Specifications_10_14_16.pdf

Baltimore District

Georgetown Reservoir Building Improvements, Washington Aqueduct Division

Specifications October 2016

Allen W.

Welch

Digitally signed by Allen W. Welch DN: cn=Allen W. Welch, o, ou=Arcadis, email=wayne.welch@arcadis.com, c=US Date: 2016.10.14 16:21:42 -04'00'

This page intentionally left blank.

Georgetown Reservoir

PROJECT TABLE OF CONTENTS

DIVISION 01 - GENERAL REQUIREMENTS

01 00 00 ADMINISTRATIVE REQUIREMENTS

01 05 00 JOB CONDITIONS

01 07 00 CUTTING, PATCHING AND REPAIRING

01 31 19 PROJECT MEETINGS

01 32 01.00 10 PROJECT SCHEDULE

01 33 00 SUBMITTAL PROCEDURES

01 35 26 GOVERNMENTAL SAFETY REQUIREMENTS

01 42 00 SOURCES FOR REFERENCE PUBLICATIONS

01 45 00.00 10 QUALITY CONTROL

01 45 00.10 10 QUALITY CONTROL SYSTEM (QCS)

01 50 00 TEMPORARY CONSTRUCTION FACILITIES AND CONTROLS

01 57 20.00 10 ENVIRONMENTAL PROTECTION

01 57 23 TEMPORARY STORM WATER POLLUTION CONTROL

01 62 35 RECYCLED / RECOVERED MATERIALS

01 74 19 CONSTRUCTION AND DEMOLITION WASTE MANAGEMENT

01 75 00 STARTING AND ADJUSTING

01 78 02.00 10 CLOSEOUT SUBMITTALS

01 78 23 OPERATION AND MAINTENANCE DATA

01 80 00 COMMISSIONING

DIVISION 02 - EXISTING CONDITIONS

02 41 00 DEMOLITION AND DECONSTRUCTION

02 42 91 REMOVAL AND SALVAGE OF HISTORIC CONSTRUCTION MATERIALS

DIVISION 03 - CONCRETE

03 01 30 RESTORATION OF CONCRETE IN HISTORIC STRUCTURES

03 01 30.71 CONCRETE REHABILITATION

03 30 53 MISCELLANEOUS CAST-IN-PLACE CONCRETE

DIVISION 04 - MASONRY

04 01 00.91 RESTORATION AND CLEANING OF MASONRY IN HISTORIC STRUCTURES

DIVISION 05 - METALS

05 50 13 MISCELLANEOUS METAL FABRICATIONS

05 51 00 METAL STAIRS

05 52 00 METAL RAILINGS

05 72 00 DECORATIVE METAL SPECIALTIES

DIVISION 06 - WOOD, PLASTICS, AND COMPOSITES

06 10 00 ROUGH CARPENTRY

DIVISION 07 - THERMAL AND MOISTURE PROTECTION

07 21 16 MINERAL FIBER BLANKET INSULATION

07 53 23 ETHYLENE-PROPYLENE-DIENE-MONOMER ROOFING

07 60 00 FLASHING AND SHEET METAL

07 92 00 JOINT SEALANTS

DIVISION 08 - OPENINGS

PROJECT TABLE OF CONTENTS Page 1

08 14 00 WOOD DOORS

08 52 00 WOOD WINDOWS

08 71 00 DOOR HARDWARE

08 81 00 GLAZING

DIVISION 09 - FINISHES

09 06 90 COLOR SCHEDULE

09 29 00 GYPSUM BOARD

09 30 13 CERAMIC TILING

09 90 00 PAINTS AND COATINGS

DIVISION 10 - SPECIALTIES

10 28 13 TOILET ACCESSORIES

DIVISION 22 - PLUMBING

22 00 00 PLUMBING, GENERAL PURPOSE

22 07 19.00 40 PLUMBING PIPING INSULATION

DIVISION 23 - HEATING, VENTILATING, AND AIR CONDITIONING (HVAC)

23 00 00 AIR SUPPLY, DISTRIBUTION, VENTILATION, AND EXHAUST SYSTEMS

23 05 93 TESTING, ADJUSTING, AND BALANCING FOR HVAC

23 07 00 THERMAL INSULATION FOR MECHANICAL SYSTEMS

23 08 00.00 10 COMMISSIONING OF HVAC SYSTEMS

23 09 23 LONWORKS DIRECT DIGITAL CONTROL FOR HVAC AND OTHER

BUILDING CONTROL SYSTEMS

23 82 01.00 10 WARM AIR HEATING SYSTEMS

DIVISION 26 - ELECTRICAL

26 00 00.00 20 BASIC ELECTRICAL MATERIALS AND METHODS

26 08 00 APPARATUS INSPECTION AND TESTING

26 20 00 INTERIOR DISTRIBUTION SYSTEM

26 51 00 INTERIOR LIGHTING

DIVISION 31 - EARTHWORK

31 00 00 EARTHWORK

31 05 19 GEOTEXTILE

DIVISION 32 - EXTERIOR IMPROVEMENTS

32 10 00 BITUMINOUS CONCRETE PAVEMENT

32 11 23 AGGREGATE BASE COURSE

32 12 10 BITUMINOUS TACK AND PRIME COATS

32 16 13 CONCRETE SIDEWALKS AND CURBS AND GUTTERS

32 16 15 CONCRETE BLOCK PAVEMENTS

32 31 13 FENCES AND GATES

DIVISION 33 - UTILITIES

33 01 30.96 BYPASS CONDUIT CLEANING

33 40 00 STORM DRAINAGE UTILITIES

DIVISION 40 - PROCESS INTERCONNECTIONS

PROJECT TABLE OF CONTENTS Page 2

40 05 52 SLUICE GATES AND APPURTENANCES

-- End of Project Table of Contents --

PROJECT TABLE OF CONTENTS Page 3

SECTION 01 00 00

ADMINISTRATIVE REQUIREMENTS

10/06

PART 1 GENERAL

1.1 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Proof of purchase for equipment and/or materials.

Invoice Copies; G, WA

Proof of rental equipment costs.

Payment Evidence; G, WA

Proof of full payment.

PHOTOGRAPHS; G, WA

Photographs and, as applicable, negatives showing construction progress.

SD-03 Product Data

Cost or Pricing Data; G, WA

EQUIPMENT DATA; G, WA

Proof of actual equipment costs.

An itemized list of serial/model numbers and equipment installed by the Contractor under this contract..

SD-10 Operation and Maintenance Data

O and M Data; G, WA

A list of proposed maintenance and instruction manuals that is mainly used for but not limited to customized equipment.

Commissioning Activity for HVAC; G, WA

The Contractor shall provide a separate activity for commissioning.

Commissioning shall start only after all HVAC related work has been completed and all HVAC O&M manuals have been submitted and approved by the Government.

SECTION 01 00 00 Page 1 10/14/16

1.2 PROGRESS SCHEDULING AND REPORTING (DEC 1998)

1.2.1 Practicable Progress Schedule

The Contractor shall, within 20 days after date of commencement of work or as otherwise determined by the Contracting Officer, submit for approval a practicable progress schedule in accordance with specification Section 01 32 01.00 10 PROJECT SCHEDULE showing the manner in which he intends to prosecute the work.

1.2.2 Software Package

The program and data must be IBM PC compatible in a Window environment.

These requirements are not intended to restrict the Contractors selection of an automated scheduling system but to establish a format which will allow use of the same program with government computers and automated information systems. The Contractor will provide at least one program installation and maintenance on government hardware complete with all program and data files. Such installation shall be maintained for the duration of the project until fiscal completion and shall allow analysis of the project schedule by government personnel or agents. The Contractor will be required to submit a submittal register, transmittal log and schedule that is compatible with the Corps of Engineers Quality Control System for Windows (QCS-W). The submittal register can be made available by the Corps of Engineers.

1.2.3 Preparation of Operation and Maintenance (O&M) Manuals

The Contractor shall provide a separate activity for the preparation and submission of all O&M manuals

1.2.4 Commissioning Activity for HVAC

The Contractor shall provide a separate activity for commissioning of the HVAC system. The activity shall be as a minimum of 15 days long.

Commissioning shall start only after all HVAC related work has been completed and all HVAC O&M manuals have been submitted and approved by the Government.

1.3 PAYMENTS TO CONTRACTORS: (NOV 1976)

For payment purposes only, an allowance will be made by the Contracting Officer of 100 percent of the invoiced cost of materials or equipment delivered to the site but not incorporated into the construction, pursuant to the Contract Clause entitled "PAYMENTS UNDER FIXED-PRICE CONSTRUCTION CONTRACTS". The Contracting Officer may also, at his discretion, take into consideration the cost of materials or equipment stored at locations other than the jobsite, when making progress payments under the contract. In order to be eligible for payment, the Contractor must provide satisfactory evidence that he has acquired title to such material or equipment (Title Evidence, Payment Evidence or Invoice Copies), and that it will be utilized on the work covered by this contract. Further, all items must be properly stored and protected. Earnings will be computed using 100% of invoiced value. (CENAB-CO-E)

1.4 IDENTIFICATION OF EMPLOYEES: (OCT 1983)

Each employee assigned to this project by the Contractor and subcontractors shall be required to display at all times, while on the project site, an

SECTION 01 00 00 Page 2 10/14/16 approved form of identification provided by the Contractor, as an authorized employee of the Contractor/subcontractor. In addition, on those projects where identification is prescribed and furnished by the Government, it shall be displayed as required and it shall immediately be returned to the Contracting Officer for cancellation upon release of the assigned employee and or completion of project. (CENAB)

1.5 PURCHASE ORDER: (SEP 1975)

One readable copy of all purchase orders for material and equipment, showing firm names and addresses, and all shipping bills, or memoranda of shipment received regarding such material and equipment, shall be furnished the appointed Contracting Officer's Representative as soon as issued. Such orders, shipping bills or memoranda shall be so worded or marked that all material and each item, piece or member of equipment can be definitely identified on the drawings. Where a priority rating is assigned to a contract, this rating, the required delivery date, and the scheduled shipping date shall also be shown on the purchase order. At the option of the Contractor, the copy of the purchase order may or may not indicate the purchase price. (CENAB-CO-E)

1.6 EQUIPMENT OWNERSHIP AND OPERATING EXPENSE SCHEDULE (EFARS 52.0231.5000

(OCT 1995))

(a) This clause does not apply to terminations. See 52.249-5000, Basis for settlement of proposals and FAR Part 49.

(b) Allowable cost for construction and marine plant and equipment in sound workable conditions owned or controlled and furnished by a contractor or subcontractor at any tier shall be based on actual costs data for each piece of equipment or groups of similar serial and services for which the government can determine both ownership and operating costs from the contractor’s accounting records. When both ownership and operating costs can not be determined for any piece of equipment or groups of similar serial or series equipment from the contractor’s accounting records, costs for that equipment shall be based upon the applicable provisions of EP1110-1-8 Construction Equipment Ownership and Operating Expenses Schedule, Region East. Working conditions shall be considered to be average for determining equipment rates using the schedule unless specified otherwise by the contracting officer. For equipment not included in the schedule, rates for comparable pieces of equipment may be used or a rate may be developed using the formula provided in the schedule. For forward pricing, the schedule in effect at the time of negotiations shall apply.

For retroactive pricing, the schedule in effect at the time the work was performed shall apply.

(c) Equipment rental costs are allowable, subject to the provisions of FAR 31.105(d) (ii) and Far 31.205-36. Rates for equipment rented from an organization under common control, lease-purchase arrangements, and sale-leaseback arrangements, will be determined using the schedule, except that actual rates will be used for equipment leased from an organization under common control that has an established proactive of leasing the same or similar equipment to unaffiliated leasees.

(d) When actual equipment costs are proposed and the total amount of the pricing action exceeds the small purchase threshold, the contracting officer shall request the contractor to submit either certified cost or pricing data, or partial/limited data, as appropriate. The data shall be submitted on Standard Form 1411, Contract Pricing Proposal Cover Sheet.

SECTION 01 00 00 Page 3 10/14/16

CENAB-CT/SEP 95 (EFARS 52.231-5000)

1.7 REAL PROPERTY EQUIPMENT DATA: (APR 1975)

At or before the time of completion of the contract, the Contractor shall submit to the Contracting Officer a complete itemized list, including serial and model number where applicable, showing the unit retail value of each Contractor furnished item of mechanical, electrical and plumbing equipment installed by the Contractor under this contract. For each of the items which is specified herein to be guaranteed for a specified period from the date of acceptance thereof, either for beneficial use or final acceptance, whichever is earlier, against defective materials, design, and workmanship, the following information shall be given: the name, address and telephone number of the Subcontractor, Equipment Supplier, or Manufacturer originating the guaranteed item. The list shall be accompanied by a copy of the specific guarantee document for each item which is specified herein to be guaranteed if one had been furnished to the Contractor by the Equipment Supplier or Manufacturer. The Contractor's guarantee to the Government of these items will not be limited by the terms of any manufacturer's guarantee to the Contractor. Baltimore District NADB Form 1019 may be utilized for the itemized listing and will be made available to the Contractor upon request. (CENAB-CO-E)

1.8 O and M DATA: (JUL 1979)

The requirements for furnishing operating and maintenance data and field instruction are specified elsewhere in the specifications. The Contractor shall submit to the Contracting Officer, at a time prior to the 50% project completion time, a list of proposed maintenance and instruction manuals to be furnished the Government and the scheduled dates of all required field instructions to be provided by Contractor furnished personnel or manufacturer's representatives. All maintenance and instruction manuals must be furnished to the Contracting Officer at least 2 weeks prior to the scheduled dates of any required Contractor furnished field instructions or at least one month prior to project completion if no Contractor furnished field instructions are required. (CENAB)

1.9 FACILITY SECURITY CLEARANCE:

The Washington Aqueduct has been designated a Critical Infrastructure Facility under the National Critical Infrastructure Program which was outlined in Presiential Decision directive 63. Contractor shall furnish a list of contact personnel of the Contracctor and subcontractors including addresses and telephone numbers. All Contractor and sub-contractor personnel must consent to a review of public records and screening of personal background information before access is granted to Washington Aqueduct facilities. Failure to provide requested information may result in denial of access to facilities. No information will be released to outside agencies. The following major types of adverse information may exclude a contractor from gaining access to restricted areas or general unescorted access to Washington Aqueduct property. Each case will be reviewed on its own merit:

a. Illegal use or abuse of drugs or alcohol, theft or dishonesty, unreliability, instability, use of force, violence and weapons related incidents that indicate a general disregard for the law. Use of illegal drugs and alcohol and the carrying of weapons on Washington Aqueduct property is strictly prohibited.

SECTION 01 00 00 Page 4 10/14/16

b. Individuals who have felony convictions (e.g., murder, rape, drug offences, theft) or who are deemed untrustworthy.

c. Failing or refusing to sign the proper authorization documents to conduct the background screenings.

d. Knowingly providing false information on Official Government Documents.

1.10 HOT-WORK PERMIT

A hot-work permit, DA Form 5383-R (copy attached to the end of this section), must be submitted to the Contracting Officer before using heat-producing equipment.

1.11 NEGOTIATED MODIFICATIONS: (OCT 84)

Whenever profit is negotiated as an element of price for any modification to this contract with either prime or subcontractor, a reasonable profit shall be negotiated or determined by using the OCE Weighted Guidelines method outlined in EFARS 15.902. (Sugg. NAB 84-232)

1.12 PHOTOGRAPHS

The Contractor shall provide monthly, and within one month of the completion of work, digital photographs in JPEG file format showing the sequence and progress of work. A minimum of ten digital photographs shall be taken prior to the seventh day of each month of views and points located by the Contracting Officer. Submit a view location sketch indicating points of view. Submit with the monthly invoice two sets of digital photographs each set on a separate CD-r, cumulative of all photos to date.

Photographs for each month shall be in a separate monthly directory and each file shall be named to indicate its location on the view location sketch. The view location sketch shall also be provided on the CD as a digital file. All file names shall include a date designator. (CENAB-EN)

1.13 PARTNERING: (NOV 92)

In order to most effectively accomplish this contract, the Government is willing to form a cohesive partnership with the Contractor and its subcontractors. This partnership would strive to draw on the strengths of each organization in an effort to achieve a quality project done right the first time, within budget and on schedule. This partnership would be bilateral in make-up and participation will be totally voluntary. Any cost associated with effectuating this partnership will be agreed to by both parties and will be shared equally with no change in contract price.

(CENAB-EN-DT)

1.14 PERMITS

The permits listed below will be obtained by the Government and are in the approval process and may require additional action by the Contractor to become complete. After final approvals by the respective state agencies are received, the Government will furnish approval letters and permits to the Contracting Officer who will furnish the Contractor all such permits before construction. The Contractor shall abide by all permit requirements.

a. Erosion and Sedimentation (E&S) Control Plan: The E&S control

SECTION 01 00 00 Page 5 10/14/16 plans were submitted to the District of Columbia Department of the Environment (DOEE) and the Maryland Department of Environment (MDE).

b. Stormwater Management (SWM) Plan: The (SWM) Plans were submitted to the DOEE.

c. Notice of Intent (NOI) to comply with the General Permit for construction activities in accordance with EPA's National Pollution Discharge Elimination System (NPDES) stormwater management program : The NOI form has been completed and submitted to DOEE. Upon the issuance of the Notice to Proceed to the Contractor, a Transfer of Authority form will be prepared by the COE project designer and routed through the Contracting Officer to the Contractor. The Contractor shall return the signed Transfer of Authority form to the COE designer through the Contracting Officer who shall forward it to DOEE. At completion of the construction contract the Contractor shall complete a Notice of Termination (NOT) form and furnish it to DOEE through the Contracting Officer notifying that agency of the end of construction.

1.15 NAMEPLATES

Each piece of equipment, electric actuator, and control panel shall be provided with a substantial nameplate of non-corrodible metal (aluminum or SS depending on location), securely fastened in place and clearly and permanently inscribed with the manufacturer's name, model, or type designation, serial number; principal rated capacities, electrical or other power characteristics, and similar information as appropriate.

PART 2 PRODUCTS

Not used.

PART 3 EXECUTION

Not used.

-- End of Section --

SECTION 01 00 00 Page 6 10/14/16

HOT-WORK PERMIT

For use of this form, see AR 420-90; the proponent agency is ACSIM

24. REMARKS

NOTE: PERMIT VALID ON DAY OF OPERATION AT ONE LOCATION ONLY

19.a. Was Fire Department notified after hot-work operation was completed?

19.b. Time:

DA FORM 5383-R, SEP 92 USAPPC V1.00

1. LOCATION 2. DATE 3. PERMIT NO.

4. TYPE OF WORK 5. START TIME 6. FINISH TIME

7.a. NAME OF PERSON RESPONSIBLE FOR HOT-WORK AT JOB SITE (Contractor/Government Employee)

7.b. SIGNATURE

PRECAUTIONS BEFORE OPERATIONS

CHECKLIST

CHECK ONE

YES NO

8. Did Fire Department Inspector inspect site?

9. Are there procedures for Fire Department emergency notification? (Emergency No.)

10. Are combustibles in area noted?

11. Should combustibles be covered? (If yes, note in remarks)

12. Are proper extinguishers on hand?

18.a. FIRE DEPARTMENT INSPECTOR'S SIGNATURE 18.b. DATE

PRECAUTIONS AFTER OPERATIONS

CHECKLIST

CHECK ONE

YES NO

13. Is wet-down necessary? (If yes, note in remarks)

14. Is smoking permissible at work sites?

15. Is continuous fire watch required?

16. Is Fire Department standby required?

17. Are other precautions required? (If yes, note in remarks)

20.a. Did Fire Department inspector inspect work site?

20.b. Time:

21. Are after work conditions safe? (If no, note in remarks)

23.a. FIRE DEPARTMENT INSPECTOR'S SIGNATURE 23.b. DATE

22. Are heat producing devices safe if left at work site?

EDITION OF JAN 85 IS OBSOLETE

SECTION 01 05 00

JOB CONDITIONS

07/06

PART 1 GENERAL

1.1 LAYOUT OF WORK

LAYOUT OF WORK: (APR 1972) The Contractor shall lay out his work and shall be responsible for all measurements in connection therewith. The Contractor shall furnish, at his own expense, all templates, platforms, equipment, tools and materials and labor as may be required in laying out any part of the work. The Contractor will be held responsible for the execution of the work to such lines and elevations shown on the drawings or indicated by the Contracting Officer. (CENAB)

It shall be the responsibility of the Contractor to maintain and preserve all stakes and other marks established until authorized by the government to remove them. If such marks are destroyed, by the Contractor or through his negligence, prior to their authorized removal, they may be replaced by the government at his discretion. The expense of replacement will be deducted from any amounts due or to become due the Contractor. (CENAB)

1.2 PHYSICAL DATA: (APR 1984)

Data and information furnished or referred to below is for the Contractor's information. The Government shall not be responsible for any interpretation or conclusion drawn from the data or information by the Contractor. (CENAB)

1.2.1 Transportation Facilities

WASHINGTON AQUEDUCT GEORGETOWN RESERVOIR, WASHINGTON, D.C.

The Washington Aqueduct Georgetown Reservoir is located at Reservoir Road and MacArthur Boulevard, NW, Washington, DC 20007.

The Dalecarlia Reservoir is located at Little Falls Road, NW Washington, DC 20007.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Shut Down Utility Services; G, WA.

Prior approval for service/utility interruptions.

Qualified Instructor; G, WA

Name and Qualifications of the Proposed Instructor.

SECTION 01 05 00 Page 1 10/14/16

When changes and/or relocations are required.

Checklist; G, WA

A Risk Assessment for excavation and other work in the vicinity of utilities.

The recording for which all materials and equipment specified to be salvaged and turned over to the Government.

SD-06 Test Reports

Complete Signed Report of the Result of His Inspection, Operation, Adjustments and Tests; G, WA

1.4 UTILITIES

1.4.1 Availability of Utilities Including Lavatory Facilities: (JUN 1980)

Maintenance of Plant Operations (MOPO)

A. Permission to interrupt any roads and/or utility service shall be requested in writing a minimum of 15 calendar days prior to the desired date of interruption.

B. Prior to performing any work on the existing reservoir and related facilities, all of the existing electrical and security systems must be de-energized and relocated to their temporary locations. Those systems to remain in service during construction shall be confirmed to be in proper working order by the Government prior to initiating construction activities on the reservoir.

It shall be the responsibility of the Contractor to provide all utilities he may require during the entire life of the contract. He shall make his own investigation and determinations as to the availability and adequacy of utilities for his use for construction purposes and domestic consumption.

He shall install and maintain all necessary supply lines, connections, piping, and meters if required, but only at such locations and in such manner as approved by the Contracting Officer. Before final acceptance of work under this contract, all temporary supply lines, connections and piping installed by the Contractor shall be removed by him in a manner satisfactory to the Contracting Officer. (CENAB)

1.4.2 Interruption of Utilities: (1972)

a. No utility services shall be interrupted by the Contractor to make connections, to relocate, or for any purpose without approval of the Contracting Officer.

b. Request for permission to shut down utility services shall be submitted in writing to the Contracting Officer not less than 15 days prior to proposed date of interruption. The request shall give the following information:

c. Nature of Utility (Gas, L.P. or H.P., Water, Etc.)

d. Size of line and location of shutoff.

SECTION 01 05 00 Page 2 10/14/16

e. Buildings and services affected.

f. Hours and date of shutoff.

g. Estimated length of time service will be interrupted.

h. Services will not be shut off until receipt of approval of the proposed hours and date from the Contracting Officer.

i. Shutoffs which will cause interruption of Government work operations as determined by the Contracting Officer shall be accomplished during regular non-work hours or on non-work days of the Using Agency without any additional cost to the Government.

j. Operation of valves on water mains will be by Government personnel. Where shutoff of water lines interrupts service to fire hydrants or fire sprinkler systems, the Contractor shall arrange his operations and have sufficient material and personnel available to complete the work without undue delay or to restore service without delay in event of emergency.

1.4.3 Utility Markings

Prior to any excavation the Contractor shall contact the facility manager's office and the One-Call Service, a minimum of 14 days and 48 hours, respectively, requesting utility location markings. The Contractor shall not proceed with any excavation until all utilities, including abandoned utilities, have been marked to the satisfaction of the Contracting Officer. Prior to requesting the marking of utilities, the Contractor shall stake out proposed excavations and limits of work with white lines ("White Lining"). It is the Contractor's responsibility to ensure that all permits (excavation or otherwis) are current and up-to-date without expiration. In addition to the above requirements the Contractor shall:

a) Visually survey and verify that all utility markings are consistent with existing appurtenances such as manholes, valve boxes, poles, pedestals, pad-mounted devices, gas meters, etc.

prior to any excavation.

b) Hand dig test holes to verify the depth and location of all utilities prior to any mechanical excavation within the limits of work. Other non-damaging methods for utility verification, as indicated in (d) below, may be considered subject to approval by the Contracting Officer. Also, verify that any abandoned utilities are not active.

c) Preserve all utility markings for the duration of the project to the furthest extent possible.

d) When excavation is performed within 2 feet of any utility line, a non-damaging method of excavation shall be used. The non-damaging method shall be hand digging. Other non-damaging methods, such as, soft digging, vacuum excavation, pneumatic hand tools, may be considered subject to approval by the Contracting Officer.

e) Regardless of the type of excavation, the Contractor shall notify the Contracting Officer a minimum of 72 hours prior to any excavation activity. Failure to notify the Contracting Officer can result in the issuance of a "Stop Work" order, which shall not

SECTION 01 05 00 Page 3 10/14/16 be justification for contract delay or time extension. The Government reserves the right to have personnel present on site during any type of excavation.

f) The Contractor's Quality Control System Manager shall ensure that all excavation requirements herein are met at the time of the preparatory phase of quality control, and that the excavation procedures are reviewed during the preparatory phase meeting.

This preparatory phase of control shall also establish and document contingency plans and actions to be followed in the event that existing utilities are damaged or interrupted. Locations of shut off or isolation devices along with other safety features shall be established and their operation reviewed.

g) Any work other than excavation in the vicinity of a utility, that could damage or interrupt a utility, such as, exterior or interior work near transformers, power lines, poles, above ground gas lines, gas meters, etc., shall be done with extreme care. The Contractor shall specifically note during the preparatory phase of quality control, the construction techniques to be used to preclude damaging or interrupting any utility. This preparatory phase of control shall also establish and document contingency plans and actions to be followed in the event that existing utilities are damaged or interrupted. Locations of shut off or isolation devices along with other safety features shall be established and their operation reviewed.

h) The Contractor shall complete a risk assessment, using the attached checklist, at least one week prior to the start of any excavation or other work in the vicinity of a utility. The risk assessment shall be submitted for government approval prior to any excavation or other work in the vicinity of a utility. A risk assessment shall be completed for each definable feature of work encountering utilities and shall include all utilities anticipated to be encountered.

1.5 DISPOSAL OF EXISTING MATERIAL AND EQUIPMENT: (DEC 1975)

All removed, dismantled or demolished material and/or equipment including rubble, scrap and debris not specified or indicated to be Government salvaged, reinstalled under this contract or otherwise retained for disposal on Government land will become the property of the Contractor and shall be promptly removed from the site and disposed of by the Contractor at his own expense and responsibility. (CENAB)

1.6 COMPLIANCE WITH FACILITY REGULATIONS: (JUL 1980)

The site of the work is on a government facility and all rules and regulations issued by the Plant Management Staff covering general safety, security, sanitary requirements, pollution control, traffic regulations and parking, shall be observed by the Contractor. Information regarding these requirements may be obtained by contacting the Contracting Officer, who will provide such information or assist in obtaining same from appropriate authorities. (MEMO)

Contractor shall obey all local speed limits and yield right-of-way to pedestrians walking to/from the site.

SECTION 01 05 00 Page 4 10/14/16

1.6.1 No Smoking Policy

Smoking is prohibited within and outside of all buildings on installations under the cognizance of USACE except in designated smoking areas. This applies to existing buildings, buildings under construction and buildings under renovation. Discarding tobacco materials other than into designated tobacco receptacles is considered littering and is subject to fines. The Contracting Officer will identify designated smoking areas.

1.7 MAINTENANCE OF ACCESS: (DEC 1975)

The Contractor shall not block passage through sidewalks, roads, alleys or other entranceways to the facility during performance of work under this contract. In addition, the Contractor shall at all times maintain safe and clear passage for Government personnel on and about the project site to allow minimal disruption of normal activities. No equipment or new materials are to be stored on the site except those items that are necessary for progress of the immediate work. All existing equipment, materials and debris removed during the work that are not to be reinstalled shall be removed daily by the Contractor from the site.

Restore access roads and walkways affected by construction upon completion of other work.

1.7.1 Emergency Return to Service

If the Contractor is working in an area that is required for an emergency, the Contractor shall immediately make the area ready for service and allow the WA access to operate.

1.8 PROTECTION OF GOVERNMENT PROPERTY AND PERSONNEL: (DEC 1975)

1.8.1 Protection of Equipment

All existing Government owned equipment within the work area shall be protected by the Contractor from damage caused by construction operations.

As a minimum, the Contractor shall cover all furniture, equipment and carpets in the work area with dust barriers and protect such items from any damage due to dust, vibration, water, heat or other conditions resulting from construction activities. Existing work damaged by construction operations shall be promptly repaired by the Contractor at his own expense.

1.8.2 Protection of Personnel

The Contractor shall protect personnel accessing the buildings by installing safety rails and/or barricades as applicable to prevent injury from unauthorized entry of personnel into work areas. Warning signs shall be erected as necessary to indicate Construction areas or hazardous zones.

Work shall proceed in such manner as to prevent the undue spread of dust and flying particles.

1.8.3 Measures to Prevent Damage/Injury

The Contractor shall take such additional measures as may be directed by the Contracting Officer to prevent damage or injury to Government property or personnel. (CENAB)

SECTION 01 05 00 Page 5 10/14/16

1.9 STREET CLOSINGS: (MAY 1978)

When operations in connection with contract work necessitate the closing of streets, it shall be the Contractor's responsibility to conform to the approved traffic control permit requirements, and also to arrange in advance with the Contracting Officer for such street closings and to provide appropriate barricades, signs, markers, flares, and other devices as may be required by the Contracting Officer's Representative for traffic guides and public safety. (CENAB)

1.10 ORDER OF WORK AND COORDINATION WITH OTHER CONTRACTORS: (FEB 1979)

Other Contractors may be presently working in the same area. After award of this contract a meeting will be held with all contractor representatives and the Contracting Officer to develop a plan of work coordination. In case of disagreement regarding use of an area the decision of the Contracting Officer will control. (CENAB)

1.11 SALVAGE MATERIAL AND EQUIPMENT: ( OCT 1993)

The Contractor shall maintain adequate property control records for all materials and equipment specified to be salvaged. These records may be in accordance with the Contractor's system of property control, if approved by the property administrator. The Contractor shall be responsible for the adequate storage and protection of all salvaged materials and equipment and shall replace, at no cost to the Government, all salvage materials and equipment which are broken or damaged during salvage operations as the result of his negligence, or while in his care. The Contractor shall deliver such salvage material to a location as directed by the Contracting Officer. (CENAB-EN-DT)

1.12 ASBESTOS HANDLING AND REMOVAL (FEB 85)

Through site investigations, friable asbestos has not been found, however if asbestos is encountered, its testing, removal and disposal is covered in "CHANGES" clause of the Contract Clauses. (CENAB)

1.13 TIME EXTENSIONS FOR UNUSUALLY SEVERE WEATHER

1.13.1 Procedure for Determination

This provision specifies the procedure for determination of time extensions for unusually severe weather in accordance the contract clause entitled "Default: (Fixed Price Construction)". In order for the Contracting Officer to award a time extension under this clause, the following conditions must be satisfied:

a. The weather experienced at the project site during the contract period must be found to be unusually severe, that is, more severe than the adverse weather anticipated for the project location during any given month.

b. The unusually severe weather must actually cause a delay to the completion of the project. The delay must be beyond the control and without the fault or negligence of the contractor.

1.13.2 Anticipated Adverse Weather Delays

The following schedule of monthly anticipated adverse weather delays is based on National Oceanic and Atmospheric Administration (NOAA) or similar

SECTION 01 05 00 Page 6 10/14/16 data for the project location and will constitute the base line for monthly weather time evaluations. The contractor's progress schedule must reflect these anticipated adverse weather delays in all weather dependent activities.

MONTHLY ANTICIPATED ADVERSE WEATHER DELAY

WORK DAYS BASED ON (5) DAY WORK WEEK

Washington Aqueduct (WA) Facilities, Washington, D.C.

JAN FEB MAR APR MAY JUN JUL AUG SEP OCT NOV DEC

4 5 6 7 6 6 6 5 2 5 4 3

1.13.3 Impact

Upon acknowledgment of the Notice to Proceed (NTP) and continuing throughout the contract, the contractor will record on the daily CQC report, the occurrence of adverse weather and resultant impact to normally scheduled work. Actual adverse weather delay days must prevent work on critical activities for 50 percent or more of the contractor's scheduled work day. The number of actual adverse weather delay days shall include days impacted by actual adverse weather (even if adverse weather occurred in previous month), be calculated chronologically from the first to the last day of each month, and be recorded as full days. If the number of actual adverse weather delay days exceeds the number of days anticipated in paragraph "Anticipated Adverse Weather Delays", above, the Contracting Officer will convert any qualifying delays to calendar days, giving full consideration for equivalent fair weather work days, and issue a contract modification.

1.14 WORKING HOURS

Regular working hours shall consist of an 8 hour period established by the Contractor Officer, between 7 a.m. and 5:30 p.m., during weekdays and Saturday, excluding Government holidays.

1.14.1 Work Outside Regular Hours

Work outside regular working hours requires Contracting Officer approval.

Make application 15 calendar days prior to such work to allow arrangements to be made by the Government for inspecting the work in progress, giving the specific dates, hours, location, type of work to be performed, contract number and project title. Based on the justification provided, the Contracting Officer may approve work outside regular hours. During periods of darkness, the different parts of the work shall be lighted in a manner approved by the Contracting Officer. Make utility cutovers after normal working hours or on Saturdays, Sundays, and Government holidays unless directed otherwise.

1.14.2 Utility Cutovers and Interruptions

a. Make utility cutovers and interruptions after normal working hours or on Saturdays, Sundays, and Government holidays. Conform to procedures required in the paragraph "Work Outside Regular Hours."

b. Ensure that new utility lines are complete, except for the connection, before interrupting existing service.

c. Operation of Station Utilities: The Contractor shall not operate nor disturb the setting of control devices in the station

SECTION 01 05 00 Page 7 10/14/16 utilities system, including water, sewer, electrical, and steam services. The Government will operate the control devices as required for normal conduct of the work. The Contractor shall notify the Contracting Officer giving reasonable advance notice when such operation is required.

1.15 LIMITS OF WORK AREAS

The limits of work areas as shown on the drawings are necessarily approximate. In case of doubt as to the actual limits of any work area, determination as to the actual limits will be made by the Contracting Officer.

1.16 Training

A. The Contractor shall arrange for a qualified service representative from each company manufacturing or supplying certain equipment, to perform the duties herein described.

B. Verification of Installation: After installation of the equipment has been completed and the equipment is presumably ready for operation, but before it is operated by others, the representative shall inspect, operate, test, and adjust the equipment. The inspection shall include but shall not be limited to, the following points as applicable:

1. Soundness (without cracked or otherwise damaged parts).

2. Completeness in all details, as specified.

3. Correctness of setting, alignment, and relative arrangement of various parts

4. Adequacy and correctness of packing, sealing and lubricants.

C. The operation, testing, and adjustment shall be as required to prove that the equipment is left in proper condition for satisfactory operation under the conditions specified.

D. On completion of his work, the manufacturer's or supplier's representative shall submit in triplicate to the Government a complete signed report of the result of his inspection, operation, adjustments and tests. The report shall include detailed descriptions of the points inspected, tests and adjustments made, quantitative results obtained if such are specified, and suggestions for precautions to be taken to ensure proper maintenance. The report also shall include a certificate that the equipment conforms to the requirements of the Contract and is ready for permanent operation and that nothing in the installation will render the manufacturer's warranty null and void.

E. After the Government has reviewed the reports from the manufacturers' representatives, the Contractor shall make arrangements to have the manufacturers' representatives present when the field acceptance tests are made.

F. Training: In addition to and completely independent from the services of the manufacturers' representatives described herein, before, the Contractor shall arrange for professionally prepared and delivered training sessions on equipment listed below.

SECTION 01 05 00 Page 8 10/14/16

G. Equipment Minimum Training (hours)

HVAC System (To include equipment and controls) 8 hrs Electric Actuators 8 hrs

H. The objective of all specified training is to provide Owner's operational and maintenance personnel with sufficient information and skills training of the theory, design and site specific operation and maintenance practices to assure that the equipment can be efficiently and effectively operated and maintained by the trainees upon completion of the training. Training shall be a combination of classroom, field and "hands-on" training necessary to achieve this objective.

I. Copies of the following information shall be submitted as a shop drawing to the Engineer through the Construction Manager by the Contractor to assist the Owner in determining the quality and applicability of training to be provided.

1. A detailed training outline indicating the topics to be discussed with each training group, i.e., operations and maintenance, and the expected duration of each training task. The outline shall also include the type or location of training, i.e., "hands-on", field or classroom training.

2. Information about the qualified instructor. Sales representatives will not be considered acceptable unless their qualifications as submitted indicate substantial knowledge and experience in equipment servicing.

3. A trainee manual that includes all pertinent information needed to operate and maintain the equipment. One copy of the trainee manual shall be given to each trainee. Note that this manual may be different than the Operating and Maintenance Instructions and Parts Lists, as the training manual should include only the information related to the discipline being trained. Thus different training manuals may be used for Operations personnel and Maintenance personnel. There will be a total of 30 trainees, consisting of approximately 20 operations personnel and 10 maintenance personnel.

J. Training will not be scheduled until receipt of an acceptable training and Operations & Maintenance Manual submittal as here before described.

K. All costs associated with the service of manufacturers' representative shall be borne by the Contractor.

1.17 Confined Spaces

There are areas within the work area, including buried utility structures, that are designated as Permit-required Confined Spaces. The Contractor shall comply with all safety requirements for work in such spaces and reflect that in his Accident prevention Plan required in Section 01 35 26.

PART 2 PRODUCTS

Not used.

SECTION 01 05 00 Page 9 10/14/16

PART 3 EXECUTION

Not used.

SECTION 01 05 00 Page 10 10/14/16

RISK ASSESSMENT FOR

EXCAVATION AND OTHER WORK IN THE VICINITY OF UTILITIES

PROJECT NAME:_____________________________________________________________________ CONTRACT NUMBER:_________________________________________________________________ PROJECT INSTALLATION AND LOCATION:________________________________________________ PROPOSED EXCAVATION START DATE:__________________________________________________

1. ESTABLISH EXCAVATION DETAILS AND DRAWINGS (check when completed)

2. PROPOSED EXCAVATION AREA MARKED (“white lining”) (check when completed)

3. CONTACT APPROPRIATE ONE-CALL SERVICE FOR PUBLIC UTILITIES:

MD: Miss Utility 1-800-257-7777 N Y : New York City - Long Island One Call Center 1-800-272-4480 N. VA: Miss Utility 1-800-552-7777 PA: Pennsylvania One-Call System Incorporated 1-800-242-1776 VA: Miss Utility of VA 1-800-552-7001 DC: Miss Utility 1-800-257-7777

ONE-CALL NATIONAL REFERRAL CENTER: 1-888-258-0808

CONTACT INSTALLATION/OWNERS OF ALL PRIVATELY OWNED UTILITIES (NON ONE-CALL

MEMBERS)

4. DATE UTILITIES MARKED AND METHOD OF MARKING

ONE-CALL LOCATORS ______________________________________________________________

OTHER LOCAT ORS _________________________________________________________________

5. CONTACT APPROPRIATE DPW REPRESENTATIVES AND COMPLY WITH INSTALLATION PERMIT

REQUIREMENTS: _____________________________________________________________________

6. UTILITIES IDENTIFIED ON-SITE:

NONE ELECTRIC GAS WATER TELEPHONE CATV SEWER OTHER __________

7. LEVEL OF RISK: (Based upon personnel safety and consequences of utility outages.)

SEVERE: Excavation required within the immediate vicinity (<2-ft) of a MARKED utility.

MODERATE: Excav. required outside the immediate vicinity (> 2-ft) of MARKED utility.

MINIMAL: Excavation required in an area with NO utilities.

8. EXISTING FACILITIES/UTILITIES IN VICINITY:

NON-CRITICAL MISSION CRITICAL HIGH-PROFILE CEREMONIAL

OTHER_________________________________________________________

CONSEQUENCES IF EXISTING UTILITIES ARE DAMAGED/DISRUPTED _________________

9. ENGINEERING CONTROLS REQUIRED:

NONE HAND EXCAVATE TO LOCATE UTILITY EXCAVATE WITH DUE CARE

OTHER_______________________________________________________________

10. ADMINISTRATIVE CONTROLS REQUIRED:

Notification of Contracting Officer’s Representative, NOTIFIED on: _____________________ Notification of Installation/DPW Representative, NOTIFIED on:________________________

11. EMERGENCY NOTIFICATION AT INSTALLATION: POC & PHONE NUMBER ______________________

THE INFORMATION NOTED ABOVE IS ACCURATE AND THE WORK IS READY TO PROCEED

SIGNED and DATE _______________________________________________________________CQC MANAGER

12. ON-SITE GOVERNMENT REP. RECOMMENDATION FOR APPROVAL TO EXCAVATE:

YES NO SIGNATURE AND DATE: _______________________________

Comments :_____________________________________________________________________

13. AREA ENGINEER APPROVAL TO EXCAVATE:

APPROVED DENIED SIGNATURE AND DATE: _______________________________

Comments :_____________________________________________________________________

14. CHIEF,________________ DIVISION APPROVAL TO EXCAVATE:

APPROVED DENIED SIGNATURE AND DATE: _______________________________

Comments :_____________________________________________________________________

SECTION 01 07 00

CUTTING, PATCHING AND REPAIRING

01/01

PART 1 GENERAL

1.1 Description

This section pertains to the provision of all cutting, removing, replacing, patching, repairing, restoration, refinishing and similar type work as necessary to existing work scheduled to remain and to new work required to be cut or uncovered. All existing facilities damaged as a result of the construction activities shall be restored to a condition equivalent to that prior to the start of work, except where otherwise shown or specified.

1.2 Work Execution

Extent of work includes uncovering work to provide for installation of ill-timed work, removal and replacement of defective work or work that does not conform to the contract documents, installation of new work to be installed in existing construction, and as necessary to make several parts fit.

1.3 SUBMITTALS

Government approval is required for submittals with a "G" designation;

submittals not having a "G" designation are for information only. When used, a designation following the "G" designation identifies the office that will review the submittal for the Government. The following shall be submitted in accordance with Section 01 33 00 SUBMITTAL PROCEDURES:

SD-01 Preconstruction Submittals

Procedures; G, WA.

The accomplishment of cutting, patching, and repairing of the work.

PART 2 PRODUCTS

2.1 MATERIALS

Materials for replacement, repairing, patching, restoration, and similar type work shall conform to applicable sections of the specifications for new materials or work. Where existing materials and/or installations are not covered by the specifications, such materials shall match existing.

All excess materials resulting from cutting and removal work shall be removed from the job site.

PART 3 EXECUTION

3.1 INSPECTION AND PREPARATION

3.1.1 Inspection of Conditions of Work

Inspect all existing conditions of work, for possible movement or damage

SECTION 01 07 00 Page 1 10/14/16 during cutting or uncovering procedures. After uncovering work, inspect conditions affecting installation of new products. Do not proceed with any further cutting, patching or repairing work if defects are observed; or if any unsafe condition exists.

3.1.2 Preparation of the Work Site

Prior to cutting or uncovering work, provide all shoring, bracing and supports as required to maintain the structural integrity of the project.

Prior to restoration work, properly prepare existing surfaces to receive new materials such as to provide a proper bond or joining.

3.2 CUTTING AND DRILLING

Contractor shall do all cutting and drilling of existing…