W912EF20B0017-0003.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The purpose for this amendment is to provide updated details in FAR clause 52.211-10 and to provide updates to techncial specifications sections: 00 01 00.15 28 LIST OF DRAWINGS, 01 14 00.10 28 PROJECT SITE RESTRICTIONS, 01 55 10.00 28 CONTRACTOR WORK, ACCESS AND STORAGE AREAS, 22 00 00 PLUMBING GENERAL PURPOSE, 26 60 13.00 40 ELECTRICAL. Also, included in this amendment are updated draw ings G-002, M-001, M-401, M-504, and R011 through R-015 are added. Please see summary of changes for details.

All other terms and conditions remain unchanges.

1. CONTRACT ID CODE PAGE OF PAGES

1 4

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 02-Sep-2020

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912EF20B0017

X 9B. DATED (SEE ITEM 11)

31-Jul-2020

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

02-Sep-2020

CODE

USAED, WALLA WALLA - CONTRACTING DIV.

LEANNE WALLING

201 N. THIRD AVENUE

WALLA WALLA WA 99362-1876

W912EF 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912EF20B0017

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

SUMMARY OF CHANGES

SECTION 00 21 00 - INSTRUCTIONS

The following have been added by full text:

Summary of Changes for McNary Nav-Lock Upstream Unwatering Sump Repairs (amendment 0003)

FAR Clause 52.211-10 was revised

Specifications:

00 01 00.15 28 LIST OF DRAWINGS

1.2: Updated revision number and date for drawings revised by this amendment 1.3: Added R-011 through R-015 to table.

01 14 00.10 28 PROJECT SITE RESTRICTIONS

1.3: Significantly revised subpart “SITE CONDITIONS AND OPERATIONAL

RESTRICTIONS”

Added subpart 1.8 ELEVATOR USE

01 55 10.00 28 CONTRACTOR WORK, ACCESS AND STORAGE AREAS

1.4.2: Revised Elevator 2 information

22 00 00 PLUMBING, GENERAL PURPOSE

1.2: Added “Grout Installation” submittal under SD-01 and “Grout” submittal under SD-03.

This info will also be included on the submittal register.

Added new subpart 2.5.2 Grout Added new subpart 3.3.7 Grout Installation

26 60 13.00 40 ELECTRICAL

2.2.1: Added 2nd paragraph to allow Totally Enclosed, Fan Cooled (TEFC) motor enclosures for the drainage pumps.

Drawings:

G-002: Revised to include R-011 through R-015 M-001: Revised General Note 2 M-401: Blind flange removed M-504: Changed C8X11.5 to C6X8.2 R-011 through R-015 were added

W912EF20B0017

SECTION 00 70 00 - CONDITIONS OF THE CONTRACT

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984) -

ALTERNATE I (APR 1984)

The Contractor shall be required to (a) Commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than the dates listed below.

(1) Onsite construction at McNary, with the exception of the work windows defined below, may begin anytime after the contractor receives Notice to Proceed (NTP), all preconstruction contract requirements are completed, and all required preconstruction submittals are approved. See SECTION 01 14 00.10 28 PROJECT SITE RESTRICTIONS for additional information.

(2) The drainage and unwatering pumps may be taken out of service temporarily between NTP and February 19, 2021 for field verification and to determine layouts.

(3) The Contractor shall remove the existing equipment and install the new spectacle flange (item 9 on M- 001), expansion joint (item 10 on M-001) and the first 10NPS 45 degree elbow on both legs of the suction piping during the Navigation Lock outage in March 2021. Work shall begin no sooner than 10 prior to the completion of the outage and shall be completed no later than 4 days prior to the end of the Navigation Lock outage.

(4) The Contractor shall complete all remaining work from the completion of the Navigation Lock outage through October 01, 2021. With the exception of items (5) and (6) below, the Contractor shall complete all work required for this contract, to include testing and commissioning, not later than October 01, 2021.

(5) The Contractor shall complete final cleanup and demobilization by not later than 15 calendar days after completion of work in (3) above.

(6) The Contractor shall complete the final, approved submission of the following by not later than 30 calendar days after completion of work in (4) above. See SECTION 01 78 00.00 28 CLOSEOUT SUBMITTALS and 01 78 23.00 28 OPERATION AND MAINTENANCE DATA for additional information:

a. O&M manuals.

b. As-Built drawings.

c. Shop Drawings.

d. Record Drawings.

e. Spare parts

The completion date is based on the assumption that the successful offeror will receive the notice to proceed by October 14, 2020. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer.

(End of clause)

(End of Summary of Changes)