9.39

LABORER: Flagger................$ 18.31 8.89

LABORER: Pipelayer..............$ 20.13 8.63

OPERATOR:

Backhoe/Excavator/Trackhoe.......$ 23.60 12.65

OPERATOR: Bulldozer.............$ 21.72 7.45

OPERATOR: Loader................$ 30.35 0.00

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after

January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is ike family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses

(29CFR 5.5 (a) (1) (iii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than

""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-

0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

State Adopted Rate Identifiers

Classifications listed under the ""SA"" identifier indicate that the prevailing wage rate set by a state (or local) government was adopted under 29 C.F.R �1.3(g)-(h). Example: SAME2023-007 01/03/2024. SA reflects that the rates are state adopted. ME refers to the State of Maine. 2023 is the year during which the state completed the survey on which the listed classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 01/03/2024 reflects the date on which the classifications and rates under the ?SA? identifier took effect under state law in the state from which the rates were adopted.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and

Hour National Office because National Office has responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the

Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations

Wage and Hour Division

U.S. Department of Labor

200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator

U.S. Department of Labor

The request should be accompanied by a full statement of the interested party's position and by any information

(wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative

Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board

U.S. Department of Labor

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION"

Section B - Supplies or Services and Prices

PRICE BREAKOUT SCHEDULE

Price Schedule

Wolf Creek Power Plant GSU Transformer Replacement

Item No. Description Est Quantity Unit Amount

0001 Design three (3) 90,000/150,000 kVA, 161 kV Grd. Y high-volage winding, 13.2kV delta low- voltage winding, Class OFAF/OFAF, three-phase GSU power transformers

1 JOB $__________

0002 Manufacture and factory test three (3)

90,000/150,000 kVA, 161 kV Grd. Y high-volage winding, 13.2kV delta low- voltage winding, Class OFAF/OFAF, three-phase

GSU power transformers

0003 Deliver three (3) 90,000/150,000 kVA, 161 kV Grd. Y high-volage winding, 13.2kV delta low- voltage winding, Class OFAF/OFAF, 0004 Offload three 90,000/150,000 kVA, 161 kV transformers and accessories at the Wolf

Creek power plant, perform inspections, perform cleaning, perform reassembly, move the transformers to the long-term transformer storage location, furnish transformer oil and perform oil-filling and processing, perform field tests, and provide the of services of an

Erecting Engineer, provide transformer specific training, 1 JOB $__________

Provide long-term transformer storage for three 90,000/150,000 kVA, 161 kV transformers

1 JOB $__________

0006 Perform pre-move field tests, move the three transformers from the long-term transformer storage location to the switchyard locations, perform post move field tests, and provide the services of an erecting engineer.

1 JOB $__________

0007 Furnish Transformer Spare Parts. 1 JOB $__________

0008 Materials

The Government will make an Economic

Price Adjustment (EPA) limited to the Steel, Copper, and Transformer Oil listed below, as

FAR clause 52.216-4. In accordance with

FAR 52.216-4(a), supporting data shall include, but is not limited to, material invoices.

0008AA Cold-Rolled Steel Pound (lbs) $__________

0008AB Standard Plate Steel Pound (lbs) $__________

0008AC Copper Pound (lbs) $__________

0008AD

Transformer Oil

Total Base Items Amount

Option 1 Items

Gallon (gal) $__________

1001 Design the oil containment and foundations for Transformers 1 & 3.

1 JOB $__________

1002 Design the oil containment and foundations for Transformer 2.

1 JOB $__________

1003 Design the medium-voltage tubular bus system for Transformers 1 & 3.

1 JOB $__________

1004 Design the medium-voltage tubular bus system for Transformer 2.

1 JOB $__________

1005 Design the 161kV strain bus system for

Transformers 1, 2, and 3.

1 JOB $__________

1006 Mobilization And Demobilization. 1 JOB $__________

1007 Removal of first switchyard 480V AC feeder. 1 JOB $__________

1008 Install of first switchyard 480V AC feeder. 1 JOB $__________

1009 Removal of second switchyard 480V AC feeder.

1 JOB $__________

1010 Install of second switchyard 480V AC feeder. 1 JOB $__________

1011 Demolition and Removal of the First

Transformer Bank and Spare Transformer.

1 JOB $__________

1012 Construction of the First Oil Containment and

Foundation.

1 JOB $__________

1013 Installation of the First Transformer. 1 JOB $__________

1014 Commissioning of the First Transformer. 1 JOB $__________

1015 Demolition and Removal of the Second

Transformer Bank.

1016 Construction of the Second oil Containment and Foundation.

1 JOB $__________

1017 Installation of the Second Transformer 1 JOB $__________

1018 Commissioning of the Second Transformer

1019 Demolition and Removal of the Third

Transformer Bank.

1 JOB $__________

1020 Construction of the Third Oil Containment and Foundation.

1 JOB $__________

1021 Installation of the Third Transformer. 1 JOB $__________

1022 Commissioning of the Third Transformer. 1 JOB $__________

1023 Provide Training on non-transformer systems. 1 JOB $__________

Total Option Items Amount $ _________________

Total Estimated Contract Price (Base + Option Items) $__________________

1.0 The quantity for Item's marked EST is estimated and may be increased or decreased, or may not be used at all, at the discretion of the Government.

2.0 Contractor's Excise Tax applies to this project.

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job Design Three (3) GSU Power Transformers

FFP

Design three (3) 90,000/150,000 kVA, 161 kV Grd. Y high-volage winding, 13.2kV delta low- voltage winding, Class OFAF/OFAF, three-phase GSU power transformers

NOTE: The requirements in DFARS 252.211-7003, Item Identification and

Valuation, are applicable for this line item. The contractor shall provide DoD unique identification or a DoD recognized unique identification equivalent.

FOB: Destination

PSC CD: N061

NET AMT

0002 1 Job Manufacture and Test Three (3) GSUs

FFP

Manufacture and factory test three (3) 90,000/150,000 kVA, 161 kV Grd. Y high-volage winding, 13.2kV delta low- voltage winding, Class OFAF/OFAF, three-phase GSU power transformers unique identification or a DoD recognized unique identification equivalent.

0003 1 Job Deliver Three (3) GSU Power Transformers

FFP

Deliver three (3) 90,000/150,000 kVA, 161 kV Grd. Y high-volage winding, 13.2kV delta low- voltage winding, Class OFAF/OFAF, unique identification or a DoD recognized unique identification equivalent.

0004 1 Job Offload Three (3) GSU Power Transformers

FFP

Offload three 90,000/150,000 kVA, 161 kV transformers and accessories at the

Wolf Creek power plant, perform inspections, perform cleaning, perform reassembly, move the transformers to the long-term transformer storage location, furnish transformer oil and perform oil-filling and processing, perform field tests, and provide the of services of an Erecting Engineer, provide transformer specific training, unique identification or a DoD recognized unique identification equivalent.

0005 1 Job Longterm Storage Three(3) GSU

FFP

Provide long-term transformer storage for three 90,000/150,000 kVA, 161 kV transformers.

0006 1 Job Pre and Post Move Field Tests

FFP

Perform pre-move field tests, move the three transformers from the long-term transformer storage location to the switchyard locations, perform post move field tests, and provide the services of an erecting engineer.

0007 1 Job Furnish Transformer Spare Parts

FFP

Furnish Transformer Spare Parts.

unique identification or a DoD recognized unique identification equivalent.

Materials- FOR INFO ONLY

FP-EPA

The Government will make an Economic Price Adjustment (EPA) limited to the

Steel, Copper, and Transformer Oil listed below, as FAR clause 52.216-4. In accordance with FAR 52.216-4(a), supporting data shall include, but is not limited to, material invoices.

0008AA 1 Pound

Cold Rolled Steel

FP-EPA

0008AB 1 Pound

Standard Plate Steel

FP-EPA

0008AC 1 Pound

Copper

FP-EPA

0008AD 1 Gallon

Transformer Oil

FP-EPA

1001 1 Job OPTION Design Oil Containment and Foundations

FFP

Design the oil containment and foundations for Transformers 1 & 3. - Construction

CLIN.

1002 1 Job OPTION Design Oil Containment and Foundations

FFP

Design the oil containment and foundations for Transformer 2 -.Construction

CLIN.

1003 1 Job OPTION Design Med Volt Tubular- Transformer 1&3

FFP

Design the medium-voltage tubular bus system for Transformers 1 & 3.-

Construction CLIN.

1004 1 Job OPTION Design Med Volt Tubular- Transformer 2

FFP

Design the medium-voltage tubular bus system for Transformer 2.- Construction

CLIN.

1005 1 Job OPTION Design 161kV Strain Bus System

FFP

Design the 161kV strain bus system for Transformers 1, 2, and 3.- Construction

CLIN.

1006 1 Job OPTION Mobilization and Demobilization

FFP

Mobilization and Demobilization- Construction CLIN.

1007 1 Job OPTION Remove First Switchyard 480V AC feeder

FFP

Removal of first switchyard 480V AC feeder.- Construction CLIN.

1008 1 Job OPTION Install First Switchyard 480V AC feeder

FFP

Install of first switchyard 480V AC feeder.- Construction CLIN.

1009 1 Job OPTION Remove Second Switchyard 480V AC feeder

FFP

Removal of second switchyard 480V AC feeder. - Construction CLIN.

1010 1 Job OPTION Install Second Switchyard 480V AC feeder

FFP

Install of second switchyard 480V AC feeder. - Construction CLIN.

1011 1 Job OPTION Demo & Removal

FFP

Demolition and Removal of the First Transformer Bank and Spare Transformer. -

Construction CLIN.

1012 1 Job OPTION Construct First Oil Containment & Founda

FFP

Construction of the First Oil Containment and Foundation. - Construction CLIN.

1013 1 Job OPTION Installation of the First Transformer

FFP

Installation of the First Transformer. - Construction CLIN.

1014 1 Job OPTION Commissioning of the First Transformer

FFP

Commissioning of the First Transformer. - Construction CLIN.

1015 1 Job OPTION Demo & Removal of Second Transformer Ban

FFP

Demolition and Removal of the Second Transformer Bank -Construction CLIN.

1016 1 Job OPTION Construct Second Oil Containment Foundat

FFP

Construction of the Second oil Containment and Foundation. - Construction CLIN.

1017 1 Job OPTION Installation of the Second Transformer

FFP

Installation of the Second Transformer - Construction CLIN.

1018 1 Job OPTION Commisioning of the Second Transformer

FFP

Commissioning of the Second Transformer - Construction CLIN.

1019 1 Job OPTION Demo & Removal of Third Transformer

FFP

Demolition and Removal of the Third Transformer Bank. - Construction CLIN.

1020 1 Job OPTION Construct Third Oil Containment & Founda

FFP

Construction of the Third Oil Containment and Foundation. Construction CLIN.

1021 1 Job OPTION Installation of the Third Transformer

FFP

Installation of the Third Transformer. - Construction CLIN.

1022 1 Job OPTION Commissioning Third Transformer

FFP

Commissioning of the Third Transformer.- Construction CLIN.

1023 1 Job OPTION Provide Training- non-transformer system

FFP

Provide Training on non-transformer systems. - Construction CLIN.

Section C - Descriptions and Specifications

SUPPLY CONSTRUCTION CONTRACT

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

This is a firm fixed price with economic price adjustment hybrid Supply / Construction Contract. Provisions and clauses applicable to supply only apply to the supply of the Three (3) 3-Phase Generator Step Up Units (GSUs) for

Wolf Creek Power Plant (CLINs 0001 through 0008).

Provisions and clauses applicable to construction only apply to the construction installation and commissioning of the supplied GSUs and demolition and removal of the current transformer banks (CLINs 1001 through 1023).

Provisions and clauses that do not differentiate between supply and construction apply to both CLINs (i.e. both phases of the contract), when applicable.

Please Note: This solicitation requires offerors to enter a National Institute of Standards and Technology (NIST) score in the Supplier Performance Risk System (SPRS). The NIST score is required before an award can be made.

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

0002 Destination Government Destination Government

0003 Destination Government Destination Government

0004 Destination Government Destination Government

0005 Destination Government Destination Government

0006 Destination Government Destination Government

0007 Destination Government Destination Government

0008 N/A N/A N/A N/A

0008AA Destination Government Destination Government

0008AB Destination Government Destination Government

0008AC Destination Government Destination Government

0008AD Destination Government Destination Government

1001 Destination Government Destination Government

1002 Destination Government Destination Government

1003 Destination Government Destination Government

1004 Destination Government Destination Government

1005 Destination Government Destination Government

1006 Destination Government Destination Government

1007 Destination Government Destination Government

1008 Destination Government Destination Government

1009 Destination Government Destination Government

1010 Destination Government Destination Government

1011 Destination Government Destination Government

1012 Destination Government Destination Government

1013 Destination Government Destination Government

1014 Destination Government Destination Government

1015 Destination Government Destination Government

1016 Destination Government Destination Government

1017 Destination Government Destination Government

1018 Destination Government Destination Government

1019 Destination Government Destination Government

1020 Destination Government Destination Government

1021 Destination Government Destination Government

1022 Destination Government Destination Government

1023 Destination Government Destination Government

CLAUSES INCORPORATED BY REFERENCE

52.246-2 Inspection Of Supplies--Fixed Price AUG 1996

52.246-12 Inspection of Construction AUG 1996

52.246-13 Inspection--Dismantling, Demolition, or Removal of

Improvements

AUG 1996

52.246-16 Responsibility For Supplies APR 1984

CLAUSES INCORPORATED BY FULL TEXT

52.246-11 HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT (DEC 2014)

(a) The Contractor shall comply with the higher-level quality standard(s) listed below.

Design, manufacture, factory test, and deliver three (3) 90,000/150,000 kVA, 161 kV Grd. Y high-voltage winding, 13.2kV delta low-voltage winding, Class OFAF/OFAF three phase generator step up (GSU) power transformers and accessories complete from the manufacturing facility to the Wolf Creek Power Plant in Jamestown, Kentucky.

(b) The Contractor shall include applicable requirements of the higher-level quality standard(s) listed in paragraph

(a) of this clause and the requirement to flow down such standards, as applicable, to lower-tier subcontracts, in--

(1) Any subcontract for critical and complex items (see 46.203(b) and (c)); or

(2) When the technical requirements of a subcontract require--

(i) Control of such things as design, work operations, in-process control, testing, and inspection; or

(ii) Attention to such factors as organization, planning, work instructions, documentation control, and advanced metrology.

(End of clause)

Section F - Deliveries or Performance

DELIVERY INFORMATION

CLIN DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

0001 1358 dys. ANP 1 EAST.KY AREA OFC,WOLF CREEK PP

SAM JASER

980 POWER PLANT RD.

JAMESTOWN KY 42629

(615)736-7279

W912P5

0002 1358 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0003 1358 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0004 1358 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0005 1358 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0006 1358 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0007 1358 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

0008 N/A N/A N/A N/A

0008AA 1358 dys. ANP 1 EAST.KY AREA OFC,WOLF CREEK PP

980 POWER PLANT RD.

JAMESTOWN KY 42629

(615)736-7279

0008AB N/A N/A N/A N/A

0008AC 1358 dys. ANP 1 EAST.KY AREA OFC,WOLF CREEK PP

980 POWER PLANT RD.

JAMESTOWN KY 42629

(615)736-7279

0008AD 1358 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1001 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1002 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1003 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1004 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1005 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1006 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1007 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1008 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1009 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1010 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1011 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1012 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1013 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1014 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1015 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1016 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1017 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1018 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1019 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1020 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1021 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1022 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

1023 613 dys. ANP 1 (SAME AS PREVIOUS LOCATION)

52.211-17 Delivery of Excess Quantities SEP 1989

52.242-15 Stop-Work Order AUG 1989

52.242-17 Government Delay Of Work APR 1984

52.247-34 F.O.B. Destination NOV 1991

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the

Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the period of performance durations, in calendar days, listed below. The time stated for completion shall include final cleanup of the premises.

Supply (base) duration - Supply NTP + 1,358 calendar days

The contractor will make delivery of all transformers and any other materials and equipment necessary for transformer installation not later than 1, 358 calendar days after receipt of notice to proceed with supply work, referred to as the Supply NTP.

Construction (option) duration - Construction NTP + 613 calendar days.

The Contractor will not begin on-site construction until the Government has issued the notice to proceed with construction, referred to as the Construction NTP. The Contractor will complete all scope items associated with this contract not later than 613 calendar days after receipt of the Construction NTP. The Government intends to issue the Construction NTP at a time that is mutually beneficial to both the Contractor and the Government but not later than Supply NTP + 1,238 calendar days.

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $6,733.53 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

Section G - Contract Administration Data

252.236-7000 Modification Proposals-Price Breakdown DEC 1991

52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

Weather conditions applicable to the Option (construction) portion of the contract:

Month Calendar Days 6 Day Workweek 5 Day Workweek 4 Day Workweek

January 10 9 8 6

February 8 7 6 5

March 6 6 5 4

April 4 4 3 3

May 4 4 3 3

June 5 5 4 3

July 5 5 4 3

August 4 4 3 3

September 4 4 3 3

October 3 3 3 2

November 4 4 3 3

December 7 6 5 4

Note: There are no applicable weather days to the Base (supply) Contract.

Section H - Special Contract Requirements

SPECIAL CONTRACT REQUIREMENTS

1. SCHEDULE OF INSURANCE:

a. The contractor shall, at its own expense, provide and maintain during the entire performance period of this contract, the minimum amounts of required insurance types listed below:

Workmen’s Compensation and Employer’s Liability Insurance $100,000

General Liability Insurance for Bodily Injury Liability

Minimum Per Occurrence for Bodily Liability $500,000

Minimum Per Each Accident for Property Damage $100,000

Minimum Aggregate for Bodily Injury $500,000

Automobile Liability Insurance

Minimum Per Person $200,000

Minimum Per Occurrence for Bodily Injury $500,000

Minimum Per Occurrence for Property Damage $20,000

b. Before commencing work under this contract, the contractor shall certify to the Contracting Officer in writing, that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government’s interest shall not be effective (1) for such period as the laws of the state in which this contract is to be performed or prescribed, and (2) until 30 days after the insurer of the contractor gives written notice to the Contracting Officer.

c. The contractor shall insert the substance of the clause entitled “Insurance-Work on a Government Installation

(FAR 52.228-5)”, in subcontracts under this contract, that require work on a Government Installation, and shall require subcontractors to provide and maintain the insurance required above.

2. TIME EXTENSION FOR UNUSUALLY SEVERE WEATHER:

a. This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with FAR clause 52.249-10, “Default (Fixed Price Construction)”. In order for the Contracting

Officer to award a time extension the following conditions must be satisfied.

1) The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

2) The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor. See FAR clause 52.236-4, “Physical Data”, for the typical number of anticipated adverse weather days. The number of days shall be exceeded for a given month before a time extension is granted.

b. Upon acknowledgement of the Notice to Proceed (NTP) and continuing throughout the contract, the

Contractor will record on the daily contractor’s quality control (CQC) report, the occurrence of adverse weather and resultant impact to the normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor’s scheduled workday. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in a previous month), be calculated chronologically from the first to the last day of each month and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in FAR clause 52.236-4, the

Contracting Officer will convert any qualifying days to calendar days, giving full consideration for equivalent fairweather workdays, and issue a modification in accordance with FAR clause 52.249-10.

3. ADMINISTRATIVE DISPUTE RESOLUTION:

In furtherance of Federal policy and the Administrative Dispute Resolution Act of 1990, ADR Act, Pub. L. 101-

552, the Contracting Officer will try to resolve all post award acquisition issues in controversy by mutual agreement of the parties. Interested parties are encouraged to use alternative resolution procedures to the maximum extent practicable in accordance with the authority and the requirement of ADR ACT.

4. ANTI-TERRORISTM OPERATIONAL SECURITY REQUIREMENTS:

General security requirements and guidance: The security requirements described below apply to all contract personnel (including employees of the prime Contractor ("Contractor") and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to the designated Government representative

(e.g., Contracting Officer Representative (COR), Requiring Activity (RA) representative, or Contracting Officer (if a COR or other RA representative is not appointed)). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USAGE) installations, facilities and activities, and security awareness training contributes to those efforts. The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Government representative. Contractor personnel and vehicles are subject to search when entering federal installations. Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as "RAMs"), and Health Protection Condition (HPCON) measures. The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures --this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

Antiterrorism (AT) Level I training: All contract personnel requiring routine access to Army installations, facilities, and controlled access areas, or requiring network access shall complete initial and annual refresher AT

Level I awareness training. Online AT Level I awareness training is available at https://jko.jten.mil/ (website subject to change).

Physical security and access control requirements: All contract personnel requiring physical access to a federal installation or facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime

Information Center-Interstate Identification Index (commonly referred to as "NCIC-111") and Terrorist Screening

Database (commonly referred to as "TSDB"). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USAGE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the RA.

Suspicious Activity Reporting training (e.g. iWATCH, CorpsWatch, or See Something, Say Something): All contract personnel shall receive initial and annual refresher training from the RA representative on the local suspicious activity reporting program. This locally developed training provides contract personnel with general information on suspicious behavior, and guidance on reporting suspicious activity to the project manager, security representative or law enforcement entity.

Escorting in classified and/or sensitive areas: In accordance with applicable regulations, all contract personnel who do not possess the appropriate security clearance or access privileges will be escorted in areas where they may be exposed to classified information or operations, sensitive information or activities, or restricted areas.

Pre-screen candidates using E-Verify Program: Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at

(https://www.e-verify.gov/) (website subject to change) to meet the contract employment eligibility requirements.

Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR

22.102-1 (i). An initial list of verified/ eligible candidates shall be provided to the COR no later than three business days after the initial contract award. When contracts are with individuals, the individuals will be required to complete a Form 1-9, Employment Eligibility Verification, and submit it to the Contracting Officer to become part of the official contract file.

UAI 5152.211-9000 EVALUATION OF SUBDIVIDED ITEMS (MAR 1995)

Item No. 0008 is subdivided into two or more estimated quantities and are to be separately priced. The Government will evaluate each of these items on the basis of total price of its sub-items.

(End of provision)

Section I - Contract Clauses

52.202-1 Definitions JUN 2020

52.203-3 Gratuities APR 1984

52.203-5 Covenant Against Contingent Fees MAY 2014

52.203-6 Restrictions On Subcontractor Sales To The Government JUN 2020

52.203-7 Anti-Kickback Procedures JUN 2020

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014

52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

JUN 2020

52.203-13 Contractor Code of Business Ethics and Conduct NOV 2021

52.204-7 System for Award Management OCT 2018

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011

52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

JUN 2020

52.204-13 System for Award Management Maintenance OCT 2018

52.204-16 Commercial and Government Entity Code Reporting AUG 2020

52.204-18 Commercial and Government Entity Code Maintenance AUG 2020

52.204-22 Alternative Line Item Proposal JAN 2017

52.204-23 Prohibition on Contracting for Hardware, Software, and

Services Developed or Provided by Kaspersky Lab Covered

Entities

DEC 2023

52.204-25 Prohibition on Contracting for Certain Telecommunications and Video Surveillance Services or Equipment

NOV 2021

52.204-27 Prohibition on a ByteDance Covered Application JUN 2023

52.204-29 Federal Acquisition Supply Chain Security Act Orders--

Representation and Disclosures.

DEC 2023

52.209-6 Protecting the Government's Interest When Subcontracting

With Contractors Debarred, Suspended, or Proposed for

Debarment

NOV 2021

52.209-9 Updates of Publicly Available Information Regarding

Responsibility Matters

OCT 2018

52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.210-1 Market Research NOV 2021

52.211-5 Material Requirements AUG 2000

52.211-13 Time Extensions SEP 2000

52.211-15 Defense Priority And Allocation Requirements APR 2008

52.211-18 Variation in Estimated Quantity APR 1984

52.215-2 Audit and Records--Negotiation JUN 2020

52.215-8 Order of Precedence--Uniform Contract Format OCT 1997

52.215-10 Price Reduction for Defective Certified Cost or Pricing Data AUG 2011

52.215-11 (Dev) Price Reduction for Defective Certified Cost or Pricing Data--

Modifications (DEVIATION 2022-O0001)

OCT 2021

52.215-12 (Dev) Subcontractor Certified Cost or Pricing Data (DEVIATION

2022-O0001)

OCT 2021

52.215-13 (Dev) Subcontractor Certified Cost or Pricing Data - Modifications

(Deviation 2022-O0001)

OCT 2021

52.215-14 Integrity of Unit Prices NOV 2021

52.215-15 Pension Adjustments and Asset Reversions OCT 2010

52.215-18 Reversion or Adjustment of Plans for Postretirement Benefits

(PRB) Other than Pensions

JUL 2005

52.215-19 Notification of Ownership Changes OCT 1997

52.215-21 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data -- Modifications

NOV 2021

52.216-2 Economic Price Adjustment - Standard Supplies NOV 2021

52.216-4 Economic Price Adjustment-Labor and Material JAN 2017

52.219-4 Notice of Price Evaluation Preference for HUBZone Small

Business Concerns

OCT 2022

52.219-8 Utilization of Small Business Concerns SEP 2023

52.219-9 Alt II Small Business Subcontracting Plan (SEP 2023) Alternate II NOV 2016

52.219-16 Liquidated Damages-Subcontracting Plan SEP 2021

52.222-1 Notice To The Government Of Labor Disputes FEB 1997

52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards - Overtime

Compensation

MAY 2018

52.222-6 Construction Wage Rate Requirements AUG 2018

52.222-7 Withholding of Funds MAY 2014

52.222-8 Payrolls and Basic Records JUL 2021

52.222-9 Apprentices and Trainees JUL 2005

52.222-10 Compliance with Copeland Act Requirements FEB 1988

52.222-11 Subcontracts (Labor Standards) MAY 2014

52.222-12 Contract Termination-Debarment MAY 2014

52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988

52.222-15 Certification of Eligibility MAY 2014

52.222-19 Child Labor -- Cooperation with Authorities and Remedies NOV 2023

52.222-20 Contracts for Materials, Supplies, Articles, and Equipment JUN 2020

52.222-21 Prohibition Of Segregated Facilities APR 2015

52.222-26 Equal Opportunity OCT 2016

52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-37 Employment Reports on Veterans JUN 2020

52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons NOV 2021

52.222-54 Employment Eligibility Verification MAY 2022

52.222-55 Minimum Wages for Contractor Workers Under Executive

Order 14026

JAN 2022

52.222-62 Paid Sick Leave Under Executive Order 13706 JAN 2022

52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-3 Hazardous Material Identification And Material Safety Data FEB 2021

52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011

52.223-20 Aerosols JUN 2016

52.223-21 Foams JUN 2016

52.225-13 Restrictions on Certain Foreign Purchases FEB 2021

52.226-7 Drug-Free Workplace MAY 2024

52.226-8 Encouraging Contractor Policies To Ban Text Messaging

While Driving

MAY 2024

52.227-1 Authorization and Consent JUN 2020

52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

JUN 2020

52.227-4 Patent Indemnity-Construction Contracts DEC 2007

52.228-2 Additional Bond Security OCT 1997

52.228-5 Insurance - Work On A Government Installation JAN 1997

52.228-11 (Dev) Individual Surety--Pledge of Assets (DEVIATION 2020-

O0016)

FEB 2021

52.228-12 Prospective Subcontractor Requests for Bonds DEC 2022

52.229-3 Federal, State And Local Taxes FEB 2013

52.229-12 Tax on Certain Foreign Procurements FEB 2021

52.230-1 Cost Accounting Standards Notices And Certification JUN 2020

52.232-1 Payments APR 1984

52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014

52.232-11 Extras APR 1984

52.232-17 Interest MAY 2014

52.232-23 Assignment Of Claims MAY 2014

52.232-27 Prompt Payment for Construction Contracts JAN 2017

52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

OCT 2018

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013

52.232-40 Providing Accelerated Payments to Small Business

Subcontractors

MAR 2023

52.233-1 Disputes MAY 2014

52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004

52.236-2 Differing Site Conditions APR 1984

52.236-3 Site Investigation and Conditions Affecting the Work APR 1984

52.236-5 Material and Workmanship APR 1984

52.236-6 Superintendence by the Contractor APR 1984

52.236-7 Permits and Responsibilities NOV 1991

52.236-8 Other Contracts APR 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.23…