B.08_Solicitation Amendment W912EP26BA0150003 SF30.pdf

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers is extended. is not extended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of theoffer submitted;

or (c) By separate letter or electronic communication which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE

RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER.

If by virtue of this amendment you desire to change an offer already submitted, such change may be made by letter or electronic communication, provided each letter or electronic communication makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NUMBER AS DESCRIBED IN ITEM 14.

CHECK ONE A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CONTRACT ORDER

NUMBER IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation data, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

15B. CONTRACTOR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNITED STATES OF AMERICA

(Signature of Contracting Officer)

16C. DATE SIGNED

Previous edition unusable STANDARD FORM 30 (REV. 11/2016) Prescribed by GSA FAR (48 CFR) 53.243

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

2. AMENDMENT/MODIFICATION NUMBER 3. EFFECTIVE DATE 4. REQUISITION/PURCHASE REQUISITION NUMBER 5. PROJECT NUMBER (If applicable)

6. ISSUED BY CODE 7. ADMINISTERED BY (If other than Item 6) CODE

8. NAME AND ADDRESS OF CONTRACTOR (Number, street, county, State and ZIP Code) (X) 9A. AMENDMENT OF SOLICITATION NUMBER

9B. DATED (SEE ITEM 11)

10A. MODIFICATION OF CONTRACT/ORDER NUMBE

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

J 1 15

0003 07 OCT 2026 126207

W912EP

W074 ENDIST JACKSNVLLE

KO CONTRACTING DIVISION, 701 SAN MARCO BLVD

JACKSONVILLE, FL 32207-0019

UNITED STATES

MEREDITH GONZALEZ, EMAIL: MEREDITH.C.GONZALEZ@USACE.ARMY.MIL

TELEPHONE: 904-232-3724

SCD: PAS:

W912EP26BA015

11 SEP 2026

SEE SECTION G - CONTRACT ADMINISTRATION DATA

See Schedule

TIMOTHY G. HUMPHREY

07 OCT 2026

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

Fort Pierce Harbor Maintenance Dredging, Block 14 (Description of Amendment/Modification):

St. Lucie County, Florida

SUMMARY OF CHANGES

1. SPECIFICATIONS:

The text changes have been updated with additions noted by underlined text and deletions noted by line/cross-outs and pertain only to changes made by this revision. The entire section is replaced if there is any change.

Changes to Volume 1 Specifications:

UPDATE Block 11 of the SF1442 with the correct Period of Performance and FAR Reference.

UPDATE Clause 52.229-11 Commencement, Prosecution, and Completion of Work. (Alternate I) (April 1984)

Changes to Volume 2 Specifications:

DELETE Submittal Register and REPLACE with the attached Submittal Register.

DELETE Section 01 57 20.00 35 and REPLACE with the attached Section 01 57 20.00 35.

DELETE Section 35 20 23.00 35 and REPLACE with the attached Section 35 20 23.00 35.

2. DRAWINGS:

DELETE Sheet C-07 and REPLACE with attached Sheet C-07.

DELETE Sheet G-05 and REPLACE with attached Sheet G-05.

Section 00 00 00 - Procurement and Contracting Requirements

The following changes have been made:

W912EP26BA0150003

The NAICS code for this project is 237990 and the small business size standard is $37 million.

An organized site visit has been scheduled, see Site Visit (Construction) in section 00 73 00 for details.

A pre-bid conference will also be held virtually. See Site Visit (Construction) in section 00 73 00 for details.

You must be registered in the System for Award Management (SAM) to receive an award from this solicitation. The SAM website is located at www.sam.gov.

**see block 11 - see Commencement, Prosecution, and Completion of Work in Section 00 73 00 for the period of performance.

Bids will be due 13 October 2026 at 1:00 pm (EDT). Bid opening will be held virtually 13 October 2026 at 2:

00 pm (EDT) via Microsoft Teams.

SEE SUBMISSION

INSTRUCTIONS AND MEETING

DETAILS UNDER SECTION 00 21

13 - INSTRUCTIONS FOR

BIDDERS.

The NAICS code for this project is 237990 and the small business size standard is $37 million.

An organized site visit has been scheduled, see Site Visit (Construction) in section 00 73 00 for details.

A pre-bid conference will also be held virtually. See Site Visit (Construction) in section 00 73 00 for details.

You must be registered in the System for Award Management (SAM) to receive an award from this solicitation. The SAM website is located at www.sam.gov.

**see block 11 - see Commencement, Prosecution, and Completion of Work in Section 00 73 00 for the period of performance.

Bids will be due 16 October 2026 at 1:00 pm (EDT). Bid opening will be held virtually 16 October 2026 at 2:

00 pm (EDT) via Microsoft Teams.

SEE SUBMISSION

INSTRUCTIONS AND MEETING

DETAILS UNDER SECTION 00 21

13 - INSTRUCTIONS FOR

BIDDERS.

Response Due Date

13 Oct 2026 16 Oct 2026

Contractor Performance Date

The contractor shall begin performance within 60 calendar days and complete it within 157* calendar days after receiving notice to proceed.

This performance period is mandatory. (See FAR 52.211-10)

The contractor shall begin performance within 60 calendar days and complete it within * calendar days after receiving notice to proceed. This performance period is mandatory.

(See FAR 52.229-11) http://www.sam.gov/ http://www.sam.gov/

Miscellaneous text in this section has been modified from:

ELECTRONIC BIDS

(a) Definition:

Electronic bid, as used in this provision, means a bid, revision or modification of a bid, or withdrawal of a bid that is transmitted to and received by the Government via email or other means for transmitting electronic data. No flash drives will be accepted.

(b) Offerors must submit electronic bids in responses to this solicitation in order to be considered for award.

Electronic bids are subject to the same rules as paper bids.

(c) If any portion of bid received by the Contracting Officer is unreadable to the degree that conformance to the essential requirements of the solicitation cannot be ascertained from the document.

(1) The Contracting Officer shall immediately notify the offeror and permit the offeror to resubmit the bid if the bid has been received prior to due date indicated in the solicitation.

(2) The method and time for resubmission shall by prescribed by the Contracting Officer after consultation with the offeror.

(d) The Government reserves the right to make award solely on the electronic bid. However, if requested to do so by the Contracting Officer, the apparently successful offeror shall submit the complete original signed bid.

(e) The Offeror's bid shall be submitted electronically, as described below. The use of hyperlinks in the bid is prohibited. The offeror's bid is due no later than . 1:00 PM (EDT) on 22 13 October 2026

(f) Bid opening will be held virtually on via Microsoft TEAMS. Utilize the 22 13 October 2026 at 2:00 PM (EDT) information provided below to join the TEAMS meeting:

HTTPS:// WWW.MICROSOFT .COM/EN-US/MICROSOFT-TEAMS/JOIN-A-MEETING

MEETING ID: 993 619 414 266 / PASSCODE: kD2Uc3ax

DIAL IN BY PHONE: +1 601-262-2433 / PHONE CONFERENCE ID: 652 114 008#

NOTE: The only authorized transmission method of bids in response to the subject solicitation is electronically via the Procurement Integrated Enterprise Environment (PIEE) website. No other transmission methods, such as email, facsimile, hand-carried, proprietary or DOD SAFE submissions, bids submitted by mail, etc. will be accepted. Offers submitted via any other transmission method other than the Procurement Integrated Enterprise Environment (PIEE) website will not be evaluated.

The Offeror's bid must be received by the Government no later than the date/time specified in the solicitation and cited above. Offerors shall submit their bid using the following link: https://piee.eb.mil/

Instructions for submitting electronic bids:

In an effort to reduce paperwork and cost, all bids shall be submitted electronically through the Procurement Integrated Enterprise Environment (PIEE) website.

Electronic copies of each volume shall be submitted through the Solicitation Module of PIEE at https://piee.eb.

mil. If there is a system outage, see below. All bids received after the exact time specified for receipt shall be treated as late submissions.

Section 00 21 13 - Instructions to Bidders

For instructions on how to post an offer, please refer to the Posting Offer demo: https://pieetraining.eb.mil/wbt/sol /Posting_Offer.pdf.

It is the Offeror's responsibility to obtain written confirmation of receipt of all electronic files of the full bid by the Contracting office. The submission date for all Volumes shall be no later than the date and time specified in Block 13 of the SF 1442 of the Solicitation. In the unlikely event the PIEE system is not operational, experiences technical difficulties, or a Contractor is temporarily unable to access or use the system, the Contractor shall immediately notify the Contracting Officer. This Notification must occur prior to the bid submission deadline.

Contractor notification shall be in writing and may be in conjunction with verbal notification, but verbal notification alone shall not be sufficient.

The alternate method for bid submission is via expedited delivery or hand-carried. The Offeror must obtain prior approval from the Contracting Officer to use the alternate submission method. The Contractor shall have 24 hours to provide their bid upon contracting officer approval. In the event that the Contractor alleges technical difficulties and does not notify the contracting officer until after the closing date and time, the contracting officer will follow the procedures identified in the Federal Acquisition Regulation (FAR) and then make a determination if the Contractor's late bid submission is accepted.

Screen shots of the submission should be taken to validate a submission was accepted in the PIEE system. You are limited to five (5) maximum files per upload (total size cannot exceed 2GB). If you have a large number of files, it is recommended that you combine or ZIP your files before uploading to the PIEE site. Offerors may use compression utility software such as WinZip or PKZip to reduce file size and facilitate transmission.

File Description:

To ensure your submission is received and processed appropriately, it is important that interested parties CAREFULLY ensure their electronic files adhere to the following naming convention. Each file name shall begin with the solicitation number, followed by the word "RESPONSE", followed by your firm's name and finally a brief file description.

EXAMPLE:

"W912EP26BA015 RESPONSE FIRM NAME.pdf"

File Organization, Formatting, and other instructions:

Each file shall be clearly indexed and logically assembled. Font size shall be 10 or larger. Pages shall be letter sized--larger page sizes (such as 11x17 foldouts, etc.) will be counted as two pages. Offerors shall prepare bids in the English language. Bids shall be in a narrative format, organized and titled so that each section of the bid follows the order and format of the factors. Information presented should be organized so as to pertain to only the evaluation factor in the section that the information is presented. Information pertaining to more than one evaluation factor should be repeated in each section for each factor.

Include a "File Description" for each file(s) you upload. The "File Description" will be included in the email notice to each of the recipients you choose to have access your file(s).

NOTE: Do NOT enter Privacy Act Data (Personal Identification Information (PII)) in the File Description.)

Upload Completion & Deadline:

Interested parties shall submit responses no later than the date cited above. Offerors should time their upload effort with prudence by not waiting until the last few minutes--this will allow for unexpected delays in the transmittal process. Submissions after the deadline may be emailed to Contract Specialist Meredith Gonzalez at

(Meredith.C.Gonzalez@usace.army.mil) but be advised, they will be considered late and as such, will be processed in accordance with FAR 15.208.

Submission shall be in Adobe PDF format.

Receipt of Submission:

For the purposes of establishing whether a bid submission is considered timely, the Government considers the date and time the submission is completely uploaded into the PIEE website. For multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the PIEE website.

Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases. The Government will not be responsible for submissions delivered to any location or to anyone other than those designated to receive bids. Offerors are responsible for ensuring that offers are submitted so as to reach the designated recipient. Offerors are responsible for allowing sufficient time for the offer to be received in accordance with the instructions provided.

To:

ELECTRONIC BIDS

(a) Definition:

Electronic bid, as used in this provision, means a bid, revision or modification of a bid, or withdrawal of a bid that is transmitted to and received by the Government via email or other means for transmitting electronic data. No flash drives will be accepted.

(b) Offerors must submit electronic bids in responses to this solicitation in order to be considered for award.

Electronic bids are subject to the same rules as paper bids.

(c) If any portion of bid received by the Contracting Officer is unreadable to the degree that conformance to the essential requirements of the solicitation cannot be ascertained from the document.

(1) The Contracting Officer shall immediately notify the offeror and permit the offeror to resubmit the bid if the bid has been received prior to due date indicated in the solicitation.

(2) The method and time for resubmission shall by prescribed by the Contracting Officer after consultation with the offeror.

(d) The Government reserves the right to make award solely on the electronic bid. However, if requested to do so by the Contracting Officer, the apparently successful offeror shall submit the complete original signed bid.

(e) The Offeror's bid shall be submitted electronically, as described below. The use of hyperlinks in the bid is prohibited. The offeror's bid is due no later than . 1:00 PM (EDT) on 15 16 October 2026

(f) Bid opening will be held virtually on via Microsoft TEAMS. Utilize the 13 16 October 2026 at 2:00 PM (EDT) information provided below to join the TEAMS meeting:

HTTPS:// WWW.MICROSOFT .COM/EN-US/MICROSOFT-TEAMS/JOIN-A-MEETING

MEETING ID: 993 619 414 266 / PASSCODE: kD2Uc3ax

DIAL IN BY PHONE: +1 601-262-2433 / PHONE CONFERENCE ID: 652 114 008#

NOTE: The only authorized transmission method of bids in response to the subject solicitation is electronically via the Procurement Integrated Enterprise Environment (PIEE) website. No other transmission methods, such as email, facsimile, hand-carried, proprietary or DOD SAFE submissions, bids submitted by mail, etc. will be accepted. Offers submitted via any other transmission method other than the Procurement Integrated Enterprise Environment (PIEE) website will not be evaluated.

The Offeror's bid must be received by the Government no later than the date/time specified in the solicitation and cited above. Offerors shall submit their bid using the following link: https://piee.eb.mil/

Instructions for submitting electronic bids:

In an effort to reduce paperwork and cost, all bids shall be submitted electronically through the Procurement Integrated Enterprise Environment (PIEE) website.

Electronic copies of each volume shall be submitted through the Solicitation Module of PIEE at https://piee.eb.

mil. If there is a system outage, see below. All bids received after the exact time specified for receipt shall be treated as late submissions.

For instructions on how to post an offer, please refer to the Posting Offer demo: https://pieetraining.eb.mil/wbt/sol /Posting_Offer.pdf.

It is the Offeror's responsibility to obtain written confirmation of receipt of all electronic files of the full bid by the Contracting office. The submission date for all Volumes shall be no later than the date and time specified in Block 13 of the SF 1442 of the Solicitation. In the unlikely event the PIEE system is not operational, experiences technical difficulties, or a Contractor is temporarily unable to access or use the system, the Contractor shall immediately notify the Contracting Officer. This Notification must occur prior to the bid submission deadline.

Contractor notification shall be in writing and may be in conjunction with verbal notification, but verbal notification alone shall not be sufficient.

The alternate method for bid submission is via expedited delivery or hand-carried. The Offeror must obtain prior approval from the Contracting Officer to use the alternate submission method. The Contractor shall have 24 hours to provide their bid upon contracting officer approval. In the event that the Contractor alleges technical difficulties and does not notify the contracting officer until after the closing date and time, the contracting officer will follow the procedures identified in the Federal Acquisition Regulation (FAR) and then make a determination if the Contractor's late bid submission is accepted.

Screen shots of the submission should be taken to validate a submission was accepted in the PIEE system. You are limited to five (5) maximum files per upload (total size cannot exceed 2GB). If you have a large number of files, it is recommended that you combine or ZIP your files before uploading to the PIEE site. Offerors may use compression utility software such as WinZip or PKZip to reduce file size and facilitate transmission.

File Description:

To ensure your submission is received and processed appropriately, it is important that interested parties CAREFULLY ensure their electronic files adhere to the following naming convention. Each file name shall begin with the solicitation number, followed by the word "RESPONSE", followed by your firm's name and finally a brief file description.

EXAMPLE:

"W912EP26BA015 RESPONSE FIRM NAME.pdf"

File Organization, Formatting, and other instructions:

Each file shall be clearly indexed and logically assembled. Font size shall be 10 or larger. Pages shall be letter sized--larger page sizes (such as 11x17 foldouts, etc.) will be counted as two pages. Offerors shall prepare bids in the English language. Bids shall be in a narrative format, organized and titled so that each section of the bid follows the order and format of the factors. Information presented should be organized so as to pertain to only the evaluation factor in the section that the information is presented. Information pertaining to more than one evaluation factor should be repeated in each section for each factor.

Include a "File Description" for each file(s) you upload. The "File Description" will be included in the email notice to each of the recipients you choose to have access your file(s).

NOTE: Do NOT enter Privacy Act Data (Personal Identification Information (PII)) in the File Description.)

Upload Completion & Deadline:

Interested parties shall submit responses no later than the date cited above. Offerors should time their upload effort with prudence by not waiting until the last few minutes--this will allow for unexpected delays in the transmittal process. Submissions after the deadline may be emailed to Contract Specialist Meredith Gonzalez at (Meredith.C.Gonzalez@usace.army.mil) but be advised, they will be considered late and as such, will be processed in accordance with FAR 15.208.

Submission shall be in Adobe PDF format.

Receipt of Submission:

For the purposes of establishing whether a bid submission is considered timely, the Government considers the date and time the submission is completely uploaded into the PIEE website. For multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the PIEE website.

Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases. The Government will not be responsible for submissions delivered to any location or to anyone other than those designated to receive bids. Offerors are responsible for ensuring that offers are submitted so as to reach the designated recipient. Offerors are responsible for allowing sufficient time for the offer to be received in accordance with the instructions provided.

Section 00 73 00 - Supplementary Conditions

Miscellaneous text in this section has been modified from:

SPECIAL CONTRACT REQUIREMENTS(SCR) - FAR PROVISION 52.229-11 AND FAR CLAUSE

52.229-12

FAR provision 52.229-11 and FAR clause 52.229-12 are included in this solicitation. This provision and clause concern the imposition of a 2 percent Federal excise tax withholding on any resultant contract award or payment request. This rule applies to Federal Government contracts for goods or services that are awarded to foreign persons - such as foreign contractors. It implements the

Department of the Treasury's final regulations published in the Federal Register at 81FR 55133 on August 18, 2016, under section 5000C of the Internal Revenue Code relating to the 2 percent tax on payments made by the U.S. Government to foreign persons pursuant to certain contracts.

Pursuant to the FAR 52.229-3 Federal, State, and Local Taxes, taxes imposed under 26 U.S.C.

5000 C may not be included in the contract price or reimbursed. Exemptions from this excise tax must be claimed by an Offeror when it submits, with its offer, a U.S. Department of Treasury Internal Revenue Service (IRS) Form W-14, Certificate of Foreign Contracting Party Receiving Federal Procurement Payments, available via the internet at www.irs.gov/W14. If not submitted with the offer, exemptions will not be applied to any resulting contract and the Government will withhold a full 2 percent on each contract payment. Failure to submit an IRS Form W-14 with each payment request will also result in an automatic withholding of 2 percent from the payment request.

When filling out the IRS FormW-14 the following information may be used to complete Part I, Lines 6 and 7.

Line 6 Contract/reference number: W912EP26BA015

Line 7 "Name and address of the acquiring agency":

US Army Corps of Engineers Jacksonville District

701 San Marco Blvd.

Jacksonville, FL 32207

Any exemption claimed and self-certified is subject to audit by the IRS. Any disputes concerning this tax are adjudicated by the IRS because the Section 5000C tax is a tax matter not a contract issue. Offerors are encouraged to seek guidance from their own tax professionals for advice concerning the provision, clause, and exclusions exclusion/submission of IRS Form W-14.

Notwithstanding the above, the USACE does not have a means of withholding this excise tax at this time. Asa result, contractors are expected to comply with the instructions above and to properly complete and return the W-14 at proposal submission, and with each pay application. The amount due for each withholding will be confirmed by USACE, BUT WILL NOT BE WITHHELD. It is the contractor's responsibility to set aside, or remit to the IRS, the amount confirmed by USACE.

Whether the contractor sets the money aside for future payment to the IRS, or makes payment to the IRS, is the contractor's discretion, based on its analysis of the regulations regarding the excise tax. In the event that USACE is able to withhold during contract performance, it will notify the contractor and make such a withholding (including any catch up withholdings); no advance notice is required to the contractor prior to the withholding. Under no circumstances is USACE liable for any tax not paid by the contractor. The contractor is liable for the tax, to the extent required by law, regardless of whether USACE makes a withholding.

FAR 29.204 expressly states that "[a]gencies merely withhold the tax (section 5000C tax) for the Internal Revenue Service (IRS). All substantive issues regarding the underlying section 5000C tax, e.g., the imposition of, and exemption from the tax, are matters under the jurisdiction of the IRS."

Therefore, we cannot help you determine how the tax law applies to you. We strongly recommend that you contact the IRS and/or a tax professional should you have any questions of this nature. To be clear, this information does not constitute tax advice or a representation of your tax liability.

Furnishing this information does not create liability for the USACE for any Federal, state, or local taxes applicable to the above[1]referenced contract or any other contract.

For submission requirements and basis of evaluation:

Executed FAR Provision 52.229-11.

Completed IRS Form W-14, Certificate of Foreign Contracting Party Receiving Federal Procurement Payments, if applicable. If not submitted with the offer, exemptions will not be applied to any resulting contract and the Government will withhold a full 2 percent on each payment.

(End of SCR)

Commencement, Prosecution, and Completion of Work. (Alternate I) (APR 1984)

The Contractor shall be required to (a) commence work under this contract within SIXTY (60) calendar days after the date the Contractor receives the Notice to Proceed (NTP), (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than , and30 May 2027 be off the beach by 30 June 2027 for the entire contract work. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by . The completion date will be extended by the number of calendar 7 January 2027 days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of Paragraph)

Physical Data (APR 1984).

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by (See Section(s) 01 32 01 and 01 11 00 of this contract).

(b) Weather conditions (See Section 01 32 01 of this contract).

(c) Location (See Section 01 11 00 and drawings of this contract).

(End of Paragraph)

Site Visit (Construction). (Alternative I) (FEB 1995).

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for at 10 AM EDT. 28 September 2026

(c) Participants should contact Jaime Perez Figueroa at (561-631-0340, Jaime.J.

PerezFigueroa@usace.army.mil) on or before 25 September 2026 at 5 PM EDT to make arrangements.

(d) A PRE-BID CONFERENCE WILL BE HELD VIRTUALLY VIA MICROSOFT TEAMS ON 29 September 2026 AT AM10:00 EDT:

Meeting ID: 993 213 964 588 | Passcode: qQ9LT3zi

Dial-In: +1 601-262-2433 | Passcode: 453 007 326#

(End of Paragraph)

LIST OF WAGE DETERMINATIONS ATTACHMENTS

To:

SPECIAL CONTRACT REQUIREMENTS(SCR) - FAR PROVISION 52.229-11 AND FAR CLAUSE

52.229-12

FAR provision 52.229-11 and FAR clause 52.229-12 are included in this solicitation. This provision and clause concern the imposition of a 2 percent Federal excise tax withholding on any resultant contract award or payment request. This rule applies to Federal Government contracts for goods or services that are awarded to foreign persons - such as foreign contractors. It implements the Department of the Treasury's final regulations published in the Federal Register at 81FR 55133 on August 18, 2016, under section 5000C of the Internal Revenue Code relating to the 2 percent tax on payments made by the U.S. Government to foreign persons pursuant to certain contracts.

Pursuant to the FAR 52.229-3 Federal, State, and Local Taxes, taxes imposed under 26 U.S.C.

5000 C may not be included in the contract price or reimbursed. Exemptions from this excise tax must be claimed by an Offeror when it submits, with its offer, a U.S. Department of Treasury Internal Revenue Service (IRS) Form W-14, Certificate of Foreign Contracting Party Receiving Federal Procurement Payments, available via the internet at www.irs.gov/W14. If not submitted with the offer, exemptions will not be applied to any resulting contract and the Government will withhold a full 2 percent on each contract payment. Failure to submit an IRS Form W-14 with each payment request will also result in an automatic withholding of 2 percent from the payment request.

When filling out the IRS FormW-14 the following information may be used to complete Part I, Lines 6 and 7.

Line 6 Contract/reference number: W912EP26BA015

Line 7 "Name and address of the acquiring agency":

US Army Corps of Engineers Jacksonville District

701 San Marco Blvd.

Jacksonville, FL 32207

Any exemption claimed and self-certified is subject to audit by the IRS. Any disputes concerning this tax are adjudicated by the IRS because the Section 5000C tax is a tax matter not a contract issue. Offerors are encouraged to seek guidance from their own tax professionals for advice concerning the provision, clause, and exclusions exclusion/submission of IRS Form W-14.

Notwithstanding the above, the USACE does not have a means of withholding this excise tax at this time. Asa result, contractors are expected to comply with the instructions above and to properly complete and return the W-14 at proposal submission, and with each pay application. The amount due for each withholding will be confirmed by USACE, BUT WILL NOT BE WITHHELD. It is the contractor's responsibility to set aside, or remit to the IRS, the amount confirmed by USACE.

Whether the contractor sets the money aside for future payment to the IRS, or makes payment to the IRS, is the contractor's discretion, based on its analysis of the regulations regarding the excise tax. In the event that USACE is able to withhold during contract performance, it will notify the contractor and make such a withholding (including any catch up withholdings); no advance notice is required to the contractor prior to the withholding. Under no circumstances is USACE liable for any tax not paid by the contractor. The contractor is liable for the tax, to the extent required by law, regardless of whether USACE makes a withholding.

FAR 29.204 expressly states that "[a]gencies merely withhold the tax (section 5000C tax) for the Internal Revenue Service (IRS). All substantive issues regarding the underlying section 5000C tax, e.g., the imposition of, and exemption from the tax, are matters under the jurisdiction of the IRS."

Therefore, we cannot help you determine how the tax law applies to you. We strongly recommend that you contact the IRS and/or a tax professional should you have any questions of this nature. To be clear, this information does not constitute tax advice or a representation of your tax liability.

Furnishing this information does not create liability for the USACE for any Federal, state, or local taxes applicable to the above[1]referenced contract or any other contract.

For submission requirements and basis of evaluation:

Executed FAR Provision 52.229-11.

Completed IRS Form W-14, Certificate of Foreign Contracting Party Receiving Federal Procurement Payments, if applicable. If not submitted with the offer, exemptions will not be applied to any resulting contract and the Government will withhold a full 2 percent on each payment.

(End of SCR)

Commencement, Prosecution, and Completion of Work. (Alternate I) (APR 1984)

The Contractor shall be required to (a) commence work under this contract within SIXTY (60) calendar days after the date the Contractor receives the Notice to Proceed (NTP), (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than , and30 May 2027 be off the beach by 30 June 2027 for the entire contract work. The time stated for completion shall include final cleanup of the premises.

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by . The completion date will be extended by the 7 January 2027 10 December 2026 number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

Physical Data (APR 1984).

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation of or conclusion drawn from the data or information by the Contractor.

(a) The indications of physical conditions on the drawings and in the specifications are the result of site investigations by (See Section(s) 01 32 01 and 01 11 00 of this contract).

(b) Weather conditions (See Section 01 32 01 of this contract).

(c) Location (See Section 01 11 00 and drawings of this contract).

(End of Paragraph)

Site Visit (Construction). (Alternative I) (FEB 1995).

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for at 10 AM EDT. 28 September 2026

(c) Participants should contact Jaime Perez Figueroa at (561-631-0340, Jaime.J.

PerezFigueroa@usace.army.mil) on or before 25 September 2026 at 5 PM EDT to make arrangements.

(d) A PRE-BID CONFERENCE WILL BE HELD VIRTUALLY VIA MICROSOFT TEAMS ON 29 September 2026 AT AM10:00 EDT:

Meeting ID: 993 213 964 588 | Passcode: qQ9LT3zi

Dial-In: +1 601-262-2433 | Passcode: 453 007 326#

LIST OF WAGE DETERMINATIONS ATTACHMENTS

W912EP26BA0150003

General Decision Number: FL20260002

General Decision Number: FL20260136

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 1 OF 7 PAGES

W912EP26BA015

Fort Pierce Harbor Maintenance Dredging

01 20 00 SD-01 Preconstruction Submittals

1.3 G ROCost Breakdown

SD-07 Certificates

3.2 G RORequest for Progress Payment

01 30 00 SD-01 Preconstruction Submittals

1.5.1 G ROSuperintendent Qualifications

SD-07 Certificates

1.10Signature Authority

1.11Drug-Free Work Place Record

1.12Insurance Requirements

01 32 01.10 35 SD-01 Preconstruction Submittals

1.2 G ROProject Scheduler Qualifications

1.3.1 G ROInitial Project Schedules

SD-07 Certificates

1.4 G ROPeriodic Schedule Update

01 33 00 SD-01 Preconstruction Submittals

1.8 GSubmittal Register

01 35 26 SD-01 Preconstruction Submittals

1.8 G DOAccident Prevention Plan (APP)

1.16 G DODive Operations Plan

SD-06 Test Reports

1.12.2 G ROAccident Reports

1.12.3LHE Inspection Reports

1.5 G ROMonthly Exposure Reports

SD-07 Certificates

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P H

C L A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

AUTH REMARKS

(a) (b) (c) (d) (e) (f) (g) (h) (i) (j) (k) (l) (m) (n) (o) (p) (q) (r)

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 2 OF 7 PAGES

Fort Pierce Harbor Maintenance Dredging

01 35 26 1.7.7 G ROCrane Operators, Signal Persons and Riggers

1.9 G ROActivity Hazard Analysis (AHA)

1.12.4 G ROCertificate of Compliance

1.13Hot Work Permit

1.14 G ROLicense Certificates

1.14.1 G DOPortable Gauge Operations

Planning Worksheet

1.14.1 G DORadiography Operation Planning

Work Sheet

1.12.4 G ROStandard Lift Plan

01 35 30.00 35 SD-01 Preconstruction Submittals

1.5 G DOMEC Safety and Work Plan

01 45 05 SD-01 Preconstruction Submittals

1.5.2 G ROContractor Quality Control (CQC)

Plan

SD-06 Test Reports

1.12.3Verification Statement

01 50 00.00 35 SD-01 Preconstruction Submittals

1.4.1 G ROConstruction Site Plan

1.4.2 G ROMobilization/Demobilization Plan

1.4.3 G ROSecurity Plan

1.4.4 G ROVegetation Protection and

Restoration Plan

3.3.1 G ROTraffic Control Plan

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 3 OF 7 PAGES

Fort Pierce Harbor Maintenance Dredging

01 50 00.00 35 1.4.5 G RODocumentation Of Existing

Conditions

2.2.1 G ROHaul Road Plan

SD-02 Shop Drawings

3.2.6Temporary Electric Drawings

SD-03 Product Data

2.1.2 G ROProject Identification And Safety

Signs

SD-11 Closeout Submittals

3.11.1 G RODocumentation Of Post

Construction Restoration

01 57 20.00 35 SD-01 Preconstruction Submittals

1.8 G DOEnvironmental Protection Plan

3.1.5.1 G ROWhale Alert Text Message

Address

SD-02 Shop Drawings

3.1.5.6 G ROTurtle Deflector Device

SD-06 Test Reports

3.1.5.9 G ROEscarpment Site Visit Report(s)

3.1.5.7 G ROLog of The Results of Turtle Egg

Monitoring and Recovery Activities

3.1.5.2 G ROProtected Listed Species Sighting

Reports

3.1.5.3 G ROWeekly Protected Species

Summary Report

3.1.5.14 G DONonbreeding Shorebird Survey

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 4 OF 7 PAGES

Fort Pierce Harbor Maintenance Dredging

01 57 20.00 35 SD-07 Certificates

1.9.1 G DOMarine Turtle Nesting Monitor

and Relocation Qualifications

1.9.2 G DOBird Monitoring Qualifications

1.9.4 G DOEndangered Species Observer

and Trawl Supervisor

Qualifications (For Hopper

Dredges Only)

1.9.3 G DOMarine Animal Observer

Qualifications

(Clamshell/Mechanical Only)

SD-11 Closeout Submittals

3.1.5.3 G DOProtected Species Summary

Report

3.1.5.11 G DOLogs/Summary of Bird Nesting

Monitoring Report

3.1.5.12 G DOLogs/Summary of Bird Nesting

Monitoring Report

3.1.5.7 G DOLogs/Summary of Marine Turtle

Nesting and Relocation

3.4.2.1 G DOInvasive and Nuisance Species

Report

1.10 G DOProject Environmental Summary

Sheet

01 57 25.00 35 SD-01 Preconstruction Submittals

1.3 G ROTurbidity Monitor Qualifications

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 5 OF 7 PAGES

Fort Pierce Harbor Maintenance Dredging

01 57 25.00 35 1.4 G ROTurbidity Monitoring Plan

1.4 G RODraft Turbidity Sampling Map

3.1.1.1 G ROTesting Equipment and

Procedure

SD-03 Product Data

3.1.1.1 GCalibration Standard

SD-06 Test Reports

3.2.2 G ROTurbidity Monitoring Reports

3.3.1 G ROTurbidity Exceedance Report

3.3.2 G ROUpdated Turbidity Exceedance

Report

02 22 13.00 35 SD-01 Preconstruction Submittals

1.3.1 G DOVibration Control Specialist

1.3.1 G DOVibration Control Specialist

Alternate

1.3.2 G DOVibration Monitoring

Technician(s)

1.3.3 G DOStructural Inspection/Evaluation

Engineer

3.2 G DOPre-Construction Structural

Survey

3.3 G DOVibration Control Plan

SD-06 Test Reports

3.5Vibration Monitoring Report

3.4Daily Instrument Logs

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 6 OF 7 PAGES

Fort Pierce Harbor Maintenance Dredging

02 22 13.00 35 3.6 G DOPost-Construction Structural

Survey

35 20 23.00 35 SD-01 Preconstruction Submittals

1.5Notice of Intent to Dredge

3.2.1Relocation of Navigation Aids

3.13.2Marine Survey Inspection

Certificates

SD-02 Shop Drawings

3.9.2Drag Bar

3.6.1 G DOAcceptance Sections Plan

3.5.2.2 G DOProgress Map

3.5.2.6 G DOConstruction and Grade Stakes

Recovery Plan

1.6 G ROGeneral Work Plan

1.7 G ROPublic Protection Plan

3.5.2.1 G ROUnacceptable Material Disposal

Plan

SD-07 Certificates

1.18Equipment and Performance

Data

1.11Historical Period Shipwreck Sites

3.7Surveys

3.1Daily Report of Operations

3.5.7Misplaced Material

1.13Declaration of Inspection

3.5.2.6.1Grade Stake Log

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

SUBMITTAL FORM,Jan 96 PREVIOUS EDITION IS OBSOLETE PAGE 7 OF 7 PAGES

Fort Pierce Harbor Maintenance Dredging

35 20 23.00 35 3.5.2.6.1Grade Stake Recovery Certificate

SD-11 Closeout Submittals

3.7.5 G DOBeach Placement Survey

35 20 23.13 SD-07 Certificates

1.4National Dredging Quality

Management Program Certification

35 20 23.23 SD-07 Certificates

1.4National Dredging Quality

Management Program Certification

35 20 23.33 SD-07 Certificates

1.4National Dredging Quality

Management Program Certification

35 20 23.43 SD-07 Certificates

1.4National Dredging Quality

Management Program Certification

SUBMITTAL REGISTER

CONTRACT NO.

TITLE AND LOCATION CONTRACTOR

CONTRACTOR:

SCHEDULE DATES

CONTRACTOR

ACTION

APPROVING AUTHORITY

A C T I V I T Y

N O

T R A N S M I T T A L

N O

S P E C

S E C T

DESCRIPTION

ITEM SUBMITTED

P A R A G R A P

A S S I F I C A T I O N

G O V T

O R

A E

R E V W

R SUBMIT

APPROVAL

NEEDED

BY

MATERIAL

NEEDED

BY

A C T I O N

C O D E

DATE

OF

ACTION

DATE FWD

TO APPR

AUTH/

DATE RCD

FROM

CONTR

DATE FWD

TO OTHER

REVIEWER

DATE RCD

FROM OTH

REVIEWER

A C T I O N

C O D E

DATE

OF

ACTION

MAILED

TO

CONTR/

DATE RCD

FRM APPR

Fort Pierce Harbor Maintenance Dredging St. Lucie County, Florida

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 57 20.00 35

ENVIRONMENTAL PROTECTION

PART 1 GENERAL

1.1 SCOPE

1.2 ENVIRONMENTAL LAWS, REGULATIONS AND DOCUMENTS

1.2.1 Miscellaneous Environmental Laws And Regulations

1.2.2 NEPA Reference

1.3 REFERENCES

1.4 QUALITY CONTROL

1.5 PERSONNEL TRAINING

1.6 PERMITS AND AUTHORIZATIONS

1.7 SUBMITTALS

1.8 ENVIRONMENTAL PROTECTION PLAN

1.9 QUALIFICATIONS

1.9.1 Marine Turtle Nesting Monitor and Relocation Qualifications

1.9.2 Bird Monitoring Qualifications

1.9.3 Marine Animal Observer Qualifications (Clamshell/Mechanical

Only)

1.9.4 Endangered Species Observer and Trawl Supervisor

Qualifications (For Hopper Dredges Only)

1.10 NOTIFICATION

1.11 CONTRACTOR PERSONNEL QUALIFICATIONS IN POLLUTION CONTROL

PART 2 PRODUCTS

PART 3 EXECUTION

3.1 PROTECTION OF ENVIRONMENTAL RESOURCES

3.1.1 General Project Environmental Design and Installation Criteria

3.1.1.1 Sewage-Based Systems Environmental Design and Installation

Criteria

3.1.2 Protection of Land Resources

3.1.2.1 Work Area Limits

3.1.2.2 Contractor Facilities and Other Work Areas

3.1.2.3 Solid Wastes

3.1.2.4 Fuel, Oil, and Lubricants

3.1.2.5 Hazardous Waste

3.1.2.6 Hazardous Materials

3.1.2.7 Soil/Sediment Reuse, Testing and Disposal

3.1.2.8 Disposal of Other Materials

3.1.3 Preservation and Recovery of Historic, Archeological, and

Cultural Resources

3.1.3.1 Applicable Law

3.1.3.2 Known Resources

3.1.3.3 Inadvertent Discoveries

3.1.3.4 Claims for Downtime due to Inadvertent Discoveries

SECTION 01 57 20.00 35 Page 1 W912EP26BA015 Amendment 0003

3.1.4 Protection of Water Resources

3.1.4.1 Monitoring of Water Areas

3.1.4.2 Turbidity

3.1.4.3 Oil, Fuel, and Hazardous Substance Spill Prevention and

Mitigation

3.1.5 Protection of Fish and Wildlife Resources

3.1.5.1 Listed Species Protection

3.1.5.2 Protected Listed Species Sighting Reports

3.1.5.3 Protected Species Summary Report

3.1.5.4 Endangered Species Observers (Hopper Dredge Only)

3.1.5.5 Disposition of Endangered or Threatened Species Carcasses

3.1.5.6 Hopper Dredge Equipment

3.1.5.7 Sea Turtle Beach Nest Monitoring

3.1.5.8 Beach Placement Restrictions

3.1.5.9 Escarpments

3.1.5.10 Hardbottom Protection

3.1.5.11 Protection of Migratory Bird Species

3.1.5.12 Protection of Shorebird and Shorebird Surveys

3.1.5.13 Shorebird Buffer Zones and Travel Corridors

3.1.5.14 Protection of Piping Plover and Rufa Red Knot

3.1.6 Seagrass Protection Measures

3.1.7 Protection of Air Resources

3.1.7.1 Particulates

3.1.7.2 Burning

3.1.7.3 Odors

3.1.8 Protection of Sound Intrusions

3.2 POSTCONSTRUCTION CLEANUP

3.3 PRESERVATION AND RESTORATION OF LANDSCAPE AND AQUATIC VEGETATION

DAMAGES

3.4 INVASIVE AND NUISANCE SPECIES

3.4.1 Prevention of Invasive and Nuisance Species Transfer

3.4.2 Invasive and Nuisance Species Reporting

3.4.2.1 Invasive and Nuisance Species Report

3.5 MAINTENANCE OF POLLUTION CONTROL FACILITIES

3.6 CONSTRUCTION FORMS AND DETAILS

ATTACHMENTS:

Attachment A - ODESS Guidance

-- End of Section Table of Contents --

SECTION 01 57 20.00 35 Page 2

SECTION 01 57 20.00 35

ENVIRONMENTAL PROTECTION

PART 1 GENERAL

1.1 SCOPE

This Section covers prevention of environmental damage as the result of construction operations under this contract and for those measures set forth in other Technical Requirements of these specifications. For the purpose of this specification, environmental damage is defined as the presence of hazardous, physical, chemical, or biological elements or agents which adversely affect human health or welfare; unfavorably alter ecological balances; affect other species, biological communities, or ecosystems; or degrade the quality of the environment for aesthetic, cultural, and historical purposes. The control of environmental damage requires consideration of land, water, and air, and includes management of visual aesthetics, noise, solid waste, radiant energy and radioactive materials, as well as other pollutants.

1.2 ENVIRONMENTAL LAWS, REGULATIONS AND DOCUMENTS

1.2.1 Miscellaneous Environmental Laws And Regulations

There are numerous environmental laws and regulations. At the Federal level, the applicable laws and regulations include compliance with the Clean Water Act (CWA); Clean Air Act (CAA); Coastal Zone Management Act (CZMA); Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA); Endangered Species Act (ESA); Fish and Wildlife Coordination Act (FWCA); Marine Protection, Research, and Sanctuaries Act (MPRSA);

Magnuson-Stevens Fishery Conservation and Management Act (MSFCMA);

National Environmental Policy Act (NEPA); National Historic Preservation Act (NHPA); National Pollutant Discharge Elimination System (NPDES);

Research and Sanctuaries Act (RSA); Native American Graves Protection and Repatriation Act (NAGPRA); Resource Conservation and Recovery Act (RCRA);

Rivers and Harbors Act (R&H); Safe Drinking Water Act (SDWA); Toxic Substance Control Act (TSCA); Wild and Scenic Rivers Act (WSRA); Federal Insecticide, Fungicide, and Rodenticide Act (FIFRA); Marine Mammal Protection Act (MMPA); Migratory Bird Treaty Act (MBTA); Code of Federal Regulations (CFRs); Executive Orders (EO); and,…