B.08 W912EP25BA006TampaHarborMDFY25Volume1Specs_RTA.pdf

W912EP25BA006

Jacksonville District

Tampa Harbor, Maintenance Dredging Upper Channels and Cut-G (PT)

Hillsborough County, Florida

Construction Solicitation and Specifications Volume 1 of 2

17 JUNE 2025

Tampa Harbor, Maintenance Dredging W912EP25BA006 Upper Channels and Cut-G (PT)

DESIGN AUTHENTICATION

I, the undersigned Technical Lead, hereby confirm that all required quality control procedures have been duly followed and completed for this project by the Jacksonville District, U.S. Army Corps of Engineers. This certification is made in accordance with ECB No. 2024-3.

William Heausler, P.E. Date Technical Lead

CESAJ-EN-SN

This project was designed by the Jacksonville District, U.S. Army Corps of Engineers. The initials or signatures and registration designations of individuals appear on these project documents within the scope of their employment as required by ER 1110-1-8152.

Viktoria M. Bogina, P.E. Date Chief, Navigation Section

CESAJ-EN-SN

William L. Reilly, P.E. Date Chief, Waterways Branch

CESAJ-EN-S

Dennis J. Zeveney, P.E. Date Chief, Geosytems Branch

CESAJ-EN-G

Jason A. Engle Date Acting Chief, Engineering Division

CESAJ-EN

REILLY.WILLIAM.LUKE.1527897994 Digitally signed by REILLY.WILLIAM.LUKE.1527897994 Date: 2025.06.06 12:41:56 -04'00'

ZEVENEY.DENNIS.J.1249349085 Digitally signed by ZEVENEY.DENNIS.J.1249349085 Date: 2025.06.06 14:53:49 -04'00'

BOGINA.VIKTORIA.M.1366852472 Digitally signed by BOGINA.VIKTORIA.M.1366852472 Date: 2025.06.09 09:06:01 -04'00'

HEAUSLER.WILLIAM.IAN.15181261

Digitally signed by

HEAUSLER.WILLIAM.IAN.1518126179

Date: 2025.06.09 09:46:59 -04'00'

MARIN.AMANDA.LAVIGNE.1005787277 Digitally signed by MARIN.AMANDA.LAVIGNE.1005787277 Date: 2025.06.09 15:43:16 -04'00'

(See ).

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair) IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

9. FOR

INFORMATION CALL:

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid and "bidder".

SOLICITATION

1. SOLICITATION NUMBER

5. REQUISITION/PURCHASE REQUEST NUMBER

CODE

6. PROJECT NUMBER

8. ADDRESS OFFER TO

4. CONTRACT NUMBER

7. ISSUED BY

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS (Title, identifying number, date)

11. The contractor shall begin performance within

12a. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES", indicate within how many calendar days after award in Item 12b.)

13. ADDITIONAL SOLICITATION REQUIREMENTS:

a. Sealed offers in original and

b. An offer guarantee

c. All offers are subject to the (1) work requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

d. Offers providing less than

STANDARD FORM 1442 (REV. 12/2022)

Prescribed by GSA - FAR (48 CFR) 53.236-1(d) calendar days for Government acceptance after the date offers are due will not be considered and will be rejected.

is, is not required.

local time containing offers shall be marked to show the offeror's name and address, the solicitation number, and the date and time offers are due.

(date). If this is a sealed bid solicitation, offers will be publicly opened at that time. Sealed envelopes copies to perform the work required are due at the place specified in Item 8 by (hour) award, YES NO notice to proceed. This performance period is mandatory negotiable.

calendar days and complete it within calendar days after receiving

a. NAME b. TELEPHONE NUMBER (Include area code) (NO COLLECT CALLS)

12b. CALENDAR DAYS

2. TYPE OF SOLICITATION

SEALED BID (IFB)

INVITATION FOR BID

NEGOTIATED (RFP)

REQUEST FOR PROPOSAL

3. DATE ISSUED PAGE OF PAGES

Created On:

17 Jun 2025, 12:02 PM Central Daylight Time

AWARD (To be completed by Government)

17. The offeror agrees to perform the work required at the prices specified below in strict accordance with the terms of this solicitation, if this offer is accepted calendar days after the date offers are due. (Insert any number equal to or greater than the minimum requirement by the Government in writing within stated in Item 13d. Failure to insert any number means the offeror accepts the minimum in Item 13d.)

OFFER (Must be fully completed by offeror)

AMOUNTS

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT

NUMBER

DATE

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

14. NAME AND ADDRESS OF OFFEROR (Include ZIP Code)

CODE FACILITY CODE

15. TELEPHONE NUMBER (Include area code)

16. REMITTANCE ADDRESS (Include only if different than Item 14.)

20a. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN OFFER (Type or print)

21. ITEMS ACCEPTED:

22. AMOUNT

26. ADMINISTERED BY

30a. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED TO SIGN (Type or print)

31c. DATE

STANDARD FORM 1442 (REV. 12/2022) BACK

31b. UNITED STATES OF AMERICA

BY

31a. NAME OF CONTRACTING OFFICER (Type or print)

29. AWARD (Contractor is not required to sign this document.) Your offer on this solicitation is hereby accepted as to the items listed. This award consummates the contract, which consists of (a) the Government solicitation and your offer, and (b) this contract award. No further contractual document is necessary.

30b. SIGNATURE 30c. DATE

28. NEGOTIATED AGREEMENT (Contractor is required to sign this document and return and deliver all items or perform all work requirements identified on this form and any continuation sheets for the consideration stated in this contract. The rights and obligations of the parties to this contract shall be governed by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certifications, and specifications incorporated by reference in or attached to this contract.

copies to issuing office.) Contractor agrees to furnish

24. SUBMIT INVOICES TO ADDRESS SHOWN IN

(4 copies unless otherwise specified)

23. ACCOUNTING AND APPROPRIATION DATA

ITEM

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO THE UNITED STATES

CODE AT

27. PAYMENT WILL BE MADE BY

10 U.S.C. 3204(a) ( ) 41 U.S.C. 3304(a) ( )

20b. SIGNATURE 20c. OFFER DATE

Section 00 00 00 - Procurement and Contracting Requirements

Tampa Harbor, Maintenance Dredging, Upper Channels and Cut-G (PT), Hillsborough County, Florida

Section 00 01 10 - Table of Contents

SOLICITATION, OFFER, AND AWARD SF 1442 and SF 1442 BACK

SECTION 00 10 00 - BID SCHEDULE, NOTES

SECTION 00 21 00 - INSTRUCTIONS, CONDITIONS AND NOTICES TO OFFERORS

SECTION 00 45 00 - REPRESENTATIONS & CERTIFICATIONS

SECTION 00 70 00 - CONTRACT CLAUSES

SECTION 00 73 00 - SPECIAL CONTRACT REQUIREMENTS

SECTION 01 00 00 - GENERAL REQUIREMENTS

Attachments - See table in Section 00 01 15

Section 00 10 00 - Solicitation, Contract Line Item Number (CLIN) Schedule

Additional Information/Notes

Item Supplies/Service Quantity Unit Unit Price Amount

MOBILIZATION AND DEMOBILIZATION

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

1 Job

EXCAVATION, UNCLASSIFIED

UPPER

CHANNELS (ESTIMATED QUANTITY, SEE

NOTE 2)

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

293,000 Cubic Yard

EXCAVATION, UNCLASSIFIED

CUT-G (PT)

(ESTIMATED QUANTITY, SEE NOTE 2)

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

73,000 Cubic Yard

TURBIDITY MONITORING

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

1 Job

ENVIRONMENTAL SPECIES MONITORING

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

1 Job

BIRD MONITORING

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

1 Job

MOBILIZATION AND DEMOBILIZATION

FOR

SEA TURTLE TRAWLING (HOPPER

DREDGE ONLY, SEE NOTE 3)

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

1 Job

SEA TURTLE TRAWLING AND

RELOCATION

(HOPPER DREDGE ONLY, SEE

NOTE 3)

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

1 Days

STANDBY TIME (SEE NOTE 4)

W912EP25BA006

0009 24 Hours

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

PARTNERING REGROUP

Claimant Program Code: C2 Pricing Arrangement: Firm Fixed Price

1 Each

W912EP25BA006

TOTAL BID (LINE ITEMS 0001 THROUGH 0010) $______________

NOTES:

(1) OFFER MUST PRICE ALL LINE ITEMS.

(2) QUANTITY INCLUDES REQUIRED DEPTH, ALLOWABLE OVERDEPTH, AND SHOALING ESTIMATED TO OCCUR

BETWEEN THE DATES OF THE SURVEYS SHOWN ON THE DRAWINGS AND ACTUAL DREDGING.

(3) SEA TURTLE TRAWLING IS REQUIRED IN ACCORDANCE WITH SECTION 01 57 20 ENVIRONMENTAL PROTECTION.

(4) STANDBY TIME IS DEFINED AS WHEN, AT THE DIRECTION OF THE CONTRACTING OFFICER, THE DREDGE IS PUT OUT OF OPERATION FOR REASONS OUTSIDE THE REQUIREMENTS IN THE CONTRACT. SEE SECTION

01 20 00 PRICE AND PAYMENT PROCEDURES.

SECTION 00010A, Attachment A

INSTRUCTIONS FOR TECHNICAL INQUIRIES AND QUESTIONS

Technical inquiries and questions relating to this solicitation are to be submitted via Bidder Inquiry in ProjNet at (https://www.projnet.org) No Later Than (NLT) July 10, 2025, 5:00 p.m. EDT. To submit and review inquiry items, prospective vendors will need to use the Bidder Inquiry Key presented below and follow the instructions listed below the key for access. A prospective vendor who submits a comment /question will receive an acknowledgement of their comment/question via email, followed by an answer to the comment/question after it has been processed by our technical team.

All timely questions and approved answers will be made available through ProjNet.

The Solicitation Number is: W912EP25BA006

The Bidder Inquiry Key is: 44DSFK-235RQJ

Specific Instructions for ProjNet Bid Inquiry Access from ProjNet home page:

1. Identify the Agency. This should be marked as USACE.

2. Email. Enter the email address you would like to use for communication.

3. Key. Enter the Bidder Inquiry Key listed above.

4. Click Continue. A page will then open saying that a user account was not found and will ask you to create one using the provided form.

5. Enter your First Name, Last Name, Company, City, State, Phone, Email, Secret Question, Secret

Answer, and Time Zone. Make sure to remember your Secret Question and Answer as they will be used from this point on to access the ProjNet system.

6. Click Add User. Once this is completed you are now registered within ProjNet and are currently logged into the system.

Specific Instructions for Future ProjNet Bid Inquiry Access from ProjNet home page:

1. For future access to ProjNet, you will not be emailed any type of password. You will utilize your Secret Question and Secret Answer to log in.

2. Identify the Agency. This should be marked as USACE.

3. Email. Enter the email address you used to register previously in ProjNet.

4. Key. Enter the Bidder Inquiry Key listed above.

5. Click Continue. A page will then open asking you to enter the answer to your Secret Question.

6. Enter your Secret Answer and click Login. Once this is completed you are now logged into the system.

Section 00 21 00 - Instructions

FAR Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.204-7 System for Award Management. Nov 2024 52.204-16 Commercial and Government Entity Code Reporting. Aug 2020 52.204-22 Alternative Line Item Proposal. Jan 2017

52.211-2 Availability of Defense Specifications, Standards, and Data Item Descriptions in the Acquisition Streamlining and Standardization Information System (ASSIST) website.

Sep 2023

52.214-3 Amendments to Invitations for Bids. Dec 2016 52.214-4 False Statements in Bids. Apr 1984 52.214-5 Submission of Bids. Dec 2016 52.214-6 Explanation to Prospective Bidders. Apr 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids. Nov 1999 52.214-10 Contract Award-Sealed Bidding. Jul 1990 52.214-12 Preparation of Bids. Apr 1984 52.214-34 Submission of Offers in the English Language. Apr 1991 52.214-35 Submission of Offers in U.S. Currency. Apr 1991 52.225-12 Notice of Buy American Requirement-Construction Materials Under Trade Agreements. May 2014

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

Nov 2023 Mar 2023 Jan 2023

(Apr 1984)

252.204-7019 Notice of NIST SP 800-171 DoD Assessment Requirements.

252.204-7024 Notice on the Use of the Supplier Performance Risk System.

252.215-7013 Supplies and Services Provided by Nontraditional Defense Contractors.

FAR Clauses Incorporated by Full Text

52.216-1 Type of Contract.

Type of Contract (Apr 1984)

The Government contemplates award of a Firm Fixed Priced contract resulting from this solicitation.

(End of provision)

52.228-1 Bid Guarantee. (Sep 1996)

Bid Guarantee (Sept 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States. The Contracting Officer will return bid guarantees, other than bid bonds-

(1) To unsuccessful bidders as soon as practicable after the opening of bids; and

(2) To the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.

(c) The amount of the bid guarantee shall be twenty (20) percent of the bid price or $3,000,000.00, whichever is less.

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

(End of clause)

52.233-2 Service of Protest. (Sep 2006)

Service of Protest (Sept 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from person identified in item 9A of the SF1442 at the address in block 7 of the SF1442.

(b) The copy of any protest shall be received in the office designated above within oneday of filing a protest with the GAO.

(End of provision)

52.236-27 Site Visit (Construction). (Alternate I) (Feb 1995) Alternate I (Feb 1995)

Alternate I (Feb 1995). If an organized site visit will be conducted, substitute a paragraph substantially the same as the following for paragraph (b) of the basic provision:

(b) An organized site visit has been scheduled for Tuesday, July 1, 2025, at 9:00AM, EDT.

(c) Participants should contact Yvette Powell at Yvette.L.Powell@usace.army.mil on or before Friday, June 27, 2025 by 5:00 PM, EDT, to make arrangements. If you have any questions please call Yvette Powell at 813-574-8461.

(d) d) A Pre-Bid Conference will be held virtually on Wednesday, July 2, 2025, at 11:00 AM, EDT. Please utilize the link and call information provided below: LINK: HTTPS://WWW.MICROSOFT.COM/EN-US/MICROSOFT-TEAMS/JOIN-A-MEETING MEETING ID: 993 221 059 39 / PASSCODE: Qe9Yh7Q8

DIAL IN BY PHONE: +1 601-262-2433 / PHONE CONFERENCE ID: 281 249 944#

(End of provision)

52.252-1 Solicitation Provisions Incorporated by Reference. (Feb 1998)

Solicitation Provisions Incorporated by Reference (Feb 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

https://www.acquisition.gov/content/regulations

(End of provision)

52.252-5 Authorized Deviations in Provisions. (Nov 2020)

Authorized Deviations in Provisions (Nov 2020)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense Federal Acquisition Regulation (48 CFR Chapter 2) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

(End of provision)

Section 00 21 13 - Instructions to Bidders

ELECTRONIC BIDS

(a) Definition:

Electronic bid, as used in this provision, means a bid, revision or modification of a bid, or withdrawal of a bid that is transmitted to and received by the Government via email or other means for transmitting electronic data. No flash drives will be accepted.

(b) Offerors must submit electronic bids in responses to this solicitation in order to be considered for award.

Electronic bids are subject to the same rules as paper bids.

(c) If any portion of bid received by the Contracting Officer is unreadable to the degree that conformance to the essential requirements of the solicitation cannot be ascertained from the document.

(1) The Contracting Officer shall immediately notify the offeror and permit the offeror to resubmit the bid if the bid has been received prior to due date indicated in the solicitation.

(2) The method and time for resubmission shall by prescribed by the Contracting Officer after consultation with the offeror.

(d) The Government reserves the right to make award solely on the electronic bid. However, if requested to do so by the Contracting Officer, the apparently successful offeror shall submit the complete original signed bid.

(e) The Offeror's bid shall be submitted electronically, as described below. The use of hyperlinks in the bid is prohibited. The offeror's bid is due no later than .1:00 PM (EDT) on 21 July 2025

NOTE: The only authorized transmission method of bids in response to the subject solicitation is electronically via the Procurement Integrated Enterprise Environment (PIEE) website. No other transmission methods, such as email, facsimile, hand-carried, proprietary or DOD SAFE submissions, bids submitted by mail, ect. will be accepted. Offers submitted via any other transmission method other than the Procurement Integrated Enterprise Environment (PIEE) website will not be evaluated.

The Offeror's bid must be received by the Government no later than the date/time specified in the solicitation and cited above. Offerors shall submit their bid using the following link: Instructions for submitting electronic bids:https://piee.eb.mil/

In an effort to reduce paperwork and cost, all bids shall be submitted electronically through the Procurement Integrated Enterprise Environment (PIEE) website.

Electronic copies of each volume shall be submitted through the Solicitation Module of PIEE at . If there is a system outage, see https://piee.eb.mil below. All bids received after the exact time specified for receipt shall be treated as late submissions.

For instructions on how to post an offer, please refer to the Posting Offer demo: .https://pieetraining.eb.mil/wbt/sol/Posting_Offer.pdf

It is the Offeror's responsibility to obtain written confirmation of receipt of all electronic files of the full bid by the Contracting office. The submission date for all Volumes shall be no later than the date and time specified in Block 13 of the SF 1442 of the Solicitation. In the unlikely event the PIEE system is not operational, experiences technical difficulties, or a Contractor is temporarily unable to access or use the system, the Contractor shall immediately notify the Contracting Officer. This Notification must occur prior to the bid submission deadline.

Contractor notification shall be in writing and may be in conjunction with verbal notification, but verbal notification alone shall not be sufficient.

The alternate method for bid submission is via expedited delivery or hand-carried. The Offeror must obtain prior approval from the Contracting Officer to use the alternate submission method. The Contractor shall have 24 hours to provide their bid upon contracting officer approval. In the event that the Contractor alleges technical difficulties and does not notify the contracting officer until after the closing date and time, the contracting officer will follow the procedures identified in the Federal Acquisition Regulation (FAR) and then make a determination if the Contractor's late bid submission is accepted. Screen shots of the submission should be taken to validate a submission was accepted in the PIEE system.

You are limited to five (5) maximum files per upload (total size cannot exceed 2GB). If you have a large number of files, it is recommended that you combine or ZIP your files before uploading to the PIEE site. Offerors may use compression utility software such as WinZip or PKZip to reduce file size and facilitate transmission.

File Description:

To ensure your submission is received and processed appropriately, it is important that interested parties CAREFULLY ensure their electronic files adhere to the following naming convention. Each file name shall begin with the solicitation number, followed by the word "RESPONSE", followed by your firm's name and finally a brief file description.

EXAMPLE:

"W912EP25BA006 RESPONSE FIRM NAME.pdf"

W912EP25BA006

https://piee.eb.mil/ https://piee.eb.mil https://pieetraining.eb.mil/wbt/sol/Posting_Offer.pdf

File Organization, Formatting, and other instructions:

Although hard copies are not accepted, each file shall be clearly indexed, and logically assembled. Font size shall be 10 or larger.

Pages shall be letter sized--larger page sizes (such as 11x17 foldouts, etc.) will be counted as two pages. Offerors shall prepare bids in the English language. Bids shall be in a narrative format, organized and titled so that each section of the bid follows the order and format of the factors.

Information presented should be organized so as to pertain to only the evaluation factor in the section that the information is presented. Information pertaining to more than one evaluation factor should be repeated in each section for each factor.

Include a "File Description" for each file(s) you upload. The "File Description" will be included in the email notice to each of the recipients you choose to have access your file(s).

NOTE: Do NOT enter Privacy Act Data (Personal Identification Information (PII)) in the File Description.)

Upload Completion & Deadline:

Interested parties shall submit responses no later than the date cited above. Offerors should time their upload effort with prudence by not waiting until the last few minutes--this will allow for unexpected delays in the transmittal process. Submissions after the deadline may be emailed to Contract Specialist Nicole Batista-Cruz at (Nicole.M.Batista-Cruz@usace.army.mil) but be advised, they will be considered late and as such, will be processed in accordance with FAR 15.208.

Submission shall be in Adobe PDF format.

Receipt of Submission:

For the purposes of establishing whether a bid submission is considered timely, the Government considers the date and time the submission is completely uploaded into the PIEE website. For multiple submissions, the Government will consider the date and time the last submission is completely uploaded into the PIEE website. Do not assume that electronic communication is instantaneous. It can take several minutes or even hours in some cases. The Government will not be responsible for submissions delivered to any location or to anyone other than those designated to receive bids. Offerors are responsible for ensuring that offers are submitted so as to reach the designated recipient. Offerors are responsible for allowing sufficient time for the offer to be received in accordance with the instructions provided.

Section 00 45 00 - Representations and Certifications

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.203-11 Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions.

Sep 2024

52.204-17 Ownership or Control of Offeror. Aug 2020

52.204-24 Representation Regarding Certain Telecommunications and Video Surveillance Services or Equipment.

Nov 2021

52.204-26 Covered Telecommunications Equipment or Services-Representation. Oct 2020 52.204-29 Federal Acquisition Supply Chain Security Act Orders-Representation and Disclosures. Dec 2023 52.209-5 Certification Regarding Responsibility Matters. Aug 2020 52.209-7 Information Regarding Responsibility Matters. Oct 2018 52.229-12 Tax on Certain Foreign Procurements. Feb 2021

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.203-7005 Representation Relating to Compensation of Former DoD Officials. Sep 2022 252.204-7008 Compliance with Safeguarding Covered Defense Information Controls. Oct 2016 252.204-7016 Covered Defense Telecommunications Equipment or Services-Representation. Dec 2019

252.204-7017 Prohibition on the Acquisition of Covered Defense Telecommunications Equipment or Services-Representation.

May 2021

252.225-7055 Representation Regarding Business Operations with the Maduro Regime. May 2022

252.225-7059 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region- Representation.

Jun 2023

FAR Clauses Incorporated by Full Text

52.204-8 Annual Representations and Certifications. (Jan 2025)

Annual Representations and Certifications (Jan 2025)

(a)

(1) The North American Industry Classification System (NAICS) code for this acquisition is 237990.

(2) The small business size standard is $37,000,000.00.

(3) The small business size standard for a concern that submits an offer, other than on a construction or service acquisition, but proposes to furnish an end item that it did not itself manufacture, process, or produce is 500 employees, or 150 employees for information technology value-added resellers under NAICS code 541519 if the acquisition-

(i) Is set aside for small business and has a value above the simplified acquisition threshold;

(ii) Uses the HUBZone price evaluation preference regardless of dollar value, unless the offeror waives the price evaluation preference; or

(iii) Is an 8(a), HUBZone, service-disabled veteran-owned, economically disadvantaged women-owned, or women-owned small business set-aside or sole-source award regardless of dollar value.

(b)

(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (d) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (d) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

(i) [ ] Paragraph (d) applies.

(ii) [ ] Paragraph (d) does not apply and the offeror has completed the individual representations and certifications in the solicitation.

(c)

(1) The following representations or certifications in SAM are applicable to this solicitation as indicated:

(i) 52.203-2, Certificate of Independent Price Determination. This provision applies to solicitations when a firm-fixed-price contract or fixed-price contract with economic price adjustment is contemplated, unless-

(A) The acquisition is to be made under the simplified acquisition procedures in part 13;

(B) The solicitation is a request for technical proposals under two-step sealed bidding procedures; or

(C) The solicitation is for utility services for which rates are set by law or regulation.

(ii) 52.203-11, Certification and Disclosure Regarding Payments to Influence Certain Federal Transactions. This provision applies to solicitations expected to exceed $150,000.

(iii) 52.203-18, Prohibition on Contracting with Entities that Require Certain Internal Confidentiality Agreements or Statements-Representation. This provision applies to all solicitations.

(iv) 52.204-3, Taxpayer Identification. This provision applies to solicitations that do not include the provision at 52.204-7, System for Award Management.

(v) 52.204-5, Women-Owned Business (Other Than Small Business). This provision applies to solicitations that-

(A) Are not set aside for small business concerns;

(B) Exceed the simplified acquisition threshold; and

(C) Are for contracts that will be performed in the United States or its outlying areas.

(vi) 52.204-26, Covered Telecommunications Equipment or Services-Representation. This provision applies to all solicitations.

(vii) 52.209-2, Prohibition on Contracting with Inverted Domestic Corporations-Representation.

(viii) 52.209-5, Certification Regarding Responsibility Matters. This provision applies to solicitations where the contract value is expected to exceed the simplified acquisition threshold.

(ix) 52.209-11, Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law. This provision applies to all solicitations.

(x) 52.214-14, Place of Performance-Sealed Bidding. This provision applies to invitations for bids except those in which the place of performance is specified by the Government.

(xi) 52.215-6, Place of Performance. This provision applies to solicitations unless the place of performance is specified by the Government.

(xii) 52.219-1, Small Business Program Representations (Basic, Alternates I, and II). This provision applies to solicitations when the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(A) The basic provision applies when the solicitations are issued by other than DoD, NASA, and the Coast Guard.

(B) The provision with its Alternate I applies to solicitations issued by DoD, NASA, or the Coast Guard.

(C) The provision with its Alternate II applies to solicitations that will result in a multiple-award contract with more than one NAICS code assigned.

(xiii) 52.219-2, Equal Low Bids. This provision applies to solicitations when contracting by sealed bidding and the contract is for supplies to be delivered or services to be performed in the United States or its outlying areas, or when the contracting officer has applied part 19 in accordance with 19.000(b)(1)(ii).

(xiv) 52.222-22, Previous Contracts and Compliance Reports. This provision applies to solicitations that include the clause at 52.222-26, Equal Opportunity.

(xv) 52.222-25, Affirmative Action Compliance. This provision applies to solicitations, other than those for construction, when the solicitation includes the clause at 52.222-26, Equal Opportunity.

(xvi) 52.222-38, Compliance with Veterans' Employment Reporting Requirements. This provision applies to solicitations when it is anticipated the contract award will exceed the simplified acquisition threshold and the contract is not for acquisition of commercial products or commercial services.

(xvii) 52.223-1, Biobased Product Certification. This provision applies to solicitations that require the delivery or specify the use of biobased products in USDA-designated product categories; or include the clause at 52.223-2, Reporting of Biobased Products Under Service and Construction Contracts.

(xviii) 52.223-4, Recovered Material Certification. This provision applies to solicitations that are for, or specify the use of, EPA-designated items.

(xix) 52.223-22, Public Disclosure of Greenhouse Gas Emissions and Reduction Goals-Representation. This provision applies to solicitations that include the provision at 52.204-7.

(xx) 52.225-2, Buy American Certificate. This provision applies to solicitations containing the clause at 52.225-1.

(xxi) 52.225-4, Buy American-Free Trade Agreements-Israeli Trade Act Certificate. (Basic, Alternates II and III.) This provision applies to solicitations containing the clause at 52.225-3.

(A) If the acquisition value is less than $50,000, the basic provision applies.

(B) If the acquisition value is $50,000 or more but is less than $100,000, the provision with its Alternate II applies.

(C) If the acquisition value is $100,000 or more but is less than $102,280, the provision with its Alternate III applies.

(xxii) 52.225-6, Trade Agreements Certificate. This provision applies to solicitations containing the clause at 52.225-5.

(xxiii) 52.225-20, Prohibition on Conducting Restricted Business Operations in Sudan-Certification. This provision applies to all solicitations.

(xxiv) 52.225-25, Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-Representation and Certifications. This provision applies to all solicitations.

(xxv) 52.226-2, Historically Black College or University and Minority Institution Representation. This provision applies to solicitations for research, studies, supplies, or services of the type normally acquired from higher educational institutions.

(2) The following representations or certifications are applicable as indicated by the Contracting Officer:

[Contracting Officer check as appropriate.]

[ ] (i) 52.204-17, Ownership or Control of Offeror.

[ ] (ii) 52.204-20, Predecessor of Offeror.

[ ] (iii) 52.222-18, Certification Regarding Knowledge of Child Labor for Listed End Products.

[ ] (iv) 52.222-48, Exemption from Application of the Service Contract Labor Standards to Contracts for Maintenance, Calibration, or Repair of Certain Equipment- Certification.

[ ] (v) 52.222-52, Exemption from Application of the Service Contract Labor Standards to Contracts for Certain Services-Certification.

[ ] (vi) 52.227-6, Royalty Information.

[ ] (A) Basic.

[ ] (B) Alternate I.

[ ] (vii) 52.227-15, Representation of Limited Rights Data and Restricted Computer Software.

(d) The offeror has completed the annual representations and certifications electronically in SAM website accessed through https://www.sam.gov.

After reviewing the SAM information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in paragraph (c) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [offeror to insert changes, identifying change by clause number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications posted on SAM.

(End of provision)

52.209-11 Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law.

(Feb 2016)

Representation by Corporations Regarding Delinquent Tax Liability or a Felony Conviction under any Federal Law (Feb 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that-

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that-

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

(End of provision)

DFARS Clauses Incorporated by Full Text

252.204-7007 Alternate A, Annual Representations and Certifications. (Oct 2024) Alternate A (Oct 2024)

ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (OCT 2024)

Substitute the following paragraphs (b), (d), and (e) for paragraphs (b) and (d) of the provision at FAR 52.204-8:

(b)(1) If the provision at 52.204-7, System for Award Management, is included in this solicitation, paragraph (e) of this provision applies.

(2) If the provision at 52.204-7, System for Award Management, is not included in this solicitation, and the Offeror has an active registration in the System for Award Management (SAM), the Offeror may choose to use paragraph (e) of this provision instead of completing the corresponding individual representations and certifications in the solicitation. The Offeror shall indicate which option applies by checking one of the following boxes:

[ ] (i) Paragraph (e) applies.

[ ] (ii) Paragraph (e) does not apply and the Offeror has completed the individual representations and certifications in the solicitation.

(d)(1) The following representations or certifications in the SAM database are applicable to this solicitation as indicated:

(i) 252.204-7016, Covered Defense Telecommunications Equipment or Services-Representation. Applies to all solicitations.

(ii) 252.216-7008, Economic Price Adjustment-Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(iv) 252.225-7049, Prohibition on Acquisition of Certain Foreign Commercial Satellite Services-Representations. Applies to solicitations for the acquisition of commercial satellite services.

(v) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vi) 252.229-7012, Tax Exemptions (Italy)-Representation. Applies to solicitations and contracts when contract performance will be in Italy.

(vii) 252.229-7013, Tax Exemptions (Spain)-Representation. Applies to solicitations and contracts when contract performance will be in Spain.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

[ ](i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

[ ](ii) 252.225-7000, Buy American-Balance of Payments Program Certificate.

[ ](iii) 252.225-7020, Trade Agreements Certificate.

[ ] Use with Alternate I.

[ ](iv) 252.225-7031, Secondary Arab Boycott of Israel.

[ ](v) 252.225-7035, Buy American-Free Trade Agreements-Balance of Payments Program Certificate.

[ ] Use with Alternate I.

[ ] Use with Alternate II.

[ ] Use with Alternate III.

[ ] Use with Alternate IV.

[ ] Use with Alternate V.

[ ](vi) 252.226-7002, Representation for Demonstration Project for Contractors Employing Persons with Disabilities.

[ ](vii) 252.232-7015, Performance-Based Payments-Representation.

(e) The Offeror has completed the annual representations and certifications electronically via the SAM website at https://www.sam.gov. After reviewing the SAM database information, the Offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below [Offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Provision # Title Date Change

Any changes provided by the Offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

(End of provision)

Section 00 70 00 - Conditions of the Contract

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

52.203-3 Gratuities. Apr 1984 52.203-5 Covenant Against Contingent Fees. May 2014 52.203-6 Restrictions on Subcontractor Sales to the Government. (Alternate I) Jun 2020 Alternate I Nov 2021 52.203-7 Anti-Kickback Procedures. Jun 2020

52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or Improper Activity.

May 2014

52.203-10 Price or Fee Adjustment for Illegal or Improper Activity. May 2014 52.203-12 Limitation on Payments to Influence Certain Federal Transactions. Jun 2020 52.203-13 Contractor Code of Business Ethics and Conduct. Nov 2021 52.204-13 System for Award Management Maintenance. Oct 2018 52.204-18 Commercial and Government Entity Code Maintenance. Aug 2020 52.204-19 Incorporation by Reference of Representations and Certifications. Dec 2014

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, Proposed for Debarment, or Voluntarily Excluded

Jan 2025

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters. Oct 2018 52.209-10 Prohibition on Contracting with Inverted Domestic Corporations. Nov 2015 52.210-1 Market Research. Nov 2021 52.211-18 Variation in Estimated Quantity. Apr 1984 52.219-9 Small Business Subcontracting Plan. (Alternate I) Jan 2025 Alternate I Nov 2016 52.222-3 Convict Labor. Jun 2003 52.222-7 Withholding of Funds. May 2014 52.222-50 Combating Trafficking in Persons. Nov 2021 52.222-54 Employment Eligibility Verification. Jan 2025 52.223-23 Sustainable Products and Services. (DEVIATION 2025-O0004) May 2024 Deviation 2025-O0004 Mar 2025 52.225-13 Restrictions on Certain Foreign Purchases. Feb 2021 52.232-23 Assignment of Claims. May 2014 52.232-39 Unenforceability of Unauthorized Obligations. Jun 2013 52.233-1 Disputes. May 2014 52.233-3 Protest after Award. Aug 1996 52.233-4 Applicable Law for Breach of Contract Claim. Oct 2004 52.236-2 Differing Site Conditions. Apr 1984 52.236-3 Site Investigation and Conditions Affecting the Work. Apr 1984 52.236-5 Material and Workmanship. Apr 1984 52.236-6 Superintendence by the Contractor. Apr 1984 52.236-7 Permits and Responsibilities. Nov 1991 52.236-8 Other Contracts. Apr 1984

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements.

Apr 1984

52.236-10 Operations and Storage Areas. Apr 1984 52.236-11 Use and Possession Prior to Completion. Apr 1984 52.236-12 Cleaning Up. Apr 1984 52.236-13 Accident Prevention. Nov 1991 52.236-15 Schedules for Construction Contracts. Apr 1984 52.236-17 Layout of Work. Apr 1984 52.236-21 Specifications and Drawings for Construction. Feb 1997 52.242-13 Bankruptcy. Jul 1995 52.242-14 Suspension of Work. Apr 1984 52.243-4 Changes. Jun 2007 52.249-1 Termination for Convenience of the Government (Fixed-Price) (Short Form). Apr 1984 52.249-2 Termination for Convenience of the Government (Fixed-Price). Apr 2012 52.249-10 Default (Fixed-Price Construction). Apr 1984

DFARS Clauses Incorporated by Reference

Number Title Effective Date

Alternate/ Deviation

Variation Effective Date

252.219-7003 Small Business Subcontracting Plan (DoD Contracts). Dec 2019 252.223-7008 Prohibition of Hexavalent Chromium. Jan 2023 252.225-7056 Prohibition Regarding Business Operations with the Maduro Regime. Jan 2023 252.225-7060 Prohibition on Certain Procurements from the Xinjiang Uyghur Autonomous Region. Jun 2023 252.232-7010 Levies on Contract Payments. Dec 2006 252.244-7000 Subcontracts for Commercial Products or Commercial Services. Nov 2023

252.247-7023 Transportation of Supplies by Sea. Oct 2024

FAR Clauses Incorporated by Full Text

52.204-1 Approval of Contract. (Dec 1989)

Approval of Contract (Dec 1989)

This contract is subject to the written approval of Contracting Officer and shall not be binding until so approved.

(End of clause)

52.211-10 Commencement, Prosecution, and Completion of Work. (Apr 1984)

Commencement, Prosecution, and Completion of Work (Apr 1984)

The Contractor shall be required to (a) commence work under this contract within 60 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 210 calendar days after the date the Contractor receives the notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

52.211-12 Liquidated Damages-Construction. (Sep 2000)

Liquidated Damages-Construction (Sept 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,973.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

52.232-5 Payments under Fixed-Price Construction Contracts. (May 2014)

Payments under Fixed-Price Construction Contracts (May 2014)

(a) Payment of price. The Government shall pay the Contractor the contract price as provided in this contract.

(b) Progress payments. The Government shall make progress payments monthly as the work proceeds, or at more frequent intervals as determined by the Contracting Officer, on estimates of work accomplished which meets the standards of quality established under the contract, as approved by the Contracting Officer.

(1) The Contractor's request for progress payments shall include the following substantiation:

(i) An itemization of the amounts requested, related to the various elements of work required by the contract covered by the payment requested.

(ii) A listing of the amount included for work performed by each subcontractor under the contract.

(iii) A listing of the total amount of each subcontract under the contract.

(iv) A listing of the amounts previously paid to each such subcontractor under the contract.

(v) Additional supporting data in a form and detail required by the Contracting Officer.

(2) In the preparation of estimates, the Contracting Officer may authorize material delivered on the site and preparatory work done to be taken into consideration. Material delivered to the Contractor at locations other than the site also may be taken into consideration if-

(i) Consideration is specifically authorized by this contract; and

(ii) The Contractor furnishes satisfactory evidence that it has acquired title to such material and that the material will be used to perform this contract.

(c) Contractor certification. Along with each request for progress payments, the Contractor shall furnish the following certification, or payment shall not be made: (However, if the Contractor elects to delete paragraph (c)(4) from the certification, the certification is still acceptable.)

I hereby certify, to the best of my knowledge and belief, that-

(1) The amounts requested are only for performance in accordance with the specifications, terms, and conditions of the contract;

(2) All payments due to subcontractors and suppliers from previous payments received under the contract have been made, and timely payments will be made from the proceeds of the payment covered by this certification, in accordance with subcontract agreements and the requirements of Chapter 39 of Title 31, United States Code;

(3) This request for progress payments does not include any amounts which the prime contractor intends to withhold or retain from a subcontractor or supplier in accordance with the terms and conditions of the subcontract; and

(4) This certification is not to be construed as final acceptance of a…