09b0034Amend5.pdf

14. DESCRIPTION OF AMENDMENT/MODIFICATION (Organized by UCF section headings, including solicitation/contract subject matter where feasible.)

THIS AMENDMENT DOES NOT EXTEND THE BID OPENING DATE OF 01 SEPTEMBER 2009 AT 1:00 P.M. EST.

CUTOFF FOR ALL QUESTIONS IS 25 AUGUST 2009 AT 2:00 P.M. EST.

REVISED SECTION 00800, SC-1 "COMMENCEMENT, PROSECUTION AND COMPLETION OF WORK"

CONTINUED ON NEXT PAGE.

8. NAME AND ADDRESS OF CONTRACTOR (No., street, county, State and ZIP Code)

AMENDMENT OF SOLICITATION/MODIFICATION OF CONTRACT

The above numbered solicitation is amended as set forth in Item 14. The hour and date specified for receipt of Offers

MODIFICATION OF CONTRACTS/ORDER

NO.

E. IMPORTANT: Contractor

15B. CONTRACTOR/OFFEROR

is not, copies of the amendment; (b) By acknowledging receipt of this amendment on each copy of the offer tended.

Offers must acknowledge receipt of this amendment prior to the hour and date specified in the solicitation or as amended, by one of the following methods:

(a) By completing Items 8 and 15, and returning submitted; or (c) By separate letter or telegram which includes a reference to the solicitation and amendment numbers. FAILURE OF YOUR ACKNOWLEDG- MENT TO BE RECEIVED AT THE PLACE DESIGNATED FOR THE RECEIPT OF OFFERS PRIOR TO THE HOUR AND DATE SPECIFIED MAY RESULT IN REJECTION OF YOUR OFFER. If by virtue of this amendment you desire to change an offer already submitted, such change may be made by telegram or letter, provided each telegram or letter makes reference to the solicitation and this amendment, and is received prior to the opening hour and date specified.

is extended, B.

A. THIS CHANGE ORDER IS ISSUED PURSUANT TO: (Specify authority) THE CHANGES SET FORTH IN ITEM 14 ARE MADE IN THE CON-

TRACT ORDER NO. IN ITEM 10A.

2. AMENDMENT/MODIFICATION NO.

6. ISSUED BY

11. THIS ITEM ONLY APPLIES TO AMENDMENTS OF SOLICITATIONS

12. ACCOUNTING AND APPROPRIATION DATA (If required)

13. THIS ITEM APPLIES ONLY TO MODIFICATIONS OF CONTRACTS/ORDERS,

IT MODIFIES THE CONTRACT/ORDER NO. AS DESCRIBED IN ITEM 14.

THE ABOVE NUMBERED CONTRACT/ORDER IS MODIFIED TO REFLECT THE ADMINISTRATIVE CHANGES (such as changes in paying office, appropriation date, etc.) SET FORTH IN ITEM 14, PURSUANT TO THE AUTHORITY OF FAR 43.103(b).

C. THIS SUPPLEMENTAL AGREEMENT IS ENTERED INTO PURSUANT TO AUTHORITY OF:

D. OTHER (Specify type of modification and authority) is required to sign this document and return

15A. NAME AND TITLE OF SIGNER (Type or print)

PAGE OF PAGES 1. CONTRACT ID CODE

5. PROJECT NO. (If applicable) 4. REQUISITION/PURCHASE REQ. NO. 3. EFFECTIVE DATE

7. ADMINISTERED BY (If other than Item 6)

15C. DATE SIGNED

16A. NAME AND TITLE OF CONTRACTING OFFICER (Type or print)

16B. UNITED STATES OF AMERICA

BY

16C. DATE SIGNED

9A. AMENDMENT OF SOLICITATION NO.

9B. DATED (SEE ITEM 11)

10B. DATED (SEE ITEM 13)

CODE CODE

Except as provided herein, all terms and conditions of the document referenced in Item 9A or 10A, as heretofore changed, remains unchanged and in full force and effect.

is not ex-copies to the issuing office.

NSN 7540-01-152-8070

PREVIOUS EDITION UNUSABLE

STANDARD FORM 30 (REV. 10-83)

Prescribed by GSA

FAR (48 CFR) 53.243

(Signature of person authorized to sign) (Signature of Contracting Officer)

USAPPC V2.00

10A.

30-105-02

US ARMY ENGINEER DISTRICT, PHILADELPHIA

POC: RYAN ANNIBALI

WANAMAKER BUILDING, 100 PENN SQUARE EAST

PHILADELPHIA, PENNSYLVANIA 19107-3390

US ARMY ENGINEER DISTRICT, PHILADELPHIA

WANAMAKER BUILDING, 100 PENN SQUARE EAST

PHILADELPHIA, PENNSYLVANIA 19107-3390

CODE

FACILITY CODE

0005 08/24/2009

W912BU-09-B-0034

22 July 2009

RECOVERY - COAT AND REPAIR BULKHEAD POINT PLEASANT CANAL

THIS PAGE IS INTENTIONALLY LEFT BLANK

Amendment No. 0005

IFB W912BU-09-B-0034

SPECIAL CLAUSES

SC-1 COMMENCEMENT, PROSECUTION, AND COMPLETION OF WORK (APR 1984)

The Contractor shall be required to (a) commence base bid work under this contract within 14 calendar days after the Contractor receives the notice to proceed for the work (b) prosecute the work diligently, and (c) complete the work ready for use not later than 260 calendar days after the date the Contractor receives the notice to proceed. The Contracting Officer has the right to award Options 1 and 2 within 90 days of Notice to Proceed for the Base Bid. If awarded, the contract duration will be extended 110 days for Option 1 and 80 days for Option 2. The time stated for completion shall include final cleanup of the premises.(FAR 52.211-10)

SC-2 LIQUIDATED DAMAGES - CONSTRUCTION (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of $1,350.00 for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed.

These liquidated damages are in addition to excess costs of repurchase under the Termination clause. (FAR 52.211-12)

SC-3 CONTRACT DRAWINGS, MAPS AND SPECIFICATIONS

a. Upon obtaining the drawings and specifications, the Contractor shall:

(1) Immediately check the specifications and all drawings;

(2) Compare the specifications and all drawings and verify the figures before laying out the work;

(3) Promptly notify the Contracting Officer of any discrepancies; and

(4) Be responsible for any errors which might have been avoided by complying with this paragraph.

b. Large scale drawings shall, in general, govern small scale drawings.

Figures marked on drawings shall, in general, be followed in preference to scale measurements.

c. Omissions from the drawings or specifications or the misdescription of details of work which are manifestly necessary to carry out the intent of the drawings and specifications, or which are customarily performed, shall not relieve the contractor from performing such omitted or misdescribed details of the work, but shall be performed as if fully and correctly set forth and described in the drawings and specifications.

d. The work shall conform to the specifications and the contract drawings identified on the following, all of which are available in the office of the District Engineer, U.S. Army Engineer District, Philadelphia, Room 643, Wanamaker Building, 100 Penn Square East, Philadelphia, PA 19107. Drawings are titled: "Recovery, Coat and Repair Bulkhead, Point Pleasant Canal, New Jersey Intracoastal Waterway, New Jersey" and have the drawing numbers, subtitles, and dates as indicated on Drawing No. 61826. (DFARS 252.236-7001)

Section00800 Page 2