W912ES-16-T-0080-0003.pdf

W81G6760757793

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is to change the Small Business Set Aside to Unrestricted and extend the closing date to 16 September, 2016 at 3:00 pm.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 02-Sep-2016

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912ES-16-T-0080

X 9B. DATED (SEE ITEM 11)

13-Jul-2016

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

02-Sep-2016

CODE

CONTRACTING DIVISION

USACE - ST. PAUL

180 5TH STREET E SUITE 700

ST. PAUL MN 55101-1678

W912ES 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912ES-16-T-0080

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00010 - SOLICITATION CONTRACT FORM

The required response date/time has changed from 18-Aug-2016 10:00 AM to 16-Sep-2016 03:00 PM.

The required performance has changed from Roofing Lock and Dam 6: Project consists of the removal of the existing EPDM roofing systems on the Central Control Station building roofs at Lock and Dam 6 and the Comfort Station at Lock and Dam 5 and replacement with new EPDM roof system.Estimated price range for this requirement is between $25,000 to $100,000. The North American Industry Classification (NAICS) code is 238160, with a Small Buisness size standard of $15,000,000. This solicitation is issued as a request for quote (RFQ) with a 100% Small Business set aside. to Roofing Lock and Dam 6: Project consists of the removal of the existing EPDM roofing systems on the Central Control Station building roofs at Lock and Dam 6 and the Comfort Station at Lock and Dam 5 and replacement with new EPDM roof system.Estimated price range for this requirement is between $25,000 to $100,000. The North American Industry Classification (NAICS) code is 238160. This solicitation is issued as a request for quote (RFQ) and is issued Unrestricted. There will not be a bid opening as this is a RFQ.,.

DELIVERIES AND PERFORMANCE

The following Delivery Schedule item for CLIN 0002 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

30-JUN-2017 1 CONTRACTING DIVISION

GWENDOLYN K DAVIS

USACE - ST PAUL

180 5TH STREET EAST

SUITE 700

ST. PAUL MN 55101-1678

651-290-5723 FOB: Destination

W912ES

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS UIC

10 dys. ADC 1 CONTRACTING DIVISION

GWENDOLYN K DAVIS

USACE - ST PAUL

180 5TH STREET EAST

SUITE 700

ST. PAUL MN 55101-1678

651-290-5723 FOB: Destination

W912ES

SECTION 00700 - CONTRACT CLAUSES

The following have been modified:

W912ES-16-T-0080

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 30 June 2017. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 31 October 2016. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

(End of Summary of Changes)