B.07.01 Pre-Bid WebEx Presentation (22B0009 Jax Harbor).pptx
PPTX presentation 6 MB Posted
- Solicitation number
- w912ep22b0009
About this file
This pre-bid presentation outlines a federal contract opportunity for maintenance dredging of portions of the Jacksonville Harbor channel in Duval County, Florida. The project involves dredging approximately 1.7 million cubic yards of material from sections of the harbor channel and disposing of it at designated disposal sites. Work will be divided between a base bid and four options, and includes turbidity monitoring, endangered species observation, sea turtle protection measures, bird monitoring, and disposal area pumpout. Interested parties must submit electronic bids no later than August 8, 2022. The contract value is estimated between $20-35 million. The period of performance is 255 calendar days from notice to proceed. The Navy Corps of Engineers Engineering District Jacksonville will administer this unrestricted contract for maintenance dredging services.
View the file
Other files
Show all 11
On GovTribe
Work with this file
- Download the original file
- Contacts named in this file
- Similar government files
- Ask GovTribe AI about this file
Text version
PRE-BID CONFERENCE
SOLICITATION NO. W912EP22B0009
Jacksonville Harbor, Maintenance Dredging, 47-foot, 40-Foot, 38-Foot & 34-Foot Project-Duval County, Florida
Thank you for joining, we will begin shortly.
Please mute your microphone.
Working Today to Build a Better Tomorrow
PRE-Bid CONFERENCE: AGENDA
INTRODUCTION
PROJECT INFORMATION
SUBJECT REQUIREMENTS
OTHER ADMINISTRATIVE ITEMS
Q&A SESSION
CLOSING REMARKS
PRE-bid CONFERENCE: PROJECT INFORMATION
SOLICITATION NUMBER: W912EP22B0009
PROJECT TITLE: JACKSONVILLE HARBOR, MAINTENANCE DREDGING, 47-FOOT, 40-FOOT, 38-FOOT & 34-FOOT PROJECT-DUVAL COUNTY, FLORIDA
DESCRIPTION OF WORK: Project work consists of maintenance dredging portions of the Jacksonville Harbor channel between Bar Cut-3 and Upper Terminal Channel including portions of Cut-F and Cut-G. Work will be divided into a Base and four options as indicated in Section 00010A LINE ITEMS AND PRICING SCHEDULE and on the drawings.
Disposal of materials will be at Buck Island Cell A and Bartram Island Cell A as shown on the drawings. Work also includes turbidity monitoring, endangered species observers (hopper dredges only), sea turtle trawl-sweeping (hopper dredges only), marine animal observer (mechanical dredges only), bird monitoring, and disposal area pumpout.
MAGNITUDE OF CONSTRUCTION: $20,000,000.00 - $35,000,000.00.
52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984):
The Contractor shall be required to (a) commence work under this contract within 60 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 255 calendar days after receipt of the Notice to Proceed (NTP). The time stated for completion shall include final cleanup of the premises.
The total completion time of 255 calendar days includes the following:
| Base Bid 158 calendar days (includes 60 calendar days mob/demob) |
| Option A – 10 Calendar Days |
| Option B – 25 Calendar Days |
| Option C – 20 Calendar Days |
| Option D – 42 Calendar Days |
52.211-12 LIQUIDATED DAMAGES--CONSTRUCTION (SEP 2000):
If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $4,608 for each calendar day of delay until the work is completed or accepted.
52.217-7 OPTION FOR INCREASED QUANTITY--SEPARATELY PRICED LINE ITEM (MAR
1989)
The Government may require the delivery of the numbered line item, identified in the Schedule as an option item, in the quantity and at the price stated in the Schedule. The Contracting Officer may exercise the options A and B by written notice to the Contractor within on or before 3 March 2023. Delivery of added items shall continue at the same rate that like items are called for under the contract, unless the parties otherwise agree.
PRE-bid CONFERENCE: Subject REQUIREMENTS
TYPE OF SOLICITATION: Unrestricted
The subject requirement will be procured as a FFP contract pursuant to FAR 16.202-2, whereas there is adequate price competition; there are reasonable price comparisons with prior purchases of the same or similar supplies or services made on a competitive basis or supported by valid certified cost or pricing data; and performance uncertainties can be identified and reasonable estimates of their cost impact can be made, and the contractor is willing to accept a firm fixed price representing assumption of the risks involved.
PRE-bid CONFERENCE: submission REQUIREMENTS
TRANSMISSION METHOD:
Offers are due electronically by 2:00PM, eastern on August 8, 2022.
The Offeror’s bid must be received by the Government no later than the date/time specified in the solicitation. Offerors shall submit their bid using the following link: https://piee.eb.mil/
Please utilize the link above to send bids to the Contracting Officer, Tedra N. Thompson and Contract Specialist, Guesley Leger.
All Amendments must be acknowledged. (Any Forthcoming Amendments)
SITE VISIT: Held on July 19th, 2022, at 9:00 am EDT
INSTRUCTIONS FOR TECHNICAL INQUIRIES AND QUESTIONS:
ProjNet closes on July 22, 2022, at 5:00 pm, eastern.
All Inquiries must be entered into ProjNet for an official answer.
PRE-bid CONFERENCE: OTHER ADMINISTRATIVE ITEMS
PRE-bid CONFERENCE: Q&a
PRE-bid CONFERENCE: CLOSING REMARKS
PROJECT DELIVERY TEAM:
Tedra Thompson, Contracting Officer
Guesley Leger, Contract Specialist
Jason Harrah, Project Manager
Viktoria Bogina, Engineer Technical Lead image8.png image9.png image10.png image11.png image12.svg image1.png image2.png image3.tif image4.tif image5.png image6.png image7.png
File details come from the government source that posted it. Updated .