W912BU22R0007- AM2.pdf

462100

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

The reason for this amendment is as follows:

-Answers to RFI questions ( See page 2) -Clarification of Proposal due date of March 25 1:00pmEST

******PLEASE INDICATE RECEIPT OF THIS AMENDMENT ON SF1442 (SOLICITATION,OFFER, AND AWARDS) AS AMENDMENT 0002.

FAILURE TO ACKNOWLEDGE ALL AMENDMENTS MAY BE CAUSE FOR REJECIO OF THE PROPOSAL*******

1. CONTRACT ID CODE PAGE OF PAGES

1 2

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA15C. DATE SIGNED15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer)(Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912BU22R0007

X 9B. DATED (SEE ITEM 11)

11-Feb-2022

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer is extended, X is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN

REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO.

5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

22- Mar-2022

CODE

US ARMY ENGINEER DISTRICT, PHILADELPHIA

CONTRACTING DIVISION

WANAMAKER BUILDING

100 PENN SQUARE EAST

PHILADELPHIA PA 19107-3390

W912BU 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODECODE

EMAIL:TEL:

X

RFI questions for W912BU22R0007_03.22.2022

1. The SF1442, block 13 does not have a submission time on it. We recognize that Sam.gov says 1pm but want to be sure that this is correct as the instructions for bidders in the documents only references back to block 13 and not Sam.gov. Could you please provide confirmation of the proposal date and time? Bid/Proposal due date as shown on SAM.gov of 1:00 pm/EST is confirmed

2. The question on block 11 where it states 60 calendar days to complete the work. Amendment 1 confirmed that the contract end date would be 12/31/22 but, not the duration of the contract.

For example, both the stated contract completion date and the 60 days could be accurate if the government plans to issue a notice to proceed on November 1, 2022. However, if the government intend is to issue a notice to proceed as soon as the successful bidder can start the work, the 60 days in block 11 would not be accurate.

The completion date shall be 31December2022. Contract will be awarded no later than November 1, 2022

3. Question: “Contractor shall act in good faith and use all commercially reasonable efforts to complete the Project. However, the Government understands and agrees that Contractor cannot guarantee that the Project Grade of -47’ will be successful throughout the entire hatched contract limits. Please confirm that the Government shall accept the Works once Contractor has exhausted all commercially reasonable efforts to achieve completion, and this forms part of the Contract for the Works.”

Govt/ Operations Division Concurs that the information will apply to this contract “Revised response to RFI question regarding contract language: "The intent of the contract is to dredge to an elevation of 47’ MLLW exhausting commercially available means and methods at your disposal "

4. Section 00 21 16 - Instructions to Proposers, Item 7. States the following: “The Corps will perform after dredge surveys for each section acceptance. The contractor will be required to request surveys three working days advanced notice of the requested after dredging survey for acceptance. The Government will have three to five days to review results of acceptance/clearance survey. Survey control data sheets will be provided by Survey Branch.”

How much time standby time should contractors include in their pricing to account for Government review of acceptance/clearance surveys?

Operation Division – 5 business days