A22 W912ES21Q0111 0001 Pokegama Log Pavilion.pdf

W81G6712428285

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this solicitation amendment is to answ er Vendor submitted questions.

All solicitation terms and conditions remain unchanged.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 13-Sep-2021

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912ES21Q0111

X 9B. DATED (SEE ITEM 11)

02-Sep-2021

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

13-Sep-2021

CODE

CONTRACTING DIVISION

USACE - ST PAUL

180 FIFTH STREET EAST

SUITE 700

SAINT PAUL MN 55101-1678

W912ES 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912ES21Q0111

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION SF 30 - BLOCK 14 CONTINUATION PAGE (SF 30)

The following have been added by full text:

VENDOR QUESTIONS AND ANSWERS

Question: Can you please confirm if the lumber required is rough-sawn Doug Fir?

Answer: The lumber is not required to be rough-sawn Douglas Fir.

Question: Will the government accept modification requests if the cost of materials increases from the date the proposal was submitted to the date the contract is awarded and approved to commence?

Answer: No, as stated in the solicitation, the resulting contract will be a firm, fixed-price contract.

Question: Is this contract bound to 52.219-14 Limitations on Subcontracting or any other subcontracting limitations?

Answer: If the resulting contract is above the simplified acquisition threshold, then FAR clause 52.219-14 would be applicable.

Question: Solicitation states that all work must be completed by June 1, 2022. Can you please confirm if the Government has an anticipated start date?

Answer: There is no firm start date; just a firm completion date.

Question: Does the Government have an anticipated award date and are funds appropriated for this solicitation contract?

Answer: Block 13 of the SF 1442 indicates that offers need to provide 30 calendar days for Government acceptance. This should indicate that the Government intends to award a contract within those 30 calendar days.

Question: What submittals or deliverables will the Government require upon award, before commencing deconstruction and construction?

Answer: Nothing that is not already mentioned in the solicitation.

Question: Will the contractor be granted time extensions in the event of weather delays?

W912ES21Q0111

Answer: No. With approximately 8 months between contract award and the completion date of June 1, 2022, the Government does not foresee any reason for a delay due to weather.

(End of Summary of Changes)