W912DW24R0021R0001 CJD Units 1-16 Isolated Phase Bus.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

W912DW24R0021R0001

CJD Units 1-16 Isolated Phase Bus, Chief Joseph Dam, Bridgeport, WA

See continuation page

1. CONTRACT ID CODE PAGE OF PAGES

1 13

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY 15-Feb-2024

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street , County, State and Zip Code) X W912DW24R0021

X 9B. DATED (SEE ITEM 11)

25-Jan-2024

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

14-Feb-2024

CODE

USA ENGINEER DISTRICT, SEATTLE

ATTN: CENWS-CT

4735 EAST MARGINAL WAY SOUTH, BLDG. 1202

SEATTLE WA 98134-2388

W912DW 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

W912DW24R0021

SECTION SF 30 BLOCK 14 CONTINUATION PAGE

The following items are applicable to this modification:

R0001

Summary of Changes in Amendment No. R0001

1. 01 11 00.00 26 SUMMARY OF WORK

Changes: Revised paragraph 1.3.

2. 01 14 00 WORK RESTRICTIONS (CJD)

Changes: Revised paragraph 1.6.1.

3. Revised Davis Bacon Wage Determination - WA20240068 dated 02/02/2024

4. 52.211-10 – Commencement, Prosecution, and Completion of Work is revised to reflect new duration of 1,100 days.

5. Sign-in sheet for the site visit held on February 1, 2024.

6. The proposal submittal time and date of 22 Mar 2024 at 12:00:00 p.m. LOCAL TIME remains the same.

7. The attached revised sections are to be replaced in their entirety. Specifications changes are generally identified, for convenience, either by strikeout for deletions, and double underlining of text for additions or a single dark line in the margin. All portions of the revised sections shall apply whether or not changes have been indicated.

8. NOTICE TO OFFERORS: Offerors must acknowledge receipt of this amendment by number and date on offer.

SUMMARY OF CHANGES

SECTION 00 72 00 - GENERAL CONDITIONS

The following have been modified:

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 10 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 1,100 days after notice to proceed. The time stated for completion shall include final cleanup of the premises.

(End of clause)

SECTION 00 73 00 - SUPPLEMENTARY CONDITIONS

The following have been added by full text:

WAGE DETERMINATION REV1 02/24

General Decision Number: WA20240068 02/02/2024

Superseded General Decision Number: WA20230068

State: Washington

Construction Type: Heavy including water and sewer line construction

County: Douglas County in Washington.

HEAVY CONSTRUCTION PROJECTS (including sewer/water construction).

Note: Contracts subject to the Davis-Bacon Act are generally required to pay at least the applicable minimum wage rate required under Executive Order 14026 or Executive Order 13658.

Please note that these Executive Orders apply to covered contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but do not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(1).

|If the contract is entered |. Executive Order 14026 | |into on or after January 30, | generally applies to the | |2022, or the contract is | contract. | |renewed or extended (e.g., an |. The contractor must pay | |option is exercised) on or | all covered workers at | |after January 30, 2022: | least $17.20 per hour (or | | | the applicable wage rate | | | listed on this wage | | | determination, if it is | | | higher) for all hours | | | spent performing on the | | | contract in 2024. | |If the contract was awarded on|. Executive Order 13658 | |or between January 1, 2015 and| generally applies to the | |January 29, 2022, and the | contract. | |contract is not renewed or |. The contractor must pay all| |extended on or after January | covered workers at least | |30, 2022: | $12.90 per hour (or the | | | applicable wage rate listed| | | on this wage determination,| | | if it is higher) for all | | | hours spent performing on | | | that contract in 2024. |

The applicable Executive Order minimum wage rate will be adjusted annually. If this contract is covered by one of the Executive Orders and a classification considered necessary for performance of work on the contract does not appear on this wage determination, the contractor must still submit a conformance request.

Additional information on contractor requirements and worker protections under the Executive Orders is available at http://www.dol.gov/whd/govcontracts.

Modification Number Publication Date 0 01/05/2024 1 02/02/2024

CARP0059-011 06/01/2021

Rates Fringes

CARPENTER (Including Formwork)

EAST OF 120TH MERIDIAN......$ 38.87 17.84

MILLWRIGHT

EAST OF 120TH MERIDIAN......$ 50.68 20.14

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - ALL

CLASSIFICATIONS EXCEPT MILLWRIGHTS AND PILEDRIVERS

Hourly Zone Pay shall be paid on jobs located outside of the free zone computed from the city center of the following listed cities:

Seattle Olympia Bellingham Auburn Bremerton Anacortes Renton Shelton Yakima Aberdeen-Hoquiam Tacoma Wenatchee Ellensburg Everett Port Angeles Centralia Mount Vernon Sunnyside Chelan Pt. Townsend

Zone Pay:

0 -25 radius miles Free 26-35 radius miles $1.00/hour 36-45 radius miles $1.15/hour 46-55 radius miles $1.35/hour Over 55 radius miles $1.55/hour

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - MILLWRIGHT

AND PILEDRIVER ONLY)

Hourly Zone Pay shall be computed from Seattle Union Hall, Tacoma City center, and Everett City center

Zone Pay:

0 -25 radius miles Free 26-45 radius miles $ .70/hour Over 45 radius miles $1.50/hour

CARP0770-002 06/01/2020

Rates Fringes

CARPENTER (Including Formwork)

WEST OF 120TH MERIDIAN......$ 46.92 18.02

MILLWRIGHT

WEST OF 12OTH MERIDIAN......$ 48.42 18.02

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - ALL

CLASSIFICATIONS EXCEPT MILLWRIGHTS AND PILEDRIVERS

Hourly Zone Pay shall be paid on jobs located outside of the free zone computed from the city center of the following listed cities:

Seattle Olympia Bellingham Auburn Bremerton Anacortes Renton Shelton Yakima Aberdeen-Hoquiam Tacoma Wenatchee Ellensburg Everett Port Angeles Centralia Mount Vernon Sunnyside

Chelan Pt. Townsend

Zone Pay:

0 -25 radius miles Free 26-35 radius miles $1.00/hour 36-45 radius miles $1.15/hour 46-55 radius miles $1.35/hour Over 55 radius miles $1.55/hour

(HOURLY ZONE PAY: WESTERN AND CENTRAL WASHINGTON - MILLWRIGHT

AND PILEDRIVER ONLY)

Hourly Zone Pay shall be computed from Seattle Union Hall, Tacoma City center, and Everett City center

Zone Pay:

0 -25 radius miles Free 26-45 radius miles $ .70/hour Over 45 radius miles $1.50/hour

ELEC0191-013 06/01/2022

Rates Fringes

ELECTRICIAN

DOUGLAS, CHELAN, and OKANOGAN Counties...........$ 46.15 26.10

ISLAND, SAN JUAN, SKAGIT,

SNOHOMISH and WHATCOM Counties....................$ 53.20 27.51

* ENGI0302-025 06/01/2023

WEST OF THE 120TH MERIDIAN

Rates Fringes

Power equipment operators:

Group 1A...................$ 54.93 25.57 Group 1AA..................$ 55.75 25.57 Group 1AAA.................$ 56.54 25.57 Group 1.....................$ 54.13 25.57 Group 2.....................$ 53.42 25.57 Group 3.....................$ 52.83 25.57 Group 4.....................$ 49.40 25.57

Zone Differential (Add to Zone 1 rates):

Zone 2 (26-45 radius miles) - $1.00 Zone 3 (Over 45 radius miles) - $1.30

BASEPOINTS: Aberdeen, Bellingham, Bremerton, Everett, Kent, Mount Vernon, Port Angeles, Port Townsend, Seattle, Shelton, Wenatchee, Yakima

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1AAA - Cranes-over 300 tons, or 300 ft of boom (including jib with attachments)

GROUP 1AA - Cranes 200 to 300 tons, or 250 ft of boom (including jib with attachments); Tower crane over 175 ft in height, base to boom; Excavator/Trackhoe: Over 90 metric tons

GROUP 1A - Cranes, 100 tons thru 199 tons, or 150 ft of boom (including jib with attachments); Crane-overhead, bridge type, 100 tons and over; Tower crane up to 175 ft in height base to boom; Excavator/Trackhoe: over 50 metric tons to 90 metric tons

GROUP 1 - Cranes 45 tons thru 99 tons, under 150 ft of boom (including jib with attachments); Crane-overhead, bridge type, 45 tons thru 99 tons; Derricks on building work;;

Excavator/Trackhoe: over 30 metric tons to 50 metric tons;

Dozer D-10; Paver; Scraper-self propelled 45 yards and over

GROUP 2 - Cranes, 20 tons thru 44 tons with attachments;

Crane-overhead, bridge type-20 tons through 44 tons;;

Excavator/Trackhoe: 15 to 30 metric tons; Drilling Machine;

Screed; Piledriver; Scraper-self propelled under 45 yards;

Boring Machine

GROUP 3 - Cranes-thru 19 tons with attachments; A-frame crane over 10 tons;; Dozers-D-9 and under; Excavator/Trackhoe:

under 15 metric tons; Forklift: 3000 lbs and over with attachments; Oiler; Drill Assistant; Boom Truck over 10 tons

GROUP 4 - Cranes-A frame-10 tons and under; Forklift: under 3000 lbs with attachments; Boom Truck 10 tons and under

ENGI0370-024 07/01/2019

EAST OF THE 120TH MERIDIAN

Rates Fringes

POWER EQUIPMENT OPERATOR

GROUP 1.....................$ 28.46 17.25

GROUP 2.....................$ 28.78 17.25

GROUP 3.....................$ 29.38 17.25

GROUP 4.....................$ 29.55 17.25

GROUP 5.....................$ 29.71 17.25

GROUP 6.....................$ 29.99 17.25

GROUP 7.....................$ 30.26 17.25

GROUP 8.....................$ 31.36 17.25

ZONE DIFFERENTIAL (Add to Zone 1 rate): Zone 2 - $2.00

Zone 1: Within 45 mile radius of Spokane, Pasco, Washington;

Lewiston, Idaho

Zone 2: Outside 45 mile radius of Spokane, Pasco, Washington; Lewiston, Idaho

POWER EQUIPMENT OPERATORS CLASSIFICATIONS

GROUP 1: Drill Assistant

GROUP 2: Fork Lift

GROUP 3: Boring Machine

GROUP 4: Oiler; Drill (churn, core, calyx or diamond)

GROUP 5: Trackhoe/Excavator (under 3/4 yd.); Drilling equipment (8 unch bit and over) (robbins, reverse circulation and similar); Piledriver; Cranes (25 tons & under); Boom Truck (Under 25 tons)

GROUP 6: Trackhoe/Excavator (3/4 yd. to 3 yd.), Bulldozer, 834 R/T & similar; Paver; Scraper; Screed; Cranes (over 25 tons, to and including 45 tons)

GROUP 7: Trackhoe/Excavator (3 yds & over); Cranes (over 45 tons to but not including 85 tons)

GROUP 8: Cranes (85 tons and over, and all climbing, overhead,rail and tower)

BOOM PAY: (All Cranes, Including Tower) 180 ft to 250 ft $ .50 over scale Over 250 ft $ .80 over scale

NOTE:

In computing the length of the boom on Tower Cranes, they shall be measured from the base of the Tower to the point of the boom.

HAZMAT:

Anyone working on HAZMAT jobs, working with supplied air shall receive $1.00 an hour above classification.

IRON0014-013 01/02/2023

Rates Fringes

IRONWORKER (Ornamental, Reinforcing and Structural)......$ 37.11 31.57

LABO0238-010 06/01/2023

EAST OF THE 120TH MERIDIAN

Rates Fringes

LABORER

GROUP 1.....................$ 33.88 15.60

GROUP 2.....................$ 36.72 15.60

GROUP 3.....................$ 37.03 15.60

GROUP 4.....................$ 37.33 15.60

Zone Differential (Add to Zone 1 rates): Zone 2 - $2.00

BASE POINTS: Pasco

Zone 1: 0-45 radius miles from the main post office.

Zone 2: 45 radius miles and over from the main post office

LABORERS CLASSIFICATIONS

GROUP 1: Flagger

GROUP 2: Common or General Laborer; Form-Stripping

GROUP 3: Mason Tender-Cement/Concrete; Handheld Drill

GROUP 4: Grade Checker; High Scaler; Pipelayer

LABO0238-014 06/01/2023

Rates Fringes

LABORER: Mason Tender - Brick...$ 34.97 15.60

LABO0348-009 06/01/2022

WEST OF THE 120TH MERIDIAN

Rates Fringes

LABORER

GROUP 2.....................$ 29.16 13.80

GROUP 3.....................$ 31.94 13.80

GROUP 4.....................$ 32.72 13.80

GROUP 5.....................$ 33.30 13.80

ZONE DIFFERENTIAL (ADD TO ZONE 1 RATES):

ZONE 2 - $1.00

ZONE 3 - $1.30

BASE POINTS: BELLINGHAM, MT. VERNON, EVERETT, SEATTLE, KENT,

TACOMA, OLYMPIA, CENTRALIA, ABERDEEN, SHELTON, PT.

TOWNSEND, PT. ANGELES, AND BREMERTON

ZONE 1 - Projects within 25 radius miles of the respective city hall ZONE 2 - More than 25 but less than 45 radius miles from the respective city hall ZONE 3 - More than 45 radius miles from the respective city hall

LABORERS CLASSIFICATIONS

GROUP 2: Flagger

GROUP 3: General or Common Laborer; Form-Stripping

GROUP 4: Pipelayer; Handheld Drill

GROUP 5: Mason Tender-Brick; Mason Tender-Cement/Concrete;

Grade Checker; High Scaler

PAIN0005-003 07/01/2022

Rates Fringes

PAINTER (Brush, Roller, and Spray.)..........................$ 28.41 14.50

TEAM0690-006 06/01/2022

Rates Fringes

Truck drivers: (ANYONE

WORKING ON HAZMAT JOBS SEE

FOOTNOTE A BELOW)

ZONE 1:SPOKANE ZONE CENTER

GROUP 5....................$ 37.37 20.03

Zone Differential (Add to Zone 1 rate: Zone 1 + $2.00)

BASE POINTS: Spokane, Moses Lake, Pasco, Lewiston

Zone 1: 0-45 radius miles from the main post office Zone 2: Outside a 45 mile radius from the main post office

TRUCK DRIVERS CLASSIFICATIONS

GROUP 5: Semi-Trailer Truck

FOOTNOTE A - Anyone working on a HAZMAT job, where HAZMAT cerfification is required, shall be compensated as a premium, in addition to the classification working in as follows:

LEVEL C-D: - $.50 PER HOUR - This level may use an air purifying respirator or additional protective clothing.

LEVEL A-B: - $1.00 PER HOUR - Uses supplied air in conjunction with a chemical splash suit or fully encapsulated suit with a self-contained breathing apparatus.

Employees shall be paid Hazmat pay in increments of four(4) and eight(8) hours.

* SUWA2009-059 08/07/2009

Rates Fringes

CEMENT MASON/CONCRETE FINISHER...$ 24.50 6.30

LABORER: Common or General (Water and Sewer Lines)..........$ 20.79 4.63

LABORER: Landscape & Irrigation.......................$ 12.27 ** 2.73

OPERATOR: Asphalt Plant.........$ 34.14 0.68

OPERATOR: Backhoe...............$ 28.46 6.04

OPERATOR: Bobcat/Skid Steer/Skid Loader................$ 10.63 ** 0.00

OPERATOR: Broom/Sweeper.........$ 27.03 4.67

OPERATOR: Grader/Blade..........$ 27.56 5.53

OPERATOR: Loader................$ 26.90 7.65

OPERATOR: Mechanic..............$ 27.09 7.30

OPERATOR: Power Shovel..........$ 25.12 7.83

OPERATOR: Roller................$ 29.18 4.14

TRUCK DRIVER, Includes Dump Truck............................$ 13.00 ** 0.26

TRUCK DRIVER: Flatbed Truck.....$ 22.74 6.29

TRUCK DRIVER: Lowboy Truck......$ 22.89 5.72

TRUCK DRIVER: Water Truck.......$ 23.46 6.06

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

** Workers in this classification may be entitled to a higher minimum wage under Executive Order 14026 ($17.20) or 13658 ($12.90). Please see the Note at the top of the wage determination for more information. Please also note that the minimum wage requirements of Executive Order 14026 are not currently being enforced as to any contract or subcontract to which the states of Texas, Louisiana, or Mississippi, including their agencies, are a party.

Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year.

Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at https://www.dol.gov/agencies/whd/government-contracts.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (iii)).

The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of ""identifiers"" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate).

Union Rate Identifiers

A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than ""SU"" or ""UAVG"" denotes that the union classification and rate were prevailing for that classification in the survey. Example:

PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014.

Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate.

Survey Rate Identifiers

Classifications listed under the ""SU"" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier.

Survey wage rates are not updated and remain in effect until a new survey is conducted.

Union Average Rate Identifiers

Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010

08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier.

A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour National Office because National Office has responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION

The following have been deleted:

WAGE DETERMINATION

(End of Summary of Changes)

CJD Units 1-16 Isolated Phase Bus 22016 Chief Joseph Dam, Bridgeport, WA W912DW24R0021

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 11 00.00 26

SUMMARY OF WORK

PART 1 GENERAL

1.1 SUMMARY

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Summary of Work

1.2.2 Location

1.3 OCCUPANCY OF PREMISES

1.4 EXISTING WORK

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section Table of Contents --

SECTION 01 11 00.00 26 Page 1

SECTION 01 11 00.00 26

SUMMARY OF WORK

PART 1 GENERAL

1.1 SUMMARY

This Section provides a summary of the various Contract work elements and their relationship to each other. This Section does not provide the technical detail for particular work activities, but describes the work as a whole, providing overall perspective to the separate tasks and their interrelationships. Use this Section in conjunction with all the Specification Sections and the Drawings to establish the total work requirements.

1.2 WORK COVERED BY CONTRACT DOCUMENTS

1.2.1 Summary of Work

The scope of this Contract covers the following:

1. Replacement of the 7000 amperes sections of the iso-phase bus for Units 1-4. The work must include:

a. Demolition of all existing bus work

b. Installation of new bus work

c. Perform all associated field-testing including torque hardware, digital low resistance measurements at each connection, and hi-pot testing

2. Replacement of the 4000 amperes outdoor sections of the iso-phase bus for Units 1-16. The work must include:

a. Demolition of all existing bus work

b. Demolition of all existing steel supports

c. Installation of new bus work including new supporting structure

d. Perform all associated field-testing including torque hardware, digital low resistance measurements at each connection, and hi-pot testing

e. Provide new transformer compartments designed with removable covers and low point drains

f. Provide new flexible bellows

g. Provide new wall seal assemblies and through-bushings

3. Refurbishment of the iso-phase bus for Units 1-16, not replaced under this contract. The work must include:

a. Cleaning and testing of all insulators

b. Replacement of damaged insulators; if any insulators show signs of voltage tracking, determine the cause of tracking

c. Replacement of all gaskets and bellows

d. Replacement of all steel isolation material between bus housing and support

e. Replacement of all of seal-off bushings

SECTION 01 11 00.00 26 Page 2

f. Complete cleaning

g. Replacement of adapter bars as required

h. Replacement of flexible links

i. Splice locations disassembly, check silver plate and re-silver the plate, re-assemble

j. Perform all associated field-testing including torque hardware, digital low resistance measurements at each connection, and hi-pot testing

k. Bring bus support system up to current seismic standards, either by replacing supports with new or analyzing existing supports and rehabilitating as necessary. This includes steel supports and associated concrete anchors.

4. Provide the iso-phase bus manufacturer's field engineering services on site to oversee installation of the new iso-phase bus.

5. Provide as-constructed contract drawings and as-constructed shop drawings, as indicated.

6. Provide Operations and Maintenance instructions on the new iso-phase bus.

1.2.2 Location

The work site is located at Chief Joseph Powerhouse in Bridgeport, Washington.

1.3 OCCUPANCY OF PREMISES

The Chief Joseph Dam and Powerhouse is a working facility and daily routines require frequent operations to be conducted. In addition, other equipment at the powerhouse must remain accessible for routine inspections, testing, and maintenance activities. Buildings will be occupied during performance of work under this Contract.

Before work is started, arrange with the Contracting Officer a sequence of procedure, means of access, space for storage of materials and equipment, and use of approaches, decks, and roadways. All major components shall be on site, prior to a transformer outage, to ensure outages are complete as scheduled with no manufacturing delays. Major components are any components requiring more than 3 months lead time. Major components shall be individually identified in the project schedule with delivery to site as a predecessor to outage start.

1.4 EXISTING WORK

In addition to "FAR 52.236-9, Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements":

a. Remove or alter existing work in such a manner as to prevent injury or damage to any portions of the existing work which remain.

b. Repair or replace portions of existing work which have been altered during construction operations to match existing or adjoining work, as approved by the Contracting Officer. At the completion of operations, existing work must be in a condition equal to or better than that which existed before new work started.

SECTION 01 11 00.00 26 Page 3

PART 2 PRODUCTS - NOT USED

PART 3 EXECUTION - NOT USED

-- End of Section --

SECTION 01 11 00.00 26 Page 4

SECTION TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

SECTION 01 14 00

WORK RESTRICTIONS (CJD)

PART 1 GENERAL

1.1 REFERENCES

1.2 SUBMITTALS

1.3 GENERAL ACCESS REQUIREMENTS

1.4 ACCESS TO RESTRICTED AREAS

1.4.1 Background Check

1.4.2 Escorting of Contract Personnel

1.5 WORK AREAS AND ACCESS

1.5.1 Access Roads

1.5.2 Government Roadways

1.5.3 Access By Government Personnel

1.5.4 Contractor's Staging Area and Employee Access

1.5.5 Storage of Equipment and Materials

1.5.6 Material Deliveries for the Contractor

1.5.7 Contractor's Vehicles

1.5.8 Contractor Employee Privately-Owned Vehicles

1.6 WORK RESTRICTIONS

1.6.1 General

1.6.2 Operating Project Coordination

1.7 CONTRACTOR'S PROJECT PERSONNEL

1.7.1 Contractor's General Personnel

1.7.1.1 Contractor Employees

1.7.1.2 Employee Termination

1.7.1.3 Access Control

1.8 HECP PROCEDURES TRAINING CERTIFICATION

1.9 SUPPLEMENTAL ANTITERRORISM/OPERATIONS SECURITY REQUIREMENTS

1.9.1 Physical security and access control requirements

1.9.2 Escorting in classified and/or sensitive areas

1.9.3 E-Verify Pre-Screening

1.10 PLANT AND EQUIPMENT LIST

1.11 DAMAGED EQUIPMENT OR ABNORMAL CONDITIONS

1.12 PROTECTION OF MATERIAL AND WORK

1.13 CONTRACTOR'S EQUIPMENT AND MATERIAL

1.14 SITE WORKING HOURS

1.14.1 Government Project Personnel Working Hours

1.14.2 Contractor's Working Hours

1.15 WEEKLY COORDINATION MEETINGS

1.16 COORDINATION WITH OTHERS

1.16.1 Work By The Government Concurrent With Contractor Work

1.16.2 Use and Possession in the Working Areas Prior to Completion

1.17 NOISE CONTROL

1.18 FIRE CONTROL

1.19 SITE INVESTIGATIONS AND CONDITIONS AFFECTING THE WORK

PART 2 PRODUCTS

SECTION 01 14 00 Page 1

PART 3 EXECUTION

3.1 EQUIPMENT AVAILABILITY AND ACCESS

-- End of Section Table of Contents --

SECTION 01 14 00 Page 2

SECTION 01 14 00

WORK RESTRICTIONS (CJD)

PART 1 GENERAL

1.1 REFERENCES

The publications listed below form a part of this specification to the extent referenced. The publications are referenced to in the text by basic designation only.

U.S. ARMY CORPS OF ENGINEERS (USACE)

EM 385-1-1 (2014) Safety and Health Requirements Manual

U.S. NATIONAL ARCHIVES AND RECORDS ADMINISTRATION (NARA)

29 CFR 1910 Occupational Safety and Health Standards

29 CFR 1926 Safety and Health Regulations for Construction

1.2 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. Submit the following in accordance with SECTION 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Background Check; G

Loading Diagram; G

Contractor Employees

Organizational Chart

HECP Procedures Training Certification

1.3 GENERAL ACCESS REQUIREMENTS

Access to the dam structures will be controlled at an entrance security station. Incoming traffic will be restricted from entering the controlled area until proper identification is provided. All personnel entering this area will be required to pick up their Contractor badge and sign in/out at the security station. Access other than established working hours will require prior approval by the Contracting Officer. The Government may search any vehicle or personnel passing through the security station.

Prohibited items include weapons, incendiary devices, bombs, and

SECTION 01 14 00 Page 3 ammunition. Contractor and sub-contractor employees will not be permitted to bring guests, family members, non-employees, or pets to the job site at any time.

1.4 ACCESS TO RESTRICTED AREAS

Contractor employees and equipment located between the red restricted signs and the dam including the powerhouse, transformer deck, intake structure, spillway, or water surface are subject to restrictions on entry and movement.

1.4.1 Background Check

The Contractor's Site Superintendent, CQC Manager, and SSHO must receive a favorable background check or FBI fingerprint process prior to accessing work at the Chief Joseph Dam (CJD) project.

Previously existing background checks (NCIC-III) must be verifiable through the Defense information Security System (DISS). Contractor personnel without existing background checks must complete the attached packet (01 14 00-A) including Contractor PSI Data Prep Information Sheet, OF 306 - Dated OCT 2019, and SF-86 Signature Sheet - Dated November 2016.

Submit packet (01 14 00-A) and provide Driver's License to the District Security Officer via the Contracting Officer. The District Security Office will forward requests to the appropriate investigating agency. Personnel will be granted access to the unclassified restricted areas, only after the verification of an existing investigation or the favorable review of their investigation request.

If Contractor is submitting fingerprints, complete all required forms and processes for fingerprints at CJD. Additionally, Contractor will need to provide hard copies of their Social Security Card, Driver's License, Passport or Birth Certificate for fingerprints. The fingerprint services are offered at CJD or at locations such as police station, closest military installation, etc. For locations other than CJD, the Contractor will also complete a FD-258 (Rev. 5-15-2017). Mail the hard copy documents through the project security specialist to the District Security Office.

1.4.2 Escorting of Contract Personnel

Contractor with a favorable Tier 1 Background Investigation will be issued an access badge or an identification badge (depending on access level) for access through the main gate and granted unescorted access to the areas listed in the contract. Persons with a favorable Tier 1 Background Investigation may also escort persons with favorable FBI Background Check (NCIC-III) . Persons with favorable FBI Background Check (NCIC-III) only will have to be escorted by a Government representative or by a Contractor who has a favorable Tier 1 background investigation. Contractors are not allowed to work on-site until at least an NCIC-III is returned as favorable. When on-site, Contractor's identification badge must always be worn and visible.

The COR will submit an RVA for Foreign contractors. The contractor must submit legible color copy of their passport showing the page with photo, name, dates, etc. The submittal must be submitted 30 days in advance.

Foreign contractors will not be permitted to get access to the site nor can they be escorted without RVA approval.

SECTION 01 14 00 Page 4

All Government issued badges must be returned prior to end of contract.

1.5 WORK AREAS AND ACCESS

1.5.1 Access Roads

New access roads are NOT required. Use existing access roads designated by Project office. Any Contractor-caused damage to existing roadways or CJD Project grounds used for access shall be repaired and the surface shall be restored to its pre-damaged condition. Comply with all requirements of the State and County authorities for use of existing roadways, such as traffic regulations, load limits, etc. Notify the Contracting Officer prior to blocking any roads within the CJD project site.

1.5.2 Government Roadways

Access to the powerhouse access decks by heavy construction vehicles, such as truck cranes, shall be limited to AASHTO HS-20-44 loading. For any vehicles in excess of this capacity, a loading diagram shall be submitted for review and approval showing the wheel loads and wheel spacing. Do not block the full width of the powerhouse access deck unless otherwise approved in advance.

1.5.3 Access By Government Personnel

Maintain clear access through all work areas for access of Government personnel and equipment. The minimum width of clear access shall be 4 feet unless otherwise approved.

1.5.4 Contractor's Staging Area and Employee Access

Areas off-limits to Contractor personnel will be discussed at the preconstruction meeting. Salespersons or personnel seeking the Contractor will not be granted access.

Upon Contractor's request, the Contracting Officer will designate a supplemental area for the Contractor's use and storage of trailers, equipment, and materials required to perform work under this contract.

The security of the Contractor's property and items furnished or used to perform work under this contract, are the Contractor’s responsibility whether stored inside or outside the powerhouse. Utilities will not be provided to the supplemental area by the Government.

All Contractor site facilities shall be disposed of prior to final acceptance of all work.

1.5.5 Storage of Equipment and Materials

Storage of equipment and materials will be permitted only in designated staging areas approved by the Contracting Officer. All equipment and materials to be stored shall be approved prior to storage within the Government designated temporary storage area. Any chemicals used or stored on the job site shall have appropriate MSDS documentation.

Hazardous materials shall be stored in appropriate flammable material storage lockers provided by the Contractor and located in an area designated by the Contracting Officer. A minimum access space of 4 feet shall be maintained.

SECTION 01 14 00 Page 5

1.5.6 Material Deliveries for the Contractor

All deliveries to CJD shall be coordinated with the Contracting Officer.

In no case shall a delivery be received after 2:30 p.m. Monday through Thursday, weekends, or on Holidays. If the Contractor needs to unload materials within the restricted area and cannot clearly show, to the Government’s satisfaction, that the delivery will be complete before 5:00 p.m., then the delivery will be denied. All materials delivered on-site are subject to search. Contractor is to verify that delivery drivers are properly credentialed and have the EM 385-1-1 required PPE in their possession.

1.5.7 Contractor's Vehicles

Contractor's vehicles shall only park in areas approved by the Contracting Officer. The actual quantity of vehicles onsite shall be minimized.

Label vehicles with the Contractor’s company name. Magnetic signs are acceptable.

1.5.8 Contractor Employee Privately-Owned Vehicles

Parking of private vehicles shall be restricted to areas designated by the Contracting Officer. Privately-owned vehicles (POV's) are prohibited beyond the powerhouse access road bridge entrance (Foster Creek Bridge), and on the spillway/intake deck. While work is being performed in or near these areas, Contractor personnel shall park their POV's outside the prohibited area. Transport personnel to the work area via Contractor's vehicles.

1.6 WORK RESTRICTIONS

1.6.1 General

Chief Joseph Dam is a peaking plant with operational restraints and restrictions to maintain operational readiness status and load following requirements with 27 main units and two station service house units. The isolated phase bus for generating units 1-16 is original to the plant and was provided by two manufacturers (General Electric and I-T-E). Each transformer bank connecting to four (4) generators by isolated phase bus will be taken out of service, locked, and tagged out by the Government for the refurbishment or replacement of the isolated phase bus. No overlapping outages of the transformers will be allowed for Transformer Banks T1 to T4. All work associated with each isolated phase bus will be fully installed and commissioned before the next transformer bank can be removed from service. Line outages including transformer bank outages require 60 days advanced notice from the beginning of the month the work is to be performed. All major components shall be on site, prior to a transformer outage, to ensure outages are complete as scheduled with no manufacturing delays. Major components are any components requiring more than 3 months lead time. Major components shall be individually identified in the project schedule with delivery to site as a predecessor to outage start.

1.6.2 Operating Project Coordination

Careful coordination with the operating project will be necessary to address operational restraints and ensure a successful project.

Contact the Contracting Officer for any requests, questions, or concerns regarding project scheduling and phasing.

SECTION 01 14 00 Page 6

1.7 CONTRACTOR'S PROJECT PERSONNEL

1.7.1 Contractor's General Personnel

Maintain and update as necessary a complete organizational chart of all positions that will be working on the project. Input this data into RMS.

1.7.1.1 Contractor Employees

Submit under letterhead, a listing of all employees and two clear legible sets of color photocopies of the employees’ state issued ID card or drivers licenses to the Contracting Officer a minimum of two weeks before they will be working on site. The ID card shall include the following information:

Name of Employee Recent photo Birth date Height Weight Hair color Eye color

If an employee cannot be positively identified from photo, they will not be admitted onsite. Employees working for subcontractors must also be authorized under the primary Contractor’s letterhead. Upon an employee’s first arrival onsite, the Government will provide a Project photo identification tag before the employee will be allowed to enter the powerhouse and dam structures. Preparation of the identification tag may take up to 2 hours. The identification tag must be returned to the Contracting Officer when the work is complete or when the individual departs from the Project. Prominently display at all times onsite (on each person) the identification tag issued. When required by the Government, obtain and submit fingerprints of all workers.

1.7.1.2 Employee Termination

If a Contractor employee resigns or is terminated the Contracting Officer, or designated representative shall be so notified at the earliest opportunity, but in no case later than the start of the succeeding workday.

1.7.1.3 Access Control

Contractor personnel shall be instructed to present identification credential upon request by proper authority as established by the Contracting Officer.

1.8 HECP PROCEDURES TRAINING CERTIFICATION

a. Provide annual Hazardous Energy Control Program (HECP) training to all Contractor and subcontractor personnel working under clearances as required for all "affected personnel" utilizing the online methodology defined below. Non-craft personnel (administration staff and other non-craft personnel) will be required to take the General Safety Awareness training at the same website.

b. Chief Joseph employees will provie HECP training on project.

Contractors must pass exam to become certified.

SECTION 01 14 00 Page 7

C. Submit requests for HECP Affected Persons training to the Contracting Officer Representative at least 5 days in advance.

1.9 SUPPLEMENTAL ANTITERRORISM/OPERATIONS SECURITY REQUIREMENTS

The security requirements described below apply to all contract personnel (including employees of the prime Contractor (“Contractor”) and all subcontractor employees) supporting the performance requirements of this contract. The Contractor is responsible for compliance with these security requirements. Questions regarding security matters shall be addressed to Contracting Officer Representative (COR). Contract personnel are critical to the overall security and safety of US Army Corps of Engineers (USACE) installations, facilities and activities, and security awareness training contributes to those efforts. The Department of Defense (DoD) and Army security training requirements specified below, if applicable, are performance requirements; all applicable contract personnel shall complete initial training within 30 days of contract award or the date new contract personnel begin performance on the contract. Within five business days from the completion of training, the Contractor shall provide written documentation (e.g., email or memorandum) to the Government representative. The documentation shall include the names of contract personnel trained and which training they completed; the Contractor shall maintain training records as part of their contract files and be prepared to provide copies of training certificates to the Contracting Officer Representative (COR). Contractor personnel and vehicles are subject to search when entering federal installations. Additionally, all contract personnel shall comply with Force Protection Condition (FPCON) measures, Random Antiterrorism Measures (commonly referred to as “RAMs”), and Health Protection Condition (HPCON) measures. The Contractor is responsible for meeting performance requirements during elevated FPCON and/or HPCON levels in accordance with applicable RA plans and procedures -- this includes identifying mission essential and non-mission essential personnel. In addition to the changes otherwise authorized by the changes clause of this contract, should the FPCON or HPCON levels at any individual facility or installation change, the Government may implement security changes that affect contract personnel. The Contractor shall ensure all contract personnel are aware of their security responsibilities, including any site-specific requirements identified in local policies or procedures.

1.9.1 Physical security and access control requirements

All contract personnel requiring physical access to a facility shall comply with the access control procedures of that location. Contract personnel requiring unescorted access to meet contract performance requirements on a DoD installation in the US shall be vetted by the installation/facility Provost Marshal/Directorate of Emergency Services/Security Office using the National Crime Information Center-Interstate Identification Index (commonly referred to as “NCIC-III”) and Terrorist Screening Database (commonly referred to as “TSDB”). Contract personnel shall comply with all personal identity verification requirements specified in installation/facility policies and procedures. Contract personnel who do not meet requirements for unescorted access to USACE facilities shall coordinate escorted access with the Government representative, as needed. Contract personnel who receive keys, access cards, or lock combinations that provide access to government-owned property shall comply with key and lock control procedures of the requiring activities.

SECTION 01 14 00 Page 8

1.9.2 Escorting in classified and/or sensitive areas

In accordance with applicable regulations, all contract personnel who do not possess the appropriate security clearance or access privileges will be escorted in areas where they may be exposed to classified information or operations, sensitive information or activities, or restricted areas.

1.9.3 E-Verify Pre-Screening

Contractors shall comply with the requirements set forth in FAR clause 52.222-54 Employment Eligibility Verification and FAR Subpart 22.18 in using the E-Verify Program at (https://www.e-verify.gov/) to meet the contract employment eligibility requirements. Contractors are encouraged to cooperate with Federal and State agencies responsible for enforcing labor requirements to include eligibility for employment under United States immigration laws in accordance with FAR 22.102-1(i). An initial list of verified/eligible candidates shall be provided to the COR no later than three business days after the initial contract award.

1.10 PLANT AND EQUIPMENT LIST

A complete list of Plant and Equipment List to be used onsite shall be produced in RMS. List shall include rented equipment as well as lease-purchase or sale-leaseback equipment. The list shall indicate dates equipment is assigned to or removed from the project, dates scheduled for repairs and returned for use, and adequate identification or description of each item of equipment including manufacturer's name (abbreviated), model number, manufacturer's serial number, year of manufacture, and Contractor's assigned serial or record number.

1.11 DAMAGED EQUIPMENT OR ABNORMAL CONDITIONS

Notify the Contracting Officer immediately upon finding any damaged equipment or other abnormal conditions that requires additional work outside the contract requirements. The failure or abnormality shall not be disturbed until witnessed by the Contracting Officer. Damaged equipment or abnormal conditions not reported shall be corrected at the Contractor's expense.

1.12 PROTECTION OF MATERIAL AND WORK

Materials, supplies, tools, equipment and Government property (including all tools, equipment, and special devices supplied by the Contractor and to be turned over to the Government at the end of the Contract) shall be protected and preserved in accordance with manufacturer's recommendations. If material, equipment, supplies, and work performed are not adequately protected, such property may be protected by the Government and the cost thereof will be charged to the Contractor or deducted from any payment due.

1.13 CONTRACTOR'S EQUIPMENT AND MATERIAL

Unless otherwise specifically cited elsewhere in these specifications, provide rigging, lifts, operators, and other necessary means to unload, load, and move equipment or materials as required to perform the work.

SECTION 01 14 00 Page 9

1.14 SITE WORKING HOURS

1.14.1 Government Project Personnel Working Hours

The working hours of the project staff are Mondays through Thursdays from 6:30 a.m. until 5:00 p.m., excluding Federal holidays. Fridays are non-work days. All Project support required by the Contractor shall be scheduled to occur during these hours.

1.14.2 Contractor's Working Hours

The Contractor's working hours are 6:30 A.M. to 5:00 P.M., Monday through Thursday, excluding Federal Holidays.