A22. W912EK24B0021_AMND 0001.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose of this amendment is due to the follow ing:

1. The Government has extended the contract duration by 180 days. The new contract completion date is 545 days after notice to proceed based on the Government's response to the question received via ProjNet.

2. The Government provided responses to questions recevied via ProjNet.

1. CONTRACT ID CODE PAGE OF PAGES

J 1 3

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 23-Aug-2024

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912EK24B0021

X 9B. DATED (SEE ITEM 11)

14-Aug-2024

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

23-Aug-2024

CODE

CONTRACTING DIVISION

US ARMY CORPS OF ENGINEERS 1500 ROCK ISLAND D

ROCK ISLAND IL 61201

W912EK 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EK24B0021

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION B - SUPPLIES OR SERVICES AND PRICES

The following have been modified:

SCHEDULE OF PRICES

ITEM

NO.

SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT DELIVERY

DATE

0001 Bulkhead

1 JOB XXXXXXXX $__________ __________

0002 Barge Demurrage

0002AA First 7 Days

7 DA __________ $__________ XXXXXXXX

0002AB Over 7 Days

21 DA __________ $__________ XXXXXXXX

TOTAL OF ESTIMATED AMOUNTS

(ITEM NOS. 0001 THROUGH 0002AB, INCL.)

DA = DAYS JOB = LUMP SUM

ENSURE UNIT PRICES AND AMOUNT LINES FOR ALL ITEMS ARE COMPLETED.

THE CONTRACT COMPLETION DATE

IS 545 DAYS AFTER NOTICE TO

PROCEED.

BARGE DEMURRAGE DAYS WILL NOT BE COUNTED

AGAINST THE

COMPLETION DATE.

DO NOT FILL-IN/COMPLETE THE DELIVERY DATE COLUMN WHEN

SUBMITTING YOUR PROPOSAL. THE GOVERNMENT WILL FILL-

IN/COMPLETE

THIS INFORMATION AT THE TIME OF AWARD AND/OR

MODIFICATIONS.

REFER TO FAR 52.217-8 OPTION TO EXTEND SERVICES FOR MORE

INFORMATION.

W912EK24B0021

ALL POTENTIAL OFFERORS SHALL SUBMIT A COPY OF A AMERICAN INSTITUTE

OF STEEL CONSTRUCTION (AISC) AND/OR SOCIETY FOR PROTECTIVE

COATING (SSPC) CERTIFICATION WITH THEIR SUBMISSSON OF BID.

SECTION F - DELIVERIES OR PERFORMANCE

The following Delivery Schedule item for CLIN 0001 has been changed from:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

1 yr. ANP 1 N/A

FOB: Destination

To:

DELIVERY DATE QUANTITY SHIP TO ADDRESS DODAAC /

CAGE

545 dys. ANP 1 N/A

FOB: Destination

(End of Summary of Changes)