W912ES23B0015 FMMSE4__SPEC.pdf

SOLICITATION NO. W912ES23B0015

US Army Corps of Engineers St. Paul District

RED RIVER OF THE NORTH RIVER BASIN

FARGO-MOORHEAD FLOOD RISK

MANAGEMENT

MOORHEAD, MN

CONSTRUCTION

DOCUMENTS FOR

FMM SOUTHERN EMBANKMENT REACH SE-4

APRIL 2024

The Fargo-Moorhead Metropolitan (FMM) Area Flood Risk Management Project - Southern Embankment Reach 4.

This solicitation is issued as an Invitation for Bid (IFB) and Unrestricted (full and open). The anticipated magnitude of this project is between $25,000,000 and $100,000,000. The NAICS code for this procurement is 237990 Other Heavy and Civil Engineering Construction with a size standard of $45,000,000.

Payment and Performance Protection is required in accordance with FAR Part 28.

X

SCOTT E HENDRIX 651-290-5406

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

02-Apr-2024

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance within _______ 10 calendar days and complete it within ________ calendar days after receiving award, X notice to proceed. This performance period is mandatory, negotiable. (See _________________________ 52.211-10 Alt1

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the work required are due at the place specified in Item 8 by ___________ local time ______________ 02 May 2024 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______ 60 calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

CONTRACTING DIVISION

USACE, ST PAUL

332 MINNESOTA STREET

SUITE E1500

ST PAUL MN 55101-1323

W912ES

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

02:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO.

W81G6740861223

6. PROJECT NO.

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX: TEL:651-290-5414 TEL: FAX:

W912ES23B0015 228

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

W912ES23B0015

Section 00 10 00 - Solicitation

TABLE OF CONTENTS

SECTION 00 10 00 - SOLICITATION

TABLE OF CONTENTS

BID SCHEDULE

SECTION 00 21 13 - INSTRUCTIONS TO BIDDERS

BID SUBMISSION INSTRUCTIONS

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (AUG 2020)

52.204-22 ALTERNATIVE LINE ITEM PROPOSAL (JAN 2017)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS (DEC 2016)

52.214-4 FALSE STATEMENTS IN BIDS (APR 1984)

52.214-5 SUBMISSION OF BIDS (DEC 2016)

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS (APR 1984)

52.214-7 LATE SUBMISSIONS, MODIFICATIONS, AND WITHDRAWALS OF BIDS (NOV 1999)

52.214-18 PREPARATION OF BIDS--CONSTRUCTION (APR 1984)

52.214-19 CONTRACT AWARD--SEALED BIDDING--CONSTRUCTION (AUG 1996)

52.214-34 SUBMISSION OF OFFERS IN THE ENGLISH LANGUAGE (APR 1991)

52.214-35 SUBMISSION OF OFFERS IN U.S. CURRENCY (APR 1991)

52.216-1 TYPE OF CONTRACT (APR 1984)

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY 2014) 52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL EMPLOYMENT

OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

52.222-33 NOTICE OF REQUIREMENT FOR PROJECT LABOR AGREEMENT (JAN 2024) ALTERNATE I (JAN 2024) ... 23

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT - CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014) ALTERNATE I (MAY 2014)

52.228-1 BID GUARANTEE (SEP 1996)

52.228-17 INDIVIDUAL SURETY--PLEDGE OF ASSETS (BID GUARANTEE) (FEB 2021)

52.233-2 SERVICE OF PROTEST (SEP 2006)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

252.236-7008 CONTRACT PRICES - BIDDING SCHEDULES. (DEC 1991)

5152.211-9000 EVALUATION OF SUBLINE ITEMS (DEC 2019)

SECTION 00 45 00 - REPRESENTATIONS AND CERTIFICATIONS

52.204-7 SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

52.204-8 ANNUAL REPRESENTATIONS AND CERTIFICATIONS (MAR 2023)

52.204-24 REPRESENTATION REGARDING CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE

SERVICES OR EQUIPMENT (NOV 2021)

52.209-13 VIOLATION OF ARMS CONTROL TREATIES OR AGREEMENTS--CERTIFICATION (NOV 2021)

52.229-11 TAX ON CERTAIN FOREIGN PROCUREMENTS--NOTICE AND REPRESENTATION (JUN

2020) 252.203-7005 REPRESENTATION RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (SEP 2022)

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (NOV 2023)

252.204-7017 PROHIBITION ON THE ACQUISITION OF COVERED DEFENSE TELECOMMUNICATIONS EQUIPMENT

OR SERVICES--REPRESENTATION (MAY 2021)

252.225-7055 REPRESENTATION REGARDING BUSINESS OPERATIONS WITH THE MADURO REGIME (MAY 2022) . 39 252.225-7057 PREAWARD DISCLOSURE OF EMPLOYMENT OF INDIVIDUALS WHO WORK IN THE PEOPLE'S

REPUBLIC OF CHINA (AUG 2022)

252.225-7059 PROHIBITION ON CERTAIN PROCUREMENTS FROM THE XINJIANG UYGHUR AUTONOMOUS

REGION - REPRESENTATION (JUN 2023)

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

52.202-1 DEFINITIONS (JUN 2020)

52.203-3 GRATUITIES (APR 1984)

52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014)

52.203-6 RESTRICTIONS ON SUBCONTRACTOR SALES TO THE GOVERNMENT (JUN 2020)

52.203-7 ANTI-KICKBACK PROCEDURES (JUN 2020)

52.203-8 CANCELLATION, RESCISSION, AND RECOVERY OF FUNDS FOR ILLEGAL OR IMPROPER ACTIVITY (MAY

2014)

52.203-10 PRICE OR FEE ADJUSTMENT FOR ILLEGAL OR IMPROPER ACTIVITY (MAY 2014)

52.203-12 LIMITATION ON PAYMENTS TO INFLUENCE CERTAIN FEDERAL TRANSACTIONS (JUN 2020)

52.203-13 CONTRACTOR CODE OF BUSINESS ETHICS AND CONDUCT (NOV 2021)

52.203-19 PROHIBITION ON REQUIRING CERTAIN INTERNAL CONFIDENTIALITY AGREEMENTS OR STATEMENTS

(JAN 2017)

52.204-4 PRINTED OR COPIED DOUBLE-SIDED ON POSTCONSUMER FIBER CONTENT PAPER (MAY 2011) 52.204-10 REPORTING EXECUTIVE COMPENSATION AND FIRST-TIER SUBCONTRACT AWARDS (JUN 2020)

52.204-13 SYSTEM FOR AWARD MANAGEMENT MAINTENANCE (OCT 2018)

P52.204-18 COMMERCIAL AND GOVERNMENT ENTITY CODE MAINTENANCE (AUG 2020)

52.204-19 INCORPORATION BY REFERENCE OF REPRESENTATIONS AND CERTIFICATIONS (DEC 2014) 52.204-23 PROHIBITION ON CONTRACTING FOR HARDWARE, SOFTWARE, AND SERVICES DEVELOPED OR

PROVIDED BY KASPERSKY LAB COVERED ENTITIES (DEC 2023)

52.204-25 PROHIBITION ON CONTRACTING FOR CERTAIN TELECOMMUNICATIONS AND VIDEO SURVEILLANCE

SERVICES OR EQUIPMENT (NOV 2021)

52.204-27 PROHIBITION ON A BYTEDANCE COVERED APPLICATION (JUN 2023)

52.209-6 PROTECTING THE GOVERNMENT'S INTEREST WHEN SUBCONTRACTING WITH CONTRACTORS

DEBARRED, SUSPENDED, OR PROPOSED FOR DEBARMENT (NOV 2021)

52.209-9 UPDATES OF PUBLICLY AVAILABLE INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018).. 64 52.209-10 PROHIBITION ON CONTRACTING WITH INVERTED DOMESTIC CORPORATIONS. (NOV 2015)

52.210-1 MARKET RESEARCH (NOV 2021)

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) - ALTERNATE I (APR

1984)

52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000)

52.211-13 TIME EXTENSIONS (SEP 2000)

52.211-18 VARIATION IN ESTIMATED QUANTITY (APR 1984)

52.214-26 AUDIT AND RECORDS--SEALED BIDDING (JUN 2020)

52.214-27 PRICE REDUCTION FOR DEFECTIVE CERTIFIED COST OR PRICING DATA - MODIFICATIONS - SEALED

BIDDING. (JUN 2020)

52.214-28 SUBCONTRACTOR CERTIFIED COST OR PRICING DATA - MODIFICATIONS - SEALED BIDDING. (JUN

2020) 52.219-4 NOTICE OF PRICE EVALUATION PREFERENCE FOR HUBZONE SMALL BUSINESS CONCERNS (OCT 2022)

52.219-8 UTILIZATION OF SMALL BUSINESS CONCERNS (SEP 2023)

52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN (SEP 2023)--ALTERNATE I (NOV 2016)

52.219-16 LIQUIDATED DAMAGES-SUBCONTRACTING PLAN (SEP 2021)

52.219-28 POST-AWARD SMALL BUSINESS PROGRAM REREPRESENTATION (SEP 2023)

52.222-3 CONVICT LABOR (JUN 2003)

52.222-4 CONTRACT WORK HOURS AND SAFETY STANDARDS - OVERTIME COMPENSATION (MAY 2018)

52.222-6 CONSTRUCTION WAGE RATE REQUIREMENTS (AUG 2018)

52.222-7 WITHHOLDING OF FUNDS (MAY 2014)

52.222-8 PAYROLLS AND BASIC RECORDS (JUL 2021)

52.222-9 APPRENTICES AND TRAINEES (JUL 2005)

52.222-10 COMPLIANCE WITH COPELAND ACT REQUIREMENTS (FEB 1988)

52.222-11 SUBCONTRACTS (LABOR STANDARDS) (MAY 2014)

52.222-12 CONTRACT TERMINATION--DEBARMENT (MAY 2014)

52.222-13 COMPLIANCE WITH CONSTRUCTION WAGE RATE REQUIREMENTS AND RELATED REGULATIONS (MAY

2014)

52.222-14 DISPUTES CONCERNING LABOR STANDARDS (FEB 1988)

52.222-15 CERTIFICATION OF ELIGIBILITY (MAY 2014)

52.222-21 PROHIBITION OF SEGREGATED FACILITIES (APR 2015)

52.222-26 EQUAL OPPORTUNITY (SEPT 2016)

52.222-34 PROJECT LABOR AGREEMENT (JAN 2024)

52.222-27 AFFIRMATIVE ACTION COMPLIANCE REQUIREMENTS FOR CONSTRUCTION (APR 2015)

52.222-35 EQUAL OPPORTUNITY FOR VETERANS (JUN 2020)

52.222-36 EQUAL OPPORTUNITY FOR WORKERS WITH DISABILITIES (JUN 2020)

52.222-37 EMPLOYMENT REPORTS ON VETERANS (JUN 2020)

52.222-40 NOTIFICATION OF EMPLOYEE RIGHTS UNDER THE NATIONAL LABOR RELATIONS ACT (DEC 2010)

52.222-50 COMBATING TRAFFICKING IN PERSONS (NOV 2021)

52.222-54 EMPLOYMENT ELIGIBILITY VERIFICATION (MAY 2022)

52.222-55 MINIMUM WAGES FOR CONTRACTOR WORKERS UNDER EXECUTIVE ORDER 14026 (JAN 2022)

52.222-62 PAID SICK LEAVE UNDER EXECUTIVE ORDER 13706 (JAN 2022)

52.223-2 AFFIRMATIVE PROCUREMENT OF BIOBASED PRODUCTS UNDER SERVICE AND CONSTRUCTION

CONTRACTS (SEP 2013)

52.223-6 DRUG-FREE WORKPLACE (MAY 2001)

52.223-17 AFFIRMATIVE PROCUREMENT OF EPA-DESIGNATED ITEMS IN SERVICE AND CONSTRUCTION

CONTRACTS (AUG 2018)

52.223-18 ENCOURAGING CONTRACTOR POLICIES TO BAN TEXT MESSAGING WHILE DRIVING (JUN 2020)

52.223-20 AEROSOLS (JUN 2016)

52.225-11 BUY AMERICAN--CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS (NOV 2023)

52.225-13 RESTRICTIONS ON CERTAIN FOREIGN PURCHASES (FEB 2021)

52.227-1 AUTHORIZATION AND CONSENT (JUN 2020)

52.227-2 NOTICE AND ASSISTANCE REGARDING PATENT AND COPYRIGHT INFRINGEMENT (JUN 2020)

52.227-4 PATENT INDEMNITY--CONSTRUCTION CONTRACTS (DEC 2007)

52.228-2 ADDITIONAL BOND SECURITY (OCT 1997)

52.228-5 INSURANCE--WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

52.228-11 INDIVIDUAL SURETY—PLEDGE OF ASSETS (FEB 2021) (DEVIATION 2020-O0016)

52.228-12 PROSPECTIVE SUBCONTRACTOR REQUESTS FOR BONDS (DEC 2022)

52.228-14 IRREVOCABLE LETTER OF CREDIT (NOV 2014)

52.228-15 PERFORMANCE AND PAYMENT BONDS-CONSTRUCTION (JUN 2020) (DEVIATION 2020-O0016)

52.229-3 FEDERAL, STATE, AND LOCAL TAXES (FEB 2013)

52.232-5 PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS (MAY 2014)

52.232-17 INTEREST (MAY 2014)

52.232-23 ASSIGNMENT OF CLAIMS (MAY 2-14) - ALTERNATE I (APR 1984)

52.232-27 PROMPT PAYMENT FOR CONSTRUCTION CONTRACTS (JAN 2017)

52.232-33 PAYMENT BY ELECTRONIC FUNDS TRANSFER—SYSTEM FOR AWARD MANAGEMENT (OCT 2018) .. 148

52.232-39 UNENFORCEABILITY OF UNAUTHORIZED OBLIGATIONS (JUN 2013)

52.232-40 PROVIDING ACCELERATED PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (MAR 2023)

52.233-1 DISPUTES. (MAY 2014)

52.233-3 PROTEST AFTER AWARD (AUG. 1996)

52.233-4 APPLICABLE LAW FOR BREACH OF CONTRACT CLAIM (OCT 2004)

52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

52.236-2 DIFFERING SITE CONDITIONS (APR 1984)

52.236-3 SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (APR 1984)

52.236-4 PHYSICAL DATA (APR 1984)

52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

52.236-6 SUPERINTENDENCE BY THE CONTRACTOR (APR 1984)

52.236-7 PERMITS AND RESPONSIBILITIES (NOV 1991)

52.236-8 OTHER CONTRACTS (APR 1984)

52.236-9 PROTECTION OF EXISTING VEGETATION, STRUCTURES, EQUIPMENT, UTILITIES, AND IMPROVEMENTS

(APR 1984)

52.236-10 OPERATIONS AND STORAGE AREAS (APR 1984)

52.236-11 USE AND POSSESSION PRIOR TO COMPLETION (APR 1984)

52.236-12 CLEANING UP (APR 1984)

52.236-13 ACCIDENT PREVENTION (NOV 1991) – ALTERNATE I (NOV 1991)

52.236-15 SCHEDULES FOR CONSTRUCTION CONTRACTS (APR 1984)

52.236-16 QUANTITY SURVEYS (APR 1984) - ALTERNATE I (APR 1984)

52.236-17 LAYOUT OF WORK (APR 1984)

52.236-21 SPECIFICATIONS AND DRAWINGS FOR CONSTRUCTION (FEB 1997) - ALTERNATE I (APR 1984

52.236-26 PRECONSTRUCTION CONFERENCE (FEB 1995)

52.242-5 PAYMENTS TO SMALL BUSINESS SUBCONTRACTORS (JAN 2017)

52.242-13 BANKRUPTCY (JUL 1995)

52.242-14 SUSPENSION OF WORK (APR 1984)

52.243-4 CHANGES (JUN 2007)

52.244-6 SUBCONTRACTS FOR COMMERCIAL PRODUCTS AND COMMERCIAL SERVICES (DEC 2023)

52.246-12 INSPECTION OF CONSTRUCTION (AUG 1996)

52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

52.248-3 VALUE ENGINEERING--CONSTRUCTION (OCT 2020)

52.249-2 TERMINATION FOR CONVENIENCE OF THE GOVERNMENT (FIXED-PRICE) (APR 2012) - ALTERNATE I

(SEP 1996)

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

52.252-6 AUTHORIZED DEVIATIONS IN CLAUSES (NOV 2020)

52.253-1 COMPUTER GENERATED FORMS (JAN 1991)

252.201-7000 CONTRACTING OFFICER'S REPRESENTATIVE (DEC 1991)

252.203-7000 REQUIREMENTS RELATING TO COMPENSATION OF FORMER DOD OFFICIALS (SEP 2011) 252.203-7001 PROHIBITION ON PERSONS CONVICTED OF FRAUD OR OTHER DEFENSE-CONTRACT-RELATED

FELONIES (JAN 2023)

252.203-7002 REQUIREMENT TO INFORM EMPLOYEES OF WHISTLEBLOWER RIGHTS (DEC 2022)

252.203-7003 AGENCY OFFICE OF THE INSPECTOR GENERAL (AUG 2019)

252.203-7004 DISPLAY OF HOTLINE POSTERS (JAN 2023)

252.204-7003 CONTROL OF GOVERNMENT PERSONNEL WORK PRODUCT (APR 1992)

252.204-7012 SAFEGUARDING COVERED DEFENSE INFORMATION AND CYBER INCIDENT REPORTING (JAN 2023) 252.204-7015 NOTICE OF AUTHORIZED DISCLOSURE OF INFORMATION FOR LITIGATION SUPPORT (JAN 2023) . 181 252.204-7018 PROHIBITION ON THE ACQUISITION OF COVERED DEFENSE TELECOMMUNICATIONS EQUIPMENT

OR SERVICES (JAN 2023)

252.205-7000 PROVISION OF INFORMATION TO COOPERATIVE AGREEMENT HOLDERS (JUN 2023) 252.209-7004 SUBCONTRACTING WITH FIRMS THAT ARE OWNED OR CONTROLLED BY THE GOVERNMENT OF A

COUNTRY THAT IS A STATE SPONSOR OF TERRORISM (MAY 2019)

252.219-7003 SMALL BUSINESS SUBCONTRACTING PLAN (DOD CONTRACTS) (DEC 2019)

252.223-7004 DRUG-FREE WORK FORCE (SEP 1988)

252.223-7008 PROHIBITION OF HEXAVALENT CHROMIUM (JAN 2023)

252.225-7012 PREFERENCE FOR CERTAIN DOMESTIC COMMODITIES (APR 2022)

252.225-7048 EXPORT-CONTROLLED ITEMS (JUNE 2013)

252.225-7052 RESTRICTION ON THE ACQUISITION OF CERTAIN MAGNETS, TANTALUM, AND TUNGSTEN (JAN

2023) 252.225-7056 PROHIBITION REGARDING BUSINESS OPERATIONS WITH THE MADURO REGIME (JAN 2023) 252.225-7058 POSTAWARD DISCLOSURE OF EMPLOYMENT OF INDIVIDUALS WHO WORK IN THE PEOPLE'S

REPUBLIC OF CHINA (JAN 2023)

252.225-7060 PROHIBITION ON CERTAIN PROCUREMENTS FROM THE XINJIANG UYGHUR AUTONOMOUS

REGION (JUN 2023)

252.227-7033 RIGHTS IN SHOP DRAWINGS (APR 1966)

252.232-7003 ELECTRONIC SUBMISSION OF PAYMENT REQUESTS AND RECEIVING REPORTS (DEC 2018)

252.232-7010 LEVIES ON CONTRACT PAYMENTS (DEC 2006)

252.236-7000 MODIFICATION PROPOSALS - PRICE BREAKDOWN. (DEC 1991)

252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

252.242-7006 ACCOUNTING SYSTEM ADMINISTRATION (FEB 2012)

252.243-7001 PRICING OF CONTRACT MODIFICATIONS (DEC 1991)

252.243-7002 REQUESTS FOR EQUITABLE ADJUSTMENT (DEC 2022)

252.244-7000 SUBCONTRACTS FOR COMMERCIAL PRODUCTS OR COMMERCIAL SERVICES (NOV 2023)

252.247-7023 TRANSPORTATION OF SUPPLIES BY SEA (JAN 2023)

5152.211-9001 VARIATIONS IN ESTIMATED QUANTITIES — SUBLINE ITEMS (DEC 2019)

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

CONTRACTOR SUPPLY AND USE OF ELECTRONIC SOFTWARE FOR PROCESSING DAVIS-BACON ACT CERTIFIED

PAYROLLS

AT/OPSEC SECURITY REQUIREMENTS

PARTNERING

TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

ALL OR NONE QUALIFICATIONS

APPARENT CLERICAL MISTAKES

WORK PERFORMED BY THE CONTRACTOR

DAVIS-BACON WAGE DETERMINATION - CONFLICTING SCHEDULES – CLAY COUNTY AND WILKIN COUNTY

INSURANCE

EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE

INVOICE PROCEDURES

UNAVAILABILITY OF UTILITY SERVICES

SAFETY AND HEALTH REQUIREMENTS MANUAL INTERIM CHANGES, EM 385-1-1

BASIS FOR SETTLEMENT OF PROPOSALS

VETERANS EMPLOYMENT EMPHASIS FOR U.S. ARMY CORPS OF ENGINEERS CONTRACTS

DBA WD MN20240041

DBA WD MN20240053

Fargo-Moorhead Area Diversion FMM Southern Embankment Reach SE-4 Clay County, MN BID SCHEDULE

Solicitation No. W912ES23B0015

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 Performance and Payment Bonds 1 JOB $ $

0002 Demolition 1 JOB $ $

0003 Temporary Traffic Control 1 JOB $ $

0004 Temporary Erosion Control 1 JOB $ $

0005 Traffic Control Signs 1 JOB $ $

0006 Clearing and Grubbing 1 JOB $ $

0007 Removal of Road Surfacing 2,265 CY $ $

0008 Removal of Road Surfacing ‐ 180th Ave S

168 CY $ $

0009 Stripping 1 JOB $ $

0010 Inspection Trench 29,919 LF $ $

0011 Inspection Trench ‐ 180th Ave S 307 LF $ $

0012 Excavation

0012AA First 20,000 Cubic Yards 20,000 CY $ $

0012AB Over 20,000 Cubic Yards 8,772 CY $ $

0013 Excavation ‐ 180th Ave S 2,538 CY $ $

0014 Embankment

0014AA First 1,250,000 Cubic Yards 1,250,000 CY $ $

0014AB Over 1,250,000 Cubic Yards 90,702 CY $ $

0015 Embankment ‐ 180th Ave S 4,005 CY $ $

0016 Embankment ‐ Stockpiles 17,000 CY $ $

Reach SE-4 Clay County, MN BID SCHEDULE (continued)

Solicitation No. W912ES23B0015

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0017 Aggregate Surface 56,013 TN $ $

0018 Aggregate Surface ‐ 180th Ave S 3,050 TN $ $

0019 Aggregate Base 2,377 TN $ $

0020 Aggregate Base ‐ 180th Ave S 177 TN $ $

0021 Hot-Mix Asphalt 5,940 SY $ $

0022 Hot-Mix Asphalt ‐ 180th Ave S 429 SY $ $

0023 Pavement Marking 5,540 LF $ $

0024 Topsoil Respread 1 JOB $ $

0025 Topsoil - Stockpile 13,000 CY $ $

0026 Turf Reinforcement Mat (TRM) 215,860 SY $ $

0027 Turf Reinforcement Mat (TRM) ‐ 180th Ave S

432 SY $ $

0028 18-Inch Corrugated Steel Pipe 54 LF $ $

0029 18-Inch Corrugated Steel Pipe Flared End

2 EA $ $

0030 24-Inch Corrugated Steel Pipe 368 LF $ $

0031 24-Inch Corrugated Steel Pipe Flared End

14 EA $ $

0032 30-Inch Corrugated Steel Pipe 200 LF $ $

0033 30-Inch Corrugated Steel Pipe Flared End

4 EA $ $

0034 48-Inch Corrugated Steel Pipe 612 LF $ $

0035 48-Inch Corrugated Steel Pipe Flared End

12 EA $ $

Reach SE-4 Clay County, MN BID SCHEDULE (continued)

Solicitation No. W912ES23B0015

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0036 60-Inch Corrugated Steel Pipe 1,162 LF $ $

0037 60-Inch Corrugated Steel Pipe Flared End

16 EA $ $

0038 64-Inch by 43-Inch Corrugated Steel Arch Pipe

320 LF $ $

0039 64-Inch by 43-Inch Corrugated Steel Arch Pipe ‐ 180th Ave S

118 LF $ $

0040 64-Inch by 43-Inch Corrugated Steel Arch Pipe Flared End

4 EA $ $

0041 64-Inch by 43-Inch Corrugated Steel Arch Pipe Flared End ‐ 180th Ave S

6 EA $ $

0042 Bedding - B1 650 TN $ $

0043 Bedding - B2 1,342 TN $ $

0044 Riprap - R20 855 TN $ $

0045 Riprap - R45 307 TN $ $

0046 Riprap - R80 668 TN $ $

0047 Riprap - R140 1,407 TN $ $

0048 Access Gates 8 EA $ $

0049 Access Gates ‐ 180th Ave S 1 EA $ $

0050 Seeding 490 AC $ $

0051 Seeding ‐ 180th Ave S 16 AC $ $

0052 Temporary Irrigation System 1 JOB $ $

Reach SE-4 Clay County, MN BID SCHEDULE (continued)

Solicitation No. W912ES23B0015

ITEM NO. SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0053 Watering 1 JOB $ $

0054 Monthly Internet Service 26 MO $ $

AC = ACRE CY = CUBIC YARD EA = EACH

LF = LINEAR FOOT MO = MONTH SY = SQUARE YARD

TN = TON

ENSURE UNIT PRICES AND AMOUNT LINES FOR ALL ITEMS ARE COMPLETED.

TOTAL OF AMOUNTS

(ITEM NOS. 0001 THROUGH 0054, INCL.)

Section 00 21 13 - Instructions to Bidders

BID SUBMISSION INSTRUCTIONS

1. SAM REGISTRATION. All bidders must register and complete online representations and certifications in the System for Award Management (SAM) at https://sam.gov/content/entity-landing prior to the bid opening. Bidders that have not registered or completed their online representations and certifications may be rejected. Bidders are advised that the initial registration in SAM may take several weeks. The Government will review completed representations and certifications in SAM following the bid opening. Submission of paper copies of completed Representations and Certifications is NOT required with bid submissions.

2. RESPONSIBILITY DETERMINATION. In accordance with Federal Acquisition Regulation (FAR) Subpart 9.1, the apparent low bidder will be requested to provide the following information:

A detailed description of the work to be self-performed and resources available to demonstrate the firm is capable of complying with 52.219-14, Limitations on Subcontracting.

Financial Statements, including balance sheets that identify major categories of assets, liabilities, and owner’s equity; and profit and loss statements for the past three (3) years.

A Bank Certification of Financial Capability (line of credit).

Bidder qualification information, as referenced in Section 00 73 00 – Supplementary Conditions, must be received by the Contracting Officer within two (2) business days after the bid opening. This information will be treated as confidential commercial or financial information to the extent permitted by law under exemption 4 to the Freedom of Information Act, 5 U.S.C. § 552(b)(4). The financial statements should be not over 60 days old. If over 60 days old, a certification should be attached stating that the financial condition of the firm is substantially the same or, if not the same, the changes that have taken place.

3. SMALL BUSINESS SUBCONTRACTING PLAN. In accordance with FAR 52.219-9 SMALL BUSINESS SUBCONTRACTING PLAN (SEP 2023)--ALTERNATE I (NOV 2016), the apparent low bidder will be required to submit a Small Business Subcontracting Plan prior to contract award. This does not apply to bidders who are considered small business concerns. For informational purposes, there are five government-wide statutory small business contracting goals set by Congress:

Type of Firm Goal Measure of Contract Awards Small Business 23% Dollar value of prime contract awards Small Disadvantaged Business 5% Dollar value of prime and subcontract awards Woman-Owned Small Business 5% Dollar value of prime and subcontract awards Service-Disabled, Veteran-Owned Small Business (SDVOSB) 5% Dollar value of prime and subcontract awards HUBZone Small Business 3% Dollar value of prime and subcontract awards

4. BIDDER INQUIRIES. Any prospective bidder desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must submit their questions using the ProjNet system at https://www.projnet.org.

Provision 52.214-6 requires that all inquiries be submitted in writing. To submit a new inquiry or to view inquiries submitted by other prospective bidders, users must be registered and signed into the ProjNet system. Bidders may register online at https://www.projnet.org (click on “Register”).

The following information will be needed to submit or view bidder inquiries:

Managing Agency: USACE https://sam.gov/content/entity-landing https://www.projnet.org/ https://www.projnet.org/

Solicitation Number: W912ES23B0015

Bidder Inquiry Key: UT5H98-2GEICA

Bidders shall submit inquiries not later than 10 days prior to bid opening in order to ensure adequate time is allotted to form an appropriate response and amend the solicitation if necessary. Those who submit an inquiry will receive a system-generated email acknowledgement. All answers to inquiries will be posted in ProjNet after they have been reviewed by the USACE technical team. Bidders are advised to review the solicitation in its entirety and to review all previously submitted questions and responses prior to submitting a new inquiry.

5. IFB EXPENSES AND PRE-CONTRACT COSTS. This IFB does not commit the Government to pay any costs incurred in the preparation and submission of materials or for any other costs incurred by any firm submitting materials in response to this solicitation. Finally, the Government will not pay for or subsidize any costs incurred for attendance at the site visit.

6. Any forthcoming amendments will be available on this website: https://sam.gov/content/opportunities. It is recommended that each registered firm check this website periodically for updates.

7. All Quantities are estimated except where unit is given as “EA” (each) or “JOB” (job).

8. FACSIMILE BIDS AND MODIFICATIONS WILL NOT BE ACCEPTED.

9. Bidders are directed to FAR Clause 52.211-10, COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) - ALTERNATE I (APR 1984) for completion date requirements.

10. BID BONDS: In accordance with FAR 52.228-1, all bidders must provide a properly executed bid bond with their submitted bid. Bid bonds must be executed on the current version of Standard Form (SF) 24, which can be located at https://www.gsa.gov/reference/forms/bid-bond. All signatures must be either original “wet”, or a digital signature which allows for authentication. Photocopied signatures will not be accepted.

BID SUBMISSION & BID OPENING

1. BID SUBMISSION (HAND-CARRIED OR MAIL – authorized transmission methods)

The sealed, hand-carried or mailed, bid envelope containing the bid package must be annotated on the outside of the envelope as follows:

Bidders Name Bidders Address Solicitation Number: W912ES23B0015, FMM Southern Embankment Reach SE-4 Bid Receipt Date: May 2, 2024 (or as amended) Bid Receipt Time: 2:00pm Central

HAND-CARRIED BIDS:

Public access to USACE St. Paul District Headquarters, 332 Minnesota Street, Suite E1500, St. Paul, MN 55101 is through the East tower elevators. Persons delivering hand-carried bids shall go to the Security desk on the 15th floor, between the hours of 8:00am and 3:30pm on the days prior to the bid opening date, and between 8:00am and 2:00pm on the bid opening date. Someone from the Security Desk will contact a member of Contracting, who will meet you there and accept the bid. Bids shall only be accepted by a member of the Contracting office.

MAILED BIDS: Bids may be mailed to ensure receipt by USACE before the sealed bid due date and time at the following mail address:

https://sam.gov/content/opportunities https://www.gsa.gov/reference/forms/bid-bond

Contracting Division Attn: Ken Eshom (IFB No: W912ES23B0015)

USACE - ST. PAUL

332 Minnesota Street Suite E1500 Saint Paul, MN 55101-1678

Sealed bids received at the designated location after the required due date and time may be rejected. See Federal Acquisition Regulation Part 14.304.

2. BID OPENING

Bid opening will be conducted both in-person, and by telephone. To attend the bid opening, persons will need to check in at the security desk on the 15th floor. It is requested that you show up no later than 10 minutes before the bid opening in order to be signed in and be at the bid opening when it begins. To participate by telephone, use the call-in information below.

Join by phone

+1-669-234-1177 US Toll +1-844-800-2712 US Toll Free Meeting number (access code): 2760 180 2412 Meeting password: WVbNjmZ@525

USACE Contracting will be on the line starting at 1:50pm to take attendance prior to bid opening.

52.204-16 COMMERCIAL AND GOVERNMENT ENTITY CODE REPORTING (AUG 2020)

(a) Definition. As used in this provision--

Commercial and Government Entity (CAGE) code means—

(1) An identifier assigned to entities located in the United States or its outlying areas by the Defense Logistics Agency (DLA) Commercial and Government Entity (CAGE) Branch to identify a commercial or government entity by unique location; or

(2) An identifier assigned by a member of the North Atlantic Treaty Organization (NATO) or by the NATO Support and Procurement Agency (NSPA) to entities located outside the United States and its outlying areas that the DLA Commercial and Government Entity (CAGE) Branch records and maintains in the CAGE master file. This type of code is known as a NATO CAGE (NCAGE) code.

(b) The Offeror shall provide its CAGE code with its offer with its name and location address or otherwise include it prominently in its proposal. The CAGE code must be for that name and location address. Insert the word "CAGE" before the number. The CAGE code is required prior to award.

(c) CAGE codes may be obtained via--

(1) Registration in the System for Award Management (SAM) at www.sam.gov. If the Offeror is located in the United States or its outlying areas and does not already have a CAGE code assigned, the DLA Commercial and Government Entity (CAGE) Branch will assign a CAGE code as a part of the SAM registration process. SAM registrants located outside the United States and its outlying areas shall obtain a NCAGE code prior to registration in SAM (see paragraph (c)(3) of this provision).

(2) The DLA Commercial and Government Entity (CAGE) Branch. If registration in SAM is not required for the subject procurement, and the Offeror does not otherwise register in SAM, an Offeror located in the United States or its outlying areas may request that a CAGE code be assigned by submitting a request at https://cage.dla.mil.

(3) The appropriate country codification bureau. Entities located outside the United States and its outlying areas may obtain an NCAGE code by contacting the Codification Bureau in the foreign entity's country if that country is a member of NATO or a sponsored nation. NCAGE codes may be obtained from the NSPA at https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx if the foreign entity's country is not a member of NATO or a sponsored nation. Points of contact for codification bureaus, as well as additional information on obtaining NCAGE codes, are available at http://www.nato.int/structur/AC/135/main/links/contacts.htm.

(d) Additional guidance for establishing and maintaining CAGE codes is available at https://cage.dla.mil.

(e) When a CAGE code is required for the immediate owner and/or the highest-level owner by Federal Acquisition Regulation (FAR) 52.204-17 or 52.212-3(p), the Offeror shall obtain the respective CAGE code from that entity to supply the CAGE code to the Government.

(f) Do not delay submission of the offer pending receipt of a CAGE code.

(g) If the solicitation includes FAR clause 52.204-2, Security Requirements, a subcontractor requiring access to classified information under a contract shall be identified with a CAGE code on the DD Form 254. The Contractor shall require a subcontractor requiring access to classified information to provide its CAGE code with its name and location address or otherwise include it prominently in the proposal. Each location of subcontractor performance listed on the DD Form 254 is required to reflect a corresponding unique CAGE code for each listed location unless the work is being performed at a Government facility, in which case the agency location code shall be used. The CAGE code must be for that name and location address. Insert the word "CAGE" before the number. The CAGE code is required prior to award.

http://www.sam.gov/ https://cage.dla.mil/ https://eportal.nspa.nato.int/AC135Public/scage/CageList.aspx http://www.nato.int/structur/AC/135/main/links/contacts.htm https://cage.dla.mil/

(End of Provision)

52.204-22 ALTERNATIVE LINE ITEM PROPOSAL (JAN 2017)

(a) The Government recognizes that the line items established in this solicitation may not conform to the Offeror's practices. Failure to correct these issues can result in difficulties in acceptance of deliverables and processing payments. Therefore, the Offeror is invited to propose alternative line items for which bids, proposals, or quotes are requested in this solicitation to ensure that the resulting contract is economically and administratively advantageous to the Government and the Offeror.

(b) The Offeror may submit one or more additional proposals with alternative line items, provided that alternative line items are consistent with subpart 4.10 of the Federal Acquisition Regulation. However, acceptance of an alternative proposal is a unilateral decision made solely at the discretion of the Government. Offers that do not comply with the line items specified in this solicitation may be determined to be nonresponsive or unacceptable.

(End of provision)

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (OCT 2018)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management, which can be accessed via https://www.sam.gov (see 52.204-7).

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS (DEC 2016)

(a) If this solicitation is amended, then all terms and conditions which are not modified remain unchanged.

(b) (1) Bidders shall acknowledge receipt of any amendment to this solicitation--

(i) By signing and returning the amendment;

(ii) By identifying the amendment number and date in space provided for this purpose on the form for submitting a bid;

(iii) By letter;

(iv) By facsimile, if facsimile bids are authorized in the solicitation; or

(v) By email, if email bids are authorized in the solicitation.

(2) The Government must receive the acknowledgement by the time and at the place specified for receipt of bids.

52.214-4 FALSE STATEMENTS IN BIDS (APR 1984)

Bidders must provide full, accurate, and complete information as required by this solicitation and its attachments.

The penalty for making false statements in bids is prescribed in 18 U.S.C. 1001.

https://www.sam.gov/

52.214-5 SUBMISSION OF BIDS (DEC 2016)

(a) Bids and bid modifications shall be submitted in sealed envelopes or packages (unless submitted by electronic means) (1) addressed to the office specified in the solicitation, and (2) showing the time and date specified for receipt, the solicitation number, and the name and address of the bidder.

(b) Bidders using commercial carrier services shall ensure that the bid is addressed and marked on the outermost envelope or wrapper as prescribed in subparagraphs (a)(1) and (2) of this provision when delivered to the office specified in the solicitation.

(c) Facsimile bids, modifications, or withdrawals, will not be considered unless authorized by the solicitation.

(d) Bids submitted by electronic commerce shall be considered only if the electronic commerce method was specifically stipulated or permitted by the solicitation.

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS (APR 1984)

Any prospective bidder desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request it in writing soon enough to allow a reply to reach all prospective bidders before the submission of their bids. Oral explanations or instructions given before the award of a contract will not be binding. Any information given a prospective bidder concerning a solicitation will be furnished promptly to all other prospective bidders as an amendment to the solicitation, if that information is necessary in submitting bids or if the lack of it would be prejudicial to other prospective bidders.

52.214-7 LATE SUBMISSIONS, MODIFICATIONS, AND WITHDRAWALS OF BIDS (NOV

1999)

(a) Bidders are responsible for submitting bids, and any modifications or withdrawals, so as to reach the Government office designated in the invitation for bids (IFB) by the time specified in the IFB. If no time is specified in the IFB, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that bids are due.

(b)(1) Any bid, modification, or withdrawal received at the Government office designated in the IFB after the exact time specified for receipt of bids is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late bid would not unduly delay the acquisition; and--

(i) If it was transmitted through an electronic commerce method authorized by the IFB, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of bids; or

(ii) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of bids and was under the Government's control prior to the time set for receipt of bids.

(2) However, a late modification of an otherwise successful bid that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(c) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the bid wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(d) If an emergency or unanticipated event interrupts normal Government processes so that bids cannot be received at the Government office designated for receipt of bids by the exact time specified in the IFB and urgent Government requirements preclude amendment of the IFB, the time specified for receipt of bids will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(e) Bids may be withdrawn by written notice received at any time before the exact time set for receipt of bids. If the IFB authorizes facsimile bids, bids may be withdrawn via facsimile received at any time before the exact time set for receipt of bids, subject to the conditions specified in the provision at 52.214-31, Facsimile Bids. A bid may be withdrawn in person by a bidder or its authorized representative if, before the exact time set for receipt of bids, the identity of the person requesting withdrawal is established and the person signs a receipt for the bid.

52.214-18 PREPARATION OF BIDS--CONSTRUCTION (APR 1984)

(a) Bids must be (1) submitted on the forms furnished by the Government or on copies of those forms, and (2) manually signed. The person signing a bid must initial each erasure or change appearing on any bid form.

(b) The bid form may require bidders to submit bid prices for one or more items on various bases, including--

(1) Lump sum bidding;

(2) Alternate prices;

(3) Units of construction; or

(4) Any combination of subparagraphs (1) through (3) above.

(c) If the solicitation requires bidding on all items, failure to do so will disqualify the bid. If bidding on all items is not required, bidders should insert the words "no bid" in the space provided for any item on which no price is submitted.

(d) Alternate bids will not be considered unless this solicitation authorizes their submission.

52.214-19 CONTRACT AWARD--SEALED BIDDING--CONSTRUCTION (AUG 1996)

(a) The Government will evaluate bids in response to this solicitation without discussions and will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the Government, considering only price and the price-related factors specified elsewhere in the solicitation.

(b) The Government may reject any or all bids, and waive informalities or minor irregularities in bids received.

(c) The Government may accept any item or combination of items, unless doing so is precluded by a restrictive limitation in the solicitation or the bid.

(d) The Government may reject a bid as nonresponsive if the prices bid are materially unbalanced between line items or subline items. A bid is materially unbalanced when it is based on prices significantly less than cost for some work and prices which are significantly overstated in relation to cost for other work, and if there is a reasonable doubt that the bid will result in the lowest overall cost to the Government even though it may be the low evaluated bid, or if it is so unbalanced as to be tantamount to allowing an advance payment.

52.214-34 SUBMISSION OF OFFERS IN THE ENGLISH LANGUAGE (APR 1991)

Offers submitted in response to this solicitation shall be in the English language. Offers received in other than English shall be rejected.

52.214-35 SUBMISSION OF OFFERS IN U.S. CURRENCY (APR 1991)

Offers submitted in response to this solicitation shall be in terms of U.S. dollars. Offers received in other than U.S.

dollars shall be rejected.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK

(MAY 2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade

Goals for female participation for each trade

0.7% 6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Clay County, Minnesota.

52.222-33 NOTICE OF REQUIREMENT FOR PROJECT LABOR AGREEMENT (JAN 2024)

ALTERNATE I (JAN 2024)

(a) Definitions. As used in this provision, the following terms are defined in clause 52.222-34, Project Labor Agreement, of this solicitation “construction,” “labor organization,” “large-scale construction project,” and “project labor agreement.”

(b) The apparent successful offeror shall--

(1) Negotiate or become a party to a project labor agreement with…