Solicitation.pdf

IFB No. W912DW-18-B-0008

Seattle District

FY18 Galvanized Landfill Fencing Mountain Home AFB, ID

Construction Solicitation and Specifications

This is a 100% Set-Aside for Service Disabled Veteran Owned Small Business (SDVOSB)

APRIL 2018

Location of the w ork to be performed shall be at Mountain Home Air Force Base, Idaho. The Contractor shall provide all personnel, equipment, supplies, facilities, transportation, tools, materials, supervision, testing, and other items necessary to service an estimated of 9,600 linear feet of 6 feet high galvanized chain link fence and 13,000 liner feet of 4 feet high cable barrier at the lagoon landfills in accordance w ith the attached plans and specif ications.

This project is 100% set-aside for Service Disabled Veteran Ow ned Small Business (SDVOSB) firms.

In accordance w ith FAR 36.204, the magnitude of w ork is betw een $1,000,000 and $5,000,000.

X

CURT STEPP 206-764-6805

NOTE: In sealed bid solicitations "offer" and "offeror" mean "bid" and "bidder".

10. THE GOVERNMENT REQUIRES PERFORMANCE OF THE WORK DESCRIBED IN THESE DOCUMENTS

NEGOTIATED

18-Apr-2018

(RFP)

(IFB)

CALL:

B. TELEPHONE NO. (Include area code) (NO COLLECT CALLS)

See Item 7

2. TYPE OF SOLICITATION

SEALED BID

3. DATE ISSUED

9. FOR INFORMATION A. NAME

SOLICITATION

NSN 7540-01-155-3212 1442-101 STANDARD FORM 1442 (REV. 4-85)

Prescribed by GSA

FAR (48 CFR) 53.236-1(e)

11. The Contractor shall begin performance w ithin _______10 calendar days and complete it w ithin ________365 calendar days after receiving aw ard, X notice to proceed. This performance period is mandatory, negotiable. (See _________________________00 73 00

12 A. THE CONTRACTOR MUST FURNISH ANY REQUIRED PERFORMANCE AND PAYMENT BONDS?

(If "YES," indicate within how many calendar days after award in Item 12B.)

X YES NO

13. ADDITIONAL SOLICITATION REQUIREMENTS:

A. Sealed offers in original and __________1 copies to perform the w ork required are due at the place specif ied in Item 8 by ___________ local time ______________18 May 2018 (date). If this is a sealed bid solicitation, offers must be publicly opened at that time.

shall be marked to show the offeror's name and address, the solicitation number, and the date and time of fers are due.

B. An offer guarantee X is, is not required.

C. All offers are subject to the (1) w ork requirements, and (2) other provisions and clauses incorporated in the solicitation in full text or by reference.

D. Offers providing less than _______90 calendar days for Government acceptance after the date offers are due w ill not be considered and w ill be rejected.

SOLICITATION, OFFER,

AND AWARD

(Construction, Alteration, or Repair)

1. SOLICITATION NO.

IMPORTANT - The "offer" section on the reverse must be fully completed by offeror.

4. CONTRACT NO.

7. ISSUED BY CODE

USA ENGINEER DISTRICT, SEATTLE

ATTN: CENWS-CT

4735 EAST MARGINAL WAY SOUTH, BLDG. 1202

SEATTLE WA 98134-2388

W912DW

PAGE OF PAGES

1 OF

CODE

(Title, identifying no., date):

12B. CALENDAR DAYS

01:00 PM (hour)

Sealed envelopes containing offers

5. REQUISITION/PURCHASE REQUEST NO. 6. PROJECT NO.

467467

8. ADDRESS OFFER TO (If Other Than Item 7)

FAX:TEL: TEL: FAX:

W912DW18B0008 41

20B. SIGNATURE

(REV. 4-85)STANDARD FORM 1442 BACK

TO SIGN

NSN 7540-01-155-3212

SOLICITATION, OFFER, AND AWARD (Continued) (Construction, Alteration, or Repair)

CODE FACILITY CODE

17. The offeror agrees to perform the w ork required at the prices specif ied below in strict accordance w ith the terms of this solicitation, if this offer is accepted by the Government in w riting w ithin ________ calendar days after the date offers are due.

the minimum requirements stated in Item 13D. Failure to insert any number means the offeror accepts the minimum in Item 13D.)

AMOUNTS SEE SCHEDULE OF PRICES

18. The offeror agrees to furnish any required performance and payment bonds.

19. ACKNOWLEDGMENT OF AMENDMENTS

(The offeror acknowledges receipt of amendments to the solicitation -- give number and date of each)

AMENDMENT NO.

DATE

20A. NAME AND TITLE OF PERSON AUTHORIZED TO SIGN

OFFER (Type or print)

AWARD (To be completed by Government)

21. ITEMS ACCEPTED:

22. AMOUNT 23. ACCOUNTING AND APPROPRIATION DATA

24. SUBMIT INVOICES TO ADDRESS SHOWN IN ITEM

(4 copies unless otherwise specified)

CODE

(Insert any number equal to or greater than

20C. OFFER DATE

25. OTHER THAN FULL AND OPEN COMPETITION PURSUANT TO

10 U.S.C. 2304(c) 41 U.S.C. 253(c)

CODE27. PAYMENT WILL BE MADE BY:26. ADMINISTERED BY

(Include ZIP Code)14. NAME AND ADDRESS OF OFFEROR 15. TELEPHONE NO. (Include area code)

See Item 14

(Include only if different than Item 14)16. REMITTANCE ADDRESS

30B. SIGNATURE

29. AWARD (Contractor is not required to sign this document.)

document and return _______ copies to issuing office.) Contractor agrees Your of f er on this solicitation, is hereby accepted as to the items listed. This award con-to f urnish and deliv er all items or perf orm all work, requisitions identif ied summates the contract, which consists of (a) the Gov ernment solicitation and on this f orm and any continuation sheets f or the consideration stated in this y our of f er, and (b) this contract award. No f urther contractual document is contract. The rights and obligations of the parties to this contract shall be necessary .

gov erned by (a) this contract award, (b) the solicitation, and (c) the clauses, representations, certif ications, and specif ications or incorporated by ref er-ence in or attached to this contract.

30A. NAME AND TITLE OF CONTRACTOR OR PERSON AUTHORIZED 31A. NAME OF CONTRACTING OFFICER (Type or print)

30C. DATE

(Type or print)

TEL: EMAIL:

31B. UNITED STATES OF AMERICA 31C. AWARD DATE

BY

CONTRACTING OFFICER WILL COMPLETE ITEM 28 OR 29 AS APPLICABLE

(Contractor is required to sign this28. NEGOTIATED AGREEMENT

(M ust be fully completed by offeror)OFFER

Landfill Fencing Installation 17018 Mountain Home AFB, ID W912DW18B0008

00 11 00 - 5

BID SCHEDULE

Item No.

Description of Item QTY Unit Unit Price

Amount

BASE ITEMS

0001 Security Fence Landfill LF001 1 JOB L.S. $________

0002 Security Fence Landfill LF002 1 JOB L.S. $________

0003 Security Fence Landfill LF003 1 JOB L.S. $________

TOTAL BASE ITEMS (CLINS 0001 THROUGH 0003) $________________

OPTION ITEMS

0004 Security Fence Landfill LF023 1 JOB L.S. $________

TOTAL BASE & OPTION ITEMS (CLINS 0001 THROUGH 0004) $________________

Notes:

1. To better facilitate the receipt and proposal process, all modifications to proposals are to be submitted on copies of the latest Bid Schedules as published in the solicitation or the latest amendment thereto. In lieu of indicating additions/deductions to line items, all Offerors should state their revised prices for each item.

2. Offerors must insert a price on all numbered items of the Bid Schedule. Failure to do so may result in the offer being unacceptable.

3. NSP: Not Seperately Priced; L.S.: Lump Sum

END OF BID SCHEDULE

W912DW18B0008

Section 00 01 10 - Table of Contents

Exhibit/Attachment Table of Contents

DOCUMENT TYPE DESCRIPTION PAGES DATE

Attachment 1 Performance Work

Statement

33 14-MAR-2018

Attachment 2 00 73 00 Special Contract Requirements

196 19-MAR-2018

Section 00 10 00 - Solicitation

SOLICITATION/CONTRACT FORM

TABLE OF CONTENTS / INDEX

Section 00 10 00, Caution to Bidders, Site Visit, Technical Questions (ProjNet-BID), Corporate Certificate Section 00 11 00, Bid Schedule Section 00 21 00, Instructions, Conditions and Notices to Offerors Section 00 45 00, Representations and Certifications & Pre-Award Information Form Section 00 72 00, Contract Clauses Wage Determination Attachment 1: Performance Work Statement Attachment 2: Section 00 73 00, Special Contract Requirements

RETURN THE FOLLOWING WITH YOUR BID:

SF1442, Solicitation, Offer and Award.

Section 00 45 00, Representations and Certifications, to include the Pre-Award Information Form.

20% Bid Bond -- Bid Bonds must be accompanied by a Power of Attorney containing an original signature from the surety. Powers of Attorney dated prior to the date of the bond will only be accepted if accompanied by certification from a current officer of the surety attesting to its authenticity and continuing validity. Electronic, mechanically-applied and printed signatures, seals and dates on the power of attorney shall be considered original signatures, seals and dates, without regard to the order in which they were affixed.

Current SF24 forms are available at the following website: http://www.gsa.gov/portal/forms/type/TOP

Unless specified, the following information does not need to be submitted with your bid, BUT it is required to be completed before the contract can be awarded:

Contractors are required, before receipt of contract award to ensure that their firm is registered in the government web site entitled System for Award Management (SAM) and that all information required is current and up to date.

https://www.sam.gov/portal/public/SAM/

SITE VISIT AND TECH QUESTIONS

This Procurement is

100% set-aside for Service-Disabled Veteran-Owned Small Business

SITE VISIT:

The purpose of the site visit is to familiarize Offerors with the scope of work and provide an opportunity to become familiar with the existing site conditions. It is the intent of the Government that all prospective Offerors visit the jobsite for the purpose of acquainting themselves with local conditions. Non-technical questions will be addressed; however, ALL technical questions regarding the solicitation will be submitted via ProjNet, a web-based program that allows Offerors to post questions regarding the solicitation and to view all questions by other Offerors and answers by USACE. Attendance at the site visit is strongly recommended.

Bidders wishing to visit the site shall contact Mr. Phuc Pham (contact information below) to sign up.

One organized site visit has been scheduled as follows:

Prospective bidders are to assemble at the Visitor Center Main Gate Mountain Home Air Force Base, ID at 8:00 am on Tuesday, 01 May 2018 to obtain 1 day access pass to the base. Individuals will need to have a current, valid state or federally issued driver's license or ID. Anyone wishing to drive on base must have a current vehicle registration and proof of insurance with them. Visitors operating vehicles with company logos, commercial license plates, or laden with tools will be referred to the contractor gate after issuance of a pass. Background checks will be conducted and anyone with an open warrant is likely to be detained. Procedures are available at:

http://www.mountainhome.af.mil/Home/VVCC.aspx. Tour at the Fencing Site will begin promptly at 10:00 am.

BIDDING DOCUMENTS: View solicitations at the Internet site:

www.fedbizopps.gov

FOR INQUIRIES, CONTACT THE FOLLOWING:

Monday through Friday between the hours of 7:00 AM - 3:00 PM.

Administrative: Curt Stepp, Contract Specialist, (206) 764-6805 / curt.stepp@usace.army.mil Technical: Phuc Pham, Project Manager, (206) 316-3332 / Phuc.V.Pham@usace.army.mil

TECHNICAL QUESTIONS:

All inquiries regarding this solicitation are to be submitted via ProjNet-Bidsm.

Telephone and email inquiries will not be accepted. ProjNet-Bidsm is a web-based program that allows bidders to post questions regarding the solicitation and to view all questions by other bidders and answers by USACE. ProjNet-Bidsm can be accessed through ProjNetsm at https://www.projnet.org To access the ProjNet-Bidsm website the first time:

1) Click the Bid tab

2) Click Bidder Inquiry. (The Agency is USACE)

3) a) Enter the following information for access:

1. The Bidder Inquiry Key: P2 467467

2. Valid business contact information (e.g. company name, contact person, business address, phone number and email address). (required on first project only)

3. Establish Secret Question and Answer which will be used as a password (required on first project only)

b) For subsequent access use your email address, the Bid Inquiry Key, and response to the Secret Question to access the ProjNet-Bidsm Module.

4) Submit technical questions. When an answer is posted to a question, the question and answer is then available for all other bidders to review.

5) For questions about the ProjNet-Bidsm, please contact the Call Center help desk toll free at 1-800- 428-HELP (4357), which operates from 8AM to 5PM (Central US time zone).

No response will be posted to inquiries after the Close of Business on the fifth business day preceding the solicitation due date. All bidders will be held to have reviewed the questions and responses in ProjNet-Bidsm prior to bid submission. Nothing in the solicitation is changed unless an amendment is issued.

CORPORATE CERTIFICATE

IF THE CONTRACTOR IS A CORPORATION OR PARTNERSHIP, THE APPLICABLE PORTION OF THE

FORM LISTED BELOW MUST BE COMPLETED. IN THE ALTERNATIVE, OTHER EVIDENCE MUST

BE SUBMITTED TO SUBSTANTIATE THE AUTHORITY OF THE PERSON SIGNING THE CONTRACT.

IF A CORPORATION, THE SAME OFFICER SHALL NOT EXECUTE BOTH THE CONTRACT AND

THE CERTIFICATE.

CORPORATE CERTIFICATE

I, , certify that I am the Secretary of the Corporation named as Contractor herein; that , who signed this contract on behalf of the Contractor was then of said corporation; that said contract was duly signed for and on behalf of said corporation by authority of its governing body and is within the scope of its corporate powers.

(CORPORATE

(Secretary) SEAL)

AUTHORITY TO BIND PARTNERSHIP

This is to certify that the names and signatures of all partners are listed below and that the person signing the contract has authority actually to bind the partnership pursuant to its partnership agreements. Each of the partners individually has full authority to enter into and execute contractual instruments on behalf of said partnership with the United States of America, except as follows: (state "none" or describe limitations, if any)

This authority shall remain in full force and effect until such time as the revocation of authority by any cause whatsoever has been furnished in writing to, and acknowledged by, the Contracting Officer.

(Names and Signatures of all Partners)

NAME SIGNATURE

CAUTION TO BIDDERS

! ! ! C A U T I O N TO B I D D E R S ! ! !

1. TELEPHONES: There are no public telephones at the Seattle District Corps of Engineers.

2. BUSINESS HOURS: For the Seattle District Corps of Engineers are from 7:30 A.M. to 4:00 P.M., Monday through Friday.

3. AVAILABILITY OF FUNDS: Funds are not currently available for this acquisition. No contract award will be made until appropriated funds are made available from which payment for contract purposes can be made.

BEFORE SIGNING AND MAILING THIS OFFER, PLEASE TAKE NOTE OF THE FOLLOWING, AS

FAILURE TO PERFORM ANY ONE OF THESE ACTIONS MAY CAUSE YOUR OFFER TO BE

REJECTED

4. AMENDMENTS: Have you acknowledged receipt of ALL amendments? If in doubt as to the number of amendments issued, please contact the representative listed on the Information Page.

5. AMENDED SECTIONS: If any of the amendments furnished amended sections, the amended sections must be used in submitting your offer.

6. MISTAKE IN OFFER: Have you reviewed your offer price for possible errors in calculation or work left out?

7. OFFER ACCEPTANCE PERIOD: The minimum offer acceptance period is specified in block 13D of SF1442, page 00 11 00 -1, Solicitation, Offer and Award. Please ensure that you allow at least the stated number of calendar days for the Government to accept your offer.

8. SYSTEM FOR AWARD MANAGEMENT: Contractors are required, before receipt of contract award, to ensure that their firm is registered in the government web site entitled System for Award Management (SAM) and that all information required is current and up to date.

https://www.sam.gov/portal/public/SAM/

9. FAR 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber Content Paper (May 2011). The Contractor is asked to submit paper documents, such as offers, letters, or reports that are printed or copied double-sided on paper containing at least 30 percent postconsumer fiber, whenever practicable, when not using electronic commerce methods to submit information or data to the Government.

10. ATTENTION: Due to heightened security, the method of Hand Delivery has changed and takes longer than the previous method of arriving at the Federal Center South building lobby to deliver your bid.

Please allow sufficient time to allow for heightened security at Government installations and to get to Building #1202. Allow time to park, pass through a metal detector, sign in, and receive a building pass at the Federal Center South Building. From there, you will be directed to the USACE Oxbow Building (#1202) which sits behind the Federal Center South Building. Allow additional time.

Report to the Security Desk in the lobby of the USACE Oxbow Building (#1202) and you will be directed to the bid opening room. This room will be available 30 minutes prior to the bid opening. If you do not wish to be present when bids are opened and would like to drop off your bid, contact the following persons upon reporting to the Security Desk: Sonia Frees, Procurement Technician, at 206-764-3516, or the Contracting Specialist, Curt Stepp at 206-764-6805.

A bid is not received by the Government until it is in the physical possession of a representative of the Contracting office. Security guards and other non-contracting personnel are NOT authorized to accept proposals on behalf of the Government. Note that official receipt of a proposal shall be in accordance with FAR 52.214-5.

Note: If delivery is by any means other than Hand Delivery, please check prior to the due date and time to ensure that your bid has arrived on time.

Hand-delivery / Fed-Ex / UPS or other commercial carrier:

Curt Stepp - Contract Specialist, Building 1202 U.S. Army Corps of Engineers, Seattle District

CENWS-CTA

4735 E. Marginal Way S, Building 1202 Seattle, WA 98134-2388

Mail:

Curt Stepp– Contract Specialist U.S. Army Corps of Engineers, Seattle District CENWS-CTA, PO Box 3755 Seattle, WA 98124-3755

Note: Commercial carriers will not deliver proposals to P.O. Boxes.

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 Job Security Fence Landfill LF001

Security Fence Landfill LF001 in accordance with the attached plans and specifications.

FOB: Destination

FFP

NET AMT

0002 Job Security Fence Landfill LF002

Security Fence Landfill LF002 in accordance with the attached plans and specifications.

0003 Job Security Fence Landfill LF003

Security Fence Landfill LF003 in accordance with the attached plans and specifications.

0004 Job OPTION Security Fence Landfill LF023

Security Fence Landfill LF023 in accordance with the attached plans and specifications.

Section 00 21 00 - Instructions

CLAUSES INCORPORATED BY REFERENCE

52.204-6 Unique Entity Identifier OCT 2016 52.204-7 System for Award Management OCT 2016 52.211-6 Brand Name or Equal AUG 1999 52.214-3 Amendments To Invitations For Bids DEC 2016 52.214-4 False Statements In Bids APR 1984 52.214-5 Submission Of Bids DEC 2016 52.214-6 Explanation To Prospective Bidders APR 1984 52.214-7 Late Submissions, Modifications, and Withdrawals of Bids NOV 1999 52.214-18 Preparation of Bids-Construction APR 1984 52.214-19 Contract Award-Sealed Bidding-Construction AUG 1996 52.214-34 Submission Of Offers In The English Language APR 1991 52.214-35 Submission Of Offers In U.S. Currency APR 1991 52.217-5 Evaluation Of Options JUL 1990 52.222-23 Notice of Requirement for Affirmative Action to Ensure

Equal Employment Opportunity for Construction

FEB 1999

52.223-4 Recovered Material Certification MAY 2008 52.225-12 Alt II Notice of Buy American Requirement--Construction

Materials Under Trade Agreements (MAY 2014) Alternate II

JUN 2009

52.225-25 Prohibition on Contracting with Entities Engaging in Certain Activities or Transactions Relating to Iran-- Representation and Certifications.

OCT 2015

52.232-14 Notice Of Availability Of Progress Payments Exclusively For Small Business Concerns

APR 1984

52.232-18 Availability Of Funds APR 1984 252.204-7008 Compliance With Safeguarding Covered Defense Information

Controls

OCT 2016

252.236-7008 Contract Prices-Bidding Schedules DEC 1991

CLAUSES INCORPORATED BY FULL TEXT

52.204-3 TAXPAYER IDENTIFICATION (OCT 1998)

(a) Definitions.

Common parent, as used in this provision, means that corporate entity that owns or controls an affiliated group of corporations that files its Federal income tax returns on a consolidated basis, and of which the offeror is a member.

Taxpayer Identification Number (TIN), as used in this provision, means the number required by the Internal Revenue Service (IRS) to be used by the offeror in reporting income tax and other returns. The TIN may be either a Social Security Number or an Employer Identification Number.

(b) All offerors must submit the information required in paragraphs (d) through (f) of this provision to comply with debt collection requirements of 31 U.S.C. 7701(c) and 3325(d), reporting requirements of 26 U.S.C. 6041, 6041A, and 6050M, and implementing regulations issued by the IRS. If the resulting contract is subject to the payment reporting requirements described in Federal Acquisition Regulation (FAR) 4.904, the failure or refusal by the offeror to furnish the information may result in a 31 percent reduction of payments otherwise due under the contract.

(c) The TIN may be used by the Government to collect and report on any delinquent amounts arising out of the offeror's relationship with the Government (31 U.S.C. 7701(c)(3)). If the resulting contract is subject to the payment reporting requirements described in FAR 4.904, the TIN provided hereunder may be matched with IRS records to verify the accuracy of the offeror's TIN.

(d) Taxpayer Identification Number (TIN).

___ TIN:.--------------------------------------------------------

___ TIN has been applied for.

___ TIN is not required because:

___ Offeror is a nonresident alien, foreign corporation, or foreign partnership that does not have income effectively connected with the conduct of a trade or business in the United States and does not have an office or place of business or a fiscal paying agent in the United States;

___ Offeror is an agency or instrumentality of a foreign government;

___ Offeror is an agency or instrumentality of the Federal Government.

(e) Type of organization.

___ Sole proprietorship;

___ Partnership;

___ Corporate entity (not tax-exempt);

___ Corporate entity (tax-exempt);

___ Government entity (Federal, State, or local);

___ Foreign government;

___ International organization per 26 CFR 1.6049-4;

___ Other--------------------------------------------------------

(f) Common parent.

___ Offeror is not owned or controlled by a common parent as defined in paragraph (a) of this provision.

___ Name and TIN of common parent:

Name-------------------------------------------------------------------

TIN--------------------------------------------------------------------

(End of provision)

52.209-11 REPRESENTATION BY CORPORATIONS REGARDING DELINQUENT TAX LIABILITY OR A

FELONY CONVICTION UNDER ANY FEDERAL LAW (FEB 2016)

(a) As required by sections 744 and 745 of Division E of the Consolidated and Further Continuing Appropriations Act, 2015 (Pub. L. 113-235), and similar provisions, if contained in subsequent appropriations acts, the Government will not enter into a contract with any corporation that--

(1) Has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability, where the awarding agency is aware of the unpaid tax liability, unless an agency has considered suspension or debarment of the corporation and made a determination that suspension or debarment is not necessary to protect the interests of the Government; or

(2) Was convicted of a felony criminal violation under any Federal law within the preceding 24 months, where the awarding agency is aware of the conviction, unless an agency has considered suspension or debarment of the corporation and made a determination that this action is not necessary to protect the interests of the Government.

(b) The Offeror represents that--

(1) It is [ ] is not [ ] a corporation that has any unpaid Federal tax liability that has been assessed, for which all judicial and administrative remedies have been exhausted or have lapsed, and that is not being paid in a timely manner pursuant to an agreement with the authority responsible for collecting the tax liability; and

(2) It is [ ] is not [ ] a corporation that was convicted of a felony criminal violation under a Federal law within the preceding 24 months.

52.214-15 PERIOD FOR ACCEPTANCE OF BIDS (APR 1984)

In compliance with the solicitation, the bidder agrees, if this bid is accepted within 90 calendar days from the date specified in the solicitation for receipt of bids, to furnish any or all items upon which prices are bid at the price set opposite each item, delivered at the designated point(s), within the time specified in the Schedule.

(End of clause)

52.216-1 TYPE OF CONTRACT (APR 1984)

The Government contemplates award of a Firm Fixed Price contract resulting from this solicitation.

52.222-5 CONSTRUCTION WAGE RATE REQUIREMENTS--SECONDARY SITE OF THE WORK (MAY

2014)

(a)(1) The offeror shall notify the Government if the offeror intends to perform work at any secondary site of the work, as defined in paragraph (a)(1)(ii) of the FAR clause at 52.222-6, Construction Wage Rate Requirements,of this solicitation.

(2) If the offeror is unsure if a planned work site satisfies the criteria for a secondary site of the work, the offeror shall request a determination from the Contracting Officer.

(b)(1) If the wage determination provided by the Government for work at the primary site of the work is not applicable to the secondary site of the work, the offeror shall request a wage determination from the Contracting Officer.

(2) The due date for receipt of offers will not be extended as a result of an offeror's request for a wage determination for a secondary site of the work.

52.225-10 NOTICE OF BUY AMERICAN REQUIREMENT--CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. “Commercially available off-the-shelf (COTS) item,” “construction material,” “domestic construction material,” and “foreign construction material,” as used in this provision, are defined in the clause of this solicitation entitled “Buy American --Construction Materials” (Federal Acquisition Regulation (FAR) clause 52.225-9).

(b) Requests for determinations of inapplicability. An offeror requesting a determination regarding the inapplicability of the Buy American statute should submit the request to the Contracting Officer in time to allow a determination before submission of offers. The offeror shall include the information and applicable supporting data required by paragraphs (c) and (d) of the clause at FAR 52.225-9 in the request. If an offeror has not requested a determination regarding the inapplicability of the Buy American statute before submitting its offer, or has not received a response to a previous request, the offeror shall include the information and supporting data in the offer.

(c) Evaluation of offers. (1) The Government will evaluate an offer requesting exception to the requirements of the Buy American statute, based on claimed unreasonable cost of domestic construction material, by adding to the offered price the appropriate percentage of the cost of such foreign construction material, as specified in paragraph (b)(3)(i) of the clause at FAR 52.225-9.

(2) If evaluation results in a tie between an offeror that requested the substitution of foreign construction material based on unreasonable cost and an offeror that did not request an exception, the Contracting Officer will award to the offeror that did not request an exception based on unreasonable cost.

(d) Alternate offers.

(1) When an offer includes foreign construction material not listed by the Government in this solicitation in paragraph (b)(2) of the clause at FAR 52.225-9, the offeror also may submit an alternate offer based on use of equivalent domestic construction material.

(2) If an alternate offer is submitted, the offeror shall submit a separate Standard Form 1442 for the alternate offer, and a separate price comparison table prepared in accordance with paragraphs (c) and (d) of the clause at FAR 52.225-9 for the offer that is based on the use of any foreign construction material for which the Government has not yet determined an exception applies.

(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of the clause at FAR 52.225-9 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic construction material, and the offeror shall be required to furnish such domestic construction material. An offer based on use of the foreign construction material for which an exception was requested--

(i) Will be rejected as nonresponsive if this acquisition is conducted by sealed bidding; or

(ii) May be accepted if revised during negotiations.

52.228-1 BID GUARANTEE (SEP 1996)

(a) Failure to furnish a bid guarantee in the proper form and amount, by the time set for opening of bids, may be cause for rejection of the bid.

(b) The bidder shall furnish a bid guarantee in the form of a firm commitment, e.g., bid bond supported by good and sufficient surety or sureties acceptable to the Government, postal money order, certified check, cashier's check, irrevocable letter of credit, or, under Treasury Department regulations, certain bonds or notes of the United States.

The Contracting Officer will return bid guarantees, other than bid bonds, (1) to unsuccessful bidders as soon as practicable after the opening of bids, and (2) to the successful bidder upon execution of contractual documents and bonds (including any necessary coinsurance or reinsurance agreements), as required by the bid as accepted.-

(c) The amount of the bid guarantee shall be 20 percent of the bid price or $3,000,000, whichever is less.-

(d) If the successful bidder, upon acceptance of its bid by the Government within the period specified for acceptance, fails to execute all contractual documents or furnish executed bond(s) within 10 days after receipt of the forms by the bidder, the Contracting Officer may terminate the contract for default.-

(e) In the event the contract is terminated for default, the bidder is liable for any cost of acquiring the work that exceeds the amount of its bid, and the bid guarantee is available to offset the difference.

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from Roger D. Williams, Chief of Contracting US Army Corps of Engineers – Seattle District PO Box 3755 Seattle, WA 98124-3755

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

http://www.farsite.hill.af.mil http://www.dtic.mil/dfars

52.252-3 ALTERATIONS IN SOLICITATION (APR 1984)

Portions of this solicitation are altered as follows:

Alterations, if necessary, will be via Amendment

Section 00 45 00 - Representations and Certifications

PRE-AWARD INFORMATION FORM

PRE-AWARD INFORMATION

SUBMIT THE FOLLOWING INFORMATION WITH YOUR BID

1.Company Name and Address: __________________________________________________________

2.Point of Contact Name: __________________________________________________________

Email address:

Telephone Number:

Fax Number:

3.Electronic Transfer Payments will now be required for all new contracts. Do you currently receive __Electronic Transfer Payments from this agency? (agency codes 00005524/00006482) Yes____No___

4.Name of Bank and Branch: __________________________________________________________

Personal Banker:

Email address:

Telephone Number:

Fax Number:

5. Name of Bonding Agent Company: ____________________________________________________ Agents Name:

Email address:

Telephone Number:

Fax Number:

6. Contractors are required, before receipt of contract award to ensure that their firm is registered in the government web site entitled System for Award Management (SAM) and that all information required is currentand up to date.https://www.sam.gov/portal/public/SAM/ Ensure that your company’s information is updated for the following areas:

•CORE DATA: Ensure that your business types are correctly filled in:

•What is your business type?_____________________________________________________________ (Examples of Business types: Small Business (SB), Small Disadvantaged Business (SDB), Woman-Owned Small Business (WOSB), Historically Underutilized Business Zone (HUBZone), Veteran-Owned Small Business (VOSB), Service-Disabled Veteran-Owned Small Business (SDVOSB), and SBA 8(a)).

DUNS Number:

CAGE Code:

TAX ID:

REPS & CERTS: Ensure that you have certified the FAR and DFARs provisions (clauses) listedon the Reps & Certs pages.

CORE DATA – Business Types updated: Yes______ Date:

REPS & CERTS – Certified Yes ______ Date:

7. Please provide the following information; it will not be used to evaluate or rank bids. It will be usedsolely as a reference check for our internal files. List no more than three projects that are substantiallycomplete or have been completed within the last ten years that are similar to this project. Projectsshould be listed in the following order:

Federal projects, state projects, city/county projects, and thencommercial projects. Use the following format:

a) Title & Location of Project:

Agency/Company:

Point of Contact (Name &Title):

Email address:

Telephone Number:

Award Amount: $ Yr of Completion:

b) Title & Location of Project:

Agency/Company:

Point of Contact (Name &Title):

Email address:

Telephone Number:

Award Amount: $ Yr of Completion:

c) Title & Location of Project:

Agency/Company:

Point of Contact (Name &Title):

Email address:

Telephone Number:

Award Amount: $ Yr of Completion:

8. List all outstanding uncompleted projects, in the following format:

a) Title of Project:

Agency/Company:

Award Amount $:

Est. Completion Date:

b) Title of Project:

Agency/Company:

Award Amount $:

Est. Completion Date:

c) Title of Project:

Agency/Company:

Award Amount $:

Est. Completion Date:

52.204-8 Annual Representations and Certifications JAN 2017

52.209-7 INFORMATION REGARDING RESPONSIBILITY MATTERS (JULY 2013)

(a) Definitions. As used in this provision--

Administrative proceeding means a non-judicial process that is adjudicatory in nature in order to make a determination of fault or liability (e.g., Securities and Exchange Commission Administrative Proceedings, Civilian Board of Contract Appeals Proceedings, and Armed Services Board of Contract Appeals Proceedings). This includes administrative proceedings at the Federal and State level but only in connection with performance of a Federal contract or grant. It does not include agency actions such as contract audits, site visits, corrective plans, or inspection of deliverables.

Federal contracts and grants with total value greater than $10,000,000 means--

(1) The total value of all current, active contracts and grants, including all priced options; and

(2) The total value of all current, active orders including all priced options under indefinite-delivery, indefinite-quantity, 8(a), or requirements contracts (including task and delivery and multiple-award Schedules).

Principal means an officer, director, owner, partner, or a person having primary management or supervisory responsibilities within a business entity (e.g., general manager; plant manager; head of a division or business segment; and similar positions).

(b) The offeror ( ) has ( ) does not have current active Federal contracts and grants with total value greater than $10,000,000.

(c) If the offeror checked “has” in paragraph (b) of this provision, the offeror represents, by submission of this offer, that the information it has entered in the Federal Awardee Performance and Integrity Information System (FAPIIS) is current, accurate, and complete as of the date of submission of this offer with regard to the following information:

(1) Whether the offeror, and/or any of its principals, has or has not, within the last five years, in connection with the award to or performance by the offeror of a Federal contract or grant, been the subject of a proceeding, at the Federal or State level that resulted in any of the following dispositions:

(i) In a criminal proceeding, a conviction.

(ii) In a civil proceeding, a finding of fault and liability that results in the payment of a monetary fine, penalty, reimbursement, restitution, or damages of $5,000 or more.

(iii) In an administrative proceeding, a finding of fault and liability that results in--

(A) The payment of a monetary fine or penalty of $5,000 or more; or

(B) The payment of a reimbursement, restitution, or damages in excess of $100,000.

(iv) In a criminal, civil, or administrative proceeding, a disposition of the matter by consent or compromise with an acknowledgment of fault by the Contractor if the proceeding could have led to any of the outcomes specified in paragraphs (c)(1)(i), (c)(1)(ii), or (c)(1)(iii) of this provision.

(2) If the offeror has been involved in the last five years in any of the occurrences listed in (c)(1) of this provision, whether the offeror has provided the requested information with regard to each occurrence.

(d) The offeror shall post the information in paragraphs (c)(1)(i) through (c)(1)(iv) of this provision in FAPIIS as required through maintaining an active registration in the System for Award Management database via https://www.acquisition.gov (see 52.204-7).

252.204-7007 ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2015)

Substitute the following paragraphs (d) and (e) for paragraph (d) of the provision at FAR 52.204-8:

(d)(1) The following representations or certifications in the System for Award Management (SAM) database are applicable to this solicitation as indicated:

(i) 252.209-7003, Reserve Officer Training Corps and Military Recruiting on Campus--Representation. Applies to all solicitations with institutions of higher education.

(ii) 252.216-7008, Economic Price Adjustment--Wage Rates or Material Prices Controlled by a Foreign Government. Applies to solicitations for fixed-price supply and service contracts when the contract is to be performed wholly or in part in a foreign country, and a foreign government controls wage rates or material prices and may during contract performance impose a mandatory change in wages or prices of materials.

(iii) 252.222-7007, Representation Regarding Combating Trafficking in Persons, as prescribed in 222.1771. Applies to solicitations with a value expected to exceed the simplified acquisition threshold.

(iv) 252.225-7042, Authorization to Perform. Applies to all solicitations when performance will be wholly or in part in a foreign country.

(v) 252.225-7049, Prohibition on Acquisition of Commercial Satellite Services from Certain Foreign Entities-- Representations. Applies to solicitations for the acquisition of commercial satellite services.

(vi) 252.225-7050, Disclosure of Ownership or Control by the Government of a Country that is a State Sponsor of Terrorism. Applies to all solicitations expected to result in contracts of $150,000 or more.

(vii) 252.229-7012, Tax Exemptions (Italy)--Representation. Applies to solicitations when contract performance will be in Italy.

(viii) 252.229-7013, Tax Exemptions (Spain)--Representation. Applies to solicitations when contract performance will be in Spain.

(ix) 252.247-7022, Representation of Extent of Transportation by Sea. Applies to all solicitations except those for direct purchase of ocean transportation services or those with an anticipated value at or below the simplified acquisition threshold.

(2) The following representations or certifications in SAM are applicable to this solicitation as indicated by the Contracting Officer: [Contracting Officer check as appropriate.]

____ (i) 252.209-7002, Disclosure of Ownership or Control by a Foreign Government.

____ (ii) 252.225-7000, Buy American--Balance of Payments Program Certificate.

____ (iii) 252.225-7020, Trade Agreements Certificate.

____ Use with Alternate I.

____ (iv) 252.225-7031, Secondary Arab Boycott of Israel.

____ (v) 252.225-7035, Buy American--Free Trade Agreements--Balance of Payments Program Certificate.

____ Use with Alternate I.

____ Use with Alternate II.

____ Use with Alternate III.

____ Use with Alternate IV.

____ Use with Alternate V.

(e) The offeror has completed the annual representations and certifications electronically via the SAM Web site at https://www.acquisition.gov/. After reviewing the SAM database information, the offeror verifies by submission of the offer that the representations and certifications currently posted electronically that apply to this solicitation as indicated in FAR 52.204-8(c) and paragraph (d) of this provision have been entered or updated within the last 12 months, are current, accurate, complete, and applicable to this solicitation (including the business size standard applicable to the NAICS code referenced for this solicitation), as of the date of this offer, and are incorporated in this offer by reference (see FAR 4.1201); except for the changes identified below ____ [offeror to insert changes, identifying change by provision number, title, date]. These amended representation(s) and/or certification(s) are also incorporated in this offer and are current, accurate, and complete as of the date of this offer.

FAR/DFARS Clause # Title Date Change

Any changes provided by the offeror are applicable to this solicitation only, and do not result in an update to the representations and certifications located in the SAM database.

Section 00 70 00 - Conditions of the Contract

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 N/A N/A N/A Government 0002 N/A N/A N/A Government 0003 N/A N/A N/A Government 0004 N/A N/A N/A Government

Section 00 72 00 - General Conditions

SUCCESSOR CONTRACTING OFFICER

The Contracting Officer who signed this contract is the primary Contracting Officer for the contract. Nevertheless, any Contracting Officer assigned to the Seattle District and acting within his/her authority may take formal action on this contract when a contract action needs to be taken and the primary Contracting Officer is unavailable.

52.202-1 Definitions NOV 2013 52.203-3 Gratuities APR 1984 52.203-5 Covenant Against Contingent Fees MAY 2014 52.203-6 Restrictions On Subcontractor Sales To The Government SEP 2006 52.203-7 Anti-Kickback Procedures MAY 2014 52.203-8 Cancellation, Rescission, and Recovery of Funds for Illegal or

Improper Activity

MAY 2014

52.203-10 Price Or Fee Adjustment For Illegal Or Improper Activity MAY 2014 52.203-12 Limitation On Payments To Influence Certain Federal

Transactions

OCT 2010

52.203-17 Contractor Employee Whistleblower Rights and Requirement To Inform Employees of Whistleblower Rights

APR 2014

52.204-2 Alt II Security Requirements (Aug 1996) - Alternate II APR 1984 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-9 Personal Identity Verification of Contractor Personnel JAN 2011 52.204-10 Reporting Executive Compensation and First-Tier

Subcontract Awards

OCT 2016

52.209-6 Protecting the Government's Interest When Subcontracting With Contractors Debarred, Suspended, or Proposed for Debarment

OCT 2015

52.209-9 Updates of Publicly Available Information Regarding Responsibility Matters

JUL 2013

52.209-10 Prohibition on Contracting With Inverted Domestic Corporations

NOV 2015

52.210-1 Market Research APR 2011 52.211-10 Commencement, Prosecution, and Completion of Work APR 1984 52.211-13 Time Extensions SEP 2000 52.211-18 Variation in Estimated Quantity APR 1984 52.214-26 Audit and Records--Sealed Bidding OCT 2010 52.214-27 Price Reduction for Defective Certified Cost or Pricing Data -

Modifications - Sealed Bidding

AUG 2011

52.214-28 Subcontracting Certified Cost Or Pricing Data-- Modifications--Sealed Bidding

OCT 2010

52.215-2 Audit and Records--Negotiation OCT 2010 52.215-13 Subcontractor Certified Cost or Pricing Data--Modifications OCT 2010 52.215-21 Requirements for Certified Cost or Pricing Data and Data

Other Than Certified Cost or Pricing Data -- Modifications

OCT 2010

52.217-7 Option For Increased Quantity-Separately Priced Line Item MAR 1989 52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-8 Utilization of Small Business Concerns NOV 2016 52.222-1 Notice To The Government Of Labor Disputes FEB 1997 52.222-3 Convict Labor JUN 2003

52.222-4 Contract Work Hours and Safety Standards- Overtime Compensation

MAY 2014

52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-27 Affirmative Action Compliance Requirements for

Construction

APR 2015

52.222-34 Project Labor Agreement MAY 2010 52.222-35 Equal Opportunity for Veterans OCT 2015 52.222-36 Equal Opportunity for Workers with Disabilities JUL 2014 52.222-37 Employment Reports on Veterans FEB 2016 52.222-40 Notification of Employee Rights Under the National Labor

Relations Act

DEC 2010

52.222-50 Combating Trafficking in Persons MAR 2015 52.222-54 Employment Eligibility Verification OCT 2015 52.223-3 Hazardous Material Identification And Material Safety Data JAN 1997 52.223-5 Pollution Prevention and Right-to-Know Information MAY 2011 52.223-6 Drug-Free Workplace MAY 2001 52.223-10 Waste Reduction Program MAY 2011 52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.223-19 Compliance with Environmental Management Systems MAY 2011 52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.226-1 Utilization Of Indian Organizations And Indian-Owned

Economic Enterprises

JUN 2000

52.227-1 Authorization and Consent DEC 2007 52.227-2 Notice And Assistance Regarding Patent And Copyright

Infringement

DEC 2007

52.227-4 Patent Indemnity-Construction Contracts DEC 2007 52.228-2 Additional Bond Security OCT 1997 52.228-11 Pledges Of Assets JAN 2012 52.228-12 Prospective Subcontractor Requests for Bonds MAY 2014 52.228-14 Irrevocable Letter of Credit NOV 2014 52.228-15 Performance and Payment Bonds--Construction OCT 2010 52.229-3 Federal, State And Local Taxes FEB 2013 52.232-17 Interest MAY 2014 52.232-23 Alt I Assignment of Claims (May 2014) - Alternate I APR 1984 52.232-25 Prompt Payment JAN 2017 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996

52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-6 Superintendence by the Contractor APR 1984 52.236-7 Permits and Responsibilities NOV 1991 52.236-8 Other Contracts APR 1984 52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-10 Operations and Storage Areas APR 1984 52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-14 Availability and Use of Utility Services APR 1984 52.236-15 Schedules for Construction Contracts APR 1984 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-13 Bankruptcy JUL 1995 52.242-14 Suspension of Work APR 1984 52.243-4 Changes JUN 2007 52.244-6 Subcontracts for Commercial Items JAN 2017 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.248-3 Value Engineering-Construction OCT 2015 52.249-1 Alt I Termination for Convenience of the Government (Fixed-price) (Short Form) (Apr 1984) - Alternate I

APR 1984

52.249-2 Alt I Termination for Convenience of the Government (Fixed- Price) (Apr 2012) - Alternate I

SEP 1996

52.249-10 Default (Fixed-Price Construction) APR 1984 52.253-1 Computer Generated Forms JAN 1991 252.201-7000 Contracting Officer's Representative DEC 1991 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7001 Prohibition On Persons Convicted of Fraud or Other Defense- Contract-Related Felonies

DEC 2008

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.203-7004 Display of Hotline Posters OCT 2016 252.204-7000…