AMND0003_EA_WWTP.pdf

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

15A. NAME AND TITLE OF SIGNER (Type or print)

30-105-04 EXCEPTION TO SF 30

APPROVED BY OIRM 11-84

STANDARD FORM 30 (Rev. 10-83) Prescribed by GSA

FAR (48 CFR) 53.243

THIS AMENDMENT EXTENDS THE PROPOSAL DUE DATE UNTIL 25 JULY 2013; 2:00 PM

The cutoff date for all Requests for Information (RFIs) has passed. Any RFI received after that date may not be addressed.

(Continued)

1. CONTRACT ID CODE PAGE OF PAGES

J 1

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16C. DATE SIGNED

BY

16B. UNITED STATES OF AMERICA 15C. DATE SIGNED 15B. CONTRACTOR/OFFEROR

(Signature of Contracting Officer) (Signature of person authorized to sign)

8. NAME AND ADDRESS OF CONTRACTOR (No., Street, County, State and Zip Code) X W912BU-13-R-0035

X 9B. DATED (SEE ITEM 11)

14-Jun-2013

10B. DATED (SEE ITEM 13)

9A. AMENDMENT OF SOLICITATION NO.

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

X The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offer X is extended, is not extended.

Offer must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended by one of the following methods:

(a) By completing Items 8 and 15, and returning 1 copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer submitted;

or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDGMENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

12. ACCOUNTING AND APPROPRIATION DATA (If required) Edgewood Area Wastewater Treatment Plant Enhanced Nutrient Removal (ENR) Upgrade, Aberdeen Proving Ground, Aberdeen, Maryland

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS.

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE

CONTRACT ORDER NO. IN ITEM 10A.

B. THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(B).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority)

E. IMPORTANT: Contractor is not, is required to sign this document and return copies to the issuing office.

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

10A. MOD. OF CONTRACT/ORDER NO.

2. AMENDMENT/MODIFICATION NO. 5. PROJECT NO.(If applicable)

6. ISSUED BY

3. EFFECTIVE DATE

16-Jul-2013

CODE

US ARMY ENGINEER DISTRICT, PHILADELPHIA

CONTRACTING DIVISION

WANAMAKER BUILDING

100 PENN SQUARE EAST

PHILADELPHIA PA 19107-3390

W912BU 7. ADMINISTERED BY (If other than item 6)

4. REQUISITION/PURCHASE REQ. NO.

CODE

See Item 6

FACILITY CODE CODE

EMAIL: TEL:

Amendment No. 0003 RFP No.: W912BU-13-R-0035

This page has been intentionally left blank for duplex printing.

14. DESCRIPTION OF AMENDMENT (CONTINUED):

a. General Note – The following pages include specification sections and drawings that have been amended. All pages have been annotated with “Amendment No. 0003” in the header.

b. CHANGES:

(1) SECTION 00010 – SF1442 (SOLICITATION, OFFER, AND AWARD)/BID SCHEDULE – Please delete pages 00010-3 through 00010-6 in their entirety and substitute revised Pages 00010-3 through 00010-6, annotated as “Amendment No. 0003,” and attached hereto.

(2) SECTION 00815 – WAGE RATES – Please delete this section in its entirety and substitute revised Section 00815, annotated as “Amendment No. 0003,” and attached hereto.

c. Note – Please be advised: Amendment No. 0002, posted Tuesday, July 16, 2013 must be acknowledged on Standard Form 1442 (Solicitation, Offer, and Award) as AMENDMENT NO. 0002.

d. PLEASE INDICATE RECEIPT OF THIS AMENDMENT ON STANDARD FORM 1442 (SOLICITATION, OFFER, AND AWARD) AS AMENDMENT NO. 0003. FAILURE TO ACKNOWLEDGE ALL

AMENDMENTS MAY BE CAUSE FOR REJECTION OF THE OFFER.

This page has been intentionally left blank for duplex printing.

RFP No. W912BU-13-R-0035

W912BU-13-R-0035 00010-3

PART I - THE PRICE SCHEDULE

SECTION 00010 - SUPPLIES OR SERVICES AND PRICES

PRICE SCHEDULE

Estimated Item Description Quantity Unit Price Amount 0001 All costs in connection with construction of Edgewood Area Waste Water Treatment Plant Repair Enhanced Nutrient Removal

Upgrades, complete as shown on drawings and specified, but exclusive of work covered under Base Bid Items 0002 through 0008 and Optional Bid Items 0009 through 0015 below. $__________

0002 Concrete Spall Repair (payment item 03 01 30.71-1 as specified in Section 03 01 30.71). 4190 SF $_______ $_________

0003 Concrete Crack Repair (payment Item 03 01 30.71-2 as specified in Section 03 01 30.71). 1140 LF $______ $__________

0004 Concrete Spall Repair in Confined Space (payment item 03 01 30.71-3 as specified in Section 03 01 30.71) 900 SF $______ $__________

0005 Concrete Crack Repair in Confined Space (payment item 03 01 30.71-4 as specified in Section 03 01 30.71) 50 LF $______ $__________

0006 Contingent Dense Graded Aggregate (payment item 31 00 01.2.1 as specified in Section 31 00 01.2) 20 CY $______ $__________

0007 Contingent Open Graded Coarse Aggregate (payment item 31 00 01.2.2 as specified in Section 31 00 01.2) 20 CY $______ $__________

0008 Contingent Unclassified Excavation (payment item 31 00 01.2.3 as specified in Section 31 00 01.2) 40 CY $______ $___________

TOTAL ESTIMATED BASE BID AMOUNT $_____________

W912BU-13-R-0035 00010-4

OPTIONAL BID ITEMS

0009 All costs in connection with construction of the Grit Removal Facility, E-3968, complete as shown on drawings and specifications as Option 1, including, but not limited to demolition of existing grit removal equipment, furnishing new grit removal equipment, blower package, weir assembly, grit screw conveyor, and associated controls and accessories. $___________

0010 All costs in connection with construction of the Aeration/Mixing System for Shellfish Protection Tank No.1. E-3960, complete as shown on drawings and specifications as Option 2, including, but not limited to all diffusers and piping in Tank E-3960 and air piping from Blower Building EBLCT to Tank E-3960. $___________

0011 All costs in connection with construction of the sludge mixing pumps(E3853-SMP-01/02), associated piping and valves from the sludge mixing pumps to Sludge Holding Tanks No. 1 and No.2 (E3851 and E3852), and all demolition, new piping, sludge mixing nozzle assemblies and controls within Sludge Holding Tanks No. 1 and No.2 (E3851 and E3852), complete as shown on the drawings and specifications as Option 3. The base bid shall include all other work for Facility E3853 as shown on the drawings and specifications. $___________

0012 All costs in connection with construction of the Rapid Mixer Drive Unit, E3962-MXR-01 complete as shown on the drawings and specifications as Option 4. The base bid shall include furnishing power to the existing Rapid Mixer and other improvements for Facility E3962 as shown on the drawings and specifications. $___________

W912BU-13-R-0035 00010-5

OPTIONAL BID ITEMS

0013 All costs in connection with construction of the Flocculation Mixer Drive Units, E3961-MXR-01 and E3961-MXR-02 complete as shown on the drawings and specifications as Option 5. The base bid shall include furnishing power to the existing Flocculation Mixers and other improvements for Facility E3961 as shown on the drawings and specifications. $__________

0014 All costs in connection with construction of the Post Aeration Mixer Drive Units, E3959-MXR-01 and E3959-MXR-02 complete as shown on the drawings and specifications as Option 6. The base bid shall include furnishing power to the existing Post Aeration Mixers and other improvements for Facility E3959 as shown on the drawings and specifications. $__________

0015 All costs in connection with construction of the Secondary Influent Flow Meter Vault, complete as shown on the drawings and specifications as Option 7. $__________

TOTAL AMOUNT

(BASE & OPTIONAL ITEMS) $_______________

Notes to Offerors

Offerors must quote on all items including Optional Items. Failure to quote on all items may be cause for rejection of the proposal.

Optional Items may be exercised at any time within 60 calendar days after contract award. The Contracting Officer may exercise the Optional Items by written notice to the Contractor, postmarked within the period specified above. The Government may exercise any, all, or none of the listed Optional Items in any order.

No additional time for contract completion will be allowed when an Optional Item is exercised.

W912BU-13-R-0035 00010-6

EVALUATION OF OPTIONS: Except when it is determined in accordance with FAR 17.206(b) not to be in the Government’s best interest, the Government will evaluate offers for award purposes by adding the total price for all options to the total price for the basic requirements. Evaluation of options will not obligate the Government to exercise the option(s). (FAR 52.217-5 JUL 1990)

VARIATION IN ESTIMATED QUANTITIES. If the quantity of a unit price item in this contract is an estimated quantity and the actual quantity of the unit price item varies more than 15 percent above or below the estimated quantity, an equitable adjustment in the contract price shall be made upon demand of either party. The equitable adjustment shall be based upon any increase or decrease in costs due solely to the variation above 115 percent or below 85 percent of the estimated quantity. If the quantity variation is such as to cause an increase in the time necessary for completion, the Contractor may request, in writing, an extension of time, to be received by the Contracting Officer within 10 days from the beginning of the delay, or within such further period as may be granted by the Contracting Officer before the date of final settlement of the contract. Upon receipt of a written request for an extension, the Contracting Officer shall ascertain the facts and make an adjustment for extending the completion date as, in the judgment of the Contracting Officer, is justified.

(FAR 52.211-18 APR 1984)

RFP No: W912BU-13-R-0035

Section 00815 Page-1

SECTION 00815 – WAGE DETERMINATION

General Decision Number: MD130032 07/12/2013 MD32

Superseded General Decision Number: MD20120056

State: Maryland

Construction Type: Heavy

County: Harford County in Maryland.

HEAVY CONSTRUCTION PROJECTS (including sewer/water construction).

Modification Number Publication Date 0 01/04/2013 1 01/11/2013 2 06/14/2013 3 06/28/2013 4 07/12/2013

CARP0101-014 07/01/2011

Rates Fringes

CARPENTER (Form Work Only).......$ 24.84 11.00

CARP0101-015 04/01/2011

Rates Fringes

MILLWRIGHT.......................$ 27.91 11.25

CARP0101-016 07/01/2011

Rates Fringes

PILEDRIVERMAN....................$ 24.84 11.00

ELEC0024-002 05/02/2012

Rates Fringes

ELECTRICIAN......................$ 34.60 5.25%+13.45

ENGI0037-015 10/01/2009

Rates Fringes

OPERATOR: Bobcat/Skid Steer/Skid Loader................$ 23.05 11.05+a OPERATOR: Bulldozer.............$ 23.95 11.05+a OPERATOR: Drill.................$ 23.95 11.05+a OPERATOR: Excavator

Section 00815 Page-2

120,000 lbs. and Under......$ 23.95 11.05+a Long and Ultra High Reach Excavators; Excavators Over 120,000 lbs............$ 24.95 11.05+a Mini-Excavators.............$ 23.05 11.05+a OPERATOR: Gradall...............$ 24.95 11.05+a OPERATOR: Grader/Blade..........$ 24.95 11.05+a OPERATOR: Loader Front End Loaders 1 1/4 yards and over..............$ 23.95 11.05+a Front End Loaders 1 Yard and Under...................$ 23.05 11.05+a OPERATOR: Mechanic..............$ 23.95 11.05+a OPERATOR: Paver (Asphalt, Aggregate, and Concrete).........$ 23.05 11.05+a OPERATOR: Piledriver............$ 24.95 11.05+a OPERATOR: Roller................$ 23.05 11.05+a

a. PAID HOLIDAYS: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day.

* IRON0016-013 04/01/2013

Rates Fringes

IRONWORKER, REINFORCING AND

STRUCTURAL.......................$ 26.88 17.55

LABO0710-002 04/01/2010

Rates Fringes

LABORER: Landscape..............$ 15.45 5.41 LABORER: Mason Tender - Cement/Concrete..................$ 16.61 5.41

PAIN0051-021 06/01/2013

Rates Fringes

PAINTER (Steel)..................$ 32.66 8.91 PAINTER: Brush, Roller, and Spray............................$ 24.89 8.91

PLUM0486-015 06/01/2013

Rates Fringes

PLUMBER/PIPEFITTER...............$ 36.495 16.79

TEAM0311-006 06/01/2012

Rates Fringes

TRUCK DRIVER: Lowboy Truck......$ 27.66 8.00+a+b

Section 00815 Page-3

a. PAID HOLIDAYS: New Year's Day, Memorial Day, Independence Day, Labor Day, Thanksgiving Day and Christmas Day.

b. VACATION: Employees with 1 year of service - 1 week paid vacation; 2 years service - 2 weeks paid vacation; 10 years service - 3 weeks paid vacation.

c. HEALTH AND WELFARE: $881 per month

SUMD2010-071 07/08/2010

Rates Fringes

BRICKLAYER.......................$ 18.70 0.00

CARPENTER, Excludes Form Work....$ 19.00 2.52

CEMENT MASON/CONCRETE FINISHER...$ 19.31 4.06

LABORER: Common or General......$ 13.06 2.81

LABORER: Flagger................$ 15.71 8.58

LABORER: Grade Checker..........$ 14.62 3.08

LABORER: Mason Tender - Brick...$ 15.93 7.83

LABORER: Pipelayer..............$ 14.16 2.04

OPERATOR: Backhoe...............$ 17.21 5.52

OPERATOR: Crane.................$ 22.00 8.85

OPERATOR: Piledriver............$ 19.95 4.50

OPERATOR: Trackhoe..............$ 20.47 10.20

TRUCK DRIVER: Dump Truck........$ 11.84 0.00

WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental.

Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)).

The body of each wage determination lists the classification

Section 00815 Page-4 and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is union or non-union.

Union Identifiers

An identifier enclosed in dotted lines beginning with characters other than "SU" denotes that the union classification and rate have found to be prevailing for that classification. Example: PLUM0198-005 07/01/2011. The first four letters , PLUM, indicate the international union and the four-digit number, 0198, that follows indicates the local union number or district council number where applicable , i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination.

The date, 07/01/2011, following these characters is the effective date of the most current negotiated rate/collective bargaining agreement which would be July 1, 2011 in the above example.

Union prevailing wage rates will be updated to reflect any changes in the collective bargaining agreements governing the rates.

0000/9999: weighted union wage rates will be published annually each January.

Non-Union Identifiers

Classifications listed under an "SU" identifier were derived from survey data by computing average rates and are not union rates; however, the data used in computing these rates may include both union and non-union data. Example: SULA2004-007 5/13/2010. SU indicates the rates are not union majority rates, LA indicates the State of Louisiana; 2004 is the year of the survey; and 007 is an internal number used in producing the wage determination. A 1993 or later date, 5/13/2010, indicates the classifications and rates under that identifier were issued as a General Wage Determination on that date.

Survey wage rates will remain in effect and will not change until a new survey is conducted.

WAGE DETERMINATION APPEALS PROCESS

1.) Has there been an initial decision in the matter? This can be:

* an existing published wage determination

Section 00815 Page-5

* a survey underlying a wage determination

* a Wage and Hour Division letter setting forth a position on a wage determination matter

* a conformance (additional classification and rate) ruling

On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.)

and 3.) should be followed.

With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to:

Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to:

Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue.

3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to:

Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W.

Washington, DC 20210

4.) All decisions by the Administrative Review Board are final.

END OF GENERAL DECISION