W912D0-17-Q-0005.pdf

W6L7 USAG FT WAINWR

W6L7 USAG FT WAINWR

DIRECTORATE OF PUBLIC WORKS

1060 GAFFNEY ROAD 4500

FORT WAINWRIGHT AK 99703-4500

TEL: 907-384-7107 FAX:

0010991857

REQUEST FOR QUOTATIONS

(THIS IS NOT AN ORDER) 1

PAGE OF PAGES

1. REQUEST NO. 2. DATE ISSUED RATING

W912D0-17-Q-0005 03-Mar-2017 5a. ISSUED BY

8. TO: NAME AND ADDRESS, INCLUDING ZIP CODE

IMPORTANT: This is a request for information, and quotations furnished are not offers. If you are unable to quote, please so indicate on this form and return it to the address in Block 5a. This request does not commit the Government to pay any costs incurred in the preparation of the submission of this quotation or to contract for supplies or services. Supplies are of domestic origin unless otherwise indicated by quoter. Any representations and/or certifications attached to this

Request for Quotations must be completed by the quoter.

11. SCHEDULE (Include applicable Federal, State, and local taxes)

ITEM NO.

(a)

SUPPLIES/ SERVICES

(b)

QUANTITY

(c)

UNIT

(d)

UNIT PRICE

(e) (f)

SEE SCHEDULE

AMOUNT

% No. %

NOTE: Additional provisions and representations [ ] are [ ] are not attached.

13. NAME AND ADDRESS OF QUOTER (Street, City, County, State, and ZIP Code)

14. SIGNATURE OF PERSON AUTHORIZED TO

SIGN QUOTATION

15. DATE OF

QUOTATION

16. NAME AND TITLE OF SIGNER (Type or print) (Include area code)

TELEPHONE NO.

AUTHORIZED FOR LOCAL REPRODUCTION STANDARD FORM 18 (REV. 6-95)

PREVIOUS EDITION NOT USABLE Prescribed by GSA FAR (48 CFR) 53.215-1(a)

THIS RFQ X[ ] IS [ ] IS NOT A SMALL BUSINESS SET-ASIDE

6. DELIVER BY (Date)

SEE SCHEDULE

AND/OR DMS REG. 1

UNDER BDSA REG. 2

4. CERT. FOR NAT. DEF.3. REQUISITION/PURCHASE

REQUEST NO.

REGIONAL CONTRACTING OFFICE - ALASKA

P O BOX 35510 1064 APPLE ST

FORT WAINWRIGHT AK 99703-0510

9. DESTINATION (Consignee and address, including ZIP Code)

7. DELIVERY

[ ]X FOB

DESTINATION

[ ] OTHER

(See Schedule)

20-Mar-2017(Date)

PLEASE FURNISH QUOTATIONS TO THE ISSUING OFFICE IN BLOCK 5a ON OR BEFORE CLOSE OF BUSINESS:10.

907.353.6924TATIANA REVERA

(Name and Telephone no.) (No collect calls)5b. FOR INFORMATION CALL:

d. CALENDAR DAYSc. 30 CALENDAR DAYSb. 20 CALENDAR DAYS12. DISCOUNT FOR PROMPT PAYMENT a. 10 CALENDAR DAYS

W912D0-17-Q-0005

Section B - Supplies or Services and Prices

ITEM NO SUPPLIES/SERVICES QUANTITY UNIT UNIT PRICE AMOUNT

0001 1 Job CHP-00007-4J, Install Bird Mitigation Me

FFP

Small Project Contract (IFB/RFQ) Project #: CHP-00007-4J / Bldgs 3429 + 3430 / Install Bird Mitigation Measures FOB: Destination

PURCHASE REQUEST NUMBER: 0010991857

NET AMT

Section E - Inspection and Acceptance

INSPECTION AND ACCEPTANCE TERMS

Supplies/services will be inspected/accepted at:

CLIN INSPECT AT INSPECT BY ACCEPT AT ACCEPT BY

0001 Destination Government Destination Government

Section F - Deliveries or Performance

CLAUSES INCORPORATED BY FULL TEXT

52.211-10 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence work under this contract within 1 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 30 days after issuing the Notice to Proceed (NTP). The time stated for completion shall include final cleanup of the premises.

(End of clause)

Section I - Contract Clauses

CLAUSES INCORPORATED BY REFERENCE

52.203-7 Anti-Kickback Procedures MAY 2014 52.204-4 Printed or Copied Double-Sided on Postconsumer Fiber

Content Paper

MAY 2011

52.204-13 System for Award Management Maintenance OCT 2016 52.209-10 Prohibition on Contracting With Inverted Domestic

Corporations

NOV 2015

52.219-6 Notice Of Total Small Business Set-Aside NOV 2011 52.219-28 Post-Award Small Business Program Rerepresentation JUL 2013 52.222-3 Convict Labor JUN 2003 52.222-6 Construction Wage Rate Requirements MAY 2014 52.222-7 Withholding of Funds MAY 2014 52.222-8 Payrolls and Basic Records MAY 2014 52.222-9 Apprentices and Trainees JUL 2005 52.222-10 Compliance with Copeland Act Requirements FEB 1988 52.222-11 Subcontracts (Labor Standards) MAY 2014 52.222-12 Contract Termination-Debarment MAY 2014 52.222-13 Compliance With Construction Wage Rate Requirements and

Related Regulations

MAY 2014

52.222-14 Disputes Concerning Labor Standards FEB 1988 52.222-15 Certification of Eligibility MAY 2014 52.222-21 Prohibition Of Segregated Facilities APR 2015 52.222-26 Equal Opportunity SEP 2016 52.222-50 Combating Trafficking in Persons MAR 2015 52.222-55 Minimum Wages Under Executive Order 13658 DEC 2015 52.223-2 Affirmative Procurement of Biobased Products Under Service and Construction Contracts

SEP 2013

52.223-15 Energy Efficiency in Energy-Consuming Products DEC 2007 52.223-17 Affirmative Procurement of EPA-Designated Items in Service and Construction Contracts

MAY 2008

52.223-18 Encouraging Contractor Policies To Ban Text Messaging While Driving

AUG 2011

52.225-10 Notice of Buy American Requirement--Construction Materials

MAY 2014

52.225-13 Restrictions on Certain Foreign Purchases JUN 2008 52.228-5 Insurance - Work On A Government Installation JAN 1997 52.228-11 Pledges Of Assets JAN 2012 52.232-5 Payments under Fixed-Price Construction Contracts MAY 2014 52.232-23 Assignment Of Claims MAY 2014 52.232-27 Prompt Payment for Construction Contracts JAN 2017 52.232-33 Payment by Electronic Funds Transfer--System for Award

Management

JUL 2013

52.232-39 Unenforceability of Unauthorized Obligations JUN 2013 52.233-1 Disputes MAY 2014 52.233-3 Protest After Award AUG 1996 52.233-4 Applicable Law for Breach of Contract Claim OCT 2004 52.236-2 Differing Site Conditions APR 1984 52.236-3 Site Investigation and Conditions Affecting the Work APR 1984 52.236-5 Material and Workmanship APR 1984 52.236-7 Permits and Responsibilities NOV 1991

52.236-9 Protection of Existing Vegetation, Structures, Equipment, Utilities, and Improvements

APR 1984

52.236-11 Use and Possession Prior to Completion APR 1984 52.236-12 Cleaning Up APR 1984 52.236-13 Accident Prevention NOV 1991 52.236-21 Specifications and Drawings for Construction FEB 1997 52.236-26 Preconstruction Conference FEB 1995 52.242-14 Suspension of Work APR 1984 52.243-5 Changes and Changed Conditions APR 1984 52.246-12 Inspection of Construction AUG 1996 52.246-21 Warranty of Construction MAR 1994 52.249-1 Termination For Convenience Of The Government (Fixed

Price) (Short Form)

APR 1984

52.249-10 Default (Fixed-Price Construction) APR 1984 252.203-7000 Requirements Relating to Compensation of Former DoD

Officials

SEP 2011

252.203-7002 Requirement to Inform Employees of Whistleblower Rights SEP 2013 252.204-7012 Safeguarding Covered Defense Information and Cyber

Incident Reporting

OCT 2016

252.227-7000 Non-estoppel OCT 1966 252.232-7003 Electronic Submission of Payment Requests and Receiving

Reports

JUN 2012

252.232-7010 Levies on Contract Payments DEC 2006 252.236-7000 Modification Proposals-Price Breakdown DEC 1991 252.236-7001 Contract Drawings, and Specifications AUG 2000 252.243-7001 Pricing Of Contract Modifications DEC 1991

52.225-9 BUY AMERICAN—CONSTRUCTION MATERIALS (MAY 2014)

(a) Definitions. As used in this clause--

Commercially available off-the-shelf (COTS) item—

(1) Means any item of supply (including construction material) that is--

(i) A commercial item (as defined in paragraph (1) of the definition at FAR 2.101);

(ii) Sold in substantial quantities in the commercial marketplace; and

(iii) Offered to the Government, under a contract or subcontract at any tier, without modification, in the same form in which it is sold in the commercial marketplace; and

(2) Does not include bulk cargo, as defined in 46 U.S.C. 40102(4) such as agricultural products and petroleum products.

Component means an article, material, or supply incorporated directly into a construction material.

Construction material means an article, material, or supply brought to the construction site by the Contractor or a subcontractor for incorporation into the building or work. The term also includes an item brought to the site preassembled from articles, materials, or supplies. However, emergency life safety systems, such as emergency lighting, fire alarm, and audio evacuation systems, that are discrete systems incorporated into a public building or work and that are produced as complete systems, are evaluated as a single and distinct construction material regardless of when or how the individual parts or components of those systems are delivered to the construction site.

Materials purchased directly by the Government are supplies, not construction material.

Cost of components means--

(1) For components purchased by the Contractor, the acquisition cost, including transportation costs to the place of incorporation into the construction material (whether or not such costs are paid to a domestic firm), and any applicable duty (whether or not a duty-free entry certificate is issued); or

(2) For components manufactured by the Contractor, all costs associated with the manufacture of the component, including transportation costs as described in paragraph (1) of this definition, plus allocable overhead costs, but excluding profit. Cost of components does not include any costs associated with the manufacture of the construction material.

Domestic construction material means--

(1) An unmanufactured construction material mined or produced in the United States;

(2) A construction material manufactured in the United States, if--

(i) The cost of its components mined, produced, or manufactured in the United States exceeds 50 percent of the cost of all its components. Components of foreign origin of the same class or kind for which nonavailability determinations have been made are treated as domestic; or

(ii) The construction material is a COTS item.

Foreign construction material means a construction material other than a domestic construction material.

United States means the 50 States, the District of Columbia, and outlying areas.

(b) Domestic preference.

(1) This clause implements 41 U.S.C. chapter 83, Buy American, by providing a preference for domestic construction material. In accordance with 41 U.S.C. 1907, the component test of the Buy American statute is waived for construction material that is a COTS item. (See FAR 12.505(a)(2)). The Contractor shall use only domestic construction material in performing this contract, except as provided in paragraphs (b)(2) and (b)(3) of this clause.

(2) This requirement does not apply to information technology that is a commercial item or to the construction materials or components listed by the Government as follows:

(3) The Contracting Officer may add other foreign construction material to the list in paragraph (b)(2) of this clause if the Government determines that

(i) The cost of domestic construction material would be unreasonable. The cost of a particular domestic construction material subject to the requirements of the Buy American Act is unreasonable when the cost of such material exceeds the cost of foreign material by more than 6 percent;

(ii) The application of the restriction of the Buy American Act to a particular construction material would be impracticable or inconsistent with the public interest; or

(iii) The construction material is not mined, produced, or manufactured in the United States in sufficient and reasonably available commercial quantities of a satisfactory quality.

(c) Request for determination of inapplicability of the Buy American Act. (1)(i) Any Contractor request to use foreign construction material in accordance with paragraph (b)(3) of this clause shall include adequate information for Government evaluation of the request, including--

(A) A description of the foreign and domestic construction materials;

(B) Unit of measure;

(C) Quantity;

(D) Price;

(E) Time of delivery or availability;

(F) Location of the construction project;

(G) Name and address of the proposed supplier; and

(H) A detailed justification of the reason for use of foreign construction materials cited in accordance with paragraph (b)(3) of this clause.

(ii) A request based on unreasonable cost shall include a reasonable survey of the market and a completed price comparison table in the format in paragraph (d) of this clause.

(iii) The price of construction material shall include all delivery costs to the construction site and any applicable duty (whether or not a duty-free certificate may be issued).

(iv) Any Contractor request for a determination submitted after contract award shall explain why the Contractor could not reasonably foresee the need for such determination and could not have requested the determination before contract award. If the Contractor does not submit a satisfactory explanation, the Contracting Officer need not make a determination.

(2) If the Government determines after contract award that an exception to the Buy American statute applies and the Contracting Officer and the Contractor negotiate adequate consideration, the Contracting Officer will modify the contract to allow use of the foreign construction material. However, when the basis for the exception is the unreasonable price of a domestic construction material, adequate consideration is not less than the differential established in paragraph (b)(3)(i) of this clause.

(3) Unless the Government determines that an exception to the Buy American statute applies, use of foreign construction material is noncompliant with the Buy American statute.

(d) Data. To permit evaluation of requests under paragraph (c) of this clause based on unreasonable cost, the Contractor shall include the following information and any applicable supporting data based on the survey of suppliers:

Foreign and Domestic Construction Materials Price Comparison Construction material description Unit of measure Quantity Price (dollars) \1\ Item 1 Foreign construction material.... ........... ___ ........ ....... ………. ___ ................ ........ ___ Domestic construction material... ........ ___ ............... .............. ___ .................. ...... ___ Item 2 Foreign construction material.... ......... ___ ............. ........ ……. ___ ............... ......... ___ Domestic construction material... ....... ___ .................. ............. ___ ................. ....... ___

Include all delivery costs to the construction site and any applicable duty (whether or not a duty-free entry certificate is issued).

List name, address, telephone number, and contact for suppliers surveyed. Attach copy of response; if oral, attach summary.

Include other applicable supporting information.

52.249-10 DEFAULT (FIXED-PRICE CONSTRUCTION) (APR 1984)

(a) If the Contractor refuses or fails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government may, by written notice to the Contractor, terminate the right to proceed with the work (or the separable part of the work) that has been delayed. In this event, the Government may take over the work and complete it by contract or otherwise, and may take possession of and use any materials, appliances, and plant on the work site necessary for completing the work. The Contractor and its sureties shall be liable for any damage to the Government resulting from the Contractor’s refusal or failure to complete the work within the specified time, whether or not the Contractor’s right to proceed with the work is terminated. This liability includes any increased costs incurred by the Government in completing the work.

(b) The Contractor’s right to proceed shall not be terminated nor the Contractor charged with damages under this clause, if—

(1) The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include—

(i) Acts of God or of the public enemy,

(ii) Acts of the Government in either its sovereign or contractual capacity,

(iii) Acts of another Contractor in the performance of a contract with the Government,

(iv) Fires,

(v) Floods,

(vi) Epidemics,

(vii) Quarantine restrictions,

(viii) Strikes,

(ix) Freight embargoes,

(x) Unusually severe weather, or

(xi) Delays of subcontractors or suppliers at any tier arising from unforeseeable causes beyond the control and without the fault or negligence of both the Contractor and the subcontractors or suppliers; and

(2) The Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the facts and the extent of delay. If, in the judgment of the Contracting Officer, the findings of fact warrant such action, the time for completing the work shall be extended. The findings of the Contracting Officer shall be final and conclusive on the parties, but subject to appeal under the Disputes clause.

(c) If, after termination of the Contractor’s right to proceed, it is determined that the Contractor was not in default, or that the delay was excusable, the rights and obligations of the parties will be the same as if the termination had been issued for the convenience of the Government.

(d) The rights and remedies of the Government in this clause are in addition to any other rights and remedies provided by law or under this contract.

52.252-2 CLAUSES INCORPORATED BY REFERENCE (FEB 1998)

This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at this/these address(es):

www.acquisition.gov http://farsite.hill.af.mil

252.232-7006 WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (MAY 2013)

(a) Definitions. As used in this clause--

Department of Defense Activity Address Code (DoDAAC) is a six position code that uniquely identifies a unit, activity, or organization.

Document type means the type of payment request or receiving report available for creation in Wide Area WorkFlow (WAWF).

Local processing office (LPO) is the office responsible for payment certification when payment certification is done external to the entitlement system.

(b) Electronic invoicing. The WAWF system is the method to electronically process vendor payment requests and receiving reports, as authorized by DFARS 252.232-7003, Electronic Submission of Payment Requests and Receiving Reports.

(c) WAWF access. To access WAWF, the Contractor shall--

(1) Have a designated electronic business point of contact in the System for Award Management at https://www.acquisition.gov; and

(2) Be registered to use WAWF at https://wawf.eb.mil/ following the step-by-step procedures for self-registration available at this Web site.

(d) WAWF training. The Contractor should follow the training instructions of the WAWF Web-Based Training Course and use the Practice Training Site before submitting payment requests through

WAWF. Both can be accessed by selecting the “Web Based Training” link on the WAWF home page at https://wawf.eb.mil/.

(e) WAWF methods of document submission. Document submissions may be via Web entry, Electronic Data Interchange, or File Transfer Protocol.

(f) WAWF payment instructions. The Contractor must use the following information when submitting payment requests and receiving reports in WAWF for this contract/order:

(1) Document type. The Contractor shall use the following document type(s).

CONSTRUCTION

(2) Inspection/acceptance location. The Contractor shall select the following inspection/acceptance location(s) in WAWF, as specified by the contracting officer.

W912D0

(3) Document routing. The Contractor shall use the information in the Routing Data Table below only to fill in applicable fields in WAWF when creating payment requests and receiving reports in the system.

Routing Data Table* Field Name in WAWF Data to be entered in WAWF Pay Official DoDAAC HQ0490 Issue By DoDAAC ____ Admin DoDAAC W912D0 Inspect By DoDAAC W912D0 Ship To Code ____ Ship From Code ____ Mark For Code ____ Service Approver (DoDAAC) W912D0 Service Acceptor (DoDAAC) W912D0 Accept at Other DoDAAC ____ LPO DoDAAC ____ DCAA Auditor DoDAAC ____ Other DoDAAC(s) ____

(4) Payment request and supporting documentation. The Contractor shall ensure a payment request includes appropriate contract line item and subline item descriptions of the work performed or supplies delivered, unit price/cost per unit, fee (if applicable), and all relevant back-up documentation, as defined in DFARS Appendix F, (e.g. timesheets) in support of each payment request.

(5) WAWF email notifications. The Contractor shall enter the email address identified below in the “Send Additional Email Notifications” field of WAWF once a document is submitted in the system.

KAILEY.A.GOOD-HALLAHAN.MIL@MAIL.MIL; MICHAEL.C.MCTAGUE.MIL@MAIL.MIL

(g) WAWF point of contact. (1) The Contractor may obtain clarification regarding invoicing in WAWF from the following contracting activity's WAWF point of contact.

NOT APPLICABLE

(2) For technical WAWF help, contact the WAWF helpdesk at 866-618-5988.

FORT WAINWRIGHT POST ACCESS

a. These instructions apply for vehicle access to Fort Wainwright, Alaska (henceforth referred to as FWA).

Procedures for commercial vehicle access to FWA are subject to change without prior notice. Current information concerning road conditions may be obtained by calling 907-353-INFO(4636).

b. Each employee who requires access to FWA to perform work under any contract, at any tier, must (1) have an issued Common Access Card (CAC), (2) obtain a Fast Access identification badge, or (3) obtain a visitor's pass to obtain access to the installation. This section describes the Fast Access Program; the next session, titled Commercial Vehicle Access to Fort Wainwright, Alaska, describes procedures for obtaining a visitor's pass.

c. A Fast Access identification badge will only be issued to an employee, at any tier, if (1) the employee was not issued a CAC, and (2) the employee requires access more than twice per week. A Fast Access identification badge will only be issued to contractor employees if the contractor participates in the Fast Access Program. The Fast Access Program is a voluntary program. Companies must be listed on the Contractors Authorized List (CAL).

d. The contractor shall provide information as required by the Fast Access Program Contractor (RPC) to enable the RPC to conduct a criminal history background check (CHBC) on contractor employees who are to have access. The contractor is responsible for paying the RPC the fee per employee for conducting the CHBC and issuing the Fast Access identification card. If the CHBC is not adverse a Fast Access identification badge will be issued by the RPC to the contractor employee. If the CHBC is adverse the RPC is prohibited from issuing a Fast Access identification badge to the contractor employee. If a Fast Access identification badge is denied for any reason, the contractor employee may only enter the installation by obtaining a visitor's pass; however, if the contractor employee does not meet the criteria for being issued a Fast Access identification badge, the Government may, at its sole discretion, decide not to issue a visitor's pass to the contractor employee.

e. Contractors participating in the Fast Access Program may enter the installation through any Fast Access lane except at Force Protection Level Charlie or Delta. During Force Protection Level Charlie or Delta all contractor vehicles must enter through the Main Gate access and commercial vehicle inspection point (CVIP). All passengers in the contractor vehicle must have a Fast Access identification card; otherwise, the contractor vehicle must enter through a CVIP and obtain visitor's passes.

f. Fast Access is valid at the Main Gate, the Badger Gate, and the Trainer Gate. The contractor may use any lane.

Current information on gate hours can be obtained from the Visitor Center at 907-361-6144. Additionally, current gate hours and locations may be obtained by calling the Fort Wainwright Police Desk at 353-7710.

g. If the Fast Access Program is terminated for any reason, the contractor will be allowed access only through the Main Gate, unless the contractor is otherwise notified by the Contracting Officer.

h. If an employee no longer needs an identification badge for any reason (e.g., quits his/her job or no longer performs work under the contract), the contractor shall return the identification badge to the Visitor Center within two (2) calendar days of such change. If the identification badge cannot be returned within the required time frame for any reason, the contractor shall immediately notify both the RPC and the Visitor Center verbally, followed up in writing the next work day. Email notification is authorized. An employee's inability to obtain entrance to a Government installation because he/she does not have the required identification badge or visitor's pass shall not excuse timely performance of the requirements of this contract. Badges are currently issued at the Main Gate Visitor Center. The Government may change the location at which identification badges are issued or returned, with or without advance notice to the contractor. Any such changes shall not be a basis for adjusting the contract price under any clause of this contract.

i. Fast Access identification badges shall not be reproduced or copied by the contractor, its subcontractors, or its employees. If an employee's identification badge is lost, stolen, or reproduced, the contractor shall verbally report the loss, theft, or reproduction to both the RPC and the Visitor Center on the day such loss, theft, or reproduction is discovered, followed by a written report of the circumstances to both the RPC and the Visitor Center within one (1) calendar day after the loss, theft, or reproduction is discovered.

j. Each contractor employee shall wear the Fast Access identification badge while performing work under the contract. The identification badge shall be worn on the upper front of the outer garment unless precluded by OSHA regulation(s). The identification badge shall not be used for access to any Government installation except for performance of work under the contract for which it was issued.

k. The contractor shall, upon expiration or termination of the contract, collect all identification badges and turn them in to the COR.

COMMERCIAL VEHICLE ACCESS TO FORT WAINWRIGHT, ALASKA

a. The following procedures apply for contractors that (1) do not have an issued CAC, (2) opt not to enroll in the Fast Access Program, or (3) if the Fast Access Program is terminated or expires. Contractor employees, at any tier, who require access twice per week or less often, or who do not participate in the Fast Access Program, shall obtain a visitor's pass at the Visitor Center. A visitor's pass can be issued for a maximum of 30 days at a time. Companies must be listed on the CAL and employees obtaining a pass must be sponsored. Only those company employees listed on the CAL may sponsor other employees. Employees may also be sponsored by a military ID cardholder associated with the contract.

b. For those not participating in the Fast Access Program, Commercial vehicles may access to the installation at any of the CVIP except during Force Protection Level Charlie and Delta at which time Commercial vehicle Access will only be authorized at the Main Gate access and CVIP. Current information on gate hours can be obtained from the Visitor Center at 907-361-6144 or 907-353-7710.

c. On Saturdays, Sundays and Federal holidays, commercial vehicles must use the Main Gate access only. All commercial vehicles will be subject to inspection. The contractor shall anticipate delays in getting commercial vehicles onto the installation and also take into account the time it takes to drive through the installation to reach a given destination.

d. If the commercial vehicle is carrying a load of cement or hot asphalt for delivery the driver shall notify the gate guard as soon as possible and request that the vehicle be given priority for being searched; however, the Government does not guarantee that the vehicle will be given priority.

e. The contractor shall ensure that its drivers, including drivers of subcontractors at any tier, comply with the procedures as explained to them for access to the installation.

(END OF RCO-AK POST ACCESS INSTRUCTIONS)

Section J - List of Documents, Exhibits and Other Attachments

LIST OF ATTACHMENTS

ATTACHMENT 1- CHP-00007-4J SOW dated 2 March 2017 ATTACHMENT 2- Drawings_B3429 ATTACHMENT 3- Specifications_Flashing Method ATTACHMENT 4- B3429_B3430 Photos

ATTACHMENT 5- DBA AK170001 02172017 AK1

ATTACHMENT 6- CHP-00007-4J , ENG Form 4025

Section K - Representations, Certifications and Other Statements of Offerors

CLAUSES INCORPORATED BY REFERENCE

52.204-16 Commercial and Government Entity Code Reporting JUL 2016 52.204-19 Incorporation by Reference of Representations and

Certifications.

DEC 2014

52.223-1 Biobased Product Certification MAY 2012 52.223-4 Recovered Material Certification MAY 2008 52.236-28 Preparation of Proposals--Construction OCT 1997 252.204-7007 Alternate A, Annual Representations and Certifications JAN 2015

52.233-2 SERVICE OF PROTEST (SEP 2006)

(a) Protests, as defined in section 33.101 of the Federal Acquisition Regulation, that are filed directly with an agency, and copies of any protests that are filed with the Government Accountability Office (GAO), shall be served on the Contracting Officer (addressed as follows) by obtaining written and dated acknowledgment of receipt from SSG KAILEY GOOD-HALLAHAN, BLDG 1064 Apple Street, Fort Wainwright, AK 99703.

(b) The copy of any protest shall be received in the office designated above within one day of filing a protest with the GAO.

(End of provision)

52.236-27 SITE VISIT (CONSTRUCTION) (FEB 1995)

(a) The clauses at 52.236-2, Differing Site Conditions, and 52.236-3, Site Investigations and Conditions Affecting the Work, will be included in any contract awarded as a result of this solicitation. Accordingly, offerors or quoters are urged and expected to inspect the site where the work will be performed.

(b) An organized site visit has been scheduled for-- 14 March 2017 at 1000

(c) Participants will meet at-- BLDG 3015, Directorate of Public Works, Facilities Mangement Conference Room Fort Wainwright, AK 99703

52.252-1 SOLICITATION PROVISIONS INCORPORATED BY REFERENCE (FEB 1998)

This solicitation incorporates one or more solicitation provisions by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. The offeror is cautioned that the listed provisions may include blocks that must be completed by the offeror and submitted with its quotation or offer. In lieu of submitting the full text of those provisions, the offeror may identify the provision by paragraph identifier and provide the appropriate information with its quotation or offer. Also, the full text of a solicitation provision may be accessed electronically at this/these address(es):

www.acquisition.gov http://farsite.hill.af.mil

Section L - Instructions, Conditions and Notices to Bidders

INSTRUCTIONS TO OFFERORS

(a) Submitting your quote. Submit your company’s quote on the SF 18 with all amendments electronically to tatiana.r.rivera.civ@mail.mil. You may submit more than one quote. If you do, we will evaluate each separately.

(b) Submission deadline. We must receive your quote at the e-mail address above by the deadline specified in Block 10 of the Standard Form (SF) 18. Close of business is 1700 AKST. We will not consider any quote that we receive after the deadline.

(c) Terms and content of your quote. Your quote must be based on the terms of this request for quote (RFQ). We may reject any quote that is not based on these terms in every respect.

(d) Evaluation procedures. The Contracting Officer will consider past performance as well as price when making a decision for award. Award may be made to other than the lowest priced offeror if upon review of past performance information it is determined to be in the best interests of the Government. FAR 13.106-2(b) allows for the evaluation of price and other factors to include a review of PPIRS or any other reasonable basis which includes a FAPIIS, SAM, & EPLS review. All eligible offerors are evaluated on Lowest Price after a PPIRS, FAPIIS, SAM, and EPLS review to exclude those with negative past performance.

(e) Site visit: Failure to attend the site visit listed in FAR Clause 52.236-27 and identify obvious conditions does not constitue a vaild claim for a differing or unforseen site condition.