W912EP20B0004 Amendment 0003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

1. CONTRACT ID CODE PAGE OF PAGES

1 70

2. AMENDMENT/MODIFICATION NO.

3. EFFECTIVE DATE

07-Oct-2020

4. REQUISITION/PURCHASE REQ. NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY CODE W912EP 7. ADMINISTERED BY (If other than item 6) CODE

USA ENGINEER DISTRICT, JACKSONVILLE

CONTRACTING DIVISION

701 SAN MARCO BLVD

JACKSONVILLE FL 32207-8175

See Item 6

8. NAME AND ADDRESS OF CONTRACT OR (No., Street, County, State and Zip Code) X 9A. AMENDMENT OF SOLICITATION NO.

W912EP20B0004

X 9B. DATED (SEE ITEM 11)

02-Sep-2020

10A. MOD. OF CONTRACT /ORDER NO.

10B. DATED (SEE ITEM 13)

CODE FACILITY CODE

11. T HIS ITEM ONLY APPLIES TO AMENDMENT S OF SOLICIT ATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNT ING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACT S/ORDERS.

IT MODIFIES THE CONTRACT /ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. T HE ABOVE NUMBERED CONTRACT /ORDER IS MODIFIED TO REFLECT THE ADMINIST RATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORT H IN ITEM 14, PURSUANT TO THE AUT HORIT Y OF FAR 43.103(B).

C. T HIS SUPPLEMENT AL AGREEMENT IS ENTERED INTO PURSUANT TO AUT HORIT Y OF:

D. OTHER (Specify type of modification and authority)

E. IMPORT ANT : Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPT ION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

NAVAL SUBMARINE BASE KINGS BAY - ENTRANCE CHANNEL, MAINTENANCE DREDGING - CUT - 1N THROUGH RANGE-E, 49,45, AND 44-FOOT PROJECT, CAMDEN COUNTY, GEORGIA & NASSAU COUNTY, FLORIDA

A.SEE CONTINUATION SHEET FOR AMENDMENT DETAILS.

B.THE BID OPENING DATE REMAINS UNCHANGED AT OCTOBER 23, 2020 @ 2:00 P.M. LOCAL TIME. LOCAL TIME.

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print) 16A. NAME AND TITLE OF CONT RACTING OFFICER (Type or print)

TEL: EMAIL:

15B. CONT RACT OR/OFFEROR

(Signature of person authorized to sign)

15C. DATE SIGNED 16B. UNIT ED STATES OF AMERICA

B Y (Signature of Contracting Officer)

16C. DATE SIGNED

EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

30-105-04 STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

SF 30 CONTINUATION SHEET

Naval Submarine Base Kings Bay – Entrance Channel, Maintenance Dredging – Cut-1N Though Range-E, 49, 45, and 44-Foot Project, Camden County, Georgia & Nassau County, Florida

W912EP20B0004 2 Amendment 0003

SUMMARY OF CHANGES

1. SPECIFICATIONS:

Text changes have been updated with additions noted by underlined text (green in PDF) and deletions noted by line/cross-outs (red in PDF). These text changes pertain only to changes made by this amendment.

VOLUME I

DELETE Section 00100 INSTRUCTIONS TO OFFERORS/EVALUATION FACTORS FOR AWARD and REPLACE with the attached revised Section 00100 INSTRUCTIONS TO OFFERORS/EVALUATION FACTORS FOR

AWARD.

VOLUME II

DELETE Section 01 11 00 and REPLACE with the attached revised Section 01 11 00.

DELETE Section 01 57 20 and REPLACE with the attached revised Section 01 57 20.

ADD new Section 01 57 20, Appendix B.

ADD new Section 01 57 20, Appendix C.

2. DRAWINGS: No change to drawings.

(End of Summary of Changes)

SECTION 00100 - INSTRUCTIONS TO OFFERORS/EVALUATION FACTORS FOR AWARD

52.204-7 System for Award Management OCT 2018 52.211-2

52.214-3

Availability of Specifications, Standards, and Data Item Descriptions Listed in the Acquisition Streamlining and Standardization Information System (ASSIST) Amendments To Invitations For Bids

APR 2014

DEC 2016

52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.216-1 Type Of Contract APR 1984 52.217-5 Evaluation of Options JUL 1990 52.222-5 Construction Wage Rate Requirements--Secondary Site of the MAY 2014

52.222-23

Work Notice of Requirement for Affirmative Action to Ensure

FEB 1999

52.222-38

Equal Employment Opportunity for Construction Compliance With Veterans' Employment Reporting

FEB 2016

52.225-12

Requirements Notice of Buy American Requirement - Construction

MAY 2014

52.225-25

Materials Under Trade Agreements Prohibition on Contracting with Entities Engaging in Certain

AUG 2018

52.233-2

Activities or Transactions Relating to Iran-- Representation and Certifications.

SERVICE OF PROTEST (SEP 2006)

OCT 2006

52.236-27 (Alt I) SITE VISIT (CONSTRUCTION) (FEB 1995) MAY 2003

52.252-5

(ALTERNATE I) (FEB 1995)

Authorized Deviations In Provisions

APR 1984

252.204-7008 Compliance With Safeguarding Covered Defense Information OCT 2016

252.225-7031

Controls Secondary Arab Boycott Of Israel

JUN 2005

W912EP20B0004 00100-i Amendment 0003

Section 00100 - INSTRUCTIONS TO OFFERORS/EVALUATION FACTORS FOR AWARD

52.204-7 SYSTEM FOR AWARD MANAGEMENT (OCT 2018)

(a) Definitions. As used in this provision--

Electronic Funds Transfer (EFT) indicator means a four-character suffix to the unique entity identifier. The suffix is assigned at the discretion of the commercial, nonprofit, or Government entity to establish additional System for Award Management records for identifying alternative EFT accounts (see subpart 32.11) for the same entity.

Registered in the System for Award Management (SAM) means that--

(1) The Offeror has entered all mandatory information, including the unique entity identifier and the EFT indicator, if applicable, the Commercial and Government Entity (CAGE) code, as well as data required by the Federal Funding Accountability and Transparency Act of 2006 (see subpart 4.14) into SAM;

(2) The offeror has completed the Core, Assertions, and Representations and Certifications, and Points of Contact sections of the registration in SAM;

(3) The Government has validated all mandatory data fields, to include validation of the Taxpayer Identification Number (TIN) with the Internal Revenue Service (IRS). The offeror will be required to provide consent for TIN validation to the Government as a part of the SAM registration process; and

(4) The Government has marked the record ``Active''.

Unique entity identifier means a number or other identifier used to identify a specific commercial, nonprofit, or Government entity. See www.sam.gov for the designated entity for establishing unique entity identifiers.

(b)(1) An Offeror is required to be registered in SAM when submitting an offer or quotation, and shall continue to be registered until time of award, during performance, and through final payment of any contract, basic agreement, basic ordering agreement, or blanket purchasing agreement resulting from this solicitation.

(2) The Offeror shall enter, in the block with its name and address on the cover page of its offer, the annotation ``Unique Entity Identifier'' followed by the unique entity identifier that identifies the Offeror's name and address exactly as stated in the offer. The Offeror also shall enter its EFT indicator, if applicable. The unique entity identifier will be used by the Contracting Officer to verify that the Offeror is registered in SAM.

(c) If the Offeror does not have a unique entity identifier, it should contact the entity designated at w ww.sam.gov for establishment of the unique entity identifier directly to obtain one. The Offeror should be prepared to provide the following information:

(1) Company legal business name.

(2) Tradestyle, doing business, or other name by which your entity is commonly recognized.

(3) Company physical street address, city, state, and Zip Code.

(4) Company mailing address, city, state and Zip Code (if separate from physical).

(5) Company telephone number.

W912EP20B0004 00100-1 Amendment 0003 http://www.sam.gov/

(6) Date the company was started.

(7) Number of employees at your location.

(8) Chief executive officer/key manager.

(9) Line of business (industry).

(10) Company headquarters name and address (reporting relationship within your entity).

(d) Processing time should be taken into consideration when registering. Offerors who are not registered in SAM should consider applying for registration immediately upon receipt of this solicitation. See https://www.sam.gov for information on registration.

(End of Provision)

52.211-2 AVAILABILITY OF SPECIFICATIONS, STANDARDS, AND DATA ITEM DESCRIPTIONS

LISTED IN THE ACQUISITION STREAMLINING AND STANDARDIZATION INFORMATION SYSTEM

(ASSIST) (APR 2014)

(a) Most unclassified Defense specifications and standards may be downloaded from the following ASSIST websites:

(1) ASSIST (https://assist.dla.mil/online/start/);

(2) Quick Search (http://quicksearch.dla.mil/);

(3) ASSISTdocs.com (http://assistdocs.com).

(b) Documents not available from ASSIST may be ordered from the Department of Defense Single Stock Point (DoDSSP) by--

(1) Using the ASSIST Shopping Wizard (https://assist.dla.mil/wizard/index.cfm);

(2) Phoning the DoDSSP Customer Service Desk (215) 697-2179, Mon-Fri, 0730 to 1600 EST; or

(3) Ordering from DoDSSP, Building 4, Section D, 700 Robbins Avenue, Philadelphia, PA 19111-5094, Telephone

(215) 697-2667/2179, Facsimile (215) 697-1462.

(End of provision)

52.214-3 AMENDMENTS TO INVITATIONS FOR BIDS (DEC 2016)

(a) If this solicitation is amended, then all terms and conditions which are not modified remain unchanged.

(b) (1) Bidders shall acknowledge receipt of any amendment to this solicitation--

(i) By signing and returning the amendment;

(ii) By identifying the amendment number and date in space provided for this purpose on the form for submitting a bid;

W912EP20B0004 00100-2 Amendment 0003 http://www.sam.gov/ http://quicksearch.dla.mil/)%3B

(iii) By letter;

(iv) By facsimile, if facsimile bids are authorized in the solicitation; or

(v) By email, if email bids are authorized in the solicitation.

(2) The Government must receive the acknowledgement by the time and at the place specified for receipt of bids.

52.214-4 FALSE STATEMENTS IN BIDS (APR 1984)

Bidders must provide full, accurate, and complete information as required by this solicitation and its attachments.

The penalty for making false statements in bids is prescribed in 18 U.S.C. 1001.

52.214-5 SUBMISSION OF BIDS (DEC 2016)

(a) Bids and bid modifications shall be submitted in sealed envelopes or packages (unless submitted by electronic means) (1) addressed to the office specified in the solicitation, and (2) showing the time and date specified for receipt, the solicitation number, and the name and address of the bidder.

(b) Bidders using commercial carrier services shall ensure that the bid is addressed and marked on the outermost envelope or wrapper as prescribed in subparagraphs (a)(1) and (2) of this provision when delivered to the office specified in the solicitation.

(c) Facsimile bids, modifications, or withdrawals, will not be considered unless authorized by the solicitation.

(d) Bids submitted by electronic commerce shall be considered only if the electronic commerce method was specifically stipulated or permitted by the solicitation.

52.214-6 EXPLANATION TO PROSPECTIVE BIDDERS (APR 1984)

Any prospective bidder desiring an explanation or interpretation of the solicitation, drawings, specifications, etc., must request it in writing soon enough to allow a reply to reach all prospective bidders before the submission of their bids. Oral explanations or instructions given before the award of a contract will not be binding. Any information given a prospective bidder concerning a solicitation will be furnished promptly to all other prospective bidders as an amendment to the solicitation, if that information is necessary in submitting bids or if the lack of it would be prejudicial to other prospective bidders.

W912EP20B0004 00100-3 Amendment 0003

52.214-7 LATE SUBMISSIONS, MODIFICATIONS, AND WITHDRAWALS OF BIDS (NOV 1999)

(a) Bidders are responsible for submitting bids, and any modifications or withdrawals, so as to reach the Government office designated in the invitation for bids (IFB) by the time specified in the IFB. If no time is specified in the IFB, the time for receipt is 4:30 p.m., local time, for the designated Government office on the date that bids are due.

(b)(1) Any bid, modification, or withdrawal received at the Government office designated in the IFB after the exact time specified for receipt of bids is “late” and will not be considered unless it is received before award is made, the Contracting Officer determines that accepting the late bid would not unduly delay the acquisition; and--

(i) If it was transmitted through an electronic commerce method authorized by the IFB, it was received at the initial point of entry to the Government infrastructure not later than 5:00 p.m. one working day prior to the date specified for receipt of bids; or

(ii) There is acceptable evidence to establish that it was received at the Government installation designated for receipt of bids and was under the Government's control prior to the time set for receipt of bids.

(2) However, a late modification of an otherwise successful bid that makes its terms more favorable to the Government, will be considered at any time it is received and may be accepted.

(c) Acceptable evidence to establish the time of receipt at the Government installation includes the time/date stamp of that installation on the bid wrapper, other documentary evidence of receipt maintained by the installation, or oral testimony or statements of Government personnel.

(d) If an emergency or unanticipated event interrupts normal Government processes so that bids cannot be received at the Government office designated for receipt of bids by the exact time specified in the IFB and urgent Government requirements preclude amendment of the IFB, the time specified for receipt of bids will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume.

(e) Bids may be withdrawn by written notice received at any time before the exact time set for receipt of bids. If the IFB authorizes facsimile bids, bids may be withdrawn via facsimile received at any time before the exact time set for receipt of bids, subject to the conditions specified in the provision at 52.214-31, Facsimile Bids. A bid may be withdrawn in person by a bidder or its authorized representative if, before the exact time set for receipt of bids, the identity of the person requesting withdrawal is established and the person signs a receipt for the bid.

52.214-18 PREPARATION OF BIDS--CONSTRUCTION (APR 1984)

(a) Bids must be (1) submitted on the forms furnished by the Government or on copies of those forms, and (2) manually signed. The person signing a bid must initial each erasure or change appearing on any bid form.

(b) The bid form may require bidders to submit bid prices for one or more items on various bases, including--

(1) Lump sum bidding;

(2) Alternate prices;

(3) Units of construction; or

(4) Any combination of subparagraphs (1) through (3) above.

(c) If the solicitation requires bidding on all items, failure to do so will disqualify the bid. If bidding on all items is

W912EP20B0004 00100-4 Amendment 0003 not required, bidders should insert the words "no bid" in the space provided for any item on which no price is submitted.

(d) Alternate bids will not be considered unless this solicitation authorizes their submission.

52.214-19 CONTRACT AWARD--SEALED BIDDING--CONSTRUCTION (AUG 1996)

(a) The Government will evaluate bids in response to this solicitation without discussions and will award a contract to the responsible bidder whose bid, conforming to the solicitation, will be most advantageous to the Government, considering only price and the price-related factors specified elsewhere in the solicitation.

(b) The Government may reject any or all bids, and waive informalities or minor irregularities in bids received.

(c) The Government may accept any item or combination of items, unless doing so is precluded by a restrictive limitation in the solicitation or the bid.

(d) The Government may reject a bid as nonresponsive if the prices bid are materially unbalanced between line items or subline items. A bid is materially unbalanced when it is based on prices significantly less than cost for some work and prices which are significantly overstated in relation to cost for other work, and if there is a reasonable doubt that the bid will result in the lowest overall cost to the Government even though it may be the low evaluated bid, or if it is so unbalanced as to be tantamount to allowing an advance payment.

(End of provison)

52.214-34 SUBMISSION OF OFFERS IN THE ENGLISH LANGUAGE (APR 1991)

Offers submitted in response to this solicitation shall be in the English language. Offers received in other than English shall be rejected.

52.214-35 SUBMISSION OF OFFERS IN U.S. CURRENCY (APR 1991)

Offers submitted in response to this solicitation shall be in terms of U.S. dollars. Offers received in other than U.S.

dollars shall be rejected.

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

52.217-5 EVALUATION OF OPTIONS (JUL 1990)

Except when it is determined in accordance with FAR 17.206(b) not to be in the Government's best interests, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirement. Evaluation of options will not obligate the Government to exercise the option(s).

W912EP20B0004 00100-5 Amendment 0003

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.222-23 NOTICE OF REQUIREMENT FOR AFFIRMATIVE ACTION TO ENSURE EQUAL

EMPLOYMENT OPPORTUNITY FOR CONSTRUCTION (FEB 1999)

(a) The offeror's attention is called to the Equal Opportunity clause and the Affirmative Action Compliance Requirements for Construction clause of this solicitation.

(b) The goals for minority and female participation, expressed in percentage terms for the Contractor's aggregate workforce in each trade on all construction work in the covered area, are as follows:

Goals for minority participation for each trade Goals for female participation for each trade

Camden 22.2% Nassau 21.8%

6.9%

These goals are applicable to all the Contractor's construction work performed in the covered area. If the Contractor performs construction work in a geographical area located outside of the covered area, the Contractor shall apply the goals established for the geographical area where the work is actually performed. Goals are published periodically in the Federal Register in notice form, and these notices may be obtained from any Office of Federal Contract Compliance Programs office.

(c) The Contractor's compliance with Executive Order 11246, as amended, and the regulations in 41 CFR 60-4 shall be based on (1) its implementation of the Equal Opportunity clause, (2) specific affirmative action obligations required by the clause entitled "Affirmative Action Compliance Requirements for Construction,'' and (3) its efforts to meet the goals. The hours of minority and female employment and training must be substantially uniform throughout the length of the contract, and in each trade. The Contractor shall make a good faith effort to employ minorities and women evenly on each of its projects. The transfer of minority or female employees or trainees from Contractor to Contractor, or from project to project, for the sole purpose of meeting the Contractor's goals shall be a violation of the contract, Executive Order 11246, as amended, and the regulations in 41 CFR 60-4. Compliance with the goals will be measured against the total work hours performed.

(d) The Contractor shall provide written notification to the Deputy Assistant Secretary for Federal Contract Compliance, U.S. Department of Labor, within 10 working days following award of any construction subcontract in

W912EP20B0004 00100-6 Amendment 0003 excess of $10,000 at any tier for construction work under the contract resulting from this solicitation. The notification shall list the --

(1) Name, address, and telephone number of the subcontractor;

(2) Employer's identification number of the subcontractor;

(3) Estimated dollar amount of the subcontract;

(4) Estimated starting and completion dates of the subcontract; and

(5) Geographical area in which the subcontract is to be performed.

(e) As used in this Notice, and in any contract resulting from this solicitation, the "covered area" is Camden County Georgia & Nassau County, Florida.

52.222-38 COMPLIANCE WITH VETERANS' EMPLOYMENT REPORTING REQUIREMENTS (FEB 2016)

By submission of its offer, the offeror represents that, if it is subject to the reporting requirements of 38 U.S.C.

4212(d) (i.e., if it has any contract containing Federal Acquisition Regulation clause 52.222-37, Employment Reports on Veterans), it has filed the most recent VETS-4212 Report required by that clause.

52.225-12 NOTICE OF BUY AMERICAN REQUIREMENT-- CONSTRUCTION MATERIALS UNDER

TRADE AGREEMENTS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “designated country construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American -- Construction Materials Under Trade Agreements” (Federal Acquisition Regulation (FAR) clause 52.225-11).

(b) Requests for determination of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of FAR clause 52.225-11 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction materials, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(4)(i) of FAR clause 52.225-11.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

W912EP20B0004 00100-7 Amendment 0003

(d) Alternate offers. (1) When an offer includes foreign construction material, other than designated country construction material, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of FAR clause 52.225-11 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material, and the offeror shall be required to furnish such domestic or designated country construction material. An offer based on use of the foreign construction material for which an exception was requested-- (i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.225-25 PROHIBITION ON CONTRACTING WITH ENTITIES ENGAGING IN CERTAIN ACTIVITIES OR

TRANSACTIONS RELATING TO IRAN--REPRESENTATION AND CERTIFICATIONS. (AUG 2018)

Person--

(1) Means--

(i) A natural person;

(ii) A corporation, business association, partnership, society, trust, financial institution, insurer, underwriter, guarantor, and any other business organization, any other nongovernmental entity, organization, or group, and any governmental entity operating as a business enterprise; and

(iii) Any successor to any entity described in paragraph (1)(ii) of this definition; and

(2) Does not include a government or governmental entity that is not operating as a business enterprise.

Sensitive technology--

(1) Means hardware, software, telecommunications equipment, or any other technology that is to be used specifically--

(i) To restrict the free flow of unbiased information in Iran; or

(ii) To disrupt, monitor, or otherwise restrict speech of the people of Iran; and

(2) Does not include information or informational materials the export of which the President does not have the authority to regulate or prohibit pursuant to section 203(b)(3) of the International Emergency Economic Powers Act (50 U.S.C. 1702(b)(3)).

W912EP20B0004 00100-8 Amendment 0003

(b) The offeror shall email questions concerning sensitive technology to the Department of State at CISADA106@state.gov.

(c) Except as provided in paragraph (d) of this provision or if a waiver has been granted in accordance with 25.703- 4, by submission of its offer, the offeror—

(1) Represents, to the best of its knowledge and belief, that the offeror does not export any sensitive technology to the government of Iran or any entities or individuals owned or controlled by, or acting on behalf or at the direction of, the government of Iran;

(2) Certifies that the offeror, or any person owned or controlled by the offeror, does not engage in any activities for which sanctions may be imposed under section 5 of the Iran Sanctions Act. These sanctioned activities are in the areas of development of the petroleum resources of Iran, production of refined petroleum products in Iran, sale and provision of refined petroleum products to Iran, and contributing to Iran's ability to acquire or develop certain weapons or technologies; and

(3) Certifies that the offeror, and any person owned or controlled by the offeror, does not knowingly engage in any transaction that exceeds $3,500 with Iran's Revolutionary Guard Corps or any of its officials, agents, or affiliates, the property and interests in property of which are blocked pursuant to the International Emergency Economic Powers Act (50 U.S.C. 1701 et seq.) (see OFAC's Specially Designated Nationals and Blocked Persons List at https://www.treasury.gov/resource-center/sanctions/SDN-List/Pages/default.aspx).

(d) Exception for trade agreements. The representation requirement of paragraph (c)(1) and the certification requirements of paragraphs (c)(2) and (c)(3) of this provision do not apply if—

(1) This solicitation includes a trade agreements notice or certification (e.g., 52.225-4, 52.225-6, 52.225-12, 52.225- 24, or comparable agency provision); and

(2) The offeror has certified that all the offered products to be supplied are designated country end products or designated country construction material.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from the person identified in item 10 of the Standard Form 33 (if this solicitation is for non-commercial supplies or services), in item 9A of the Standard Form 1442 (if this solicitation is for construction or dredging), in item 7 of the Standard Form 1449 (if this solicitation is for commercial items), or in item 7 of the DA Form 4069-R (if this solicitation is for work funded by a non-appropriated funds instrumentality) at the address shown in item 7 of the SF 33, item 7 of the SF 1442, item 9 of the SF 1449, or item 5 of the DA Form 4069-R.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995) (ALTERNATE I) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

W912EP20B0004 00100-9 Amendment 0003 mailto:CISADA106@state.gov http://www.treasury.gov/resource-center/sanctions/SDN-List/Pages/default.aspx)

(b) An organized site visit has been scheduled for -- Thursday, October 1, 2020 @ 9:00 AM Local Time.

(c) Participants will meet at -- (Location will be provided by the contract administration office via telephone. See

(d) below.)

(d) Participants should call Jen Tyler @ 904-524-3166 on or before 30 September 2020 to make arrangements.

(e) Core borings are available. (If available, follow the instructions in the Physical Data paragraph in Section 01 11 00 of individual request for proposals issued for task orders under this contract to make arrangements to inspect the borings. Failure to follow the instructions may result in a delay ranging in duration from one hour to 4 days.)

(f) After the site visit, a memorandum summarizing the visit will be posted to beta.sam.gov website (www.beta.sam.gov) under the solicitation number. This posting will be strictly for informational purposes only.

The memorandum will not become a part of the solicitation. If the solicitation needs to be changed as a result of information obtained during the site visit, a written amendment will be made available to all registered vendors.

Questions regarding any information given in the memorandum must be directed to the person whose name appears in item 9 of the Standard Form 1442.

52.252-5 AUTHORIZED DEVIATIONS IN PROVISIONS (APR 1984)

(a) The use in this solicitation of any Federal Acquisition Regulation (48 CFR Chapter 1) provision with an authorized deviation is indicated by the addition of"(DEVIATION)" after the date of the provision.

(b) The use in this solicitation of any Defense FAR Supplement (48 CFR Chapter 2 ) provision with an authorized deviation is indicated by the addition of "(DEVIATION)" after the name of the regulation.

252.204-7008 COMPLIANCE WITH SAFEGUARDING COVERED DEFENSE INFORMATION CONTROLS

(OCT 2016)

Controlled technical information, covered contractor information system, covered defense information, cyber incident, information system, and technical information are defined in clause 252.204-7012, Safeguarding Covered Defense Information and Cyber Incident Reporting.

(b) The security requirements required by contract clause 252.204-7012 shall be implemented for all covered defense information on all covered contractor information systems that support the performance of this contract.

(c) For covered contractor information systems that are not part of an information technology service or system operated on behalf of the Government (see 252.204-7012(b)(2))--

(1) By submission of this offer, the Offeror represents that it will implement the security requirements specified by National Institute of Standards and Technology (NIST) Special Publication (SP) 800-171, ``Protecting Controlled Unclassified Information in Nonfederal Information Systems and Organizations'' (see

W912EP20B0004 00100-10 Amendment 0003 http://dx.doi.org/10.6028/NIST.SP.800-171) that are in effect at the time the solicitation is issued or as authorized by the contracting officer not later than December 31, 2017.

(2)(i) If the Offeror proposes to vary from any of the security requirements specified by NIST SP 800-171 that are in effect at the time the solicitation is issued or as authorized by the Contracting Officer, the Offeror shall submit to the Contracting Officer, for consideration by the DoD Chief Information Officer (CIO), a written explanation of—

(A) Why a particular security requirement is not applicable; or

(B) How an alternative but equally effective, security measure is used to compensate for the inability to satisfy a particular requirement and achieve equivalent protection.

(ii) An authorized representative of the DoD CIO will adjudicate offeror requests to vary from NIST SP 800-171 requirements in writing prior to contract award. Any accepted variance from NIST SP 800-171 shall be incorporated into the resulting contract.

252.225-7031 SECONDARY ARAB BOYCOTT OF ISRAEL (JUN 2005)

(1) Foreign person means any person (including any individual, partnership, corporation, or other form of association) other than a United States person.

(2) United States means the 50 States, the District of Columbia, outlying areas, and the outer Continental Shelf as defined in 43 U.S.C. 1331.

(3) United States person is defined in 50 U.S.C. App. 2415(2) and means--

(i) Any United States resident or national (other than an individual resident outside the United States who is employed by other than a United States person);

(ii) Any domestic concern (including any permanent domestic establishment of any foreign concern); and

(iii) Any foreign subsidiary or affiliate (including any permanent foreign establishment) of any domestic concern that is controlled in fact by such domestic concern.

(b) Certification. If the offeror is a foreign person, the offeror certifies, by submission of an offer, that it--

(1) Does not comply with the Secondary Arab Boycott of Israel; and

(2) Is not taking or knowingly agreeing to take any action, with respect to the Secondary Boycott of Israel by Arab countries, which 50 U.S.C. App. 2407(a) prohibits a United States person from taking.

W912EP20B0004 00100-11 Amendment 0003 http://dx.doi.org/10.6028/NIST.SP.800-171)

SF 30 CONTINUATION SHEET

Naval Submarine Base Kings Bay – Entrance Channel, Maintenance Dredging – Cut-1N Though Range-E, 49, 45, and 44-Foot Project, Camden County, Georgia & Nassau County, Florida

W912EP20B0004 2 Amendment 0003

SUMMARY OF CHANGES

1. SPECIFICATIONS:

Text changes have been updated with additions noted by underlined text (green in PDF) and deletions noted by line/cross-outs (red in PDF). These text changes pertain only to changes made by this amendment.

DELETE Section 01 11 00 and REPLACE with the attached revised Section 01 11 00.

DELETE Section 01 57 20 and REPLACE with the attached revised Section 01 57 20.

ADD new Section 01 57 20, Appendix B.

ADD new Section 01 57 20, Appendix C.

2. DRAWINGS: No change to drawings.

(End of Summary of Changes)

Naval Submarine Base Kings Bay - Entrance Channel, M/D - Cut-1N Through Range-E, 49, 45, and 44-Foot Project

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 REFERENCES

1.2 DEFINITIONS

1.3 WORK COVERED BY CONTRACT DOCUMENTS

1.3.1 Project Description

1.3.2 Location

1.3.3 Safety Requirements

1.3.4 Work Performed by Others

1.4 COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK

1.5 LIQUIDATED DAMAGES - CONSTRUCTION

1.6 PHYSICAL DATA

1.6.1 Physical Conditions

1.6.2 Weather, Water Stage and Tide Data

1.6.3 Contractor Investigation

1.6.4 Maritime Traffic

1.6.5 Obstruction of Channel

1.6.6 Hydrographic Surveys

1.7 LAYOUT OF WORK

1.7.1 Established Project Control

1.7.2 Layout

1.7.3 Survey

1.8 DAMAGE TO WORK

1.9 EXISTING WORK

1.10 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 1989)

1.10.1 Contractor Responsibility

PART 2 PRODUCTS (NOT APPLICABLE)

PART 3 EXECUTION (NOT APPLICABLE)

-- End of Section Table of Contents --

SECTION 01 11 00 Page 1 W912EP20B0004 Amendment 0003

SECTION 01 11 00

SUMMARY OF WORK

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referred to in the text by the basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

GDR Section 00 31 32, Geotechnical Data Report for U.S. Naval Station Kings Bay, Maintenance Dredging, Entrance Channel, Cut 1N Through Range E, 46-Foot Through 43-Foot Project, Camden County, Georgia and Nassau County, Florida

EM 385-1-1 Safety and Health Requirements Manual

1.2 DEFINITIONS

a. "Adverse weather" occurs when atmospheric conditions at a definite time and place that are unfavorable to construction activities and is based on climatological and meteorological observations and data sources provided in Section 00 33 50 WEATHER, WATER STAGE AND TIDE

DATA.

b. "Unusually severe weather" is weather that is more severe than the adverse weather anticipated by the Contractor for the season or location involved. Adverse weather delays are considered unusually severe weather if adverse weather delay days prevent work for 50 percent or more of the Contractor's scheduled work day.

1.3 WORK COVERED BY CONTRACT DOCUMENTS

1.3.1 Project Description

Base project work involves maintenance dredging of the Kings Bay Entrance Channel Cut-1N through Range-E. The excavated material will be distributed among the Fernandina Ocean Dredged Material Disposal Site (ODMDS)(D/A-O), the Fernandina Nearshore Disposal Area (D/A-N), the Fort Clinch Disposal Area (D/A-F) and North Beach Disposal Area (D/A-NB). Incidental work includes turbidity monitoring, environmental species monitoring, vibration monitoring, beach fill quality control, and sea turtle trawling. Option A project work consists of Fort Clinch pre-placement debris removal.

1.3.2 Location

The project is located in the St. Marys River and Cumberland Sound at the Georgia-Florida boundary Camden County, Georgia and Nassau County, FL.

SECTION 01 11 00 Page 2

1.3.3 Safety Requirements

See Section 01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS and EM 385-1-1 .

1.3.4 Work Performed by Others

See paragraph PROJECT COORDINATION of Section 01 30 00 ADMINISTRATIVE

PROCEDURES.

1.4 COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK

Read this paragraph in conjunction with the Clause COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (FAR 52.211-10) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.5 LIQUIDATED DAMAGES - CONSTRUCTION

Refer to the Clause LIQUIDATED DAMAGES - CONSTRUCTION (FAR 52.211-12) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.6 PHYSICAL DATA

Read this paragraph in conjunction with the Clause PHYSICAL DATA (FAR 52.236-4) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.6.1 Physical Conditions

The indications of physical conditions on the drawings and in the specifications are the result of site investigations by surveys and/or by core borings. When the indicated physical conditions are the result of site investigations by core borings, the core boring logs and laboratory data are in Section 00 31 32 GEOTECHNICAL DATA REPORT ( GDR) and the core boring locations are shown on the drawings. Also, see the GDR for instructions concerning availability of core borings for inspection.

1.6.2 Weather, Water Stage and Tide Data

See Section 00 33 50 WEATHER, WATER STAGE AND TIDE DATA for applicable data links and information to where the Contractor can ascertain the weather conditions that could be encountered at the project location. The information provided does not preclude the Contractor from accessing and scheduling for adverse weather.

1.6.3 Contractor Investigation

Refer to the Clause SITE INVESTIGATION AND CONDITIONS AFFECTING THE WORK (FAR 52.236-3) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.6.4 Maritime Traffic

Marine Traffic in the project area consists of Naval, cruise ships, commercial, pleasure, and small recreational vessels of all types and sizes which can be accommodated by existing depths.

1.6.5 Obstruction of Channel

The Government will not undertake to keep the channel free from vessels or other obstructions, except to the extent of such regulations, if any, as may be prescribed by the Secretary of the Army, in accordance with the

SECTION 01 11 00 Page 3 provisions of Section 7 of the River and Harbor Act approved 8 August 1917. The Contractor will be required to conduct the work in such manner as to obstruct navigation as little as possible, and in case the plant so obstructs the channel as to make difficult or endanger the passage of any vessels, promptly move said plant on the approach of any vessel to such an extent as may be necessary to afford a practicable passage. Upon completion of the work, promptly remove his plant, including ranges, buoys, piles, and other marks placed by him under the contract in navigable waters or on shore.

1.6.6 Hydrographic Surveys

Hydrographic surveys are provided on the ehydro web site:

https://www.arcgis.com/apps/opsdashboard/index.html#/4b8f2ba307684cf597617bf1b6d2f85d Survey numbers are indicated on the drawings will be provided to the awardee .

1.7 LAYOUT OF WORK

Read this paragraph in conjunction with the Clause LAYOUT OF WORK (FAR 52.236-17) of Section 00700 CONTRACT CLAUSES in Volume 1.

1.7.1 Established Project Control

The Government has established monuments along the work site(s). Each monument is represented in the contract drawings by a Designation and in most cases, an alphanumeric Permanent Identifier (PID). Information concerning the location and elevations can be found within the Survey Notes on the plan sheets. The Survey Notes for each included field survey will cite a particular survey number, and specify the control used to conduct that survey. Additional information is included in the Survey Notes that must be duplicated if an attempt to recreate the subject survey is desired.

For navigation channels, the Government has established tidal calibration sites for projects constructed and maintained to a tidal datum. Each tidal calibration site is represented in the plan sheet drawings by Station ID, and is cited in the Survey Notes. All projects constructed and maintained to a tidal datum must be calibrated to the Station ID specified in the plan sheet drawings. Information regarding the location and associated benchmarks of the referenced Station ID is included in the Monument Description section of these specifications.

See Section 00 31 21 CONTROL MONUMENT DESCRIPTIONS.

1.7.2 Layout

From the monuments, control data and elevations established by the Government, complete the layout of the work and obtain all measurements that may be required for the execution of the work to the location and limit marks prescribed in the specifications or on the contract drawings, subject to such modifications as the Contracting Officer may require to meet changed conditions or as a result of necessary modifications to the contract work.

1.7.3 Survey

Furnish, at no additional expense, such stakes, templates, platforms, equipment, tools and material, and all labor as may be required in laying

SECTION 01 11 00 Page 4 out any part of the work from the monuments, control data and elevations established by the Government. Maintain and preserve all monuments, stakes and other marks established by the Contracting Officer until authorized to remove them, and if such marks or monuments are destroyed by the Contractor or through his negligence, prior to their authorized removal, they may be replaced by the Contracting Officer, at his discretion, and the expense of replacement will be deducted from any amounts due or to become due the Contractor. The Contracting Officer may require that work be suspended at any time when location and limit marks established by the Contractor are not reasonably adequate to permit checking of the work.

1.8 DAMAGE TO WORK

The responsibility for damage to any part of the permanent work will be as set forth in Clause PERMITS AND RESPONSIBILITIES of Section 00700 CONTRACT CLAUSES in Volume 1. However, if, in the judgment of the Contracting Officer, any part of the permanent work performed by the Contractor is damaged by flood, earthquake, hurricane, or tornado, which damage is not due to the failure of the Contractor to take reasonable precautions or to exercise sound engineering and construction practices in the conduct of the work, the Contractor will make the repairs as ordered by the Contracting Officer and full compensation for such repairs will be made at the applicable contract unit or job prices as fixed and established in the contract. If, in the opinion of the Contracting Officer, there are no contract unit or job prices applicable to any part of such work, an equitable adjustment pursuant to Clause CHANGES of Section 00700 CONTRACT CLAUSES in Volume 1 will be made as full compensation for the repairs of that part of the permanent work for which there are no applicable contract unit or job prices. Except as herein provided, damage to all work (including temporary construction), utilities, materials, equipment and plant must be repaired to the satisfaction of the Contracting Officer at the Contractor's expense, regardless of the cause of such damage.

1.9 EXISTING WORK

In addition to FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements:

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

1.10 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER (31 OCT 1989)

This provision specifies the procedure for the determination of time extensions for unusually severe weather in accordance with the Clause DEFAULT (FIXED-PRICE CONSTRUCTION) of Section 00700 CONTRACT CLAUSES in Volume 1. In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe; that is, more severe than the adverse weather anticipated for the project location

SECTION 01 11 00 Page 5 during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the Contractor.

1.10.1 Contractor Responsibility

The project area may be affected by stormy, windy and/or rainy weather, including thunderstorms, during any time of the year. Obtain information concerning rain, wind and wave conditions that could influence safety, hauling and placement operations prior to submitting a proposal or bid.

a. Research the project site conditions and incorporate potential adverse weather delays into their schedule prior to submitting a proposal or bid. Develop a schedule of monthly anticipated adverse weather based on the equipment to be used to complete the project and determine the conditions that would cause them to cease operations using the sources provided in Section 00 33 50 WEATHER, WATER STAGE AND TIDE DATA. The Contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

b. Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the Contractor will record on the daily CQC report the occurrence of adverse weather and unusually severe weather with the purpose to note impact to normally scheduled work.