W912EQ-21-B-0008 - SPECIFICATIONS.pdf

DD48 LEFT BANK SEEPAGE REMEDIATION SOLICITATION

PHASE 2 NOT FOR CONSTRUCTION

PROJECT TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

00 00 00.00 11 DEPARTMENT OF THE ARMY

00 10 00.00 11 INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

00 41 00.00 11 OFFEROR SCHEDULE

00 70 00.00 11 CONTRACT CLAUSE INSERTS

00 80 00.00 11 SPECIAL CONTRACT REQUIREMENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 11 00.00 11 SUMMARY OF WORK

01 22 00.00 11 MEASUREMENT AND PAYMENT

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.15 10 RESIDENT MANAGEMENT SYSTEM CONTRACTOR MODE(RMS CM)

01 45 04.00 11 CONTRACTOR QUALITY CONTROL

01 57 20.00 11 ENVIRONMENTAL PROTECTION

01 57 25.00 11 STORM WATER POLLUTION PREVENTION PLAN

01 58 01.00 11 PROJECT SIGN, BARRICADES, AND TRAFFIC CONTROL

01 78 00.00 11 CLOSEOUT SUBMITTALS

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION

DIVISION 31 - EARTHWORK

31 05 22 GEOTEXTILES USED AS FILTERS

31 11 00.00 11 CLEARING

31 14 13.24 11 PRECISION LAND LEVELING

31 23 00.00 12 EXCAVATION

31 24 00.00 12 EMBANKMENT

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 15 00.00 11 AGGREGATE SURFACE COURSE

32 92 32.01 11 ESTABLISHMENT OF TURF

DIVISION 33 - UTILITIES

33 40 00 STORM DRAINAGE UTILITIES

DIVISION 35 - WATERWAY AND MARINE CONSTRUCTION

35 31 19.00 11 STONE PROTECTION

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 1

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

DEPARTMENT OF THE ARMY

U.S. ARMY CORPS OF ENGINEERS

-- End of Section Table of Contents --

DOCUMENT 00 00 00.00 11 Page 1

DEPARTMENT OF THE ARMY

U.S. ARMY CORPS OF ENGINEERS

MEMPHIS DISTRICT

167 NORTH MAIN STREET

MEMPHIS, TN 38103-1894

PROJECT TITLE:

ST FRANCIS RIVER LEFT BANK SEEPAGE REMEDIATION, PHASE II DUNKLIN CO., MO

DRAINAGE DISTRICT 48

LOCATION:

DUNKLIN COUNTY, MISSOURI

CONSTRUCTION SOLICITATION AND SPECIFICATIONS:

THIS IS A SMALL BUSINESS SET-ASIDE

DATE: MAY 2021

DOCUMENT 00 00 00.00 11 Page 2

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 10 00.00 11

INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

02/05/16

PART 1 GENERAL

DOCUMENT 00 10 00.00 11 Page 1

SECTION 00 10 00.00 11

INSTRUCTIONS, CONDITIONS, AND NOTICES TO BIDDERS

02/05/16

PART 1 GENERAL

1 DRAWINGS/SPECIFICATIONS

There will be specifications and drawings 49 sheets in set.

2 PROGRAM DATA

AUTHORITY: The work provided for herein is authorized by the Flood Control Act approved 15 JUN 1936, as amended.

APPROPRIATION: 96X3112 - Flood Control, Mississippi River and Tributaries]

ALLOTMENT: St. Francis Basin - Construction

ESTIMATED VALUE: The estimated value of the proposed work is between $ 5,000,000 and $10,000,000.

3 SITE VISIT (CONSTRUCTION) (ALTERNATE I) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, bidders are urged and expected to inspect the site where the work will be performed.

(b) Two site visits will be scheduled. Perspective viewers must contact the Caruthersville Area Office at the number below for show dates, times and meeting place.

(c) Bidders desiring a site visit shall contact:

NAME: Mr. DAIMON MCNEW, Area Engineer ADDRESS: Caruthersville, MO Area Office 706 Harry S. Truman Boulevard Caruthersville, Missouri 63830-1268

TELEPHONE: (573) 333-1043

COLLECT TELEPHONE CALLS WILL NOT BE ACCEPTED.

-- End of Section --

DOCUMENT 00 10 00.00 11 Page 2

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

DOCUMENT 00 41 00.00 11

OFFEROR SCHEDULE

10/8/15

PART 1 OFFEROR SCHEDULE

1.1 LINE ITEMS

1.2 NOTES

DOCUMENT 00 41 00.00 11 Page 1

DOCUMENT 00 41 00.00 11

OFFEROR SCHEDULE

10/8/15

PART 1 OFFEROR SCHEDULE

Below Kennett (DD48) Seepage Remediation - Phase II, St. Francis Basin Construction, Dunklin County, Missouri

1.1 LINE ITEMS

This contract will be awarded as one lump sum with unit prices required for specifically selected work. A schedule of the unit price work is contained in Standard Form SF 1442, "Solicitation, Offer and Award." See Contract Clauses, "FAR 52.211-18, Variation in Estimated Quantity" and "FAR 52.236-16, Quantity Surveys-Alternate I," "DFARS 52.236-7008, Contract Prices."

Offer Items with Unit Prices Form Schedule A (BASE)

ITEM DESCRIPTION Estimated Unit Quantity Unit Price Amount

0001 Mobilization and Demobilization 1 JA XXX.XX $____.__

0002 Environmental Protection 1 JA XXX.XX $____.__

0003 Traffic Control and Signage 1 JA XXX.XX $____.__

0004 Demolition 1 JA XXX.XX $____.__

0005 Storm Water Pollution Prevention

0005AA Modify and Maintain SWPPP 1 JA XXX.XX $____.__

0005AB Erosion Control Berm 9,000 LF _______ $____.__

0005AC Silt Fence 1,200 LF _______ $____.__

0005AD Rock Check Dams 8 EA _______ $____.__

0005AE Temporary Environmental Seeding 86 AC _______ $____.__

0005AF Construction Exit 3 EA _______ $____.__

0006 Clearing & Grubbing 32 AC _______ $____.__

0007 Establishment of Turf 86 AC _______ $____.__

0008 Excavation 30,000 CY _______ $____.__

DOCUMENT 00 41 00.00 11 Page 2

ITEM DESCRIPTION Estimated Unit Quantity Unit Price Amount 0009 Embankment, Semi-compacted 166,500 CY _______ $____.__

0010 Stone Products

0010AA RipRap (R-200) 1,400 TN _______ $____.__

0010AB Coarse Aggregate, Size #1 1,300 TN _______ $____.__

0010AC Coarse Aggregate, Size #57 900 TN _______ $____.__

0010AD Aggregate Surface Course 150 TN _______ $____.__

0010AE Bedding Material 450 TN _______ $____.__

0011 Geotextile (Non-woven) 4,600 SY _______ $____.__

0012 Storm Drainage Pipe

0012AA 5ft x 4ft RCBC 73 LF _______ $____.__

0012AB 30in CMP 416 LF _______ $____.__

0012AC 60in CMP 60 LF _______ $____.__

0013 Precision Land Leveling

0013AA Field 1 6.8 AC _______ $____.__

0013AB Field 2 50.8 AC _______ $____.__

Grand Total Items 0001 thru 0013 $_______.__

Offer Items with Unit Prices Form Schedule B (OPTION)

ITEM DESCRIPTION Estimated Unit Quantity Unit Price Amount

0001 Mobilization and Demobilization 1 JA XXX.XX $____.__

0002 Environmental Protection 1 JA XXX.XX $____.__

0003 Traffic Control and Signage 1 JA XXX.XX $____.__

0004 Demolition 1 JA XXX.XX $____.__

0005 Storm Water Pollution Prevention

0005AA Modify and Maintain SWPPP 1 JA XXX.XX $____.__

0005AB Erosion Control Berm 1,100 LF _______ $____.__

DOCUMENT 00 41 00.00 11 Page 3

ITEM DESCRIPTION Estimated Unit Quantity Unit Price Amount

0005AE Temporary Environmental Seeding 2 AC _______ $____.__

0006 Clearing & Grubbing 2 AC _______ $____.__

0007 Establishment of Turf 2 AC _______ $____.__

0008 Embankment, Semi-compacted 3,500 CY _______ $____.__

Grand Total Items 0001 thru 0008 $_______.__

1.2 NOTES

NOTE 1: Offerors shall furnish unit prices for all items listed on the schedule of bid items, which require unit prices. If the offeror fails to insert a unit price in the appropriate blank for required items, but does furnish an extended total or an estimated amount for such items, the Government will deem their unit price to be the quotient obtained by dividing the extended estimated amount for that line item by the quantity.

IF THE OFFEROR OMITS BOTH THE UNIT PRICE AND THE EXTENDED ESTIMATED AMOUNT

FOR ANY ITEM, THEIR BID WILL BE DECLARED NONRESPONSIVE.

In the event there is a difference between a unit price and the extended total, the unit price will be held to be the intended offer. If the offeror shows only the total price but fails to enter a unit price, the total divided by the estimated quantity will be held to be the intended unit price.

Any offer price for items indicated above which are unbalanced as to price may be rejected as non-responsive. An unbalanced bid is one which is based on price significantly less than cost for some work and price which is significantly overstated for other work.

Award will be made as a whole to one bidder.

AC = Acre CF = Cubic Feet CY = Cubic Yard DH = Miles EA = Each FC = 1000 Cubic Feet FT = Foot HF = 100 Feet HH = 100 Cubic Feet HL = 100 Linear Feet HR = Hours HS = 100 Square Feet HY = 100 Yards LB = Pound LF = Linear Foot LH = Labor Hour JA = Job (lump sum) LY = Linear Yard MO = Months SB = Square Mile SF = Square Foot SQ = Square SY = Square Yard TL = 1000 Linear Feet TN = Net Ton UN = Unit YD = Yard YL = 100 Linear Yards YM = Cubic Yards Per Mile

All quantities are estimated except where unit is given as "JA" or "EA".

NOTE 2: If an offer or modification to a offer based on unit prices is submitted and provides for a lump sum adjustment to the total estimated cost, the application of the lump sum adjustment to each unit price, including lump sum units, in offeror schedule must be stated, or, if it is not stated, the offeror agrees that the lump sum adjustment shall be applied on a pro rata basis to every unit price in the offeror schedule.

DOCUMENT 00 41 00.00 11 Page 4

NOTE 3: Offerors are cautioned to read Contract Clause entitled "DFAR 252.204-7004, Alternate A, System for Award Management (FEB 2014) located in Section 00 70 00.00 11 CONTRACT CLAUSES.

-- End of Document --

DOCUMENT 00 41 00.00 11 Page 5

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 70 00.00 11

CONTRACT CLAUSE INSERTS

6/16

PART 1 GENERAL

1.1 SUBMITTALS

1.2 FAR 52.204-7 SYSTEM FOR AWARD MANAGEMENT (JUL 2013)

1.3 FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK

(APR 1984)

1.4 FAR 52.211-12 LIQUIDATED DAMAGES CONSTRUCTION (SEP 2000)

1.5 FAR 52.211-18 VARIATION IN ESTIMATED QUANTITIES (APR 1984)

1.6 FAR 52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN

1997)

1.7 FAR 52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

1.8 FAR 52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

1.9 FAR 52.236-4 PHYSICAL DATA (APR 1984)

1.10 FAR 52.236-21 SPECIFICATION AND DRAWING FOR CONSTRUCTION (FEB 1997)

1.11 FAR 52.236-16 QUANTITY SURVEYS-ALTERNATE I (APR 1984)

1.12 FAR 52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

1.13 FAR 52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION)(APR 1984)

1.14 UAI 52.249-5000 BASIS FOR SETTLEMENT OF PROPOSALS (MAR 2013)

1.15 DFARS 252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

1.16 DFARS 52.236-7004 PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (DEC

1991)

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

DOCUMENT 00 70 00.00 11 Page 1

SECTION 00 70 00.00 11

CONTRACT CLAUSE INSERTS

6/16

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-07 Certificates

Certificate or Written Evidence of Insurance; G

Field Notes and All Other Records Relating to the Survey; G

1.2 FAR 52.204-7 SYSTEM FOR AWARD MANAGEMENT (JUL 2013)

As prescribed in DFARS 204.1105 (FEB 2014), the following paragraph (a) from DFARS 252.204-7004 ALTERNATE A, SYSTEM FOR AWARD MANAGEMENT (FEB 2014) is substituted for paragraph (a) of the provision at FAR 52.204-7.

a. Definitions. As used in this provision-

"System for Award Management (SAM) database" means the primary Government repository for contractor information required for the conduct of business with the Government.

"Commercial and Government Entity (CAGE) code" means-

(1) A code assigned by the Defense Logistics Information Service (DLIS) to identify a commercial or Government entity; or

(2) A code assigned by a member of the North Atlantic Treaty Organization that DLIS records and maintains in the CAGE master file. This type of code is known as an "NCAGE code."

"Data Universal Numbering System (DUNS) number" means the 9-digit number assigned by Dun and Bradstreet, Inc. (D&B) to identify unique business entities.

"Data Universal Numbering System +4 (DUNS+4) number" means the DUNS number assigned by D&B plus a 4-character suffix that may be assigned by a business concern. (D&B has no affiliation with this 4-character suffix.)

This 4-character suffix may be assigned at the discretion of the business concern to establish additional SAM records for identifying alternative Electronic Funds Transfer (EFT) accounts (see FAR 32.11) for the same parent concern.

"Registered in the System for Award Management (SAM) database" means that-

DOCUMENT 00 70 00.00 11 Page 2

(1) The contractor has entered all mandatory information, including the DUNS number or the DUNS+4 number, and Contractor and Government Entity (CAGE) code into the SAM database; and

(2) The contractor has completed the Core Data, Assertions, Representations and Certifications, and Points of Contact sections of the registration in the SAM database;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The Contractor will be required to provide consent for TIN validation to the Government as part of the SAM registration process; and

(4) The Government has marked the record "Active."

b.(1) By submission of an offer, the offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database prior to award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation. (2) The offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation "DUNS" or "DUNS +4" followed by the DUNS or DUNS +4 number that identifies the offeror's name and address exactly as stated in the offer. The DUNS number will be used by the Contracting Officer to verify that the offeror is registered in the SAM database.

c. If the offeror does not have a DUNS number, it should contact Dun and Bradstreet directly to obtain one.

(1) An offeror may obtain a DUNS number-

(i) Via the Internet at webform or if the offeror does not have internet access, it may call Dun and Bradstreet at 1-866-705-5711 if located within the United States; or

(ii) If located outside the United States, by contacting the local Dun and Bradstreet office. The offeror should indicate that it is an offeror for a U.S. Government contract when contacting the local Dun and Bradstreet office.

(2) The offeror should be prepared to provide the following information:

(i) Company legal business.

(ii) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(iii) Company Physical Street Address, City, State, and ZIP Code.

(iv) Company Mailing Address, City, State and ZIP Code (if separate from physical).

(v) Company Telephone Number.

(vi) Date the company was started.

(vii) Number of employees at your location.

(viii) Chief executive officer/key manager.

(ix) Line of business (industry).

(x) Company Headquarters name and address (reporting relationship within your entity).

DOCUMENT 00 70 00.00 11 Page 3

d. If the Offeror does not become registered in the SAM database in the time prescribed by the Contracting Officer, the Contracting Officer will proceed to award to the next otherwise successful registered Offeror.

e. Processing time, which normally takes 48 hours, should be taken into consideration when registering. Offerors who are not registered should consider applying for registration immediately upon receipt of this solicitation.

f. Offerors may obtain information on registration at https://www.acquisition.gov .

1.3 FAR 52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR

1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 260 calendar days after the date of receipt by him of notice to proceed. The Option contract time extension is 31 days. The time stated for completion shall include final cleanup of the premises. (FAR 52.211 10)

1.4 FAR 52.211-12 LIQUIDATED DAMAGES CONSTRUCTION (SEP 2000)

a. If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of, $1,670.00 for each calendar day of delay until the work is completed or accepted.

b. If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed.

These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (FAR 52.211-12)

1.5 FAR 52.211-18 VARIATION IN ESTIMATED QUANTITIES (APR 1984)

If the quantity of a unit-priced item in this contract is an estimated quantity and the actual quantity of the unit-priced item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon the receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

1.6 FAR 52.228-5 INSURANCE - WORK ON A GOVERNMENT INSTALLATION (JAN 1997)

a. The Contractor shall, at its own expense, provide and maintain during the entire performance of this contract, at least the kinds and minimum amounts of insurance required in (d) below.

DOCUMENT 00 70 00.00 11 Page 4

b. Before commencing work under this contract, the Contractor shall notify the Contracting Officer in writing that the required insurance has been obtained. The policies evidencing required insurance shall contain an endorsement to the effect that any cancellation or any material change adversely affecting the Government's interest shall not be effective.

(1) For such period as the laws of the State in which this contract is to be performed prescribe; or

(2) Until 30 days after the insurer or the Contractor gives written notice to the Contracting Officer, whichever period is longer.

c. The Contractor shall insert the substance of this clause, including this paragraph (c), in subcontracts under this contract that require work on a Government installation and shall require subcontractors to provide and maintain the insurance required in the Schedule or elsewhere in the contract. The Contractor shall maintain a copy of all subcontractors' proofs of required insurance, and shall make copies available to the Contracting Officer upon request. (FAR 52.228-5)

d. The Contractor shall furnish to the Contracting Officer a Certificate or Written Evidence of Insurance. The following is the minimum amount of insurance required:

Type Amount Workmen's Compensation and $100,000 or statutory Employer's Liability Insurance

Comprehensive:

General Liability $1,000,000 per occurrence Automobile Liability:

(1) Bodily Injury $200,000 per person $500,000 per occurrence

(2) Property Damage $50,000 per occurrence

1.7 FAR 52.236-1 PERFORMANCE OF WORK BY THE CONTRACTOR (APR 1984)

The Contractor shall perform on the site, and with its own organization, work equivalent to at least 15 percent of the total amount of work to be performed under the contract. This percentage may be reduced by a supplemental agreement to this contract if, during performance of the work, the Contractor requests a reduction and the Contracting Officer determines that the reduction would be to the advantage of the Government. (FAR

52.236 1)

1.8 FAR 52.236-5 MATERIAL AND WORKMANSHIP (APR 1984)

a. All equipment, material, and articles incorporated into the work covered by this contract shall be new and of the most suitable grade for the purpose intended, unless otherwise specifically provided in this contract. References in the specifications to equipment, material, articles, or patented processes by trade name, make, or catalog number, shall be regarded as establishing a standard of quality and shall not be construed as limiting competition. The Contractor may, at its option, use any equipment, material, article, or process that, in the judgment of the Contracting Officer, is equal to that named in the specifications, unless otherwise specifically provided in this contract.

DOCUMENT 00 70 00.00 11 Page 5

b. The Contractor shall obtain the Contracting Officer’s approval of the machinery and mechanical and other equipment to be incorporated into the work. When requesting approval, the Contractor shall furnish to the Contracting Officer the name of the manufacturer, the model number, and other information concerning the performance, capacity, nature, and rating of the machinery and mechanical and other equipment. When required by this contract or by the Contracting Officer, the Contractor shall also obtain the Contracting Officer’s approval of the material or articles which the Contractor contemplates incorporating into the work. When requesting approval, the Contractor shall provide full information concerning the material or articles. When directed to do so, the Contractor shall submit samples for approval at the Contractor’s expense, with all shipping charges prepaid. Machinery, equipment, material, and articles that do not have the required approval shall be installed or used at the risk of subsequent rejection.

c. All work under this contract shall be performed in a skillful and workmanlike manner. The Contracting Officer may require, in writing, that the Contractor remove from the work any employee the Contracting Officer deems incompetent, careless, or otherwise objectionable.

1.9 FAR 52.236-4 PHYSICAL DATA (APR 1984)

Data and information furnished or referred to below are for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

a. Physical Conditions. The indications of physical conditions on the drawings and in the specifications are the result of site investigations by aerial photographs and topographic surveys.

b. Weather Conditions. Information with respect to temperatures and precipitation may be obtained from the National Weather Service. Also see the Special Contract Requirements Paragraph entitled TIME EXTENSIONS FOR

UNUSUALLY SEVERE WEATHER.

c. Transportation Facilities. Access to the site is provided from Missouri Hwy. 84, county road 525, and county road 513.

d. Additional Data. Additional data consisting of records of borings, and boring samples may be available for inspection at the U.S. Army Corps of Engineers District office in Memphis, Tennessee. (FAR 52.236 4)

1.10 FAR 52.236-21 SPECIFICATION AND DRAWING FOR CONSTRUCTION (FEB 1997)

a. The Contractor shall keep on the work site a copy of the drawings and specifications and shall at all times give the Contracting Officer access thereto. Anything mentioned in the specifications and not shown on the drawings, or shown on the drawings and not mentioned in the specifications, shall be of like effect as if shown or mentioned in both. In case of difference between drawings and specifications, the specifications shall govern. In case of discrepancy in the figures, in the drawings, or in the specifications, the matter shall be promptly submitted to the Contracting Officer, who shall promptly make a determination in writing. Any adjustment by the Contractor without such a determination shall be at its own risk and expense. The Contracting Officer shall furnish from time to time such detailed drawings and other information as considered necessary, unless

DOCUMENT 00 70 00.00 11 Page 6 otherwise provided.

b. Wherever in the specifications or upon the drawings the words “directed,” “required,” “ordered,” “designated,” “prescribed,” or words of like import are used, it shall be understood that the “direction,” “requirement,” “order,” “designation,” or “prescription,” of the Contracting Officer is intended and similarly the words “approved,” “acceptable,” “satisfactory,” or words of like import shall mean “approved by,” or “acceptable to,” or “satisfactory to” the Contracting Officer, unless otherwise expressly stated.

c. Where “as shown,” “as indicated,” “as detailed,” or words of similar import are used, it shall be understood that the reference is made to the drawings accompanying this contract unless stated otherwise. The word “provided” as used herein shall be understood to mean “provide complete in place,” that is “furnished and installed.”

d. Shop drawings means drawings, submitted to the Government by the Contractor, subcontractor, or any lower tier subcontractor pursuant to a construction contract, showing in detail (1) the proposed fabrication and assembly of structural elements, and (2) the installation (i.e., fit, and attachment details) of materials or equipment. It includes drawings, diagrams, layouts, schematics, descriptive literature, illustrations, schedules, performance and test data, and similar materials furnished by the contractor to explain in detail specific portions of the work required by the contract. The Government may duplicate, use, and disclose in any manner and for any purpose shop drawings delivered under this contract.

e. If this contract requires shop drawings, the Contractor shall coordinate all such drawings, and review them for accuracy, completeness, and compliance with contract requirements and shall indicate its approval thereon as evidence of such coordination and review. Shop drawings submitted to the Contracting Officer without evidence of the Contractor’s approval may be returned for resubmission. The Contracting Officer will indicate an approval or disapproval of the shop drawings and if not approved as submitted shall indicate the Government’s reasons therefore.

Any work done before such approval shall be at the Contractor’s risk.

Approval by the Contracting Officer shall not relieve the Contractor from responsibility for any errors or omissions in such drawings, nor from responsibility for complying with the requirements of this contract, except with respect to variations described and approved in accordance with (f) of this clause.

f. If shop drawings show variations from the contract requirements, the Contractor shall describe such variations in writing, separate from the drawings, at the time of submission. If the Contracting Officer approves any such variation, the Contracting Officer shall issue an appropriate contract modification, except that, if the variation is minor or does not involve a change in price or in time of performance, a modification need not be issued.

g. The Contractor shall submit to the Contracting Officer for approval four copies (unless otherwise indicated) of all shop drawings as called for under the various headings of these specifications. Three sets (unless otherwise indicated) of all shop drawings, will be retained by the Contracting Officer and one set will be returned to the Contractor.

DOCUMENT 00 70 00.00 11 Page 7

1.11 FAR 52.236-16 QUANTITY SURVEYS-ALTERNATE I (APR 1984)

a. Quantity surveys shall be conducted, and the data derived from these surveys shall be used in computing the quantities of work performed and the actual construction completed and in place.

b. The Contractor shall conduct the original and final surveys for any periods for which progress payments are requested. All these surveys shall be conducted under the direction of a representative of the Contracting Officer, unless the Contracting Officer waives this requirement in a specific instance. The Government shall make such computations as are necessary to determine the quantities of work performed or finally in place. The Contractor shall make the computations based on the surveys for any periods for which progress payments are requested.

c. Promptly upon completing a survey, the Contractor shall furnish the originals of all Field Notes and All Other Records Relating to the Survey or to the layout of the work to the Contracting Officer, who shall use them as necessary to determine the amount of progress payments. The Contractor shall retain copies of all such material furnished to the Contracting Officer. (FAR 52.236 16)

1.12 FAR 52.246-21 WARRANTY OF CONSTRUCTION (MAR 1994)

a. In addition to any other warranties in this contract, the Contractor warrants, except as provided in paragraph i. of this clause, that work performed under this contract conforms to the contract requirements and is free of any defect in equipment, material, or design furnished, or workmanship performed by the Contractor or any subcontractor or supplier at any tier.

b. This warranty shall continue for a period of one year from the date of final acceptance of the work. If the Government takes possession of any part of the work before final acceptance, this warranty shall continue for a period of one year from the date the Government takes possession.

c. The Contractor shall remedy at the Contractor's expense any failure to conform, or any defect. In addition, the Contractor shall remedy at the Contractor's expense any damage to Government owned or controlled real or personal property, when that damage is the result of--

(1) The Contractor's failure to conform to contract requirements; or

(2) Any defect of equipment, material, workmanship, or design furnished.

d. The Contractor shall restore any work damaged in fulfilling the terms and conditions of this clause. The Contractor's warranty with respect to work repaired or replaced will run for one year from the date of repair or replacement.

e. The Contracting Officer shall notify the Contractor, in writing, within a reasonable time after the discovery of any failure, defect, or damage.

f. If the Contractor fails to remedy any failure, defect, or damage within a reasonable time after receipt of notice, the Government shall have the right to replace, repair, or otherwise remedy the failure, defect, or damage at the Contractor's expense.

DOCUMENT 00 70 00.00 11 Page 8

g. With respect to all warranties, expressed or implied, from subcontractors, manufacturers, or suppliers for work performed and materials furnished under this contract, the Contractor shall

(1) Obtain all warranties that would be given in normal commercial practice;

(2) Require all warranties to be executed, in writing, for the benefit of the Government, if directed by the Contracting Officer; and

(3) Enforce all warranties for the benefit of the Government, if directed by the Contracting Officer.

h. In the event the Contractor's warranty under paragraph (b) of this clause has expired, the Government may bring suit at its expense to enforce a subcontractor's, manufacturer's, or supplier's warranty.

i. Unless a defect is caused by the negligence of the Contractor or subcontractor or supplier at any tier, the Contractor shall not be liable for the repair of any defects of material or design furnished by the Government nor for the repair of any damage that results from any defect in Government furnished material or design.

j. This warranty shall not limit the Government's rights under the Inspection and Acceptance clause of this contract with respect to latent defects, gross mistakes, or fraud. (FAR 52.246-21)

1.13 FAR 52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION)(APR 1984)

a. If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government may, by written notice to the Contractor, terminate the right to proceed with the work (or the separable part of the work) that has been delayed. In this event, the Government may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Government resulting from the Contractor’s refusal or failure to complete the work within the specified time, whether or not the Contractor’s right to proceed with the work is terminated. This liability includes any increased costs incurred by the Government in completing the work.

b. The Contractor’s right to proceed shall not be terminated nor the Contractor charged with damages under this clause, if—

(1) The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include—

(i) Acts of God or of the public enemy,

(ii) Acts of the Government in either its sovereign or contractual capacity,

(iii) Acts of another Contractor in the performance of a contract with the Government,

(iv) Fires,

(v) Floods, DOCUMENT 00 70 00.00 11 Page 9

(vi) Epidemics,

(vii) Quarantine restrictions,

(viii) Strikes,

(ix) Freight embargoes,

(x) Unusually severe weather, or

(xi) Delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers; and

(2) The Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of delay. If, in the judgment of the Contracting Officer, the findings of fact warrant such action, the time for completing the work shall be extended. The findings of the Contracting Officer shall be final and conclusive on the parties, but subject to appeal under the Disputes clause.

c. If, after termination of the Contractor’s right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Government.

d. The rights and remedies of the Government in this clause are in addition to any other rights and remedies provided by law or under this contract.

1.14 UAI 52.249-5000 BASIS FOR SETTLEMENT OF PROPOSALS (MAR 2013)

Actual costs will be used to determine equipment costs for a settlement proposal submitted on the total cost basis under FAR 49.206-2(b). In evaluating a terminations settlement proposal using the total cost basis, the following principles will be applied to determine allowable equipment costs:

a. Actual costs for each piece of equipment, or groups of similar serial or series equipment, need not be available in the Contractor's accounting records to determine total actual equipment costs.

b. If equipment costs have been allocated to a contract using predetermined rates, those charges will be adjusted to actual costs.

c. Recorded job costs adjusted for unallowable expenses will be used to determine equipment operating expenses.

d. Ownership costs (depreciation) will be determined using the Contractor's depreciation schedule (subject to the provisions of FAR 31.205-11).

e. License, taxes, storage and insurance costs are normally recovered as an indirect expense and unless the Contractor charges these costs directly to contracts, they will be recovered through the indirect expense rate.

(EFARS 52.249-5000)

1.15 DFARS 252.236-7001 CONTRACT DRAWINGS AND SPECIFICATIONS (AUG 2000)

a. The Government will provide to the Contractor, without charge, one set

DOCUMENT 00 70 00.00 11 Page 10 of contract drawings and specifications, except publications incorporated into the technical provisions by reference, in electronic or paper media as chosen by the Contracting Officer.

b. The Contractor shall

(1) Check all drawings immediately upon receipt;

(2) Compare all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies;

(4) Be responsible for any errors that might have been avoided by complying with this paragraph b; and

(5) Reproduce and print contract drawings and specifications as needed

c. In general-

(1) Large-scale drawings shall govern small-scale drawings; and

(2) The Contractor shall follow figures marked on drawings in preference to scale measurements.

d. Omissions from the drawings or specifications or the misdescription of details of work that are manifestly necessary to carry out the intent of the drawings and specifications, or that are customarily performed, shall not relieve the Contractor from performing such omitted or misdescribed details of the work. The Contractor shall perform such work as if fully and correctly set forth and described in the drawings and specifications.

e. The work shall conform to the specifications and the contract drawings identified on the following index of drawings that appears below:

ST. FRANCIS RIVER LEFT BANK,

SEEPAGE REMEDIATION, PHASE II,

DUNKLIN COUNTY, MISSOURI

INDEX TO DRAWINGS

TITLE DRAWING NUMBER

COVER SHEET G-001

LEGEND, NOTES, ETC. G-002

BENCHMARK TABLE G-003

ALIGNMENT AND LAYOUT TABLES G-004

DITCH CENTERLINE ALIGNMENT TABLES G-005

OVERALL RELOCATION & DEMOLITION LAYOUT PLAN CD-100

RELOCATION & DEMOLITION PLAN CD-101

RELOCATION & DEMOLITION PLAN CD-102

RELOCATION & DEMOLITION PLAN CD-103

RELOCATION & DEMOLITION PLAN CD-104

BORING LEGEND B-001

BORING LOGS B-002

BORING LOGS B-003

BORING LOGS B-004

BORING LOGS B-005

CONSTRUCTION CONTRACT LIMIT LINE - OVERALL C-001

DOCUMENT 00 70 00.00 11 Page 11

CONSTRUCTION CONTRACT LIMIT LINE LAYOUT C-002

CONSTRUCTION CONTRACT LIMIT LINE LAYOUT C-003

CONSTRUCTION CONTRACT LIMIT DATA TABLE C-007

BORROW PIT PLAN C-010

OVERALL BERM LAYOUT C-100

BERM PLAN AND PROFILE C-101

BERM PLAN AND PROFILE C-102

BERM PLAN AND PROFILE C-103

BERM PLAN AND PROFILE C-104

DITCH 2 PLAN & PROFILE- PHASE II C-123A

DITCH 2 PLAN & PROFILE- PHASE II C-124A

DITCH 2 PLAN & PROFILE- PHASE II C-125A

DITCH 3 PLAN & PROFILE- PHASE II C-126A

DITCH 3 PLAN & PROFILE- PHASE II C-127A

DITCH 3 PLAN & PROFILE- PHASE II C-128A

RAMP 1 PLAN & PROFILE C-150

FIELD 1 - REGRADING C-160

FIELD 2 - REGRADING C-161

TYPICAL SECTION C-300

CROSS SECTIONS C-301

CROSS SECTIONS C-302

CROSS SECTIONS C-303

CROSS SECTIONS C-304

CROSS SECTIONS C-305

CROSS SECTIONS C-306

DETAILS C-500

DETAILS C-501

DETAILS C-502

DETAILS C-503

DETAILS C-504

MODOT DETAILS C-505

MODOT DETAILS C-506

ST. FRANCIS RIVER HYDROGRAPH X-100

1.16 DFARS 52.236-7004 PAYMENT FOR MOBILIZATION AND DEMOBILIZATION (DEC

1991)

a. The Government will pay all costs for the mobilization and demobilization of all of the Contractor's plant and equipment at the contract lump sum price for this item.

(1) Sixty percent of the lump sum price upon completion of the Contractor's mobilization at the work site.

(2) The remaining 40 percent upon completion of demobilization.

b. The Contracting Officer may require the Contractor to furnish cost data to justify this portion of the bid if the Contracting Officer believes that the percentages in paragraphs (a) (1) and (2) of this clause do not bear a reasonable relation to the cost of the work in this contract.

(1) Failure to justify such price to the satisfaction of the Contracting Officer will result in payment, as determined by the Contracting Officer, of

(i) Actual mobilization costs at completion of mobilization;

(ii) Actual demobilization costs at completion of demobilization;

and

DOCUMENT 00 70 00.00 11 Page 12

(iii) The remainder of this item in the final payment under this contract.

(2) The Contracting Officer's determination of the actual costs in paragraph b (1) of this clause is not subject to appeal. (DFARS 252.236-7004)

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

-- End of Section --

DOCUMENT 00 70 00.00 11 Page 13

SECTION TABLE OF CONTENTS

DIVISION 00 - PROCUREMENT AND CONTRACTING REQUIREMENTS

SECTION 00 80 00.00 11

SPECIAL CONTRACT REQUIREMENTS

03/16

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 EXCLUSION PERIODS IN COMPUTING COMPLETION SCHEDULES

1.4 EXCEPTION TO LIQUIDATED DAMAGES

1.5 RIGHTS-OF-WAY

1.6 LAYOUT OF WORK

1.7 PROGRESS CHART

1.8 SAFETY RELATED SPECIAL REQUIREMENTS

1.9 CERTIFICATES OF COMPLIANCE

1.10 CONTRACTOR'S CERTIFICATE

1.11 SHOP DRAWINGS

1.12 AS-BUILT DRAWINGS

1.13 DAMAGE TO WORK

1.14 NOTIFICATION OF AREA ENGINEER BEFORE BEGINNING WORK

1.15 RETESTING OF CONSTRUCTION MATERIALS

1.16 VEHICLE WEIGHT LIMITATIONS

1.17 OBSTRUCTIONS

1.18 NATIONAL POLLUTANT DISCHARGE ELIMINATION SYSTEM (NPDES)

1.19 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 1989)

1.20 STONE SOURCES

1.21 FIELD OFFICE BUILDING

1.22 HAUL ROADS

1.23 TEMPORARY PROJECT FENCING

1.24 MAINTENANCE OF TRAFFIC

1.25 COOPERATION WITH OTHERS

1.26 HOURS OF WORK

1.27 Sunday, HOLIDAY AND NIGHT WORK

1.28 SECURITY REQUIREMENTS

1.29 STORAGE OF EQUIPMENT AND MATERIALS

1.30 UTILITY SERVICES

1.31 COMMERCIAL WARRANTY

1.32 PAYMENT FOR MATERIAL STORED OFF-SITE

1.33 WORK IN QUARANTINED AREA

1.34 FLOOD EMERGENCY

1.35 PATENTS, PROPRIETARY RIGHTS

1.36 PROTECTION OF MATERIALS AND WORK

1.37 EXISTING FLOOD PROTECTION

1.38 FINAL ACCEPTANCE

1.39 INSPECTION

1.40 DESIGNATED BILLING OFFICE

PART 2 PRODUCTS (Not Used)

PART 3 EXECUTION (Not Used)

DOCUMENT 00 80 00.00 11 Page 1

DOCUMENT 00 80 00.00 11 Page 2

SECTION 00 80 00.00 11

SPECIAL CONTRACT REQUIREMENTS

03/16

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this section to the extent referenced:

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) SAFETY AND HEALTH REQUIREMENTS

MANUAL

ER 1110-1-5 PLANT PEST QUARANTINED AREAS AND FOREIGN

SOIL SAMPLES

ER 415-1-15 CONSTRUCTION TIME EXTENSIONS FOR WEATHER

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals; G

Activity Hazard Analysis; G

Accident Prevention Program; G

Hazard Communication Program; G

List of all Personnel, Vehicles and Equipment; G

SD-02 Shop Drawings

Shop Drawings

SD-03 Product Data

Material Safety Data Sheets of Each Substance

SD-05 Design Data

Pre-Construction Surveys; G, EC-D

Post-Construction Surveys; G, EC-D

SD-11 Closeout Submittals

DOCUMENT 00 80 00.00 11 Page 3

Final As-Built Drawings; G

Findings of the Accident Investigation

1.3 EXCLUSION PERIODS IN COMPUTING COMPLETION SCHEDULES

No work will be required during the period between 01 DEC and 31 MAY, inclusive. This period has not been considered in computing the time allowed for completion in accordance with the contract clause entitled "COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK". The Contractor may, however, perform work during all or any part of the non work period provided that he has received prior approval, in writing, from the Contracting Officer. In the event that the Contractor's operations are suspended at the beginning of or during this period, the Contracting Officer reserves the right to direct the Contractor to restore the work area to at least the level of flood protection existing prior to the Contractor's operations in the area, in accordance with the procedures of the paragraphs entitled FLOOD EMERGENCY and EXISTING FLOOD PROTECTION as applicable, all at no additional cost to the Government.

1.4 EXCEPTION TO LIQUIDATED DAMAGES

The Contractor's obligations specified in paragraphs 1.5 FAR 52.211-12 Liquidated Damages Construction of Section 00 70 00.00 11 CONTRACT CLAUSE INSERTS and the requirements of Section 32 92 32.01 11 ESTABLISHMENT OF TURF are exempt from liquidated damages.

1.5 RIGHTS-OF-WAY

a. The rights-of-way and easements for the work to be constructed under this contract within the limits indicated on the drawings will be provided by the Government without cost to the Contractor. However, the Contractor shall make his own arrangements with the appropriate owners or organizations for transporting his equipment across, over or under railroad tracks, highways, bridges, private property, and utility lines and shall provide at his own expense any additional right-of-way or easements required to effect such crossings, including insurance requirements of owners. Limits of right-of-way which will be provided by the Government are as indicated on the drawings. The Contractor shall layout the project right-of-way so that the right-of-way is easily identified in the field.

All right-of-way markers shall remain in place throughout the life of the project and shall be removed prior to final acceptance, as directed by the Contracting Officer.

b. The Contractor shall, upon reasonable notice, without expense to the Government and at any time during the progress of the work when not being actively used for contract operations, promptly vacate and clean up any part of the Government grounds that have been allotted to or have been in use by him when directed to do so by the Contracting Officer.

c. The Contractor shall not obstruct any existing roads on the lands controlled by the United States except with the permission of the Contracting Officer, and shall maintain such roads in as good condition as exists at the time of commencement of the work.

d. Any additional right-of-way required for access or for the Contractor's method of operation must be obtained by and at the expense of the Contractor. The Contractor shall submit written evidence to the

DOCUMENT 00 80 00.00 11 Page 4

Contracting Officer that he has obtained the rights-of-way from the property owners. The written evidence shall consist of an Authenticated Copy of the Conveyance under which the Contractor Acquired the Rights-of-Way, prepared and executed in accordance with the laws of the State or States in which the work is being performed. If temporary rights are obtained by the Contractor, the period of time shall coincide with the contract clause entitled, "COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK", of Section 00 70 00.00 11 CONTRACT CLAUSES, plus a reasonable time for any extension granted for completion of the work. The Contractor shall be solely responsible for any and all damages, claims for damages, and liability of any nature whatsoever arising from or growing out of the use of rights-of-way other than those rights-of-way furnished by the Government.

e. The Contractor shall repair, at his own expense, any and all damage to the existing roads when such damage is a result of his operations on this contract. The Contractor shall also replace, at his own expense, any and all surfacing displaced or damaged by his operations on this contract. The repairs and/or replacement shall be done to the satisfaction of the Contracting Officer.

1.6 LAYOUT OF WORK

a. The Government will re-establish the following baselines and benchmarks at the site of the work:

(1) The baseline as shown on the drawings.

(2) The benchmarks as shown on the drawings.

b. From the baselines and benchmarks established by the Government, the Contractor shall complete the layout of the work and shall be responsible for all measurements that may be required for the execution of the work to the location and limit marks prescribed in the specifications or on the contract drawings, subject to such modifications as the Contracting Officer may require to meet changed conditions or as a result of necessary modifications to the contract work.

c. The Contractor shall furnish, at his own expense, such stakes, templates, platforms, equipment, tools and materials, and all labor as may be required in laying out any part of the work. It shall be the responsibility of the Contractor to maintain and preserve all stakes and marks established by the Contracting Officer, if any, until authorized to remove them, and if such marks are destroyed, by the Contractor or through his negligence, prior to their authorized removal, they may be replaced by the Contracting Officer, at his discretion, and the expense of replacement will be deducted from any amounts due or to become due the Contractor. The Contracting Officer may require that work be suspended at any time when location and limit marks established by the Contractor are not reasonably adequate to permit checking of the work.

d. Quantity Surveys. The Government shall conduct a preparatory meeting with the Contractor prior to the commencement of any work requiring quantity surveys to discuss the requirements and conditions relating to quantity surveys.

1) All surveying, including layout of work and quantity surveys, shall be accomplished by a registered land surveyor licensed in the state in which the work is performed. Surveys in accordance with 00 70 00.00 CONTRACT

DOCUMENT 00 80 00.00 11 Page 5

CLAUSE INSERTS, FAR 52.326-16 Quantity Surveys-Alternate I.

(2) For periods that progress payments are requested, the Contractor shall provide: (a) the in progress construction survey data that represents the actual work in-place and to be considered for payment along with pre-construction survey provided by the contractor. (b) Along with the survey data, provide plotted cross-sections and profiles indicating the theoretical grades and slope lines as specified by the contract drawings and the actual grades and slope lines as constructed shall be submitted.

(c) Quantity computations calculated by the end area method or other approved method indicating the end areas and tabulated volumes per station shall be submitted to verify the work in place.

(3) Quantity surveys as used in this clause means a topographical survey accomplished by ground methods with the display output recorded and stored in an electronic field book for further calculations in a computer.