B.07_Pre-Bid_Conference_W912EP26BA015_Fort_Pierce_Harbor_OM.pdf
PDF 483 KB Posted
- Solicitation number
- W912EP26BA015
About this file
This is a Pre-Bid Conference presentation for a federal construction contract solicitation. Solicitation W912EP26BA015, issued by the U.S. Army Corps of Engineers Jacksonville District, seeks a contractor for Fort Pierce Harbor Maintenance Dredging in St. Lucie County, Florida. The project involves maintenance dredging of Fort Pierce Harbor with excavated material placed onto Fort Pierce Beach via pipeline access through the South Jetty of Fort Pierce Inlet. Ancillary work includes environmental and water quality monitoring, screening, beach tilling, MEC construction support, and vibration control and monitoring. The contract structure includes a base period and two option periods.
The solicitation uses FAR Part 14 Sealed Bidding with an Invitation for Bid (IFB) for unrestricted competition. The contract type is Firm-Fixed Price, with bids submitted electronically via PIEE by October 13, 2026, at 1:00 pm EDT, followed by bid opening at 2:00 pm EDT via Microsoft Teams. The target price range is $5,000,000 to $10,000,000. Bidders must provide a bid guarantee of 20% of bid price or $3,000,000, whichever is less, and the awardee must submit performance and payment bonds equal to the total bid price within 10 days of award. Liquidated damages are $4,963 per calendar day of delay. The estimated period of performance requires work commencement within 60 days of Notice to Proceed, with completion by May 30, 2027, and full contract work completion by June 30, 2027. The NAICS code is 237990 (Dredging and Surface Cleanup Activities) with a small business size standard of $37.0 million. All amendments must be acknowledged, and technical inquiries close on ProjNet October 2, 2026, at 5:00 pm EDT. Contracting officers are Timothy Humphrey (Contracting Officer) and Meredith Gonzalez (Contract Specialist).
View the file
Other files
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
Working Today to Build a Better Tomorrow
Pre-Bid Conference
Presented by:
Jacksonville District
September 29, 2026
SOLICITATION NO. W912EP26BA015
FORT PIERCE HARBOR MAINTENANCE DREDGING,
ST. LUCIE COUNTY, FLORIDA
Thank you for joining, we will begin shortly.
Please mute your microphone and put your name/company in the chat.
PRE-BID CONFERENCE: AGENDA
• INTRODUCTION
• PROJECT OVERVIEW
• CONTRACTING OVERVIEW
• OTHER ADMINISTRATIVE ITEMS
• RESOURCES
• CLOSING REMARKS
PROJECT OVERVIEW
PRE-BID CONFERENCE: PROJECT OVERVIEW
SOLICITATION NUMBER: W912EP26BA015
PROJECT TITLE: FORT PIERCE HARBOR
MAINTENANCE DREDGING,
ST. LUCIE COUNTY, FLORIDA
DESCRIPTION OF WORK: Project work includes maintenance dredging of Fort Pierce Harbor with excavated material being placed onto Fort Pierce Beach.
Due to the extensive hardbottom areas located offshore of the fill area, offshore pipeline access to the beach site is prohibited. Offload the beach fill inside the South Jetty of Fort Pierce Inlet, as shown on the drawings. A staging area and beach access to the beach placement area are located at the end of Seaway Drive and near the south jetty pumpout location.
Work also includes but is not limited to environmental and water quality monitoring, screening, beach tilling, MEC construction support, and vibration control and monitoring. Work is divided into a base and two options.
CONTRACTING OVERVIEW
Timothy Humphrey, Contracting Officer
Email: Timothy.G.Humphrey@usace.army.mil
Meredith Gonzalez, Contract Specialist Email: Meredith.C.Gonzalez@usace.army.mil mailto:Ruth.C.Rodriguez@usace.army.mil mailto:Meredith.Coad@usace.army.mil
PRE-BID CONFERENCE: ACQUISITION APPROACH
Solicitation No. W912EP26BA015
• Contracting Method: FAR Part 14 Sealed Bidding - Invitation for Bid (IFB), Unrestricted.
• Type of Contract: Firm-Fixed Price (FFP). (FAR clause 52.216-1)
• Transmission Method: Electronically via Procurement Integrated Enterprise Environment (PIEE). Bids must be received by the Government no later than October 13, 2026, at 1:00 pm (EDT). Please see Section 00 21 13 Instructions to Bidders, for more details.
• ALL AMENDMENTS MUST BE ACKNOWLEDGED
FAILURE TO COMPLETE AND RETURN ALL REQUIRED SUBMISSION (SF 1442, SECTION 00 10 00 SOLICITATION, SECTION 00 45 00 REPRESENTATION AND CERTIFICATIONS, CONTRACT LINE ITEM
NUMBER (CLIN) SCHEDULE, AND BID BOND) COULD RENDER YOUR BID NON-RESPONSIVE.
• Bid Opening: October 13, 2026, at 2:00 pm (EDT) via Microsoft Teams. You must be registered in the system for award management (SAM) to receive an award from this solicitation.
PRE-BID CONFERENCE: GENERAL INFORMATION
• Targe Price Range: $5,000,000.00 - $10,000,000.00.
• Applicable North American Industry Classification System (NAICS): 237990 (Exception), Dredging and Surface Cleanup Activities. The Small Business Size Standard for dredging is $37.0 million.
• Estimated Period of Performance: The Contractor shall be required to (a) commence work under this contract within SIXTY (60) calendar days after the date the Contractor receives the Notice to Proceed (NTP), (b) prosecute the work diligently, and (c) complete the entire work ready for use, and be off the beach, not later than 30 May 2027, with 30 June 2027 for the entire contract work. The time stated for completion shall include final cleanup of the premises.
– The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 7 January 2027. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.. (Section 00 73 00)
PRE-BID CONFERENCE: GENERAL INFORMATION
• Liquidated Damages: $4,963.00 for each calendar day of delay until the work is completed or accepted. (FAR clause 52.211-12)
• Bid Guarantee: electronic copy of the bid guarantee shall be submitted with the bid. The bid guarantee shall be 20% of bid price or $3,000,000.00, whichever is less. (FAR clause 52.228-1)
• Payment and Performance Bonds: awardee must submit payment and performance bonds equal to the total bid price within 10 days of contract award. (SF1442 block 12)
SITE VISIT:
• Held on Monday, September 28, 2026, at 10:00 am EDT.
TECHNICAL INQUIRIES AND QUESTIONS:
• ProjNet closes on October 2, 2026, at 5:00 pm, EDT.
• All Inquiries must be submitted via ProjNet for an official answer.
PRE-BID CONFERENCE: OTHER ADMINISTRATIVE ITEMS
PRE-BID CONFERENCE: RESOURCES
System for Award Management (SAM):
www.sam.gov
Procurement Integrated Enterprise Environment (PIEE):
https://piee.eb.mil/
ProjNet:
www.projnet.org http://www.sam.gov/ https://piee.eb.mil/ http://www.projnet.org/
PRE-BID CONFERENCE: QUESTIONS
Please submit any questions via ProjNet.
ProjNet closes on October 2, 2026, by 5PM EDT.
Solicitation Number is: W912EP26BA015 Bidder Inquiry Key is: 6W977C-3PQTIA
PRE-BID CONFERENCE: CLOSING REMARKS
Thank you!
| ����Solicitation No. W912EP26BA015��FORT PIERCE HARBOR MAINTENANCE DREDGING, �ST. LUCIE COUNTY, FLORIDA���� |
| PRE-Bid CONFERENCE: AGENDA |
| Slide Number 3 |
| ��PRE-bid CONFERENCE: PROJECT OVERVIEW�� |
| Slide Number 5 |
| PRE-bid CONFERENCE: Acquisition APPROACH |
| PRE-bid CONFERENCE: GENERAL INFORMATION |
| PRE-bid CONFERENCE: GENERAL INFORMATION |
| ��PRE-bid CONFERENCE: OTHER ADMINISTRATIVE ITEMS�� |
| ��PRE-bid CONFERENCE: resources�� |
| PRE-bid CONFERENCE: Questions |
| �PRE-bid CONFERENCE: CLOSING REMARKS� |
File details come from the government source that posted it. Updated .