09B2000 A00001.doc

Section 00010 - Solicitation Contract Form

Lump Sum

BRAC - Add Hydrant Refueling Outlet

FFP

FOB: Destination

MILSTRIP: F7Z3CE9149A001

PURCHASE REQUEST NUMBER: F7Z3CE9149A001

SIGNAL CODE: A

NET AMT

0001AA

Add hydrant Refueling Outlet

FFP

Non-Personal Services to provide all plant, labor, new and current material, transportation, tools, equipment. Add hydrant Refueling Outlet as described in the attached documentation.

FOB: Destination

MILSTRIP: F7Z3CE9149A001

NET AMT

0001AB

FFP

Contaminated Water Sampling and Lab Testing

FOB: Destination

MILSTRIP: F7Z3CE9149A001

NET AMT

0001AC

FFP

Contaminated Water Treatment and Personnel

FOB: Destination

MILSTRIP: F7Z3CE9149A001

NET AMT

0001AD

FFP

Contaminated Soil Handling, Treatment and Disposal.

FOB: Destination

MILSTRIP: F7Z3CE9149A001

NET AMT

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

DELIVERY INFORMATION

1681 E GRANGE AVENUE

MILWAUKEE WI 53207-6152

414-944-8425

FOB: Destination

F7Z3CE

F7Z3CE

F7Z3CE

F7Z3CE

F7Z3CE

AVAILABILITY OF UTILITIES

Certain utilities will be provided for contractor i.e. electric, natural gas, and waste water sanitation Meters maybe required. All other utilities will be at contractor’s expense.

Section 00100 - Bidding Schedule/Instructions to Bidders

SECTION 00100

Section 00100 INSTRUCTIONS, CONDITIONS, AND NOTICES TO OFFERORS

1. SCOPE

1.1. You are invited to submit a bid in response to our Invitation for Bid (IFB) W912J2-09-B-2000, entitled BRAC – Add Hydrant Refueling Outlet, Project number HTUV059204. As a result of this solicitation, the Government intends to award a single Firm Fixed Price (FFP) contract resulting from this solicitation to the responsible offeror whose bid represents the lowest technically acceptable price after evaluation in accordance with the factors and subfactors in the solicitation.

1.2. This solicitation is set-aside 100% for small businesses.

2. NOTICE OF PRE-PROPOSAL CONFERENCE

2.1.1. A pre-bid conference will be conducted on June 23, 2009 at 10:00 am for the purposes of briefing on the bid requirements and answering questions regarding this solicitation. This conference will be held at the 128th Air Refueling Wing, 1919 E Grange Avenue, Building 611, Milwaukee, Wisconsin 53207-6141. Interested Contractors are highly encouraged to attend the pre-bid conference. The site visit will be held following the conference.

2.1.2. Due to security conditions, all offerors must register to attend this conference and site visit. Email the following information for all attendees to SMSGT James Ensign and MSGT Steven Maier at the following addresses:

James.ensign@wimilw.ang.af.mil Steven.maier@wimilw.ang.af.mil Firm Name and Telephone Number

Visitor’s Name and Birthday: MM/DD/YYY

Drivers License

Citizenship

2.1.3. This information must be provided in advance, not later than 1 business day prior to the meeting, in order to ensure access to the military base and conference site and ensure adequate seating for the conference attendees. Even if you have access to the base you must register to ensure adequate seating. The furnishing of the above information is voluntary; however, your failure to furnish all or part of the requested information may result in the Government’s denial of your access to the pre-proposal conference. This information will be provided to the Base Security Forces who will authorize your entrance to the site.

2.1.4. Visitors must pick up their passes at the Installation’s Main Entry Gate prior to arrival. You will be required to present the following information upon arrival: (1) Vehicle Registration, (2) Valid Drivers License, (3) Proof of Insurance for Vehicle, (4) Car Rental agreement if applicable. Any of the above information furnished by you is protected under the Privacy Act and shall not be released unless permitted by law and/or you have consented to such.

2.1.5. Information provided at this conference or site visit shall not qualify the terms and conditions of the solicitation and specifications. Terms of the solicitation and specifications remain unchanged unless the solicitation is amended in writing. If an amendment is issued, normal procedures relating to the acknowledgment and receipt of solicitation amendments shall apply.

2.1.6. A record of the conference shall be made and furnished to all prospective offerors via posting to our web site at http://www.nationalguardcontracting.org/Ebs/AdvertisedSolicitations.asp. The record will include minutes of the meeting, including questions (on a non-attribution basis) and answers.

3. FORMAL COMMUNICATION, OFFEROR EXPLANATIONS

3.1. A Submit all questions by email to the contracting office at the address show below.

Subject Line: Reference No. W912J2-09-B-2000

Email:

James.ensign@wimilw.ang.af.mil Steven.maier@wimilw.ang.af.mil

3.2. Any explanation desired by an offeror regarding the meaning or interpretation of the solicitation, or proposals, drawings, specifications, etc. must be requested in writing and with sufficient time allowed for a reply to reach offerors before the submission of their offer.

3.3. The Contracting Officer reserves the right to address questions received after the fifth day prior to solicitation closing with those offers deemed responsive and/or in the competitive range after closing. All questions and requests for information (RFI) must be received NOT LATER THAN the seventh working day prior to closing and will be posted not later than two working days prior to closing. OFFERORS ARE STRONGLY ENCOURAGED TO SUBMIT QUESTIONS EARLY IN THIS PROCESS.

3.4. Any interpretations made will be in the form of an amendment of the solicitation, drawings, specifications, etc., and will be furnished to all prospective offerors via posting to our web site at: http://www.nationalguardcontracting.org/Ebs/AdvertisedSolicitations.asp

3.4.1. Receipt by the offeror must be acknowledged in the space provided on the SF 1442 or by returning a signed copy of the amendment by the time set for receipt of proposals. Explanations or instructions given in a form other than an amendment to the solicitation shall not be binding. Questions (on a non-attribution basis) and answers shall be furnished to all prospective offerors via the web site.

3.4.2. For security reasons, all technical and engineering data related to this solicitation will be distributed using the Federal Business Opportunities (FedBizOpps.gov or fbo.gov) system. FedBizOpps is a web-based dissemination tool designed to safeguard acquisition-related information for all Federal agencies. Interested bidders/offerors must register with FedBizOpps before accessing the system. FedBizOpps registration requires the following information:

3.4.2.1. 1) Central Contractor Registration (CCR) Marketing Partner Identification Number (MPIN) 2) DUNS Number and CAGE Code3) Telephone Number 4) E-Mail Address. Registration instructions can be found on the FedBizOpps website at https://www.fbo.gov/downloads/FBO_Vendor_Guide.pdf. Reference paragraph 4.4 of the Vendor Guide for instructions to retrieve the specification and drawing documents for this project. Bidders/offerors who have registered with FedBizOpps must access the data for this solicitation by way of the link below. Bidders/Offerors cannot log into the FedBizOpps home page and search for data.

4. AMENDMENTS PRIOR TO DATE SET FOR RECEIPT OF BIDS

4.1. The right is reserved, as the interest of the Government may require, to revise or amend, the specifications or drawings or both prior to and/or after the date set for receipt of bids as necessary. Such amendments, if any, will be announced by an amendment or amendments to this Invitation for Bid. All information relating to this IFB, including pertinent changes/amendments and information prior to the date set for receipt of bids will be posted on the following website: http://www.nationalguardcontracting.org/Ebs/AdvertisedSolicitations.asp

4.2. Though every effort will be made to provide email notification when a change is posted such notification is NOT guaranteed and should not be expected. Offerors are strongly cautioned to check this site frequently and to “refresh” their web page to ensure they have the lasted information.

5. HAND CARRIED PROPOSALS/INVITATIONS

5.1. A bid repository is provided for hand carried proposals and is located at 128 Air refueling Wing, 1919 E Grange Avenue, Building 500 room 14, Milwaukee, Wisconsin 53207-6141. Hand carried proposals must be deposited in the repository prior to the time established for receipt of bids.

5.2. Offerors are cautioned that approval to enter the base must be obtained prior to the closing date for receipt of bids. Delays are probable at the entry point and should be accommodated for. Late receipt of proposals due to base entry delays may not be deemed excusable and the Contracting Officer may declare the bid late and remove it from consideration.

6. WAGE DETERMINATION

6.1. Davis Bacon Wage Rates are applicable to this project. Current prevailing wage determination(s) at time of issuance of solicitation are:

GENERAL DECISION: WI080010 06/05/2009 WI10

Date: June 5, 2009, Modification # 18 General Decision Number: WI080010 WI10

6.2. In the event the current prevailing Wage Determination is changed by the Department of Labor prior to the closing date of this solicitation, it is the offeror’s responsibility to insure the most recent determination is used in preparing the proposal. An Amendment will not be issued prior to closing to change Wage Determination dates and/or numbers. Should the wage rate change after closing, but prior to award, the updated Wage Determination will be incorporated by amendment and issued to all offerors submitting a proposal. If applicable, these offerors/contractors will be given an opportunity to provide revised proposals solely to amend proposals due to Wage Determination changes. If the wage determination modification does not change any affected wage rates, then the provisions of FAR 22.404-5(c)(4) will apply.

6.3. Applicable wage rates can be found at http://www.access.gpo.gov/davisbacon/wi.html for Milwaukee County.

7. PROPOSAL EXPENSES AND PRE-CONTRACT COSTS

This IFB does not commit the Government to pay costs incurred in preparation and submission of initial and subsequent bids or for other costs incurred prior to award of a formal contract.

8. REMOVAL OF SECTIONS AT TIME OF AWARD

Sections 00100, 00110, 00120, 00600 and all exhibits will be physically removed as a result of an award, but will be deemed to be incorporated by reference in that award.

9. DISPOSITION OF UNSUCCESSFUL PROPOSALS

In compliance with FAR Subpart 4.8, the Government will retain one copy of all unsuccessful proposals. The Government will destroy extra copies of unsuccessful proposals. No destruction certificate will be provided.

10. INFORMATION REGARDING AVAILABILITY OF UTILITY SERVICES

10.1. It has been determined that all reasonable amounts of gas, electric, water, and sewer, where/if physically available, used in connection with this project will be furnished to contractor without cost. The offerors will take this into consideration when computing its offer. (FAR Clause 52.236-14, Availability and Use of Utility Services)

11. EXCEPTIONS

11.1. If the offeror takes exception to any of the requirements specified in this solicitation, the offeror shall clearly identify each such exception and include a complete explanation of why the exception was taken and what benefit accrues to the Government. All exceptions to the solicitation requirements (Sections 00010 through 00800) and supporting rationale shall be included in an addendum to the bid and clearly labeled "Exceptions". An addendum is only required if the offeror takes exception to any requirement in the solicitation. (The Addendum does not have a page limitation, but shall only include information relevant to exceptions taken to the solicitation requirements.) The Government will assume an offeror takes no exceptions to any solicitation requirement if the offeror does not submit an Addendum identifying exceptions. Offerors are advised that solicitation requirements are not necessarily negotiable and such exceptions may render an offeror's proposal unacceptable and ineligible for award.

12. CLAUSES

12.1. Clauses and provisions from the Federal Acquisition Regulation (FAR) and supplements thereto are incorporated in this document by reference and in full text. Those incorporated by reference have the same force and effect as if they were given in full text.

12.2. Clauses and provisions in this document may not appear in consecutive order.

CLAUSES INCORPORATED BY REFERENCE

CLAUSES INCORPORATED BY FULL TEXT

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) One general site visit has been scheduled as follows:

23 June 2009 at 10:00 am

Contact SMSgt James Ensign via email or fax the following for all attendees:

Name of each attendee:

Date of Birth of each attendeed

Company:

Phone Number:

Email to: james.ensign@wimilw.ang.af.mil Fax Number: 414-944-8466

(End of provision)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://farsite.hill.af.mil

(End of provision

Section 00600 - Representations & Certifications

CLAUSES INCORPORATED BY REFERENCE

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Milwaukee, Wisconsin, Milwaukee County.

(End of provision) Section 00700 - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 180 days after commencement of work . The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $159.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (JUNE 2007)

(a) Definitions. As used in this clause--

Long-term contract means a contract of more than five years in duration, including options. However, the term does not include contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority.

Small business concern means a concern, including its affiliates, that is independently owned and operated, not dominant in the field of operation in which it is bidding on Government contracts, and qualified as a small business under the criteria in 13 CFR part 121 and the size standard in paragraph (c) of this clause.

(b) If the Contractor represented that it was a small business concern prior to award of this contract, the Contractor shall rerepresent its size status according to paragraph (e) of this clause or, if applicable, paragraph (g) of this clause, upon the occurrence of any of the following:

(1) Within 30 days after execution of a novation agreement or within 30 days after modification of the contract to include this clause, if the novation agreement was executed prior to inclusion of this clause in the contract.

(2) Within 30 days after a merger or acquisition that does not require a novation or within 30 days after modification of the contract to include this clause, if the merger or acquisition occurred prior to inclusion of this clause in the contract.

(3) For long-term contracts--

(i) Within 60 to 120 days prior to the end of the fifth year of the contract; and

(ii) Within 60 to 120 days prior to the exercise date specified in the contract for any option thereafter.

(c) The Contractor shall rerepresent its size status in accordance with the size standard in effect at the time of this rerepresentation that corresponds to the North American Industry Classification System (NAICS) code assigned to this contract. The small business size standard corresponding to this NAICS code can be found at http://www.sba.gov/services/contractingopportunities/sizestandardstopics/.

(d) The small business size standard for a Contractor providing a product which it does not manufacture itself, for a contract other than a construction or service contract, is 500 employees.

(e) Except as provided in paragraph (g) of this clause, the Contractor shall make the rerepresentation required by paragraph (b) of this clause by validating or updating all its representations in the Online Representations and Certifications Application and its data in the Central Contractor Registration, as necessary, to ensure they reflect current status. The Contractor shall notify the contracting office by e-mail, or otherwise in writing, that the data have been validated or updated, and provide the date of the validation or update.

(f) If the Contractor represented that it was other than a small business concern prior to award of this contract, the Contractor may, but is not required to, take the actions required by paragraphs (e) or (g) of this clause.

(g) If the Contractor does not have representations and certifications in ORCA, or does not have a representation in ORCA for the NAICS code applicable to this contract, the Contractor is required to complete the following rerepresentation and submit it to the contracting office, along with the contract number and the date on which the rerepresentation was completed:

The Contractor represents that it ( ) is, ( ) is not a small business concern under NAICS Code 237120- assigned to contract number .

(Contractor to sign and date and insert authorized signer's name and title).

(End of clause)

52.222-18 CERTIFICATION REGARDING KNOWLEDGE OF CHILD LABOR FOR LISTED END PRODUCTS (FEBRUARY 2001)

(a) Definition.

Forced or indentured child labor means all work or service--

(1) Exacted from any person under the age of 18 under the menace of any penalty for its nonperformance and for which the worker does not offer himself voluntarily; or

(2) Performed by any person under the age of 18 pursuant to a contract the enforcement of which can be accomplished by process or penalties.

(b) Listed end products. The following end product(s) being acquired under this solicitation is (are) included in the List of Products Requiring Contractor Certification as to Forced or Indentured Child Labor, identified by their country of origin. There is a reasonable basis to believe that listed endproducts from the listed countries of origin may have been mined, produced, or manufactured by forced or indentured child labor.

Listed End Product

Listed Countries of Origin

(c) Certification. The Government will not make award to an offeror unless the offeror, by checking the appropriate block, certifies to either paragraph (c)(1) or paragraph (c)(2) of this provision.

( ) (1) The offeror will not supply any end product listed in paragraph (b) of this provision that was mined, produced, or manufactured in a corresponding country as listed for that end product.

( ) (2) The offeror may supply an end product listed in paragraph (b) of this provision that was mined, produced, or manufactured in the corresponding country as listed for that product. The offeror certifies that it has made a good faith effort to determine whether forced or indentured child labor was used to mine, produce, or manufacture such end product. On the basis of those efforts, the offeror certifies that it is not aware of any such use of child labor.

(End of provision).

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Milwaukee, Wisconsin, Milwaukee County.

(End of provision) 52.232-34 PAYMENT BY ELECTRONIC FUNDS TRANSFER—OTHER THAN CENTRAL CONTRACTOR REGISTRATION (MAY 1999)

(a) Method of payment. (1) All payments by the Government under this contract shall be made by electronic funds transfer (EFT) except as provided in paragraph (a)(2) of this clause. As used in this clause, the term “EFT” refers to the funds transfer and may also include the payment information transfer.

(2) In the event the Government is unable to release one or more payments by EFT, the Contractor agrees to either--

(i) Accept payment by check or some other mutually agreeable method of payment; or

(ii) Request the Government to extend payment due dates until such time as the Government makes payment by EFT (but see paragraph (d) of this clause).

(b) Mandatory submission of Contractor's EFT information. (1) The Contractor is required to provide the Government with the information required to make payment by EFT (see paragraph (j) of this clause). The Contractor shall provide this information directly to the office designated in this contract to receive that information (hereafter: “designated office”') by no later than 15 days prior to submission of the first request for payment”. If not otherwise specified in this contract, the payment office is the designated office for receipt of the Contractor's EFT information. If more than one designated office is named for the contract, the Contractor shall provide a separate notice to each office. In the event that the EFT information changes, the Contractor shall be responsible for providing the updated information to the designated office(s).

(2) If the Contractor provides EFT information applicable to multiple contracts, the Contractor shall specifically state the applicability of this EFT information in terms acceptable to the designated office. However, EFT information supplied to a designated office shall be applicable only to contracts that identify that designated office as the office to receive EFT information for that contract.

(c) Mechanisms for EFT payment. The Government may make payment by EFT through either the Automated Clearing House (ACH) network, subject to the rules of the National Automated Clearing House Association, or the Fedwire Transfer System. The rules governing Federal payments through the ACH are contained in 31 CFR part 210.

(d) Suspension of payment. (1) The Government is not required to make any payment under this contract until after receipt, by the designated office, of the correct EFT payment information from the Contractor. Until receipt of the correct EFT information, any invoice or contract financing request shall be deemed not to be a proper invoice for the purpose of prompt payment under this contract. The prompt payment terms of the contract regarding notice of an improper invoice and delays in accrual of interest penalties apply.

(2) If the EFT information changes after submission of correct EFT information, the Government shall begin using the changed EFT information no later than 30 days after its receipt by the designated office to the extent payment is made by EFT. However, the Contractor may request that no further payments be made until the updated EFT information is implemented by the payment office. If such suspension would result in a late payment under the prompt payment terms of this contract, the Contractor's request for suspension shall extend the due date for payment by the number of days of the suspension.

(e) Liability for uncompleted or erroneous transfers. (1) If an uncompleted or erroneous transfer occurs because the Government used the Contractor's EFT information incorrectly, the Government remains responsible for--

(i) Making a correct payment;

(ii) Paying any prompt payment penalty due; and

(iii) Recovering any erroneously directed funds.

(2) If an uncompleted or erroneous transfer occurs because the Contractor's EFT information was incorrect, or was revised within 30 days of Government release of the EFT payment transaction instruction to the Federal Reserve System, and--

(i) If the funds are no longer under the control of the payment office, the Government is deemed to have made payment and the Contractor is responsible for recovery of any erroneously directed funds; or

(ii) If the funds remain under the control of the payment office, the Government shall not make payment and the provisions of paragraph (d) shall apply.

(f) EFT and prompt payment. A payment shall be deemed to have been made in a timely manner in accordance with the prompt payment terms of this contract if, in the EFT payment transaction instruction released to the Federal Reserve System, the date specified for settlement of the payment is on or before the prompt payment due date, provided the specified payment date is a valid date under the rules of the Federal Reserve System.

(g) EFT and assignment of claims. If the Contractor assigns the proceeds of this contract as provided for in the assignment of claims terms of this contract, the Contractor shall require as a condition of any such assignment, that the assignee shall provide the EFT information required by paragraph (j) of this clause to the designated office, and shall be paid by EFT in accordance with the terms of this clause. In all respects, the requirements of this clause shall apply to the assignee as if it were the Contractor. EFT information that shows the ultimate recipient of the transfer to be other than the Contractor, in the absence of a proper assignment of claims acceptable to the Government, is incorrect EFT information within the meaning of paragraph (d) of this clause.

(h) Liability for change of EFT information by financial agent. The Government is not liable for errors resulting from changes to EFT information provided by the Contractor's financial agent.

(i) Payment information. The payment or disbursing office shall forward to the Contractor available payment information that is suitable for transmission as of the date of release of the EFT instruction to the Federal Reserve System. The Government may request the Contractor to designate a desired format and method(s) for delivery of payment information from a list of formats and methods the payment office is capable of executing. However, the Government does not guarantee that any particular format or method of delivery is available at any particular payment office and retains the latitude to use the format and delivery method most convenient to the Government. If the Government makes payment by check in accordance with paragraph (a) of this clause, the Government shall mail the payment information to the remittance address in the contract.

(j) EFT information. The Contractor shall provide the following information to the designated office. The Contractor may supply this data for this or multiple contracts (see paragraph (b) of this clause). The Contractor shall designate a single financial agent per contract capable of receiving and processing the EFT information using the EFT methods described in paragraph (c) of this clause.

(1) The contract number (or other procurement identification number).

(2) The Contractor's name and remittance address, as stated in the contract(s).

(3) The signature (manual or electronic, as appropriate), title, and telephone number of the Contractor official authorized to provide this information.

(4) The name, address, and 9-digit Routing Transit Number of the Contractor's financial agent.

(5) The Contractor's account number and the type of account (checking, saving, or lockbox).

(6) If applicable, the Fedwire Transfer System telegraphic abbreviation of the Contractor's financial agent.

(7) If applicable, the Contractor shall also provide the name, address, telegraphic abbreviation, and 9-digit Routing Transit Number of the correspondent financial institution receiving the wire transfer payment if the Contractor's financial agent is not directly on-line to the Fedwire Transfer System; and, therefore, not the receiver of the wire transfer payment.

(End of clause)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 15 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performing the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government.

(End of clause)

52.236-13 ACCIDENT PREVENTION (NOV 1991)

(a) The Contractor shall provide and maintain work environments and procedures which will

(1) safeguard the public and Government personnel, property, materials, supplies, and equipment exposed to Contractor operations and activities;

(2) avoid interruptions of Government operations and delays in project completion dates; and

(3) control costs in the performance of this contract.

(b) For these purposes on contracts for construction or dismantling, demolition, or removal of improvements, the Contractor shall-

(1) Provide appropriate safety barricades, signs, and signal lights;

(2) Comply with the standards issued by the Secretary of Labor at 29 CFR Part 1926 and 29 CFR Part 1910; and

(3) Ensure that any additional measures the Contracting Officer determines to be reasonably necessary for the purposes are taken.

(c) If this contract is for construction or dismantling, demolition or removal of improvements with any Department of Defense agency or component, the Contractor shall comply with all pertinent provisions of the latest version of U.S. Army Corps of Engineers Safety and Health Requirements Manual, EM 385-1-1, in effect on the date of the solicitation.

(d) Whenever the Contracting Officer becomes aware of any noncompliance with these requirements or any condition which poses a serious or imminent danger to the health or safety of the public or Government personnel, the Contracting Officer shall notify the Contractor orally, with written confirmation, and request immediate initiation of corrective action. This notice, when delivered to the Contractor or the Contractor's representative at the work site, shall be deemed sufficient notice of the noncompliance and that corrective action is required. After receiving the notice, the Contractor shall immediately take corrective action. If the Contractor fails or refuses to promptly take corrective action, the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action has been taken. The Contractor shall not be entitled to any equitable adjustment of the contract price or extension of the performance schedule on any stop work order issued under this clause.

(e) The Contractor shall insert this clause, including this paragraph (e), with appropriate changes in the designation of the parties, in subcontracts.

(End of clause)

52.244-2 SUBCONTRACTS (JUN 2007)

(a) Definitions. As used in this clause--

Approved purchasing system means a Contractor's purchasing system that has been reviewed and approved in accordance with Part 44 of the Federal Acquisition Regulation (FAR).

Consent to subcontract means the Contracting Officer's written consent for the Contractor to enter into a particular subcontract.

Subcontract means any contract, as defined in FAR Subpart 2.1, entered into by a subcontractor to furnish supplies or services for performance of the prime contract or a subcontract. It includes, but is not limited to, purchase orders, and changes and modifications to purchase orders.

purchase orders.

(b) When this clause is included in a fixed-price type contract, consent to subcontract is required only on unpriced contract actions (including unpriced modifications or unpriced delivery orders), and only if required in accordance with paragraph (c) or (d) of this clause.

(c) If the Contractor does not have an approved purchasing system, consent to subcontract is required for any subcontract that—

(1) Is of the cost-reimbursement, time-and-materials, or labor-hour type; or

(2) Is fixed-price and exceeds—

(i) For a contract awarded by the Department of Defense, the Coast Guard, or the National Aeronautics and Space Administration, the greater of the simplified acquisition threshold or 5 percent of the total estimated cost of the contract; or

(ii) For a contract awarded by a civilian agency other than the Coast Guard and the National Aeronautics and Space Administration, either the simplified acquisition threshold or 5 percent of the total estimated cost of the contract.

(d) If the Contractor has an approved purchasing system, the Contractor nevertheless shall obtain the Contracting Officer’s written consent before placing the following subcontracts:

TBD

(e)(1) The Contractor shall notify the Contracting Officer reasonably in advance of placing any subcontract or modification thereof for which consent is required under paragraph (b), (c), or (d) of this clause, including the following information:

(i) A description of the supplies or services to be subcontracted.

(ii) Identification of the type of subcontract to be used.

(iii) Identification of the proposed subcontractor.

(iv) The proposed subcontract price.

(v) The subcontractor’s current, complete, and accurate cost or pricing data and Certificate of Current Cost or Pricing Data, if required by other contract provisions.

(vi) The subcontractor’s Disclosure Statement or Certificate relating to Cost Accounting Standards when such data are required by other provisions of this contract.

(vii) A negotiation memorandum reflecting—

(A) The principal elements of the subcontract price negotiations;

(B) The most significant considerations controlling establishment of initial or revised prices;

(C) The reason cost or pricing data were or were not required;

(D) The extent, if any, to which the Contractor did not rely on the subcontractor’s cost or pricing data in determining the price objective and in negotiating the final price;

(E) The extent to which it was recognized in the…